Amendment 0006.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Amendment 0006 for the USNS ZEUS ROH/DD to provide the follow ing:

(1) Change the period of performance to 01 February 2024 through 05 June 2024.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 14

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 20-Oct-2023

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X N3220523R4221

X 9B. DATED (SEE ITEM 11)

07-Jul-2023

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

20-Oct-2023

CODE

MILITARY SEALIFT COMMAND NORFOLK

471 EAST C STREET, BLDG SP-64 NAVAL STATION N

NORFOLK VA 23511

N32205 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N3220523R4221

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION C - DESCRIPTIONS AND SPECIFICATIONS

The following have been modified:

ACRONYM TABLE

ABIH American Board of Industrial Hygiene ABR Agreement for Boat Repair ABS American Bureau of Shipping ACO Administrative Contracting Officer AGR Additional Government Requirements AIHA American Industrial Hygiene Association ALT Alternate AMT Amount BLDG Building CCO Contract Change Order CD Compact Disc CDRL Contract Data Requirements List CD-ROM Compact Disc Read-Only Memory CFM Contractor Furnished Material CFP Contractor Furnished Property CFR Condition Found Report CHENG Chief Engineer CFR Code of Federal Regulations CIH Certified Industrial Hygienist CLIN Contract Line Item Number

CONUS

CPARS

Contiguous United States Contractor Performance Assessment Reporting System

DBIDS Defense Biometric Identification Systems DFARS Defense Federal Acquisition Regulation Supplement DOD Department of Defense DOD SAFE Department of Defense Secure Access File Exchange DON Department of the Navy EMAIL Electronic Mail ESRS Electronic Subcontract Report System FAPIIS Federal Awardee Performance and Integrity Information System FAR Federal Acquisition Regulation FBLR Fully-Burdened Labor Rate F/CC Fibers Per Cubic Centimeter FPCON Force Protection Condition FTR Federal Travel Regulations G&A General and Administrative GFI-TD Government Furnished Information – Technical Data GFM Government Furnished Material GFP Government Furnished Property GPE Governmentwide Point of Entry IAW In Accordance With ID Identification

ISO International Organization for Standardization JTR Joint Travel Regulations KO Contracting Officer KWh Kilowatt Hour LLTM Long Lead Time Material LPTA Lowest Price Technically Acceptable M&IE Meals and Incidental Expenses MSC Military Sealift Command MSCREP Military Sealift Command Representative MM Millimeter MSRA Master Ship Repair Agreement MTA Mid-Term Availability N/A Not Applicable NCACS Navy Commercial Access Control System NDA Non-Disclosure Agreement NO Number NSP Not Separately Priced ODC Other Direct Costs PAT Proficiency in Analytical Testing

PDF

PII

Portable Document Format Personally Identifiable Information

PM Program Manager PPE Principle Port Engineer PRIME Prime Contractor QA Quality Assurance QC Quality Control REV Revision RFC Request for Specification Clarification RFP Request for Proposal ROH/DD Regular Overhaul/Dry-Docking SECNAV Secretary of the Navy SF Standard Form SUB Subcontractor TPSN Time Phased Sequencing Network TWA Time-Weighted Average USC United States Code USCG United States Coast Guard USNS United States Naval Ship VR Voyage Repair WAWF Wide Area Workflow WI Work Item

SCOPE OF WORK

1. The contractor shall prepare for and accomplish the VR, overhaul, or alterations of the USNS ZEUS (T-ARC 7) as specified herein and IAW the WI package as provided in Attachment J-1 – WI Package (Specifications). Unless otherwise specified, all work shall be performed at the contractor’s shipyard.

2. In performing the WIs specified, the contractor shall be responsible for all of the following related work (in case of a discrepancy, the terms and conditions stated in the WIs take precedence over the following terms and conditions):

a. Providing the necessary management, procurement, production, testing, technical capability and resources, and quality assurance services.

b. Ensuring the timely procurement of CFM/CFP and the timely reporting, receipt, storage, installation, and accountability of GFM/GFP IAW FAR 52.245-1 and DFARS 252.211-7007, 252.245-7001, 252.245-7002, 252.245-7003, and 252.245-7004.

c. Using progress measurement systems to determine the physical progress of completed work for each of the elements in the scheduling plan, including material and manpower control, engineering, production, tests and trials IAW the CDRL and the contractor's own Technical Proposal, and the WI package. The progressing system shall permit a direct comparison of the physical progress of completed work to the planned performance measurement baseline for each of the elements in the scheduling plan.

d. Using management procedures and systems to identify behind-schedule conditions and unfavorable schedule variances based on the TPSN submitted with the contractor’s proposal. The applied procedures and systems shall provide timely identification of scheduling problem areas to permit prompt management action to correct unsatisfactory conditions.

e. Developing a performance milestone schedule/critical path chart to measure scheduled performance.

