N40027-19-R-0012.pdf

CODE

(Hour)

PAGE(S)

until 02:00 PM local time 26 Aug 2019

X

A

X B

X C X D

EX

X

G

F 75 - 92

93 - 104

X H 105 - 108 robert.t.guy4@navy .mil

RATING PAGE OF PAGES

7. ISSUED BY

(Date)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

Previous Edition is Unusable 33-134 STANDARD FORM 33 (REV. 9-97)

Prescribed by GSA

FAR (48 CFR) 53.214(c)

1 108

(If other than Item 7)

15A. NAME 16. NAME AND TITLE OF PERSON AUTHORIZED TO

AND

ADDRESS

SIGN OFFER (Type or print)

OF

OFFEROR

AMENDMENT NO. DATE

15B. TELEPHONE NO (Include area code) 17. SIGNATURE15C. CHECK IF REMITTANCE ADDRESS

IS DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

18. OFFER DATE

1. THIS CONTRACT IS A RATED ORDER

UNDER DPAS (15 CFR 700)

2. CONTRACT NO.

N40027 8. ADDRESS OFFER TO

See Item 7

9. Sealed offers in original and 1 copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 8, or if handcarried, in the depository located in

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and

SERMC BLDG 1488

conditions contained in this solicitation.

10. FOR INFORMATION

CALL:

A. NAME (NO COLLECT CALLS)

ROBERT T GUY 904-270-5126 X5867

11. TABLE OF CONTENTS

SOLICITATION/ CONTRACT FORM

SUPPLIES OR SERVICES AND PRICES/ COSTS

2 - 14

X I CONTRACT CLAUSES

DESCRIPTION/ SPECS./ WORK STATEMENT X

PACKAGING AND MARKING

15 - 36

J LIST OF ATTACHMENTS

INSPECTION AND ACCEPTANCE

DELIVERIES OR PERFORMANCE

38 - 41

42 - 43 X K

REPRESENTATIONS, CERTIFICATIONS AND

OTHER STATEMENTS OF OFFERORS

CONTRACT ADMINISTRATION DATA 44 - 54 X

SPECIAL CONTRACT REQUIREMENTS

OFFER (Must be fully completed by offeror) 55 - 57 X M

L INSTRS., CONDS., AND NOTICES TO OFFERORS

EVALUATION FACTORS FOR AWARD

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause No. 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments

AMENDMENT NO. DATE

to the SOLICITATION for offerors and related documents numbered and dated):

FACILITY

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period

SOLICITATION, OFFER AND AWARD

X

(X) SEC. DESCRIPTION (X) SEC. DESCRIPTION PAGE(S)

PART I - THE SCHEDULE

26. NAME OF CONTRACTING OFFICER (Type or print) 27. UNITED STATES OF AMERICA 28. AWARD DATE

EMAIL:TEL: (Signature of Contracting Officer)

CODE CODE

B. TELEPHONE (Include area code) C. E-MAIL ADDRESS

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

23. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

24. ADMINISTERED BY (If other than Item 7) CODE 25. PAYMENT WILL BE MADE BY CODE

PART IV - REPRESENTATIO NS AND INSTRUCTIO NS

PART III - LIST O F DO CUMENTS, EXHIBITS AND O THER ATTACHMENTS

58 - 73

PART II - CO NTRACT CLAUSES

COMMANDER SOUTHEAST REGIONAL MAINTENANCE

CTR P.O. BOX 280057, MAYPORT NAVAL STATION

JACKSONVILLE FL 32228-0057

(904) 270-5126 EXT 3259

(904) 270-5056FAX:

TEL:

FAX:

TEL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

6. REQUISITION/PURCHASE NO.

N4002A19PR00420

5. DATE ISSUED

26 Jul 2019

4. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

[ X ]

3. SOLICITATION NO.

N4002719R0012

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

CLIN

Number

1 Each

USS TORNADO (PC 14) CMAV

FFP

Prepare for and accomplish the Continuous Maintenance Availability (CMAV) onboard USS TORNADO (PC 14), as described in SSP: 004-20 (COAR 26-004).

See Attachment J-1 for Specification Package, excluding all option items.

NOTE: The requirements in DFARS 252.211-7003, Item Identification and

Valuation, are applicable for this line item. The contractor shall provide DoD unique identification or a DoD recognized unique identification equivalent.

PURCHASE REQUEST NUMBER: N4002A19PR00420

PSC CD: J998

NET AMT

CDRL, DD Form 1423

FFP

Contract Data Requirements List (CDRL) DD Form 1423, Exhibits A and B. Price to be included in CLIN CLIN 0001and Option CLINs 0003-0007(if exercised).

NOTE: The requirements in DFARS 252.211-7003, Item Identification and

Valuation, are applicable for this line item. The contractor shall provide DoD unique identification or a DoD recognized unique identification equivalent.

FOB: Destination

OPTION USS TORNADO (PC 14) CMAV

FFP

Work item 506-80-001. Prepare for and accomplish the Continuous Maintenance

Availability (CMAV) onboard USS TORNADO (PC 14), as described in SSP:

004-20 (COAR 30-004).

NOTE: The requirements in DFARS 252.211-7003, Item Identification and

Valuation, are applicable for this line item. The contractor shall provide DoD unique identification or a DoD recognized unique identification equivalent.

FOB: Destination

FFP

Work item 514-90-001. Prepare for and accomplish the Continuous Maintenance

Availability (CMAV) onboard USS TORNADO (PC 14), as described in SSP:

004-20 (COAR 26-004).

