N6660423Q0275.pdf

1301062801

PROJECT TITLE AND DESCRIPTION: BLDG 1320 5th Floor Carpet Replacement

Proposal Due: April 14, 2023 at 2:00PM EST, Email to jay.a.parker2.civ@us.navy.mil and Michael.N.Ouellette.civ@us.navy.mil

NOTE: Offeror MUST be registered in the System for Aw ard Management (SAM) to be considered for aw ard.

Magnitude per FAR 36.204: Betw een $25,000 and $100,000.

Method of Payment: If no surcharge is applicable, the Government's preferred method of payment is via credit card. Otherw ise, Electronic Payment through Wide Area Workflow (WAWF) w ill be used. Please confirm is Government Purchase Card is an acceptable form of payment w ithin the proposal.

This requirement is 100% small business set aside, NAICS 238330; $19 million

SITE VISIT DATE and TIME: April 04, 2023 at 1:00PM EST, Meet at Building 80 NUWC Division New port. Please allow f or suff icient time to process site visit request. See Section A for complete details.

IMPORTANT: PLEASE NOTE THAT TECHNICAL INFORMATION IS REQUIRED WITH SUBMISSION OF OFFER. PLEASE SEE SECTIONS L AND M FOR SPECIFIC REQUIRMENTS. OFFERORS NOT SUBMITTING THIS INFORMATION RISK BEING EXCLUDED FROM CONSIDERATION FOR AWARD.

JAY PARKER 401-864-0293

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

24-Mar-2023

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

X

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________90 calendar days after receiving aw ard, notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________14 Apr 2023 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

NAVAL UNDERSEA WARFARE CENTER

JAY PARKER, CODE 0221

CONTRACTS DEPARTMENT

1176 HOWELL STREET

NEWPORT RI 02841

N66604

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

401-832-4820FAX:TEL: 401-832-4891 TEL: FAX:

N6660423Q0275 38

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

N6660423Q0275

Section A - Solicitation/Contract Form

GENERAL INFORMATION

Section A - Solicitation/Contract Form

GENERAL INFORMATION

Distribution: TBD NUWCDIVNPT Requisition: 1301062801

NUWCDIVNPT PID: N66604-23-SIMACQ-NPT-10-0313

NUWCDIVNPT Point of Contact: Jay Parker, jay.a.parker2.civ@us.navy.mil, (401) 832 2687

SITE VISIT INSTRUCTIONS

Check-in will begin at 1:00 PM (EST) on April 04, 2023 in the lobby of NUWCDIVNPT Building 80, Newport, RI.

The following rules apply for the site visit:

• This will be an Unclassified site visit.

• The site visit will be scripted, no questions will be allowed during the tour.

• Follow-up questions can be submitted via email to Jay.A.Parker2.civ@us.navy.mil and Michael.N.Ouellette.civ@us.navy.mil

• The use of any type of camera during the site visit is strictly prohibited.

• All interested attendees must pre-register by email to Jay.A.Parker2.civ@us.navy.mil and Michael.N.Ouellette.civ@us.navy.mil

• In Addition to pre-registration, all participants MUST have an approved Visit Request.

• Instructions for submitting a visit request can be found at the following link:

http://www.navsea.navy.mil/Home/Warfare-Centers/NUWC-Newport/Contact-Us/Mandatory-Visit- Request/

• Access to NUWC Division Newport WILL NOT be granted under any circumstances without a valid visit authorization request on file. Please list Michael Ouellette, Code 0223, as the Government POC when submitting the visit request.

• Visitor Control - NUWC Newport Building 80 Lobby outside of NUWC Gate 23 Is open Monday- Friday from 7 a.m. to 3:30 p.m. (except holidays)

NUWC NEWPORT DIVISION VISITOR REQUEST

INFORMATION

A visit request is MANDATORY for all visitors to NUWC Division Newport; government and civilian, regardless of the duration or classification of the visit. Access to NUWC Division Newport will not be granted under any circumstances without a valid visit authorization request (VAR) on file.