Deviations from the milestone schedule/critical path chart dates in WI 0013 must be submitted to and approved by the KO. A performance milestone schedule and critical path chart shall be developed and submitted IAW the WI Package. The performance milestone schedule shall include and clearly identify primary and parallel critical paths.

The resource loaded performance milestone schedule shall include, at a minimum, those milestones identified in WI 0013.

f. Using approved quality control procedures as required by this contract and the WI package to ensure procured material and performed production work conforms to the required quality standards.

g. Ensuring the ship's equipment and systems remain configured to existing baselines with regard to procured material, production work, and software.

h. Applying stringent configuration control procedures to ensure that configuration baselines are maintained for procured material and production work.

i. Providing for staging and storing of material (both Government-furnished and contractor-furnished) and LLTM for use in the availabilities from the date of award.

j. Managing all subcontractors’ performance during the availability. Ensure subcontractor work is to the same quality and standards as expected from the prime contractor. Develop and maintain a subcontractor management plan. The plan shall ensure that all communication and control of subcontractors is maintained by the prime contractor.

k. Employing good judgment and sound engineering practice and principles, particularly when WIs do not describe all details of accomplishing the work. The contractor shall be expected to have, either organically or through subcontractors, access to competent engineers who have a history of working solutions in a maritime environment.

3. Contract work shall be performed by an eligible contractor as defined below.

a. The contractor shall be capable of performing the full scope of the requirement stated herein within its own facilities, utilizing its own shop(s) and work force, or be capable of subcontracting for these elements beyond its managerial, technical, or physical capability or capacity. The contractor shall assume full responsibility for the integrated scheduling, cost, and quality of subcontractor performance.

b. The contractor shall be a company recognized as engaged in ship repair work and possess an organization capable of the full scope of planning, engineering, quality control, shipboard/offship production and component/system testing and trials. The contractor shall provide industry certifications such as: MSRA, ABR, or ISO Certification that would further emphasize the contractor's ability to perform the work. To be determined responsible, the contractor shall submit acceptable evidence to demonstrate its ability to accomplish the work. This will include a conclusive demonstration of having the necessary organization, experience, accounting and operational controls, and technical skills, or the ability to obtain them (including, as appropriate, such elements as production control procedures, property control systems, quality assurance measures, and safety programs applicable to materials to be produced or services to be performed by the prospective contractor and/or subcontractors) at the time of award. The contractor’s proposal shall provide a documented and positive demonstration of established organizational elements as set forth below. These characteristics will be evaluated to determine a firm's eligibility for contract award:

1) Administration/Management Control. Established organization geared toward ship repair at all levels of size, value, and complexity, and toward technology innovation and process improvement. Clear lines of authority.

Delegation of responsibility. Mid-level managerial positions in place. Competent and experienced employees with ship repair experience. Capability to develop and integrate planning, estimating, and scheduling functions. Defined managerial responsibilities for production, quality assurance, material procurement/control, and subcontractor control.

2) Financial Control. Segregation of accounting costs. Adequate accounting system. Favorable cash flow-ratios. Availability of a line of credit or other source of financial income to support the work effort. Prompt payment of subcontractors and suppliers.

3) Production Control. A production organization. On board (or ability to obtain) trade mix/skills to perform ship repair work. Control of production efforts. Integration of other key functions with production. Use of scheduling techniques. Methods of progressing. Training available to trades employees.

4) Production Technical Support. Engineering and design support capabilities (in-house or subcontracted) with sufficient capability to diagnose and evaluate technical problems and issues and to make competent technical recommendations to MSC when necessary and appropriate. The offeror shall be fully cognizant of ABS rules and USCG regulations and how they apply and impact this specification package.

5) Material/Procurement Control. A material purchasing department with staff. Procedures for control of material (purchasing, monitoring, receipt, inspection, segregation, issuance, nonconformance, and disposal). An inventory system – ordering, tagging warehousing. CFM/GFM storage, control and protection. Existing environmentally-controlled warehouse space. Material handling equipment. Familiarity with the Navy logistics support system.

6) Subcontractor Control. Procedures for selecting, scheduling, managing, monitoring and controlling subcontractors.