NOTE: The requirements in DFARS 252.211-7003, Item Identification and

Valuation, are applicable for this line item. The contractor shall provide DoD unique identification or a DoD recognized unique identification equivalent.

FFP

Work item 531-80-001. Prepare for and accomplish the Continuous Maintenance

Availability (CMAV) onboard USS TORNADO (PC 14), as described in SSP:

004-20 (COAR 26-004).

NOTE: The requirements in DFARS 252.211-7003, Item Identification and

Valuation, are applicable for this line item. The contractor shall provide DoD unique identification or a DoD recognized unique identification equivalent.

FFP

Work item 625-80-001. Prepare for and accomplish the Continuous Maintenance

Availability (CMAV) onboard USS TORNADO (PC 14), as described in SSP:

004-20 (COAR 26-004).

NOTE: The requirements in DFARS 252.211-7003, Item Identification and

Valuation, are applicable for this line item. The contractor shall provide DoD unique identification or a DoD recognized unique identification equivalent.

FFP

Work item 980-90-001. Prepare for and accomplish the Continuous Maintenance

Availability (CMAV) onboard USS TORNADO (PC 14), as described in SSP:

004-20 (COAR 93-004).

NOTE: The requirements in DFARS 252.211-7003, Item Identification and

Valuation, are applicable for this line item. The contractor shall provide DoD unique identification or a DoD recognized unique identification equivalent.

CLAUSES INCORPORATED BY FULL TEXT

B-227-H001 PROVISIONING TECHNICAL DOCUMENTATION – WITHHOLDING OF PAYMENT

(NAVSEA) (OCT 2018)

(a) For the purpose of paragraph (c) of the "Progress Payments" clause of this contract, if included, the requirement that the Contractor develop and deliver Provisioning Technical Documentation (PTD) is considered to be a "material requirement of this contract," and Contractor failure to make adequate progress in the development of PTD, or to deliver acceptable PTD on a timely basis, may result in reduction or suspension of Progress Payments as provided in said paragraph.

(b) The PTD is considered to be a part of the "Technical Data" specified to be delivered under this contract for the purposes of the "Technical Data--Withholding of Payment" (DFARS 252.227-7030) clause. The terms and conditions of the clause entitled "Limitation On Withholding of Payments (FAR 52.232-9), if included in this contract, shall not apply to withholding of payment for failure to make timely delivery of the PTD or delivery of deficient PTD.

(End of text)

B-231-H002 WORKSITE TRAVEL COSTS (NAVSEA) (OCT 2018)

(a) The contractor shall not charge, and the Government shall not pay, as an allowable cost under this contract, any manhour costs (whether straight-time or overtime) for contractor personnel or subcontractor personnel traveling to or from worksites, including travel to worksites other than the contractor's facility for performance of contract work.

(b) Workers being paid under this contract, as prime contractor personnel or subcontractor personnel, will complete a full shift at the worksite, and no compensation will be paid for travel time before or after the shift.

(c) This requirement pertains only to payments for travel time before or after these workers' regular shifts

(commuting costs), and does not apply to legitimate travel costs incurred during normal working hours, provided that those costs are otherwise reasonable, allocable and allowable and approved in writing by the Government. This requirement does not apply to manufacturer's representatives or Original Equipment Manufacturer (OEM) representatives when specifically required by the Government work specifications.

(d) Additionally, the contractor shall not charge, and the Government shall not pay, any transportation costs under this contract associated with transporting contractor or subcontractor personnel between the contractor's facility (or subcontractor's facility), and any other worksite to perform ship repair, maintenance or modernization.

Transportation costs include, but are not limited to, bus fare, car fare, train fare, or boat fare, paid by the work force, or paid by the contractor on behalf of the work force.

STATEMENT OF WORK

1. GENERAL REQUIREMENTS

Prepare for and accomplish the Continous Maintenance (CM) onboard USS TORNADO (PC 14) as specified herein and in accordance with standard items, work item specification package SSP SERM-004-20 drawings, test procedures, and other detailed data.

NAVSEA Standard Items have been furnished to each Master Agreement for the Repair and Alteration of Vessels

(MARAV) Contractor under separate cover for retention.

Category I NAVSEA FY-20 Change 1 Standard Items as specified in SSP SERM-004-20 are applicable to all items without further reference. Category II FY-20 Change 1 Standard Items are part of this specification when invoked and/or referenced in individual work items.

The Contractor shall provide data in accordance with the following:

(a) The Contractor shall furnish data required hereunder in accordance with the Contract Data Requirements

List (CDRL), DD Form 1423, Exhibits A and B attached hereto.

(b) Exhibits A and B also identify the major data items required by the contract work specifications. The

Contractor shall notify SERMC in writing if data items required by the work item specifications are not indicated in Exhibits A and B.

2. PROGRESS PAYMENT RATES

The progress payment rate for this contract is 95 percent for small business in accordance with 10 USC 2307(g).

3. SUBMISSION OF HAZARDOUS WASTE MANIFEST

Submission of the completed and signed Hazardous Waste Manifest forms, as required by the applicable Hazardous

Waste Handling and Disposal Work Item, shall be submitted directly to Southeast Regional Maintenance Center via the Navy Maintenance Database (NMD). The completed forms must be submitted and accepted by SERMC no later than 1400 local time, 30 days after the period of performance is completed (C+30).