If you can submit your VAR via JPAS, you do not need to send a VAR on company letterhead.

Due to the number of visit requests received, please allow 7 business days for processing time, whether received by JPAS or on Company Letterhead via FAX or EMAIL.

Visitors who arrive prior to the 7 working day processing window may not be guaranteed access.

Please note, all individuals not in possession of a common access card (CAC) or Teslin Card (Retired Military/Dependent ID), will require a DBIDS card for access.

No unescorted access will be granted without a valid DBIDs card or ID mentioned above.

NUWCDIVNPT VISITOR REQUEST INFORMATION

NEEDED:

**Information must be on Company Letterhead**

1) Company/Organization Name, Address, Telephone, and FAX Number

2) Cage Code

3) Visitor(s) Full Name (As it appears on government issued ID – i.e. Driver’s License)

4) Visitor(s) Full Social Security Number

5) Visitor(s) Date of Birth

6) Visitor(s) Place of Birth (City & State)

a. If born outside the U.S, you MUST provide a Naturalization Number or US Passport

7) Visitor(s) Citizenship

8) Level of Clearance: UNCLASSIFIED or as appropriate

a. SCI Level Access MUST be coordinated SSO to SSO

9) Do they possess a CAC, Teslin or DBIDs Card? (Yes or No)

a. Please specify which visitor(s) have CAC, Retired Military/Dependent ID, DBIDS, or NOT

APPLICABLE

10) NUWCDIVNPT Point of Contact (Sponsor)

a. MUST be a NUWC Government Employee

11) Specific Date(s) of Visit, to include Year

12) Purpose of Visit

13) Contract Number, if applicable

a. If NO Contract Number is provided, then the visit will be for 30 days at the UNCLASSIFIED

Level

14) Authorized Signature:

a. Name, Title, Signature, and Date of Requesting Company/Organization Authorizing Official (MUST be a US Citizen)

b. Smaller companies that do not have a Security Officer to sign may use another Official or Secretary.

c. Individuals MUST NOT Sign their own request

Submit Visitor Request(s) and/or SECNAV form(s) 5512/1 via:

JPAS SMO CODE: 666045 (If no access to JPAS, use methods below)

EMAIL FORM TO: nuwc_npt_access_control@navy.mil

FAX FORM TO: (401) 832-4396

**ALL INCOMPLETE VISIT REQUESTS WILL BE DENIED**

Please call NUWC visitor control at (401) 832-2152 if you want to verify any visits or status on vetting.

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job

B1320 5TH FLOOR CARPET REPLACEMENT

FFP

The contractor shall provide all materials, equipment, labor and supervision to complete Building 1320 5th Floor carpet ireplacement n accordance with Attachment # 1 Specification (173 pages) and Attachment #2, Drawings SK-001 (1 page).

FOB: Destination

PURCHASE REQUEST NUMBER: 1301062801

PSC CD: Z1AZ

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0002 1 Job Submittals

FFP

Submittals in accordance with Attachment # 1 Specification (173 pages) and Attachment #2, Drawings SK-001 (1 page).

THIS CLIN IS NOT SEPARATELY PRICED. PLEASE PROVIDE TOTAL

COST WITHIN CLIN 0001.

FOB: Destination

PSC CD: Z1AZ

NET AMT

Section C - Descriptions and Specifications

CLAUSES INCORPORATED BY FULL TEXT

C-211-H018 APPROVAL BY THE GOVERNMENT (NAVSEA) (JAN 2019)

Approval by the Government as required under this contract and applicable specifications shall not relieve the Contractor of its obligation to comply with the specifications and with all other requirements of the contract, nor shall it impose upon the Government any liability it would not have had in the absence of such approval.

