N6660424R0143.pdf

1301126988

CLIN0001 PROJECT TITLE AND DESCRIPTION: B1319 CORRIDOR RENOVATIONS

Magnitude per FAR 36.204: Betw een $250,000 and $500,000

Bid Bond is required. The amount of the bid guarantee shall be 20 percent of the bid price. Performance and Payment Bonds are also required.

This requirement is 100% Small Business Set-Aside: NAICS 236220; $45 Million

Site Visit: 26 April 2024, 10:00 AM EST Meet at Building 80, NUWC Division New port. Please allow for sufficient time to process site visit request. See Section A for complete details.

Proposal Due date and time: 16 May 2024 before 2:00 pm EST.

Note: Offeror MUST be registered in the System for Aw ard Management to be considered for aw ard.

IMPORTANT: PLEASE NOTE THAT TECHNICAL INFORMATION IS REQUIRED WITH SUBMISSION OF OFFER. PLEASE SEE SECTIONS L AND M FOR SPECIFIC REQUIRMENTS. OFFERORS NOT SUBMITTING THIS INFORMATION RISK BEING EXCLUDED FROM CONSIDERATION FOR

AWARD.

JAY PARKER 401-864-0293

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

11-Apr-2024

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

X

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______15 calendar days and complete it w ithin ________150 calendar days after receiving aw ard, notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________16 May 2024 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

NAVAL UNDERSEA WARFARE CENTER

JAY PARKER, CODE 0221

CONTRACTS DEPARTMENT

1176 HOWELL STREET

NEWPORT RI 02841

N66604

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

401-832-4820FAX:TEL: 401-832-4891 TEL: FAX:

N6660424R0143 40

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

N6660424R0143

Section A - Solicitation/Contract Form

GENERAL INFORMATION

Distribution: TBD NUWCDIVNPT Requisition Number: 1301126988 NUWCDIVNPT PID Number: N66604-24-RFPREQ-NPT-10-0142 NUWCDIVNPT POC: Jay Parker, jay.a.parker2.civ@us.navy.mil

Pre-Solicitation RFI 0001:

1. Q: We’ve been told that the Vinyl Composition Tile; Cool Gray, does not exist. For the Luxury

Vinyl Tile, Patchcraft light oak is okay we just need a specified style.

A: The product specified is TSB TA4 4 X 4 1/8 TOE Baseworks 4" TA4 Gateway Part Number S102234- TA4-WB0004-TSB4 or equivalent.

2. Q: Also does the existing site have a means of getting a 2800lbs ride on floor scrapper to the different levels of work?

A: The freight elevator has a capacity of 10,000 lbs, but we will request the specifications of the ride-on floor scraper in order to do a floor load calculation for the corridors.

SITE VISIT INSTRUCTIONS

Check-in will begin at 10:00 AM (EST) on April 26, 2024 in the lobby of NUWCDIVNPT Building 80, Newport, RI.

The following rules apply for the site visit:

• This will be an Unclassified site visit.

• The site visit will be scripted, no questions will be allowed during the tour.

• Follow-up questions can be submitted via email to Jay.A.Parker2.civ@us.navy.mil and Michael.N.Ouellette.civ@us.navy.mil

• The use of any type of camera during the site visit is strictly prohibited.

• All interested attendees must pre-register by email to Jay.A.Parker2.civ@us.navy.mil and Michael.N.Ouellette.civ@us.navy.mil

• In Addition to pre-registration, all participants MUST have an approved Visit Request.

• Instructions for submitting a visit request can be found at the following link:

http://www.navsea.navy.mil/Home/Warfare-Centers/NUWC-Newport/Contact-Us/Mandatory-Visit- Request/

• Access to NUWC Division Newport WILL NOT be granted under any circumstances without a valid visit authorization request on file. Please list Michael Ouellette, Code 0223, as the Government POC when submitting the visit request.

• Visitor Control - NUWC Newport Building 80 Lobby outside of NUWC Gate 23 Is open Monday- Friday from 7 a.m. to 3:30 p.m. (except holidays)

• Site Visit attendance is not mandatory but highly encouraged.