4. GOVERNMENT FURNISHED MATERIAL

(a) Government Furnished Material (GFM) cited in the solicitation will be picked up at Warehouse Building

191, unless other location(s) is/are specified in the contract. The successful offeror is to telephone the Warehouse at

(904) 270-5700 to coordinate the pickup of Government Furnished Material.

(b) Government property permanently removed from a vessel that requires a Property Administrator's disposition instructions, shall be properly prepared for shipment and be delivered as directed by the Property

Administrator. The distance between contractor's plant and location to be designated is estimated to be less than 75 miles (one way).

(c) GFM will be Annex 9 in section J.

5. ADDITIONAL ALLOWANCES

(a) Offerors are required to include allowance of an additional 25% for electrical /electronic cable lengths and associated hardware for material ordering and shipboard installation over and above the drawing requirements in their price.

(b) Offerors are required to include allowance of an additional 10% for piping and associated fittings for material ordering and shipboard installation over and above the drawing requirements in their price.

6. PERSONAL PROTECTIVE EQUIPMENT

Whenever work is performed aboard U.S. Naval Ships or vessels at piers or drydocks of a Naval Shipyard or Naval

Station, Contractor employees (including management personnel) shall have and use at all times the following personal protective equipment:

(a) Head Protection that must comply with 29 CFR 1915.155 or shall be demonstrated to be equally effective.

(b) Eye and face protection, including prescription lenses must comply with 29 CFR 1915.153 (b) or shall be demonstrated to be equally effective.

(c) Protective footwear must comply with 29 CFR 1915.156 or shall be demonstrated to be equally effective.

7. SAFETY INSPECTOR / FIRE MARSHAL

The Contractor is responsible for providing an experienced Safety Inspector/Fire Marshal who will accomplish daily inspections of the Contractor's entire work area on the ship, together with the Contracting Office’s Safety

Representative. This Inspector or Fire Marshal shall not be one of the Contractor's supervisors or superintendents normally assigned to the ship.

8. USE OF BLACK OXIDE COATED THREADED FASTENERS (BOCTFs)

Due to safety concerns, use of BOCTFs is not authorized when installing or replacing threaded fasteners in the accomplishment of any work required by any Work Item in this contract

9. COSAL CONFIGURATION CHANGE DOCUMENTATION

The contractor shall document all changes to the ship's configuration and prepare all documentation required to bring the ship's COSAL and SPCC Weapons Systems Files (WSF) into agreement with the actual end of availability configuration. Perform COSAL/WSF maintenance action on all planned and actual equipments/components/equipage, whether furnished by the Government or the Contractor.

10. POST-AWARD SUBMISSION

After receipt of award and prior to starting work aboard the vessel, contractors must submit a SERMC Contractor

Visit Request (SERMC 5220/2) containing the listing of company employees who will be performing the contracted work, to the SERMC Security Office for access processing to designated NAVSTAMYPT Vessels and Restricted

Areas (RAs). SERMC Contractor Visit Requests (SERMC 5220/2) that are not submitted to the SERMC Security

Office in compliance with applicable instructions will not be processed, and will be returned to the submitting company for correction and resubmission. To obtain a copy of the SERMC Contractor Visit Request form, contractors may proceed to - http://www.navsea.navy.mil/Home/RMC/SERMC/ContactUs/VisitorInformation.aspx.

11. CITIZENSHIP REQUIREMENTS AND DOCUMENTATION

The contractor shall comply with the Department of Defense Industrial Security Manual (DoD 5220.22), and any revisions to that manual as of the Bid Opening Date prescribed, for verification of all U. S. Citizens.

Prospective offerors shall refer all questions pertaining to the above to the Southeast Regional Maintenance Center

(SERMC) Security Manager, phillip.actkins@navy.mil and carbon copy (cc) the contracting officer.

DOCUMENTS ACCEPTABLE FOR PROOF OF U.S. CITIZENSHIP

a. A certified birth certificate indicating the individual was born in the United States of America.

b. A U.S. Passport.

c. A certificate of naturalization if the individual claims citizenship by naturalization.

d. Report of Birth Abroad of a Citizen of the United States of America (Form FS-240), a Certification of

Birth (Form FS-545 or DS-1350), or a Certificate of Citizenship of Parents.

e. If primary evidence of U.S. Citizenship is not obtainable, then the best available secondary evidence, showing that the individual was born in the U.S., is required. Such evidence may include a combination of at least two of the following: a baptismal certificate; a hospital birth record; evidence of persons having personal knowledge of the facts of birth; or other documentary evidence, such as U.S. military records, early census, school or family Bible records, insurance papers, or newspaper files. The secondary evidence must be adequate to support a “good faith” determination that the individual is in fact a U.S. citizen. Secondary evidence submitted as proof of birth in the U.S. shall be original or certified documents. Non-certified copies are not acceptable

12. ADDITIONAL DEFINITIONS

Wherever the term "Job Order" is used in this solicitation/award, it also means "Contract".

13. THREAT CONDITIONS

While the current Threat Condition is set at Bravo, Threat Condition Charlie shall be considered when submitting a proposal for this solicitation. Any costs associated with delays, disruptions, or security precautions associated with

Threat Condition Charlie shall be included in your proposal. Contractors will not receive additional compensation for delays, disruptions, or security precautions associated with Threat Condition Charlie. Contractors are to expect delays upon gaining access to Naval Station Mayport and the vessel.

http://www.navsea.navy.mil/Home/RMC/SERMC/ContactUs/VisitorInformation.aspx

14. USE/POSSESSION OF PERSONAL ELECTRONIC DEVICES (PEDS)

The possession and use of portable electronic devices (PEDs) within the confines of any naval vessel, or in the contractor's facility where equipment removed from the vessel is being worked, is strictly controlled.