(End of text)

C-223-W002 ON-SITE SAFETY REQUIREMENTS (NAVSEA) (OCT 2018)

(a) The contractor shall ensure that each contractor employee reads any necessary safety documents within 30 days of commencing performance at any Government facility. Required safety documents can be obtained from the respective safety office. Contractors shall notify the Safety office points of contact below to report completion of the required training via email. The email shall include the contractor employee’s name, work site, and contract number.

(b) It is expected that contractor employees will have received training from their employer on hazards associated with the areas in which they will be working and know what to do in order to protect themselves. Contractors are required to adhere to the requirements of 29 CFR 1910, 29 CFR 1926 and applicable state and local requirements while in Government spaces. The contractor shall ensure that all on-site contractor work at the Government facility is in accordance with any local safety instructions as provided via the COR. The contractor shall report all work-related injuries/illnesses that occurred while working at the Government site to the COR.

(c) Contractors whose employees perform work within Government spaces in excess of 1000 hours per calendar quarter during a calendar year shall submit the data elements on OSHA Form 300A, Summary of Work Related Injuries and Illnesses, for those employees to the safety office, via the COR by 15 January for the previous calendar year, even if no work related injuries or illnesses occurred. If a contractor’s injury/illness rates are above the Bureau of Labor Statistics industry standards, a safety assessment may be performed by the Safety Office to determine if any administrative or engineering controls can be utilized to prevent further injuries/illnesses, or if any additional Personal Protective Equipment or training will be required.

(d) Any contractor employee exhibiting unsafe behavior may be removed from the Government site. Such removal shall not relieve the contractor from meeting its contractual obligations and shall not be considered an excusable delay as defined in FAR 52.249-14.

(e) The Naval Undersea Warfare Center Division Newport Safety Office phone number is (401) 832-3534.

C-228-H002 MINIMUM INSURANCE REQUIREMENTS (NAVSEA) (JAN 2019)

(a) In accordance with the clause(s) of this contract entitled "Insurance--Work On a Government Installation" (FAR 52.228-5) and “Liability and Insurance” (DFARS 252.217-7012), as applicable, the Contractor shall procure and maintain insurance, of at least the kinds and minimum amounts set forth below:

(i) Workers' compensation and employer’s liability coverage shall be at least $100,000, except as provided in

FAR 28.307-2(a), if applicable

(ii) Bodily injury liability insurance coverage shall be written on the comprehensive form of policy of at least $500,000 per occurrence.

(iii) Automobile liability policies covering automobiles operated in the United States shall provide coverage of at least $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage. The amount of liability coverage on other policies shall be commensurate with any legal requirements of the locality and sufficient to meet normal and customary claims.

(b) To be approved by the Contracting Officer, insurance certificates must include the following cancellation policy statement: Prior to cancellation or material change in coverage, the contractor shall give 30 days written notice to the Contracting Officer.

(c) Physical work cannot begin until the insurance certificate has been approved by the Contracting Officer. Failure to provide an acceptable insurance certificate will not remove the contractor’s responsibility to meet the delivery requirements outlined in Section F and FAR 52.211-11, Liquidated Damages – Supplies, Services, or Research and Development, if applicable.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 90 dys. ADC 1 NAVAL STATION NWPT, RECEIVING

OFFICER

RECEIVING OFFICER

47 CHANDLER STREET

NEWPORT RI 02841

401-841-3827

N66604

0002 90 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

N66604

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 90 days after award. The time stated for completion shall include final cleanup of the premises.

(End of clause)

Section G - Contract Administration Data

252.204-7006 BILLING INSTRUCTIONS (OCT 2005)

When submitting a request for payment, the Contractor shall--

(a) Identify the contract line item(s) on the payment request that reasonably reflect contract work performance; and

(b) Separately identify a payment amount for each contract line item included in the payment request.

G-232-H002 PAYMENT INSTRUCTIONS AND CONTRACT TYPE SUMMARY FOR PAYMENT

OFFICE (NAVSEA) (JUN 2018)

(a) The following table of payment office allocation methods applies to the extent indicated.