NUWC NEWPORT DIVISION VISITOR REQUEST

INFORMATION

A visit request is MANDATORY for all visitors to NUWC Division Newport; government and civilian, regardless of the duration or classification of the visit. Access to NUWC Division Newport will not be granted under any circumstances without a valid visit authorization request (VAR) on file.

If you can submit your VAR via JPAS, you do not need to send a VAR on company letterhead.

Due to the number of visit requests received, please allow 7 business days for processing time, whether received by JPAS or on Company Letterhead via FAX or EMAIL.

Visitors who arrive prior to the 7 working day processing window may not be guaranteed access.

Please note, all individuals not in possession of a common access card (CAC) or Teslin Card (Retired Military/Dependent ID), will require a DBIDS card for access.

No unescorted access will be granted without a valid DBIDs card or ID mentioned above.

NUWCDIVNPT VISITOR REQUEST INFORMATION

NEEDED:

**Information must be on Company Letterhead**

1) Company/Organization Name, Address, Telephone, and FAX Number

2) Cage Code

3) Visitor(s) Full Name (As it appears on government issued ID – i.e. Driver’s License)

4) Visitor(s) Full Social Security Number

5) Visitor(s) Date of Birth

6) Visitor(s) Place of Birth (City & State)

a. If born outside the U.S, you MUST provide a Naturalization Number or US Passport

7) Visitor(s) Citizenship

8) Level of Clearance: UNCLASSIFIED or as appropriate

a. SCI Level Access MUST be coordinated SSO to SSO

9) Do they possess a CAC, Teslin or DBIDs Card? (Yes or No)

a. Please specify which visitor(s) have CAC, Retired Military/Dependent ID, DBIDS, or NOT

APPLICABLE

10) NUWCDIVNPT Point of Contact (Sponsor)

a. MUST be a NUWC Government Employee

11) Specific Date(s) of Visit, to include Year

12) Purpose of Visit

13) Contract Number, if applicable

a. If NO Contract Number is provided, then the visit will be for 30 days at the UNCLASSIFIED

Level

14) Authorized Signature:

a. Name, Title, Signature, and Date of Requesting Company/Organization Authorizing Official

(MUST be a US Citizen)

b. Smaller companies that do not have a Security Officer to sign may use another Official or Secretary.

c. Individuals MUST NOT Sign their own request

Submit Visitor Request(s) and/or SECNAV form(s) 5512/1 (Version NSNPT JUL 2023) via:

JPAS SMO CODE: 666045 (If no access to JPAS, use methods below)

EMAIL FORM TO: usn.newport.nuwcdivnewportri.mbx.visitor-control@us.navy.mil

FAX FORM TO: (401) 832-4396

**ALL INCOMPLETE VISIT REQUESTS WILL BE DENIED**

Please call NUWC visitor control at (401) 832-2152 if you want to verify any visits or status on vetting.

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job

B1319 CORRIDOR RENOVATIONS

FFP

The contractor shall provide all materials, equipment, labor and supervision to complete the B1319 Corridor renovation project in accordance with Attachment #1 Drawings 23-047A (4 pages) and Attachment #2 Specification (165 pages).

FOB: Destination

PURCHASE REQUEST NUMBER: 1301126988

PSC CD: Z1AZ

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0002 1 Lot

Submittals

FFP

Submittals in accordance with Attachment #1 Drawings 23-047A (4 pages) and Attachment #2 Specification (165 pages).

THIS CLIN IS NOT SEPARATELY PRICED. PLEASE PROVIDE TOTAL

COST WITHIN CLIN 0001.

FOB: Destination

PSC CD: Z1AZ

NET AMT

Section C - Descriptions and Specifications

CLAUSES INCORPORATED BY FULL TEXT

C-211-H018 APPROVAL BY THE GOVERNMENT (NAVSEA) (JAN 2019)

Approval by the Government as required under this contract and applicable specifications shall not relieve the Contractor of its obligation to comply with the specifications and with all other requirements of the contract, nor shall it impose upon the Government any liability it would not have had in the absence of such approval.

(End of text)

C-223-W002 ON-SITE SAFETY REQUIREMENTS (NAVSEA) (OCT 2018)

(a) The contractor shall ensure that each contractor employee reads any necessary safety documents within 30 days of commencing performance at any Government facility. Required safety documents can be obtained from the respective safety office. Contractors shall notify the Safety office points of contact below to report completion of the required training via email. The email shall include the contractor employee’s name, work site, and contract number.