PEDs include:

mobile computing devices such as personal digital assistants (PDAs);

hand-held or laptop computers;

mobile telephone devices such as data-enabled cellular telephones;

two-way pagers, including those with e-mail capability;

analog and digital sound recorders; and digital cameras, including cellular phones with digital imaging capabilities.

Cellular phones with digital imaging capabilities are strictly prohibited. PEDs may not be connected to any Navy-owned or controlled network. PEDs may not be used to store or process any digital information associated with the conduct of the contract without written authorization from the Naval Supervising Activity (NSA).

15. DELAY/DISRUPTION

The contractor shall coordinate the work effort with the maintenance team project manager on a daily basis to prevent changing situations from causing delays and disruptions. Disruption due to minor delays is to be expected.

A minor delay is defined as two hours or less per event. These disruptions are considered normal rather than unusual occurrences during the performance of tasks ordered under this contract.

If, during contract performance, delays greater than two hours per event are encountered, the Contractor shall immediately verbally notify the Project Manager and Contracting Officer, followed by a written statement within 24 hours after occurrence of delay, stating time of impact, reason for delay, duration of impact, number of people affected, action taken to properly schedule the work, action taken to minimize impact, and the names of Government person(s) contacted.

16. REQUIRED STANDARD OF WORKMANSHIP

Unless otherwise specifically provided in this contract, the quality of all services rendered hereunder shall conform to the highest standards in the relevant profession, trade, or field of endeavor. All services shall be rendered by or supervised directly by individuals fully qualified in the relevant profession, trade, or field, and holding any licenses required by law.

17. QUALITY ASSURANCE PROGRAM

The Contractor shall provide and maintain a quality assurance program acceptable to the Government, and shall perform or have performed the inspections and tests pursuant to that program to substantiate that the material and workmanship provided pursuant to the job order conform to the drawings, specifications, job orders, and contract requirements listed herein. The Contractor's quality assurance program shall be in accordance with that set forth in

Standard Item 009-04. In addition to its rights under DFARS Clause 252.217-7005, the Government shall have the right to deem work or material furnished by the Contractor to be incomplete and not in accordance with the requirements of the job order by reason of the Contractor's failure to comply with the requirements of its quality assurance program and, as such, the Contractor shall not be entitled to progress payments for said work and material.

18. REQUEST FOR CONTRACT CHANGES (RCC) TIMELINE

The contractor shall provide all Class "F" Change Order Price Analysis (COPA) proposals in response to Request for Contract Changes (RCC) within three business days. The contractor shall provide all Class "C" COPA proposals in response to RCCs within five business days. If circumstances arise where the contractor is unable to submit a

COPA within three business days, the contractor shall notify the Government in writing of the specific circumstances and provide a date on which a COPA will be submitted. The contractor's timeliness in submitting

COPAs in response to RCCs will be evaluated in CPARS and utilized for past performance ratings on future proposal evaluations. Notification of late submission of COPA does not exempt the contractor from meeting the three business day requirement, but will be considered by the Government when conducting a CPARS evaluation.

a. For each Condition Report submitted provide a definition of the proposed work required, a cost estimate, with amplifying information as appropriate, for any recommended work scope change(s), any acceleration/premium time required, and any impact in time to internal major milestones and production and contract completion dates.

b. Cost estimates provided will identify the time frame for which the estimate is valid, the type/class of estimate that has been provided (Class "C" Budget Quality, +/- 15 percent, is to be the target level at this point), and recommendations for the appropriate/best time for accomplishment example: Within CNO production period, or extension required to current CNO production period, or considered more cost effective for post CNO accomplishment.

3. Condition reports that cannot be estimated within 3 working days from identification of the work requirement will be submitted to the SUPERVISOR with a Class "F" (+/- 40 percent) estimated cost, and any potential impact statements that may be required. The condition report shall also contain the date on which a reliable estimate will be available to the SUPERVISOR.

19. PLACE OF PERFORMANCE

(a) Work on the Vessel under this contract shall be performed at: Naval Station Mayport.

(b) Drydocking shall be accomplished at: N/A

(c) All other work shall be accomplished at: Naval Station Mayport.

20. DELIVERY / REDELIVERY SCHEDULE

The Government agrees to deliver the Vessel to the Contractor no later than the date set forth in Attachment J-2.

The Contractor agrees to redeliver the Vessel to the Government no later than the date set forth in Attachment J-2.

21. UTILIZATION OF NMD

The successful offeror shall utilize the Navy Maintenance Database (NMD) program to perform administrative functions with the Government. The contractor must have access to NMD no later than five days after contract award.

Each individual needing access to NMD will require a PKI certificate. For additional information concerning NMD, please contact the Southeast Regional Maintenance Center ERP Business Office Help Desk at:

SERMC_MYPT_ERP_HELPDESK@navy.mil.

22. WORK AT A GOVERNMENT INSTALLATION

If the Schedule requires work to be performed aboard ship while located at a Government installation, Offerors are urged and expected to inspect the site where services are to be performed and to satisfy themselves as to all general and local conditions, including security requirements that may affect the cost of performing the work, in the event mailto:SERMC_MYPT_ERP_HELPDESK@navy.mil such information is reasonably obtainable. In no event will the failure to inspect the site constitute grounds for a claim after award of the job order/contract.