For Government Use Only

Contract/Order Payment Clause

Type of Payment Request

Su pp ly

Se rv ic e

C on st ru ct io n

Payment Office Allocation Method

52.212-4 (Alt I), Contract Terms and Conditions— Commercial Items 52.216-7, Allowable Cost and Payment 52.232-7, Payments under Time-and-Materials and Labor-Hour Contracts

Cost Voucher X X N/A Line item specific proration. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated in the same proportion as the amount of funding currently unliquidated for each ACRN on the deliverable line or deliverable subline item for which payment is requested.

52.232-1, Payments Navy Shipbuilding Invoice (Fixed Price)

X N/A N/A Line Item specific by fiscal year. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated using the oldest funds. In the event of a deliverable line or deliverable subline item with two ACRNs with the same fiscal year, those amounts will be prorated to the available unliquidated funds for that year.

Contract/Order Payment Clause

Type of Payment Request

Su ic e

C on st ru ct io n

Payment Office Allocation Method

52.232-1, Payments;

52.232-2, Payments under Fixed-Price Research and Development Contracts;

52.232-3, Payments under Personal Services Contracts;

52.232-4, Payments under Transportation Contracts and Transportation-Related Services Contracts; and 52.232-6, Payments under Communication Service Contracts with Common Carriers

Invoice X X N/A Line Item Specific proration. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated in the same proportion as the amount of funding currently unliquidated for each ACRN on the deliverable line or deliverable subline item for which payment is requested.

52.232-5, Payments Under Fixed-Price Construction Contracts

Construction Payment Invoice

N/A N/A X Line Item specific by fiscal year. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated using the oldest funds. In the event of a deliverable line or deliverable subline item with two ACRNs with the same fiscal year, those amounts will be prorated to the available unliquidated funds for that year.

52.232-16, Progress Payments

Progress Payment*

X X N/A Contract-wide proration. Funds shall be allocated in the same proportion as the amount of funding currently unliquidated for each ACRN. Progress Payments are considered contract level financing, and the “contract price” shall reflect the fixed price portion of the contract per FAR 32.501-3.

52.232-29, Terms for Financing of Purchases of Commercial Items;

52.232-30, Installment Payments for Commercial Items

Commercial Item Financing*

X X N/A Specified in approved payment. The contracting officer shall specify the amount to be paid and the account(s) to be charged for each payment approval in accordance with FAR 32.207(b)(2) and 32.1007(b)(2).

52.232-32, Performance- Based Payments

Performance- Based Payments*

X X N/A Specified in approved payment. The contracting officer shall specify the amount to be paid and the account(s) to be charged for each payment approval in accordance with FAR 32.207(b)(2) and 32.1007(b)(2).

252.232-7002, Progress Payments for Foreign Military Sales Acquisitions

Progress Payment*

X X N/A Allocate costs among line items and countries in a manner acceptable to the Administrative Contracting Officer.

Contract/Order Payment Clause

Type of Payment Request

Su ic e

C on st ru ct io n

Payment Office Allocation Method

*Liquidation of Financing Payments. Liquidation will be applied by the payment office against those ACRNs which are identified by the payment instructions for the delivery payment and in keeping with the liquidation provision of the applicable contract financing clause (i.e., progress payment, performance-based payment, or commercial item financing).

(b) This procurement contains the following contract type(s):

Item Type*

CLIN 0001 FFP

CLIN 0002 NSP

*CR – Cost-Reimbursement FP – Fixed Price

G-232-H004 GOVERNMENT PURCHASE CARD METHOD OF PAY (NAVSEA) (OCT 2018)

(a) Payment will be made via the Government Purchase Card once evidence of material receipt or service completion and an invoice are received. At the time of shipment, or completion of services, but no later than two business days after shipment, contact the individual identified below to obtain the account number to be charged. The Government Purchase Card must not be charged without first obtaining final authorization from the appropriate Government Purchase Cardholder.

