Amendment for N3904020Q0073 Titan Boring Mills CNC Machines Repair - KO APPROVED.pdf

N3904020RC00128

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

This amendment w as issued to include the Wage Determination Rate for this requirement.

POC: Sheena Sellers sheena.m.sellers@navy.mil 207-438-4379

1. CONTRACT ID CODE PAGE OF PAGES

J 1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 13-Feb-2020

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N3904020Q0073

X 9B. DATED (SEE ITEM 11)

13-Feb-2020

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

13-Feb-2020

CODE

PORTSMOUTH NAVAL SHIPYARD

CONTRACTING DIVISION, CODE 410

BLDG 156, PNS

KITTERY ME 03904

N39040 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N3904020Q0073

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 1449 - CONTINUATION SHEET

The following have been added by full text:

WAGE RATE DETERMINATION

Wage Rate Determination No.: 2015-4012, Rev. 3 issued on 12/23/2019.

The following have been modified:

C-237-H001 ENTERPRISE-WIDE CONTRACTOR MANPOWER REPORTING APPLICATION

(NAVSEA) (OCT 2018)

(a) The contractor shall report contractor labor hours (including subcontractor labor hours) required for performance of services provided under this contract for the Titan Boring Mills CNC Machines Repair at Portsmouth Naval Shipyard via a secure data collection site. Contracted services excluded from reporting are based on Product Service Codes (PSCs). The excluded PSCs are:

(1) W, Lease/Rental of Equipment;

(2) X, Lease/Rental of Facilities;

(3) Y, Construction of Structures and Facilities; (4) D, Automatic Data Processing and Telecommunications, IT and Telecom- Telecommunications Transmission (D304) and Internet (D322) ONLY;

(5) S, Utilities ONLY;

(6) V, Freight and Shipping ONLY.

(b) The contractor is required to completely fill in all required data fields using the following web address https://www.ecmra.mil.

(c) Reporting inputs will be for the labor executed during the period of performance during each Government fiscal year (FY), which runs October 1 through September 30. While inputs may be reported any time during the FY, all data shall be reported no later than October 31 of each calendar year. Contractors may direct questions to the help desk, linked at https://dod.ecmra.support.desk@mail.mil.

(End of text)

G-242-H002 HOURS OF OPERATION AND HOLIDAY SCHEDULE (NAVSEA) (OCT 2018)

(a) The policy of this activity is to schedule periods of reduced operations or shutdown during holiday periods.

Deliveries will not be accepted on Saturdays, Sundays or Holidays except as specifically requested by the [insert activity name]. All goods or services attempted to be delivered on a Saturday, Sunday or Holiday without specific instructions from the Contracting Officer or his duly appointed representative will be returned to the contractor at the contractor’s expense with no cost or liability to the U.S. Government.

(b) The federal Government observes the following holidays:

HOLIDAYS*

New Year's Day Martin Luther King's Birthday Presidential Inauguration Day (Washington DC metro area only) President's Day Memorial Day Independence Day Labor Day Columbus Day Veteran's Day Thanksgiving Day Christmas Day

* Except for the Presidential Inauguration Day, if the actual date falls on a Saturday, the holiday will be observed the preceding Friday. If the holiday falls on a Sunday, the observance shall be on the following Monday.

The actual date of observance for each of the above holidays, for a specific calendar year, may be obtained from the OPM website at OPM.GOV or by using the following direct link: https://www.opm.gov/policy-data-oversight/snow-dismissal-procedures/federal-holidays/#url.

(c) Delayed Opening, Early Dismissal and Closure of Government Facilities. When a Government facility has a delayed opening, is closed or Federal employees are dismissed early (due to severe weather, security threat, security exercise, or a facility related problem) that prevents personnel from working, onsite contractor personnel regularly assigned to work at that facility shall follow the same reporting and/or departure directions given to Government personnel. The contractor shall not direct charge to the contract for such time off, but shall follow parent company policies regarding taking leave (administrative or other). Non-essential contractor personnel, who are not required to remain at or report to the facility, shall follow their parent company policy regarding whether they should go/stay home or report to another company facility. Subsequent to an early dismissal, delayed opening, or during periods of inclement weather, onsite contractors should monitor the OPM website as well as radio and television announcements before departing for work to determine if the facility is closed or operating on a delayed arrival basis.

(d) When Federal employees are excused from work due to a holiday or a special event (that is unrelated to severe weather, a security threat, or a facility related problem), on site contractors shall continue working established work hours or take leave in accordance with parent company policy. Those contractor employees who take leave shall not direct charge the non-working hours to the contract. Contractors are responsible for predetermining and disclosing their charging practices for early dismissal, delayed openings, or closings in accordance with the FAR, applicable cost accounting standards, and the company’s established policy and procedures. Contractors shall follow their disclosed charging practices during the contract period of performance, and shall not follow any verbal directions to the contrary. The Contracting Officer will make the determination of cost allowability for time lost due to facility closure in accordance with FAR, applicable Cost Accounting Standards, and the Contractor's established accounting policy and procedures.

(e) If you intend to visit the Contracts Office, it is advised that you call for an appointment at least 24 hours in advance.

(f) The hours of operation are as follows:

(g) All deliveries to the Receiving Officer, Portsmouth Naval Shipyard [Negotiator insert delivery location], shall be made Monday through Friday from 7 a.m. - 2:30 p.m. local time. Deliveries will not be accepted after 2:30 p.m. No deliveries will be accepted on federal government holidays.

G-242-W001 CONTRACT ADMINISTRATION FUNCTIONS (NAVSEA) (OCT 2018)

(a) In accordance with FAR 42.302(a) all functions listed are delegated to the ACO except the following items to be retained by the PCO:

Any additional contract administration functions not listed in 42.302 (a) and (b), or not otherwise delegated, remain the responsibility of the contracting office.

(End of Summary of Changes)