23. GOVERNMENT PROPERTY IN POSSESSION OF OFFERORS

(a) This solicitation does not authorize the use, in performing the work under this solicitation, of any

Government property except those items, if any, of Government furnished property specified in Section J. If the offeror or any anticipated subcontractor requires the use, in performing the work proposed under this solicitation, of any other items if Government property in their possession or otherwise, under a facilities contract or other agreement independent of this solicitation, then the offeror shall so state by submitting the following with the offer:

(1) A list of description of all Government property in possession of the offeror and his anticipated subcontractors proposed to be used in a rent-free basis under this contract, which property is accountable under other contracts.

(2) Identification of the facilities contract or other instrument under which the property is held, and the written permission of the Contracting Officer having cognizance of the property for use of that property.

(3) The months during which such property is to be available for use, which shall include the first, last, and all intervening months, and with respect to any such property which is to be used concurrently in performance of two or more contracts, the amounts of the respective uses in sufficient detail to support the pro-ration required by

FAR 45.205, and

(4) The amount of rent, which would be charged for such use, computed in accordance with FAR 45.4, Contractor Use and Rental of Government Property.

24. SENSITIVE WEAPONS TECHNOLOGIES INFORMATION

All technical data provided to the Contractor by the Government will be protected from public disclosure in accordance with the markings contained thereon. All other information relating to items to be delivered or services to be performed under this contract may not be disclosed by any means without prior approval of the authorized representative of the Contracting Officer. Dissemination or public disclosure includes, but is not limited to, permitting access to such information by foreign nationals or by any other person or entity; publication of technical or scientific papers; advertising; or any other proposed release. The Contractor shall provide adequate physical protection to such information so as to preclude access by any person or entity not authorized such access by the Government.

25. USE OF OZONE DEPLETING SUBSTANCES

(a) In accordance with Section 326 of Pub. L. 102-484, the Department of Defense is prohibited from awarding any contract which includes a DoD-directed specification or standard that requires the use of a Class I ozone-depleting substance (ODS) or that can be met only through the use of such a substance unless such use has been approved by a senior acquisition official (SA)). The SAO approval is based on a technical certification that no suitable substitute for the ODS is currently available.

(b) To comply with this statute, the Navy has screened the specifications and standards associated with this solicitation. To the extent that ODS requirements were revealed by this review they are identified below.

Class I ODS Identified Specification/Standard

(a) If offerors possess knowledge about any other Class I ODS required directly or indirectly by the specification or standards, the Navy would appreciate such information in your response to this solicitation.

Offerors are under no obligation to comply with this request and no compensation can be provided for doing so.

26. GOVERNMENT FURNISHED FACILITIES AND EQUIPMENT

(a) In accordance with the provisions of Section I, DFARS Clause 252.217-7010 entitled "Performance", this is the only provision in this contract for the Government to provide to the Contractor any facilities, equipment, or services.

The Government will provide for use in connection with and under the terms of this contract the following:

(b) (1) Access to the vessel at: Naval Station Mayport

(2) Pier space, within the vicinity of the vessel, for location of Contractor equipment.

(c) The Contractor shall furnish all other necessary material, labor, services, equipment (i.e. air compressors, crane services), accessories, facilities, and such other things and services as are necessary for accomplishing the work specified in the contract subject to the rights reserved by the Government under Section I, FAR Clause 52.245-2 entitled "Government Property".

(d) Assume all tanks and voids contain liquids that are at low suction in order to calculate disposal quantities as required by relevant work items. Tanks sounding tables may be obtained from the SERMC Tech Library.

27. INSPECTION AND ACCEPTANCE

The performance by the Contractor and the quality of the work delivered including any equipment furnished, and documentary material written or compiled, shall be subject to in-process review and inspection during performance. Inspection may be accomplished at any work location involved and authorized government personnel shall be permitted to observe the work or to conduct inspection at all reasonable hours. Inspection or test by the

Government of any services rendered or supplies furnished hereunder does not relieve the Contractor from any responsibility regarding defects or other failures to meet contract requirements which may be discovered prior to final acceptance.

Further, the contractor shall ensure for any specification work items (submitted either in part or whole) that the quality and technical requirements are passed down from the contractor to all subcontractor tiers.

NOTE: Quality assurance oversight may be provided by a third party inspector.

28. BASE ACCESS REQUIREMENTS

DBIDS (Defense Biometric Identification Systems)

The Navy transitioned from using RAPIDGate credentials to the Defense Biometric Identification System (DBIDS) for Contractors (and vendors) requiring access to US Naval facilities, including vessels.

Contractors (or vendors) who need assistance in a DBIDS temporary pass or into a DBIDS card, can contact the

Naval Station Mayport Pass & ID office or Visitor Control Center at (904) 270-5585 or (904) 270-5605.

For more information about DBIDS, proceed to: http://dbids.dmdc.mil.

29. Assume all tanks and voids contain liquids that are at low suction in order to calculate disposal quantities as required by relevant work items. Tank sounding tables may be obtained from the SERMC Tech Library.

http://dbids.dmdc.mil/

Section C - Descriptions and Specifications

C-202-H001 ADDITIONAL DEFINITIONS–BASIC (NAVSEA) (OCT 2018)

(a) Department - means the Department of the Navy.