(b) To facilitate delivery, clearly mark all boxes, cartons, containers and packing slips with the order number referenced on the order. Include an itemized and serialized invoice. (NOTE: these numbers can be found on the face of the order or contract.)

(c) To expedite payment, please do not include your invoice with your shipment. Please mail invoice separately to the address below. Any invoice is required for payment to be authorized using the Government Purchase Card. Current DoD and Local policy does not allow the use of third party card processing companies such as Pay Pal, PayPro, etc.

(d) Mail invoices and bankcard authorizations to:

NOTE: If no surcharge is applicable, the Government’s preferred method of payment is via credit card. Otherwise, Electronic Payment through Wide Area Workflow (WAWF) will be used. Please confirm if Government Purchase Card is an acceptable form of payment within the proposal.

G-242-H001 GOVERNMENT CONTRACT ADMINISTRATION POINTS-OF-CONTACT AND

RESPONSIBILITIES (NAVSEA) (OCT 2018)

(a) The Government reserves the right to administratively substitute any of the points of contact listed below at any time.

(b) The contracting officer is the only person authorized to change this contract or orders issued thereunder. The Contractor shall not comply with any order, direction or request of Government personnel - that would constitute a change - unless it is issued in writing and signed by the Contracting Officer or is pursuant to specific authority otherwise included as part of this contract. If, in the opinion of the contractor, an effort outside the existing scope of this contract is requested, the contractor shall promptly comply with the Notification of Changes clause of this contract.

(c) The points of contact are as follows:

(i) The Procuring Contracting Officer (PCO) is:

Name: Michael Ouellette Address: NUWC Division Newport, Code 0223 1176 Howell Street, Newport RI 02841-1708 Phone: (401) 832-5568 E-mail: michael.n.ouellette.civ@us.navy.mil.

(ii) The Contract Specialist is:

Name: Jay Parker Address: NUWC Division Newport, Code 0223 1176 Howell Street, Newport RI 02841-1708 Phone: (401) 832-2687 E-mail: jay.a.parker2.civ@us.navy.mil

(d) The Technical Point of Contact (TPOC) is the contracting officer’s representative for technical matters when a COR is not appointed. The TPOC is responsible for technical issues of contract administration, such as providing all items of Government Furnished Information (GFI), Government Furnished Material (GFM) and Government Furnished Equipment (GFE) if specified in the contract as well as the inspection and acceptance of all contract deliverables.

The Technical Point of Contact (TPOC) is:

[ To be provided by Government upon award.]

(e) The Alternate Technical Point of Contact (ATPOC) is responsible for TPOC responsibilities and functions in the event that the TPOC is unavailable due to leave, illness, or other official business.

The Alternate Technical Point of Contact (ATPOC) is:

[ To be provided by Government upon award.]

(f) The Competition Advocate will review complaints from the contractors and ensure that all contractors are afforded a fair opportunity to be considered, consistent with the procedures in the contract.

The Competition Advocate is:

Name: Stephen Lamb Address: NUWC Division Newport; Newport, RI 02841

E-mail: stephen.a.lamb1.civ@us.navy.mil

(g) The Contractor's point of contact for performance under this contract is *:

Name: [______________________________________________________________]

Title: [_______________________________________________________________]

Address:

Phone: [___________________________________]; Fax: [___________________]

E-mail: [_____________________________________________________________]

[ * ] To be provided by Contractor with quote and completed by Government at contract award

Section H - Special Contract Requirements

PERFORMANCE ON GOVT SITE

CONTRACTOR REQUIREMENTS FOR PERFORMANCE ON A GOVERNMENT SITE (APR 2018)

(a) Control of Contractor Personnel

The contractor shall comply with the requirements of NUWCDIVNPTINST 5500.4C regarding performance at Government facilities. All persons engaged in work while on Government property shall be subject to search of their persons and vehicles at any time by the Government, and shall report any known or suspected security violations to the Security Department of the contracting activity. Assignment, transfer, and reassignment of contractor personnel shall be at the discretion of the contractor. However, the contractor shall remove from contract performance any person who endangers life, property, or national security through improper conduct.