7) Quality Control/Test and Trials. A quality control organization/department/staff. Quality assurance procedures/manual. Calibration and metrology system availability. Test memo writing capability. Nondestructive Testing capabilities. Welding procedures and welders’ qualifications. Ability to perform trend analysis. Quality control system shall be certified or equivalent to ISO 9001:2001 standards.

8) Safety/Security. Safety Organization/Manager or Engineer. Safety manual/procedures. Safety training.

First-aid capabilities or medical services. Fire protection/procedures. Physical yard security/security procedures.

9) Hazardous Material/Waste Control. Proper procedures and facilities to meet the legal requirements for removal, storage, and disposal of hazardous waste. Segregated storage. Documentation of licensed subcontractors responsible for control of hazardous waste removal, storage, and disposal. Appropriate state/federal agency-issued hazardous waste generator number. Disposal records which indicate type of material, date, and place of disposal.

10) Facilities. Although facility requirements may vary with the work authorized for a specific ship, the contractor must be a ship repair company that possesses or has available the following facilities:

o Pier, with services in place, accessible to the CLASS size ship for berthing o Structural Shop o Machine Shop o Pipe Shop o Electrical/Electronic Shop o Carpentry Shop o Rigging Equipment o Dry-dock – when required for docking of vessel in performance of the specification

11) Agreements. To be determined responsible, a prospective contractor must possess an MSRA, ABR or submit acceptable evidence in lieu of the aforementioned to effectively communicate and demonstrate its ability to obtain required resources.

c. The government reserves the right to perform a site survey(s) for verification of policies, procedures, capabilities and facilities prior to award.

4. Asbestos removal requirements.

a. During the performance of this contract the contractor and subcontractors may be required to perform work which involves the removal or disturbance of asbestos or asbestos-containing products. This requirement applies to each instance of asbestos removal or disturbance.

b. The contractor shall comply with the precautions required in 29 CFR 1910.1001, 29 CFR 1926.58 and 40 CFR Part 61 and all other applicable Federal, state, and local restrictions. The contractor shall forward a copy of all required notices, licenses and permits to the KO immediately upon issuance or receipt.

c. The latest change to the Federal, state, and local regulations in effect at the time of issuance of the contract shall govern. Compliance with these regulations is mandatory and is necessary to protect the employees of the contractor and Naval personnel from exposure to asbestos fibers in excess of the OSHA Action level airborne concentration (currently 0.1 f/cc of air).

d. During removal or disturbance, the contractor shall control airborne asbestos concentrations outside the removal boundary to less than 0.1 f/cc at all times.

e. After removal or disturbance is complete, the areas within the removal boundary shall not be released for re-occupancy until clearance air sampling demonstrates these spaces have concentrations of asbestos less than 0.1 f/cc.

f. In all respects, the performance of air sampling and analysis shall be performed IAW the OSHA Reference Method (Appendix A of 29 CFR 1910.1001), with the following additional specifications:

1) Aggressive clearance sampling shall be performed on 25 mm cassettes at 2.0 liters per minute for a minimum of four (4) hours.

2) In performing the clearance sampling, the pump shall be placed within the compartment where the removal or disturbance occurred. When this operation is conducted in a multilevel space, at least one pump shall be placed on each level.

3) Air sampling shall be performed by a person competent in sampling procedures and overseen by a CIH by the ABIH.

4) Laboratory analysis of samples shall be performed by a participant in the AIHA PAT Program rated proficient for asbestos and air.

g. Personal sampling shall be conducted using breathing zone air samples which are representative of the 8-hour TWA exposure of each individual. Samples shall be collected and analyzed using the OSHA Reference Method contained in either 29 CFR 1910.1001 (as amended) or 29 CFR 1926.58 (as amended).

h. The contractor agrees to indemnify MSC for any fines assessed by Federal, state, or local agencies, for the contractor's failure to properly follow applicable regulations.

i. The contractor shall insert this instruction in all subcontracts entered into under this contract.

5. Post-award substitution of any major subcontractor should not be effected unless the proposed substitution is submitted to the KO and official approval is obtained. The post-award substitution or insertion of a second-tier subcontractor will be treated in the same manner as the substitution of a major subcontractor and requires specific approval by the KO.

6. Substitution of key personnel.

a. The contractor agrees to assign to this contract those persons identified as key personnel who are necessary to fulfill the requirements of this contract and whose resumes were submitted with the proposal. No substitution of key personnel shall be made except IAW these instructions.

b. All proposed substitutions must be submitted, in writing, at least seven (7) days in advance of the proposed substitutions to the KO and must provide the information required by paragraph “c” below.

c. All requests for substitution must provide a detailed explanation of the circumstances necessitating the proposed substitution, a resume for the proposed substitute, and any other information as requested by the KO. All proposed substitutes must have qualifications equal to or higher than the qualifications of the person to be replaced.