(b) It is expected that contractor employees will have received training from their employer on hazards associated with the areas in which they will be working and know what to do in order to protect themselves. Contractors are required to adhere to the requirements of 29 CFR 1910, 29 CFR 1926 and applicable state and local requirements while in Government spaces. The contractor shall ensure that all on-site contractor work at the Government facility is in accordance with any local safety instructions as provided via the COR. The contractor shall report all work-related injuries/illnesses that occurred while working at the Government site to the COR.

(c) Contractors whose employees perform work within Government spaces in excess of 1000 hours per calendar quarter during a calendar year shall submit the data elements on OSHA Form 300A, Summary of Work Related Injuries and Illnesses, for those employees to the safety office, via the COR by 15 January for the previous calendar year, even if no work related injuries or illnesses occurred. If a contractor’s injury/illness rates are above the Bureau of Labor Statistics industry standards, a safety assessment may be performed by the Safety Office to determine if any administrative or engineering controls can be utilized to prevent further injuries/illnesses, or if any additional Personal Protective Equipment or training will be required.

(d) Any contractor employee exhibiting unsafe behavior may be removed from the Government site. Such removal shall not relieve the contractor from meeting its contractual obligations and shall not be considered an excusable delay as defined in FAR 52.249-14.

(e) The Safety Office points of contacts are as follows:

To be provided at award (End of text)

C-228-H002 MINIMUM INSURANCE REQUIREMENTS (NAVSEA) (JAN 2019)

(a) In accordance with the clause(s) of this contract entitled "Insurance--Work On a Government Installation" (FAR 52.228-5) and “Liability and Insurance” (DFARS 252.217-7012), as applicable, the Contractor shall procure and maintain insurance, of at least the kinds and minimum amounts set forth below:

(i) Workers' compensation and employer’s liability coverage shall be at least $100,000, except as provided in FAR 28.307-2(a), if applicable

(ii) Bodily injury liability insurance coverage shall be written on the comprehensive form of policy of at least $500,000 per occurrence.

(iii) Automobile liability policies covering automobiles operated in the United States shall provide coverage of at least $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage. The amount of liability coverage on other policies shall be commensurate with any legal requirements of the locality and sufficient to meet normal and customary claims.

(b) To be approved by the Contracting Officer, insurance certificates must include the following cancellation policy statement: Prior to cancellation or material change in coverage, the contractor shall give 30 days written notice to the Contracting Officer.

(c) Physical work cannot begin until the insurance certificate has been approved by the Contracting Officer. Failure to provide an acceptable insurance certificate will not remove the contractor’s responsibility to meet the delivery requirements outlined in Section F and FAR 52.211-11, Liquidated Damages – Supplies, Services, or Research and Development, if applicable.

(End of text)

C-237-H002 SUBSTITUTION OF KEY PERSONNEL (NAVSEA) (OCT 2018)

(a) The Contractor agrees that a partial basis for award of this contract is the list of key personnel proposed. Accordingly, the Contractor agrees to assign to this contract those key persons whose resumes were submitted with the proposal necessary to fulfill the requirements of the contract. No substitution shall be made without prior notification to and concurrence of the Contracting Officer in accordance with this requirement.

Substitution shall include, but not be limited to, subdividing hours of any key personnel and assigning or allocating those hours to another individual not approved as key personnel.

(b) All proposed substitutes shall have qualifications equal to or higher than the qualifications of the person to be replaced. The Contracting Officer shall be notified in writing of any proposed substitution at least forty-five (45) days, or ninety (90) days if a security clearance is to be obtained, in advance of the proposed substitution. Such notification shall include: (1) an explanation of the circumstances necessitating the substitution; (2) a complete resume of the proposed substitute; (3) an explanation as to why the proposed substitute is considered to have equal or better qualifications than the person being replaced; (4) payroll record of the proposed replacement; and (5) any other information requested by the Contracting Officer to enable him/her to judge whether or not the Contractor is maintaining the same high quality of personnel that provided the partial basis for award.