Such removal shall not relieve the contractor from meeting its contractual obligations and shall not be considered an excusable delay as defined in FAR 52.249-14.

(b) Contract Personnel Administration

The contractor is responsible for managing its employees and guarding against any actions that are of the nature of personal services or give the perception that personal services are being provided. If the contractor feels that any actions constitute, or are perceived to constitute personal services, it is the contractor's responsibility to notify the PCO immediately in accordance with the clause FAR 52.243-7. When on-site in Government office spaces, laboratories, test facilities, or ship assets, Contractor employees shall be clearly identified as a Contractor (e.g.

utilizing Common Access Cards (CACs) and sign identifications in office spaces). In addition, Contractor employees shall identify themselves as Contractor personnel when answering telephones and sending emails.

Contractor personnel cannot lead/manage/supervise Government personnel. Contractor program /project managers/Senior Technical Representative (STR) shall be clearly identified and known as such by Government employees. As circumstances permit, periodic meetings shall be conducted between the COR and the Contractor organization program manager/project manager.

(c) Early Dismissal and Closure of Government Facilities

When a Government facility is closed or Federal employees are dismissed early (due to severe weather, security threat, security exercise, or a facility related problem) that prevents personnel from working, onsite contractor personnel regularly assigned to work at that facility shall follow the same reporting and/or departure directions given to Government personnel. The contractor shall not direct charge to the contract for such time off, but shall follow parent company policies regarding taking leave (administrative or other). Non-essential contractor personnel, who are not required to remain at or report to the facility, shall follow their parent company policy regarding whether they should go/stay home or report to another company facility. Subsequent to an early dismissal and during periods of inclement weather, onsite contractors should monitor radio and television announcements before departing for work to determine if the facility is closed or operating on a delayed arrival basis.

When Federal employees are excused from work due to a holiday or a special event (that is unrelated to severe weather, a security threat, or a facility related problem), on site contractors shall continue working established work hours or take leave in accordance with parent company policy. Those contractor employees who take leave shall not direct charge the non- working hours to the contract. Contractors are responsible for predetermining and disclosing their accounting standards, and company policy. Contractors shall follow their disclosed charging practices during the contract period of performance, and shall not follow any verbal directions to the contrary.

The Contracting Officer will make the determination of cost allowability for time lost due to facility closure in accordance with FAR, applicable Cost Accounting Standards, and the Contractor's established accounting policy.

(d) Training Requirements

(A) The contractor shall ensure that each contractor employee performing work at any NUWC Division Newport site take the following actions:

• Complete all required trainings as indicated on the following website:

https://newportalv3.nwpt.nuwc.navy.mil/10/101/Training/SitePages/TrainingWelcome.as px

• Read the documents titled “Occupational Safety and Health Information for Contractors” and “NUWC Division Newport Environmental Policy”, available at the following website, prior to performing any work:

http://www.navsea.navy.mil/Home/WarfareCenters/NUWCNewport/ContactUs/VisitorInformation.aspx

• Complete Environmental Awareness training, available at the following website, within 30 days of commencing performance:

http://www.navsea.navy.mil/Home/WarfareCenters/NUWCNewport/ContactUs/VisitorInformation.aspx

(2) The contractor shall email the following web address indicating completion of items (B) and (C) above upon completion of both: NWPT.NUWC_NPT_1023_Training@navy.mil

(e) Safety Requirements

(1) Prior to commencing any work that falls under the following areas, the contractor shall provide a complete listing of all qualified and trained employees who will perform the work on company letterhead to the Contracting Officer’s Representative, or, if no COR is assigned, to the NUWC Division Newport Safety Office:

(A) Permit required Confined Space Program

(B) Control of Hazardous Energy (Lock out / Tag out)

(C) Respiratory Protection

(D) Walking-Working Surfaces, Fall Protection Program and Scaffolding

(2) The contractor shall follow the posted provisions of the building’s Emergency Action Plan (EAP) for any mishap, incident, or emergency situation.