(b) Commander, Naval Sea Systems Command - means the Commander of the Naval Sea Systems Command of the

Department of the Navy or his duly appointed successor.

(c) References to The Federal Acquisition Regulation (FAR) - All references to the FAR in this contract shall be deemed to also reference the appropriate sections of the Defense FAR Supplement (DFARS), unless clearly indicated otherwise.

(d) National Stock Numbers - Whenever the term Federal Item Identification Number and its acronym FIIN or the term Federal Stock Number and its acronym FSN appear in the contract, order or their cited specifications and standards, the terms and acronyms shall be interpreted as National Item Identification Number (NIIN) and National

Stock Number (NSN) respectively which shall be defined as follows:

(1) National Item Identification Number (NIIN). The number assigned to each approved Item

Identification under the Federal Cataloging Program. It consists of nine numeric characters, the first two of which are the National Codification Bureau (NCB) Code. The remaining positions consist of a seven digit non-significant number.

(2) National Stock Number (NSN). The National Stock Number (NSN) for an item of supply consists of the applicable four-position Federal Supply Class (FSC) plus the applicable nine-position NIIN assigned to the item of supply.

C-211-H001 ACCESS TO THE VESSEL(S) (NAVSEA) (OCT 2018)

Officers, employees and associates of other prime Contractors with the Government and their subcontractors, shall, as authorized by the Supervisor, have, at all reasonable times, admission to the plant, access to the vessel(s) where and as required, and be permitted, within the plant and on the vessel(s) required, to perform and fulfill their respective obligations to the Government. The Contractor shall make reasonable arrangements with the Government or Contractors of the Government, as shall have been identified and authorized by the Supervisor to be given admission to the plant and access to the vessel(s) for office space, work areas, storage or shop areas, or other facilities and services, necessary for the performance of the respective responsibilities involved, and reasonable to their performance.

C-211-H004 HEAVY WEATHER PLAN (NAVSEA) (OCT 2018)

(a) In order to ensure that Naval vessel(s), material and Government property are protected during destructive weather such as gales, storms, hurricanes, high winds, heavy snow, ice and high water, the Contractor is required to have a written Heavy Weather Plan (HWP) which assigns responsibilities and prescribes actions to be taken on the approach of and during heavy weather conditions as delineated in NAVSEA Standard Item (SI) 009-69. A copy of Standard Item

(SI) 009-69 can be obtained from via the internet by going to:

http://www.navsea.navy.mil/Home/RMC/CNRMC/OurPrograms/SSRAC/NSI/ and selecting the NAVSEA Standard

Items (NSI) tab then select the applicable FY standard item link and then select SI 009-69. In accordance with SI 009-

69, the Contractor shall furnish to the cognizant Regional Maintenance Center (RMC), a copy of such HWP, and shall make such changes in the plan as the RMC considers necessary and reasonable to protect and care for vessel(s), material and Government property.

(b) In the event the RMC directs the Contractor to implement the HWP pursuant to SI 009-69 the Contractor may submit to the Contracting Officer a request for reimbursement for costs resulting from such actions together with any documentation that the Contracting Officer may reasonably require. The Government shall reimburse the Contractor for all reasonable, allowable and allocable costs resulting from the Contractor's implementation of the HWP based on such

Government direction.

C-211-H008 QUALIFICATION OF CONTRACTOR NON-DESTRUCTIVE TESTING (NDT) PERSONNEL

(NAVSEA) (OCT 2018)

(a) The Contractor and any Non-destructive Testing (NDT) subcontractor shall utilize for the performance of required NDT, only Level I, II and III personnel currently certified in accordance with NAVSEA Technical

Publication T9074-AS-GIB-010/271, Revision 1 of 11 September 2014. Documentation pertaining to the qualification and certification of NDT personnel shall be made available to the Contracting Officer for review upon request.

(b) These requirements do not apply with respect to nuclear propulsion plant systems and other matters under the technical cognizance of the Office of Navy Nuclear Propulsion (NAVSEA 08). Because of health and safety considerations, such matters will continue to be handled as directed by NAVSEA 08.

C-211-H016 SPECIFICATIONS AND STANDARDS (NAVSEA) (OCT 2018)

(a) Definitions.

(i) A "zero-tier reference" is a specification, standard, or drawing that is cited in the contract (including its attachments).

(ii) A "first-tier reference" is either: (1) a specification, standard, or drawing cited in a zero-tier reference, or (2) a specification cited in a first-tier drawing.

http://www.navsea.navy.mil/Home/RMC/CNRMC/OurPrograms/SSRAC/NSI/

(b) Requirements. All zero-tier and first-tier references, as defined above, are mandatory for use. All lower tier references shall be used for guidance only unless specifically identified below.

None

C-211-H017 UPDATING SPECIFICATIONS AND STANDARDS (NAVSEA) (DEC 2018)

The contractor may request that this contract be updated to include the current version of the applicable specification or standard if the update does not affect the form, fit or function of any deliverable item or increase the cost/price of the item to the Government. The contractor should submit update requests to the Procuring Contracting Officer with copies to the Administrative Contracting Officer and cognizant program office representative for approval. The contractor shall perform the contract in accordance with the existing specifications and standards until notified of approval/disapproval of its request to update by the Procuring Contracting Officer. Any approved alternate specifications or standards will be incorporated into the contract.