(c) Key personnel are identified in an attachment in Section J.

(End of text)

RECORD DRAWINGS

5252.236-9310 RECORD DRAWINGS (OCT 2004)

The Contractor shall maintain at the job site two sets of full-size prints of the contract drawings, accurately marked red with adequate dimensions, to show all variations between the construction actually provided and that indicated or specified in the contract documents, including buried or concealed construction.

Special attention shall be given to recording the horizontal and vertical location of all buried utilities that differ from the final government accepted drawings. Existing utility lines and features revealed during the course of construction, shall also be accurately located and dimensioned. Variations in the interior utility systems shall be clearly defined and dimensioned; and coordinated with exterior utility connections at the building five-foot line, where applicable. Existing topographic features which differ from those shown on the contract drawings shall also be accurately located and recorded. Where a choice of materials or methods is permitted herein, or where variations in scope or character of methods is permitted herein, or where variations in scope or character of work from that of the original contract are authorized, the drawings shall be marked to define the construction actually provided. The representations of such changes shall conform to standard drafting practice and shall include such supplementary notes, legends, and details as necessary to clearly portray the as-built construction. These drawings shall be available for review by the Contracting Officer at all times. Upon completion of the work, both sets of the marked up prints shall be certified as correct, signed by the Contractor, and delivered to the Contracting Officer for his approval before acceptance. Requests for partial payments will not be approved if the marked prints are not kept current, and request for final payment will not be approved until the marked prints are delivered to the Contracting Officer.

Section D - Packaging and Marking

CLAUSES INCORPORATED BY FULL TEXT

D-247-W001 PROHIBITED PACKING MATERIALS (NAVSEA) (OCT 2018)

The use of asbestos, excelsior, newspaper or shredded paper (all types including waxed paper, computer paper and similar hygroscopic or non-neutral material) is prohibited. In addition, the use of yellow wrapping or packaging material is prohibited except where used for the containment of radioactive material. Loose fill polystyrene is prohibited for shipboard use.

(End of text)

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.246-12 Inspection of Construction AUG 1996

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 150 dys. ADC 1 N/A FOB: Destination

0002 150 dys. ADC 1 N/A FOB: Destination

CLAUSES INCORPORATED BY REFERENCE

52.242-15 Stop-Work Order AUG 1989

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 150 days after contract award. The time stated for completion shall include final cleanup of the premises.

(End of clause)

Section G - Contract Administration Data

CLAUSES INCORPORATED BY FULL TEXT

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)

(a) Definitions. As used in this clause—

“Department of Defense Activity Address Code (DoDAAC)” is a six position code that uniquely identifies a unit, activity, or organization.

“Document type” means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

“Local processing office (LPO)” is the office responsible for payment certification when payment certification is done external to the entitlement system.

“Payment request” and “receiving report” are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232- 7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall—

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items—

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

CLIN 0001 – INVOICE AND RECEIVING REPORT (COMBO)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

CLIN 0001 – INVOICE AND RECEIVING REPORT (COMBO)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial financing, submit a commercial financing request.

(2) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF “combo” document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC To be provided at award

Issue By DoDAAC ____

Admin DoDAAC** ____

Inspect By DoDAAC ____

Ship To Code ____

Ship From Code ____

Mark For Code ____

Service Approver (DoDAAC) ____

Service Acceptor (DoDAAC) ____

Accept at Other DoDAAC ____

LPO DoDAAC ____

DCAA Auditor DoDAAC ____

Other DoDAAC(s) ____

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity’s WAWF point of contact.

To be provided at award

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

NOTE: WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

WAWF Email Notifications POC: To be provided at award

G-232-H002 PAYMENT INSTRUCTIONS (NAVSEA) (FEB 2024)

Payment office allocation methods can be found in the table at DFARS PGI 204.7108(b)(2) (https://www.acq.osd.mil/dpap/dars/pgi/pgi_htm/current/PGI204_71.htm#payment_instructions).