(3) The contractor shall report unsafe work conditions, safety hazards, and any mishaps (injury/property damage) to their supervisor, the COR, and the NUWC Division Newport Safety Office.

End of text

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.204-13 System for Award Management Maintenance OCT 2018 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities

NOV 2021

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment

NOV 2021

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.219-6 Notice Of Total Small Business Set-Aside NOV 2020 52.219-14 (Dev) Limitations on Subcontracting (DEVIATION 2021-O0008) OCT 2022 52.219-28 Post-Award Small Business Program Rerepresentation MAR 2023 52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records JUL 2021 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.223-6 Drug-Free Workplace MAY 2001 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

JUN 2020

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction JUN 2020 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

MAR 2023

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-1 Performance of Work by the Contractor APR 1984 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-4 Physical Data APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984

52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.236-27 Site Visit (Construction) FEB 1995 52.242-14 Suspension of Work APR 1984 52.243-5 Changes and Changed Conditions APR 1984 52.244-6 Subcontracts for Commercial Products and Commercial

Services

MAR 2023

52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.203-7002 Requirement to Inform Employees of Whistleblower Rights DEC 2022 252.203-7003 Agency Office of the Inspector General AUG 2019 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

JAN 2023

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

JAN 2023

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services

JAN 2023

252.204-7020 NIST SP 800-171 DoD Assessment Requirements JAN 2023 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JAN 2023 252.225-7002 Qualifying Country Sources As Subcontractors MAR 2022 252.225-7048 Export-Controlled Items JUN 2013 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7001 Contract Drawings, and Specifications AUG 2000 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.247-7023 Transportation of Supplies by Sea JAN 2023

52.213-4 TERMS AND CONDITIONS--SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL

PRODUCTS AND COMMERCIAL SERVICES) (MAR 2023)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (NOV 2021) (Section 1634 of Pub. L. 115-91).

(iii) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(iv) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

(v) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(vi) 52.222-26, Equal Opportunity (SEPT 2016) (E.O. 11246).

(vii) 52.225-13, Restrictions on Certain Foreign Purchases (FEB 2021) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(viii) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (MAR 2023) (31 U.S.C. 3903 and 10 U.S.C. 3801).

(ix) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(x) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77 and 108-78 (19 U.S.C.

3805 note)).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (APR 1984).

(ii) 52.232-8, Discounts for Prompt Payment (FEB 2002).

(iii) 52.232-11, Extras (APR 1984).

(iv) 52.232-25, Prompt Payment (JAN 2017).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (JUN 2013).

(vi) 52.233-1, Disputes (MAY 2014).

(vii) 52.244-6, Subcontracts for Commercial Products and Commercial Services (MAR 2023).

(viii) 52.253-1, Computer Generated Forms (JAN 1991).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (JUN 2020) (Pub. L. 109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at or above the threshold specified in FAR 4.1403(a) on the date of award of this contract).

(ii) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (DEC 2022) (E.O. 13126) (Applies to contracts for supplies exceeding the micro-purchase threshold, as defined in 2.101 on the date of award of this contract).

(iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment (JUN 2020) (41 U.S.C. chapter 65) (Applies to supply contracts over the threshold specified in FAR 22.602 on the date of award of this contract, in the United States, Puerto Rico, or the U.S. Virgin Islands).

(iv) 52.222-35, Equal Opportunity for Veterans (JUN 2020) (38 U.S.C. 4212) (Applies to contracts valued at or above the threshold specified in FAR 22.1303(a) on the date of award of this contract).

(v) 52.222-36, Equal Employment for Workers with Disabilities (JUN 2020) (29 U.S.C. 793) (Applies to contracts over the threshold specified in FAR 22.1408(a) on the date of award of this contract, unless the work is to be performed outside the United States by employees recruited outside the United States). (For purposes of this clause, "United States" includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

(vi) 52.222-37, Employment Reports on Veterans (JUN 2020) (38 U.S.C. 4212) (Applies to contracts valued at or above the threshold specified in FAR 22.1303(a) on the date of award of this contract).