The KO or his authorized representative will evaluate such requests and promptly notify the contractor of the approval or disapproval thereof.

7. It is anticipated the ship will arrive at the contractor’s yard on or about 1 February, 2024. All work shall be completed in no more than 125 calendar days from the actual start date designated by the Government at the time of contract award.

8. The place of performance for this contract shall be the contractor’s facility. Due to operational and national security availability considerations, the location shall be the East Coast}.

9. This award consummates the contract, which consists of the following documents: (a) the Government’s solicitation and your final proposal revision submitted on {date} inclusive of all discussion and clarification responses and (b) this award/contract.

Table 1: List of WIs:

WORK

ITEM

ITEM NAME CAT

000- GENERAL REQUIREMENTS

0001 TARC7-SWI-SCOPE GENERAL REQUIREMENTS AND DEFINITIONS NSP

0002 TARC7-SWI-TECHNICAL AND MANUFACTURERS REPRESENTATIVE NSP

0003 TARC7_APPROACH BERTHING AND MOORING REQUIREMENTS NSP

0004 TARC7_TESTING AND QUALITY ASSURANCE NSP

0005 TARC7-SWI-ELECTRICAL SAFETY PROCEDURE REQUIREMENTS NSP

0006 TARC7_HEAVY WEATHER PLAN NSP

0007 TARC7_COLD WEATHER PLAN NSP

0010 FURNISH OFFICE FOR OVERHAUL MANAGEMENT TEAM (OMT) A

0011 TARC7-SWI-GENERAL SERVICES FOR SHIP A

0012 TARC7-SWI-INFORMATION TECHNOLOGY SERVICES A

TARC7_SWI_INTEGRATED PROJECT PLANNING AND PRODUCTION STATUS

MONITORING

A

0014 TARC7-SWI-WEIGHT AND MOMENT REPORT A

0015 TARC7-SWI-ILS GFM A

0016 TARC7-SWI-FIRE PROTECTION AND SHIPS SAFETY PROGRAM A

0017 TARC7-SWI-HANDLING SHIPS STORES A

0018 TARC7-SWI-DELIVERY AND REDELIVERY OF THE VESSEL A

0019 TARC7_SHIPBOARD ACCESS AND SECURITY A

0020 TARC7-SWI-GAS FREE CERTIFICATES A

0021 TARC7_CLEAN AND GAS FREE TANKS, VOIDS, COFFERDAMS AND SPACES A

TARC7-SWI-MACHINERY SPACE TURN-OVER, DOCK TRIALS AND SEA

TRIALS

A

TARC7-SWI-HAZARDOUS WASTE DISPOSAL AT A CONTRACTOR'S

FACILITY

A

0024 TARC7-SWI-PHYSICAL SECURITY AT PRIVATE CONTRACTOR'S FACILITY NSP

0025 PHYSICAL SECURITY AT PRIVATECONTRACTOR FACILITY B

0030 TARC7-SWI-CONTINUATION OF SERVICES B

0035 FURNISH OFFICE FOR SPONSOR PERSONNEL A

100- HULL AND STRUCTURAL

0101 FWD GANTRY PRESERVATION A

0104 SUPERSTRUCTURE PRESERVATION A

0105 INSPECT AND CLEAN BILGES (1 YR) A

0106 PREPARE, PRIME, PAINT ENGINE ROOM BILGE SECTIONS A

0109 RADAR MAST REPAIRS AND PRESERVATION A

0111 NON-SLIP RENEWAL (2.5YR) A

0112 STEEL REPAIRS A

0113 BULWARK STEEL REPLACEMENT AND OUTRIGGER REMOVAL A

0116 BUOY SKID REPAIRS AND REFURBISHMENT A

0117 HOS FOUNDATION PEDESTAL RENEWAL A

0151 TARC7_CCSI_ULTRASONIC THICKNESS GAUGING (5 YR) A

0154 TARC7_CCSI_ABS SPECIAL SURVEY - TANK INSPECTION (5 YR) A

0155 TARC7_CCSI_TANK VENT INSPECTION (5 YR) A

0157 TARC7_CSI_POTABLE WATER TANK PRESERVATION (10 YR) A

0158 TARC7_CSI_SW BALLAST TANK PRESERVATION (7.5 YR) A

0162 TARC7_CCSI_WATERTIGHT CLOSURE INSPECTION (5 YR) A

0163 FWD AND AFT CABLE DECK DOOR REFURB (2) A

0164 REFURBISH WEATHER TIGHT DOOR 1-19-2 and 1-19-3 A

0165 SIDEPORT DOOR REPAIRS A

TARC7_CSI_FEEDWATER AND FRESHWATER TANK PRESERVATION (10

YR)