(End of Text)

G-232-H005 SUPPLEMENTAL INSTRUCTIONS REGARDING INVOICING (NAVSEA) (JAN 2019)

(a) For other than firm fixed priced contract line item numbers (CLINs), the Contractor agrees to segregate costs incurred under this contract/task order (TO), as applicable, at the lowest level of performance, either at the sub line item number (SLIN) or CLIN level, rather than at the total contract/TO level, and to submit invoices reflecting costs incurred at that level. Supporting documentation in Wide Area Workflow (WAWF) for invoices shall include summaries of work charged during the period covered as well as overall cumulative summaries by individual labor categories, rates, and hours (both straight time and overtime) invoiced; as well as, a cost breakdown of other direct costs (ODCs), materials, and travel, by technical instruction (TI), SLIN, or CLIN level. For other than firm fixed price subcontracts, subcontractors are also required to provide labor categories, rates, and hours (both straight time and overtime) invoiced; as well as, a cost breakdown of ODCs, materials, and travel invoiced. Supporting documentation may be encrypted before submission to the prime contractor for WAWF invoice submittal.

Subcontractors may email encryption code information directly to the Contracting Officer and Contracting Officer Representative (COR). Should the subcontractor lack encryption capability, the subcontractor may also email detailed supporting cost information directly to the Contracting Officer and COR; or other method as agreed to by the Contracting Officer.

(b) Contractors submitting payment requests and receiving reports to WAWF using either Electronic Data Interchange (EDI) or Secure File Transfer Protocol (SFTP) shall separately send an email notification to the COR and Contracting Officer on the same date they submit the invoice in WAWF. No payments shall be due if the contractor does not provide the COR and Contracting Officer email notification as required herein.

G-242-H001 Government Contract Administration Points-of-Contact and Responsibilities (NAVSEA) (OCT 2023)

(a) The Government reserves the right to administratively substitute any of the points of contact listed below at any time.

(b) The contracting officer is the only person authorized to change this contract or orders issued thereunder. The Contractor shall not comply with any order, direction or request of Government personnel - that would constitute a change - unless it is issued in writing and signed by the Contracting Officer or is pursuant to specific authority otherwise included as part of this contract. If, in the opinion of the contractor, an effort outside the existing scope of this contract is requested, the contractor shall promptly comply with the Notification of Changes clause of this contract.

(c) The points of contact are as follows:

(i) The Procuring Contracting Officer (PCO) is:

Name: Michael Ouellette Address: NUWC Division Newport, Code 0223 1176 Howell Street, Newport RI 02841-1708 Phone: (401) 832-5568 E-mail: michael.n.ouellette.civ@us.navy.mil.

(ii) The Contract Specialist is:

Name: Jay Parker Address: NUWC Division Newport, Code 0223 1176 Howell Street, Newport RI 02841-1708 Phone: (401) 832-2687 E-mail: jay.a.parker2.civ@us.navy.mil

(d) The Contracting Officer’s Representative (COR) is the contracting officer’s appointed representative for technical matters. The COR is not a contracting officer and does not have the authority to direct the accomplishment of effort which is beyond the scope of the contract or to otherwise change any contract requirements. An informational copy of the COR appointment letter, which provides a delineation of COR authority and responsibilities, will be provided upon award of this contract.

The Contracting Officer’s Representative (COR) is: To be added at time of award Name: [ * ] Address:

[ *Street ] [ *City, State, Zip ] Phone: (Area Code) xxx- [xxxx] E-mail: [ * ]

(e) The Alternate Contracting Officer’s Representative (ACOR) is responsible for COR responsibilities and functions in the event that the COR is unavailable due to leave, illness, or other official business. The ACOR is appointed by the contracting officer; a copy of the ACOR appointment will be provided upon award of this contract.

The Alternate Contracting Officer’s Representative (ACOR) is: To be added at time of award Name: [ * ] Address:

[ *City, State, Zip ]

Phone: (Area Code) xxx- [xxxx] E-mail: [ * ]

(f) The Technical Point of Contact (TPOC) is the contracting officer’s representative for technical matters when a COR is not appointed. The TPOC is responsible for technical issues of contract administration, such as providing all items of Government Furnished Information (GFI), Government Furnished Material (GFM) and Government Furnished Equipment (GFE) if specified in the contract as well as the inspection and acceptance of all contract deliverables.

The Technical Point of Contact (TPOC) is:

See COR

(g) The Alternate Technical Point of Contact (ATPOC) is responsible for TPOC responsibilities and functions in the event that the TPOC is unavailable due to leave, illness, or other official business.