C-211-H018 APPROVAL BY THE GOVERNMENT (NAVSEA) (JAN 2019)

Approval by the Government as required under this contract and applicable specifications shall not relieve the

Contractor of its obligation to comply with the specifications and with all other requirements of the contract, nor shall it impose upon the Government any liability it would not have had in the absence of such approval.

C-211-H019 COMMONALITY AND STANDARDIZATION (NAVSEA) (FEB 2019)

The Contractor shall develop and implement a Commonality and Standardization Plan, reducing range and increasing depth of like equipment, to enhance supportability, minimize life cycle costs, and increase system readiness and interoperability across ships/ship classes through the selection of equipment and components which are, to the maximum extent possible, (1) common for application within the CYCLONE (PC-1) Class and (2) common with equipment/components currently installed in U.S. Navy ships. The Contractor shall utilize both

Industry (e.g., the Common Parts Catalog) and Government (e.g., NAVSEA Enterprise Commonality Virtual Shelf and the Hull, Mechanical and Electrical Equipment Data Research System (HEDRS)) tools to implement its

Commonality and Standardization Plan. For selecting Hull Mechanical and Electrical (HM&E) equipment/components, the Contractor shall utilize NAVSEA Enterprise Commonality Virtual Shelf before other tools, if the items meet the contract requirements. The Virtual Shelf is a web-based repository of HM&E equipment/components that meet cross-platform requirements and specifications and provide superior Total

Ownership Cost (TOC). Information to gain access to the Virtual Shelf is located on the following web site:

https://www.dau.mil/team/virtualshelf/SitePages/Home.aspx.

C-211-H020 PROTECTION OF THE VESSEL (NAVSEA) (MAR 2019)

(a) The Contractor shall exercise reasonable care, as agreed upon with the Supervisor, to protect the vessel from fire, and shall maintain a system of inspection over the activities of its welders, burners, riveters, painters, pipe fitters, and similar workers, and of its subcontractors, particularly where such activities are undertaken in the vicinity of the vessel's magazines, fuel oil tanks, or store rooms containing inflammable materials. All ammunition, fuel oil, motor fuels, and cleaning fluids shall have been off-loaded and the tanks cleaned, except as may be mutually agreed upon between the Contractor and the Supervisor prior to work on the vessel by the Contractor. Fire hose lines shall be maintained by the Contractor ready for immediate use on the vessel at all times while the vessel is berthed alongside the Contractor's pier or in dry dock. All tanks under alteration or repair shall be cleaned, washed, and steamed out or otherwise made safe to the extent necessary, and the Contractor shall furnish the vessel's Gas Free

Officer and the Supervisor with a "Gas Chemists' Certificate" before any hot work is done. The Contractor shall maintain a fire watch aboard the vessel in areas where the Contractor is working. All other fire watches aboard the vessel shall be the responsibility of the Government.

(b) Except as otherwise provided in contractually invoked technical specifications or NAVSEA furnished directives, while the vessel is at the Contractor's plant and when the temperature becomes as low as thirty-five degrees Fahrenheit, the Contractor shall assist the Government when requested in keeping all pipe-lines, fixtures, traps, tanks, and other receptacles on the vessel drained to avoid damage from freezing, or if this is not practicable, the vessel shall be kept heated to prevent such damage. The vessel's stern tube and propeller hubs shall be protected by the Contractor from frost damage by applied heat through the use of a salamander or other proper means.

(c) The work shall, whenever practicable, be performed in such manner as not to interfere with the work performed by military personnel attached to the vessel, and provisions shall be made so that personnel assigned shall have access to the vessel at all times, it being understood that such personnel will not unduly interfere with the work of the Contractor's workmen.

(d) The Contractor shall at all times keep the site of the work on the vessel free from accumulation of waste material or rubbish caused by its employees, or the work performed by the Contractor in accordance with this contract, and at the completion of such work shall remove all rubbish from and about the site of the work, and shall leave the work in its immediate vicinity "broom clean", unless more exactly specified by the Supervisor.

(End of Text)

C-215-H002 CONTRACTOR PROPOSAL (NAVSEA) (OCT 2018)

(a) Performance of this contract by the Contractor shall be conducted and performed in accordance with the detailed obligations to which the Contractor committed itself in its proposal in response to SERMC Solicitation

No.N4002719R0012.

(b) The technical volume(s) of the Contractor's proposal is(are) hereby incorporated by reference and made subject to the "Order of Precedence" (FAR 52.215-8) clause of this contract. Under the "Order of Precedence" clause, the technical volume(s) of the Contractor's proposal referenced herein is (are) hereby designated as item (f) of the clause, following

"the specifications" in the order of precedence.

C-217-H001 PROVISIONED ITEMS ORDERS--BASIC (NAVSEA) (OCT 2018)

(a) General. The Contractor agrees that it will furnish the supplies or services ordered by the Government in accordance with the procedures specified herein. Orders will be placed by the Contracting Officer, Provisioning

Activity or Administrative Contracting Officer as unilateral or bilateral modifications to this contract on SF 30, Amendment of Solicitation/Modification of Contract. Any amounts shown in Section B at time of award of the initial contract for each provisioned line item are estimated amounts only and are subject to upward or downward adjustment by the issuing activity. If no amounts are shown, funding will be obligated before or at time of order issuance. It is understood and agreed that the Government has no obligation under this contract to issue any orders hereunder.