(vii) 52.222-41, Service Contract Labor Standards (AUG 2018) (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S.

Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf).

(viii)(A) 52.222-50, Combating Trafficking in Persons (NOV 2021) (22 U.S.C. chapter 78 and E.O. 13627) (Applies to all solicitations and contracts).

(B) Alternate I (MAR 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(ix) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (JAN 2022) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, Johnston Island, Wake Island, and the outer Continental Shelf as defined in the Outer Continental Shelf Lands Act (43 U.S.C. 1331, et seq.))).

(x) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2022) (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.))

(xi) 52.223-5, Pollution Prevention and Right-to-Know Information (MAY 2011) (E.O. 13423) (Applies to services performed on Federal facilities).

(xii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693)(applies to contracts for products as prescribed at FAR 23.804(a)(1)).

(xiii) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners).

(xiv) 52.223-15, Energy Efficiency in Energy-Consuming Products (MAY 2020) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR ® Program or Federal Energy Management Program (FEMP) will be--

(A) Delivered;

(B) Acquired by the Contractor for use in performing services at a Federally-controlled facility;

(C) Furnished by the Contractor for use by the Government; or

(D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance).

(xv) 52.223-20, Aerosols (Jun 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices).

(xvi) 52.223-21, Foams (Jun 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent;

or contracts for construction of buildings or facilities.

(xvii) (A) 52.225-1, Buy American--Supplies (OCT 2022) (41 U.S.C. chapter 67) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold, as defined in 2.101 on the date of award of this contract, and the acquisition--

(1) Is set aside for small business concerns; or

(2) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $50,000).

(B) Alternate I (OCT 2022) (Applies if the Contracting Officer has filled in the domestic content threshold below, which will apply to the entire contract period of performance. Substitute the following sentence for the first sentence of paragraph (1)(ii)(A) of the definition of domestic end product in paragraph (a) of 52.225-1:

(A) The cost of its components mined, produced, or manufactured in the United States exceeds percent of the cost of all its components. [Contracting officer to insert the percentage per instructions at 13.302-5(d)(4).])

(xviii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (JUN 2020) (42 U.S.C. 1792) (Applies to contracts greater than the threshold specified in FAR 26.404 on the date of award of this contract, that provide for the provision, the service, or the sale of food in the United States).

(xix) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (OCT 2018) (Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the System for Award Management (SAM) as its source of EFT information.)

(xx) 52.232-34, Payment by Electronic Funds Transfer--Other than System for Award Management (JUL 2013) (Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information.)

(xxi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (NOV 2021) (46 U.S.C. 55305) (Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d).)

(2) Listed below are additional clauses that may apply:

(i) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (NOV 2021) (Applies to contracts when the contractor or a subcontractor at any tier may have Federal contract information residing in or transiting through its information system.)

(ii) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (NOV 2021) (Applies to contracts over the threshold specified in FAR 9.405-2(b) on the date of award of this contract).

(iii) 52.211-17, Delivery of Excess Quantities (SEP 1989) (Applies to fixed-price supplies).

(iv) 52.247-29, F.o.b. Origin (FEB 2006) (Applies to supplies if delivery is f.o.b. origin).

(v) 52.247-34, F.o.b. Destination (NOV 1991) (Applies to supplies if delivery is f.o.b. destination).

(c) FAR 52.252-2, Clauses Incorporated by Reference (FEB 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov/

(d) Inspection/Acceptance. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its postacceptance rights--

(1) Within a reasonable period of time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(f) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges that the Contractor can demonstrate to the satisfaction of the Government, using its standard record keeping system, have resulted from the termination.

The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred that reasonably could have been avoided.

(g) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(h) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance

Requirements for…