The Alternate Technical Point of Contact (ATPOC) is:

See COR

(h) The Authorized Ordering Person(s) for Per-Call Maintenance is responsible for issuing and maintaining records for any per-call orders for remedial maintenance placed under this contract. No per-call order shall be placed outside the scope of this contract and the cumulative total of all orders shall not be in excess of any not-to-exceed amount specified in the contract. Per-call orders shall not, in any way, modify any terms and conditions of the contract.

(i) The Authorized Ordering Person(s) for Per-Call Maintenance is:

N/A

(j) The Contractor's point of contact for performance under this contract is: Please provide POC with proposal

Name: [ * ] Title: [ * ] Address:

[ *Street ] [ *City, State, Zip ] Phone: (Area Code) xxx- [xxxx] E-mail: [ * ]

[ * ] To be completed at contract award (End of Text)

G-242-H002 HOURS OF OPERATION AND HOLIDAY SCHEDULE (NAVSEA) (JUL 2021)

(a) The policy of this activity is to schedule periods of reduced operations or shutdown during holiday periods.

Deliveries will not be accepted on Saturdays, Sundays or Holidays except as specifically requested by the [insert activity name]. All goods or services attempted to be delivered on a Saturday, Sunday or Holiday without specific instructions from the Contracting Officer or his duly appointed representative will be returned to the contractor at the contractor’s expense with no cost or liability to the U.S. Government.

(b) The federal Government observes public Holidays that have been established under 5 U.S.C. 6103. The actual date of observance for each of the holidays, for a specific calendar year, may be obtained from the OPM website at OPM.GOV or by using the following direct link:

https://www.opm.gov/policy-data-oversight/pay-leave/federal-holidays/.

(c) Delayed Opening, Early Dismissal and Closure of Government Facilities. When a Government facility has a delayed opening, is closed or Federal employees are dismissed early (due to severe weather, security threat, security exercise, or a facility related problem) that prevents personnel from working, onsite contractor personnel regularly assigned to work at that facility shall follow the same reporting and/or departure directions given to Government personnel. The contractor shall not direct charge to the contract for such time off, but shall follow parent company policies regarding taking leave (administrative or other). Non-essential contractor personnel, who are not required to remain at or report to the facility, shall follow their parent company policy regarding whether they should go/stay home or report to another company facility. Subsequent to an early dismissal, delayed opening, or during periods of inclement weather, onsite contractors should monitor the OPM website as well as radio and television announcements before departing for work to determine if the facility is closed or operating on a delayed arrival basis.

(d) When Federal employees are excused from work due to a holiday or a special event (that is unrelated to severe weather, a security threat, or a facility related problem), on site contractors shall continue working established work hours or take leave in accordance with parent company policy. Those contractor employees who take leave shall not direct charge the non-working hours to the contract. Contractors are responsible for predetermining and disclosing their charging practices for early dismissal, delayed openings, or closings in accordance with the FAR, applicable cost accounting standards, and the company’s established policy and procedures. Contractors shall follow their disclosed charging practices during the contract period of performance, and shall not follow any verbal directions to the contrary. The Contracting Officer will make the determination of cost allowability for time lost due to facility closure in accordance with FAR, applicable Cost Accounting Standards, and the Contractor's established accounting policy and procedures.

(e) If you intend to visit the Contracts Office, it is advised that you call for an appointment at least 24 hours in advance.

(f) The hours of operation are as follows:

AREA FROM TO

NUWCDIVNPT 0730 1700

(g) All deliveries to the Receiving Officer, shall be made Monday through Friday from 0730-1700 local time.

Deliveries will not be accepted after 1700 . No deliveries will be accepted on federal government holidays.

Section H - Special Contract Requirements

PERFORMANCE ON GOVERNMENT SITE

CONTRACTOR REQUIREMENTS FOR PERFORMANCE ON A GOVERNMENT SITE (APR 2018)

(a) Control of Contractor Personnel

The contractor shall comply with the requirements of NUWCDIVNPTINST 5500.4C regarding performance at Government facilities. All persons engaged in work while on Government property shall be subject to search of their persons and vehicles at any time by the Government, and shall report any known or suspected security violations to the Security Department of the contracting activity. Assignment, transfer, and reassignment of contractor personnel shall be at the discretion of the contractor. However, the contractor shall remove from contract performance any person who endangers life, property, or national security through improper conduct.