(b) Priced Orders. For each proposed order, the Contractor agrees that it will submit such cost or pricing data as the

Contracting Officer may require. Promptly thereafter, the Contractor and the Contracting Officer shall negotiate the price and delivery schedule for the proposed order. Upon execution and receipt of the priced order, the Contractor shall promptly commence the work specified in the order.

(c) Undefinitized Orders. Whenever the Contracting Officer determines that urgent demands or requirements prevent the issuance of a priced order, he/she may issue an unpriced order. Such order may be unilateral or bilateral and shall establish a limitation of Government liability, a maximum ceiling amount, and a schedule for definitization, as described in subparagraph (e)(2) below. Upon request the Contractor shall submit a maximum ceiling amount proposal before the undefinitized order is issued. The maximum ceiling amount is the maximum price at which the order may be definitized. The Contractor shall begin performing the undefinitized order upon receipt, except as provided in paragraph (d) below. The clause entitled "Contract Definitization" (DFARS 252.217-

7027) shall be included in any undefinitized order.

(d) Rejection of Unilateral Orders. The Contractor may reject any unilateral order if the Contractor determines that it cannot feasibly perform the order, or if the Contractor does not concur with the maximum ceiling amount.

However, each unilateral order shall be deemed to have been accepted by the Contractor unless within fifteen days of issuance of the order, the Contractor notifies the Contracting Officer in writing of its rejection of the order.

(e) Definitization of Undefinitized Orders. (1) The Contractor agrees that following the issuance of an undefinitized order, it will promptly begin negotiating with the Contracting Officer the price and terms of a definitive order that will include: (A) all clauses required by regulation on the date of the order; (B) all clauses required by law on the date of execution of the definitive order; and, (C) any other mutually agreeable clauses, terms and conditions. No later than sixty (60) days after the undefinitized order is issued, the Contractor agrees to submit a cost proposal with sufficient data to support the accuracy and derivation of its price; and, when required by FAR, cost or pricing data. If additional cost information is available prior to the conclusion of negotiations, the Contractor shall provide that information to the Contracting Officer. The price agreed upon shall be set forth in a bilateral modification to the order. In no event shall the price exceed the maximum ceiling amount specified in the undefinitized order.

(2) Each undefinitized order shall contain a schedule for definitization which shall include a target date for definitization and dates for submission of a qualifying proposal, beginning of negotiations and, if appropriate, submission of make-or-buy and subcontracting plans and cost or pricing data. Submission of a qualifying proposal in accordance with the definitization schedule is a material element of the order. The schedule shall provide for definitization of the order by the earlier of:

(i) a specified target date which is not more than 180 days after the issuance of the undefinitized order.

However, that target date may be extended by the Contracting Officer for up to 180 days after the Contractor submits a qualifying proposal as defined in DFARS 217.7401; or

(ii) the date on which the amount of funds expended by the Contractor under the undefinitized order exceed fifty percent (50%) of the order's maximum ceiling amount, except as provided in subparagraph (f)(3) below.

(3) If agreement on a definitive order is not reached within the time provided pursuant to subparagraph

(e)(2) above, the Contracting Officer may, with the approval of the Head of the Contracting Activity, determine a reasonable price in accordance with Subpart 15.4 and Part 31 of the FAR, and issue a unilateral order subject to

Contractor appeal as provided in the "Disputes" clause (FAR 52.233-1). In any event, the Contractor shall proceed with completion of the order, subject to the "Limitation of Government Liability" clause (FAR 52.216-24).

(f) Limitation of Government Liability. (1) Each undefinitized order shall set forth the limitation of Government liability, which shall be the maximum amount that the Government will be obligated to pay the Contractor for performance of the order until the order is definitized. The Contractor is not authorized to make expenditures or incur obligations exceeding the limitation of Government liability set forth in the order. If such expenditures are made, or if such obligations are incurred, they will be at the Contractor's sole risk and expense. Further, the limitation of Government liability shall be the maximum Government liability if the order is terminated. The

"Limitation of Government Liability" clause shall be included in any undefinitized order.

(2) Except for undefinitized orders for Foreign Military Sales; purchases of less than $25,000; special access programs; and Congressionally-mandated long-lead procurements; and except as otherwise provided in subparagraph (f)(3) below, the limitation of Government liability shall not exceed fifty percent (50%) of the ceiling amount of an undefinitized order. In the case of orders within these excepted categories, however, the procedures set forth herein shall be followed to the maximum extent practical.

(3) If the Contractor submits a qualifying proposal (as defined in DFARS 217.7401) to definitize an order before the Government has obligated fifty percent (50%) of the ceiling amount, the Contracting Officer may increase the limitation of Government liability to up to seventy-five percent (75%) of the maximum ceiling amount or up to seventy-five percent (75%) of the price proposed by the Contractor, whichever is less.

(4) If at any time the Contractor believes that its expenditure under an undefinitized order will exceed the limitation of Government liability, the Contractor shall so notify the Contracting Officer, in writing, and propose an appropriate increase in the limitation of Government liability of such order. Within thirty (30) days of such notice, the Contracting Officer will either (i) notify the Contractor in writing of such appropriate increase, or (ii) instruct the

Contractor how and to what extent the work shall be continued; provided, however, that in no event shall the

Contractor be obligated to proceed with work on an undefinitized order beyond the point where its costs incurred plus a reasonable profit thereon exceed the limitation of Government liability, and provided also that in no event shall the Government be obligated to pay the Contractor any amount in excess of the limitation of Government liability specified in any such order prior to establishment of firm prices.

(g) Initial Spares.