Such removal shall not relieve the contractor from meeting its contractual obligations and shall not be considered an excusable delay as defined in FAR 52.249-14.

(b) Contract Personnel Administration

The contractor is responsible for managing its employees and guarding against any actions that are of the nature of personal services or give the perception that personal services are being provided. If the contractor feels that any actions constitute, or are perceived to constitute personal services, it is the contractor's responsibility to notify the PCO immediately in accordance with the clause FAR 52.243-7. When on-site in Government office spaces, laboratories, test facilities, or ship assets, Contractor employees shall be clearly identified as a Contractor (e.g.

utilizing Common Access Cards (CACs) and sign identifications in office spaces). In addition, Contractor employees shall identify themselves as Contractor personnel when answering telephones and sending emails.

Contractor personnel cannot lead/manage/supervise Government personnel. Contractor program /project managers/Senior Technical Representative (STR) shall be clearly identified and known as such by Government employees. As circumstances permit, periodic meetings shall be conducted between the COR and the Contractor organization program manager/project manager.

(c) Early Dismissal and Closure of Government Facilities

When a Government facility is closed or Federal employees are dismissed early (due to severe weather, security threat, security exercise, or a facility related problem) that prevents personnel from working, onsite contractor personnel regularly assigned to work at that facility shall follow the same reporting and/or departure directions given to Government personnel. The contractor shall not direct charge to the contract for such time off, but shall follow parent company policies regarding taking leave (administrative or other). Non-essential contractor personnel, who are not required to remain at or report to the facility, shall follow their parent company policy regarding whether they should go/stay home or report to another company facility. Subsequent to an early dismissal and during periods of inclement weather, onsite contractors should monitor radio and television announcements before departing for work to determine if the facility is closed or operating on a delayed arrival basis.

When Federal employees are excused from work due to a holiday or a special event (that is unrelated to severe weather, a security threat, or a facility related problem), on site contractors shall continue working established work hours or take leave in accordance with parent company policy. Those contractor employees who take leave shall not direct charge the non- working hours to the contract. Contractors are responsible for predetermining and disclosing their accounting standards, and company policy. Contractors shall follow their disclosed charging practices during the contract period of performance, and shall not follow any verbal directions to the contrary.

The Contracting Officer will make the determination of cost allowability for time lost due to facility closure in accordance with FAR, applicable Cost Accounting Standards, and the Contractor's established accounting policy.

(d) Training Requirements

(A) The contractor shall ensure that each contractor employee performing work at any NUWC Division Newport site take the following actions:

• Complete all required trainings as indicated on the following website:

https://newportalv3.nwpt.nuwc.navy.mil/10/101/Training/SitePages/TrainingWelcome.as px

• Read the documents titled “Occupational Safety and Health Information for Contractors” and “NUWC Division Newport Environmental Policy”, available at the following website, prior to performing any work:

http://www.navsea.navy.mil/Home/WarfareCenters/NUWCNewport/ContactUs/VisitorInformation.aspx

• Complete Environmental Awareness training, available at the following website, within 30 days of commencing performance:

http://www.navsea.navy.mil/Home/WarfareCenters/NUWCNewport/ContactUs/VisitorInformation.aspx

(2) The contractor shall email the following web address indicating completion of items (B) and (C) above upon completion of both: NWPT.NUWC_NPT_1023_Training@navy.mil

(e) Safety Requirements

(1) Prior to commencing any work that falls under the following areas, the contractor shall provide a complete listing of all qualified and trained employees who will perform the work on company letterhead to the Contracting Officer’s Representative, or, if no COR is assigned, to the NUWC Division Newport Safety Office:

(A) Permit required Confined Space Program

(B) Control of Hazardous Energy (Lock out / Tag out)

(C) Respiratory Protection

(D) Walking-Working Surfaces, Fall Protection Program and Scaffolding

(2) The contractor shall follow the posted provisions of the building’s Emergency Action Plan (EAP) for any mishap, incident, or emergency situation.

(3) The contractor shall report unsafe work conditions, safety hazards, and any mishaps (injury/property damage) to their supervisor, the COR, and the NUWC Division Newport Safety Office.

End of text

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions JUN 2020 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government JUN 2020 52.203-7 Anti-Kickback Procedures JUN 2020 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

JUN 2020

52.203-17 Contractor Employee Whistleblower Rights NOV 2023 52.203-19 Prohibition on Requiring Certain Internal Confidentiality

Agreements or Statements

JAN 2017

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-8 Annual Representations and Certifications MAR 2023 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-21 Basic Safeguarding of Covered Contractor Information Systems

NOV 2021

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities

DEC 2023

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment

NOV 2021

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

NOV 2021

52.209-7 Information Regarding Responsibility Matters OCT 2018 52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.211-15 Defense Priority And Allocation Requirements APR 2008 52.219-6 Notice Of Total Small Business Set-Aside NOV 2020 52.219-14 Limitations On Subcontracting OCT 2022 52.219-28 Post-Award Small Business Program Rerepresentation SEP 2023 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records JUL 2021 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014

52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-25 Affirmative Action Compliance APR 1984 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-35 Equal Opportunity for Veterans JUN 2020 52.222-36 Equal Opportunity for Workers with Disabilities JUN 2020 52.222-37 Employment Reports on Veterans JUN 2020 52.222-38 Compliance With Veterans' Employment Reporting

Requirements

FEB 2016

52.222-40 Notification of Employee Rights Under the National Labor Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons NOV 2021 52.222-54 Employment Eligibility Verification MAY 2022 52.222-55 Minimum Wages for Contractor Workers Under Executive

Order 14026

JAN 2022

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-11 Ozone-Depleting Substances and High Global Warming

Potential Hydrofluorocarbons.

JUN 2016

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

JUN 2020

52.223-19 Compliance with Environmental Management Systems MAY 2011 52.225-9 Buy American--Construction Materials OCT 2022 52.225-13 Restrictions on Certain Foreign Purchases FEB 2021 52.227-1 Authorization and Consent JUN 2020 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

JUN 2020

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-7 Insurance--Liability To Third Persons MAR 1996 52.228-11 Individual Surety--Pledge of Assets FEB 2021 52.228-12 Prospective Subcontractor Requests for Bonds DEC 2022 52.228-15 Performance and Payment Bonds--Construction JUN 2020 52.228-17 Individual Surety--Pledge of Assets (Bid Guarantee) FEB 2021 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-23 Alt I Assignment of Claims (May 2014) - Alternate I APR 1984 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.232-38 Submission of Electronic Funds Transfer Information with Offer

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

MAR 2023

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997) -

Alternate I

APR 1984

52.236-26 Preconstruction Conference FEB 1995 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-5 Changes and Changed Conditions APR 1984 52.244-2 Subcontracts JUN 2020 52.246-21 Warranty of Construction MAR 1994 52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

JAN 2023

252.203-7002 Requirement to Inform Employees of Whistleblower Rights DEC 2022 252.204-7000 Disclosure Of Information OCT 2016 252.204-7002 Payment For Contract Line or Subline Items Not Separately

Priced

APR 2020

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Antiterrorism Awareness Training for Contractors JAN 2023 252.204-7009 Limitations on the Use or Disclosure of Third-Party

Contractor Reported Cyber Incident Information

JAN 2023

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

JAN 2023

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

JAN 2023

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services

JAN 2023

252.204-7020 NIST SP 800-171 DoD Assessment Requirements NOV 2023 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

MAY 2019

252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements JAN 2023 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.225-7002 Qualifying Country Sources As Subcontractors MAR 2022 252.225-7048 Export-Controlled Items JUN 2013

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports

DEC 2018

252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7006 Cost Limitation JAN 1997 252.243-7002 Requests for Equitable Adjustment DEC 2022 252.244-7000 Subcontracts for Commercial Products or Commercial

Services

NOV 2023

252.247-7023 Transportation of Supplies by Sea JAN 2023 252.249-7002 Notification of Anticipated Contract Termination or

Reduction

DEC 2022

CLAUSES…