A

0171 TARC7_CSI_WASTE WATER SLUDGE TANK PRESERVATION (7.5) A

0172 TARC7_CSI_SEWAGE TANK PRESERVATION (5 YR) A

200- PROPULSION MACHINERY

0201 TARC7_CSI_PROPULSION MOTOR COOLING SYSTEM (2.5 A

0203 TARC7 LUBE OIL COOLERS A

TARC7_CSI_AUTOMATION AND PROPULSION CONTROL SYSTEM

INSPECTION AND TEST (1 YR) (SCSI)

A

TARC7_CSI_PROPULSION MOTOR INSPECTION AND CLEANING (1 YR)

(SCSI)

A

0209 TARC7 _MAIN DIESEL ENGINE SERVICE (8K HRS) (SCSI) A

0251 TARC7 CCSI WOODWARD GOVERNORS (20K HRS) (SCSI) A

0254 TARC7_CCSI_THRUST AND LINESHAFT BEARING INSPECTION (5 YR) A

300- ELECTRICAL

0302 TARC7_CSI_MOTOR GENERATOR CLEANING (5 YR) A

TARC7_CSI_BOW AND STERN THRUSTER MOTOR INSPECTION AND

CLEANING (1YR)

A

0306 TARC7_CSI_UPS SERVICE (2.5 YR) A

0353 TARC7_CCSI_THERMOGRAPHIC SURVEY (1 YR) A

0354 TARC7_CSI_GENERATOR CLEANING AND INSPECTION (5 A

0355 TARC7_CSI_CIRCUIT BREAKER INSPECTION AND SERVICING (10 YR) A

400- COMMUNICATION AND NAVIGATION

0402 TARC7_CSI_TVDTS SERVICE (1 YR) A

TARC7_CSI_SHIP CONTROL CONSOLE (SCC) SYSTEM PREVENTATIVE

MAINTENANCE (2.5 YR)

A

0404 TLI REPAIRS A

0451 TARC7_CCSI_ANNUAL RADAR SERVICE A

0452 TARC7_CCSI_ANNUAL ECDIS SERVICE (SCSI) A

0453 TARC7_CCSI_ANNUAL GYRO SYSTEM PM A

TARC7_CCSI_ANNUAL RADIO COMMUNICATION EQUIPMENT

RECERTIFICATION

A

0456 TARC7_CCSI_MAGNETIC COMPASS SERVICE (2 YR) A

0457 TARC7_CCSI_EPIRB SHORE BASED MAINTENANCE SERVICE A

0458 TARC7_CCSI_ANTENNA MAINTENANCE (5 YR) A

0459 TARC7_CCSI_ECHO SOUNDER SERVICE (2.5 YR) A

0460 TARC7_CCSI_ANNUAL INSPECTION OF MANUALLY OPERATED ALARMS A

500- AUXILIARY MACHINERY

0503 FIRE ALARM ANNUAL INSPECTIONS A

0504 AUXILIARY BOILER RETUBE A

0505 TARC7_CSI_STEERING SYSTEM INSPECTION AND SERVICE (2.5 YR) A

TARC7_CSI_INSPECT AND CLEAN MISCELLANEOUS HEAT EXCHANGERS (1

YR)

A

0507 FLEX HOSE REPLACEMENT – ALL 5 SSDGS A

0509 TARC7_CSI_FUEL OIL PURIFIER SERVICE (2.5 YR) A

0510 TARC7_CSI_LUBE OIL PURIFIER SERVICE (2.5 YR) A

TARC7_CSI_EMERGENCY DIESEL GENERATOR ENGINE TOP END

OVERHAUL (10 YR)

A

0513 TARC7_CSI_REFRIGERATION SYSTEM REPAIRS A

0514 TARC7_CSI_AIR CONDITIONING SYSTEM REPAIRS A

0515 COMMS CENTER AIR CONDITIONING INSTALLATION A

0516 TARC7_CSI_MISCELLANEOUS CENTRIGUAL PUMP OVERHAULS A

0517 TARC7_CSI_DISTILLING PLANT SERVICE (2.5 YR) A

0518 TARC7_CSI_ANCHOR WINDLASS SERVICE (5 YR) A

0519 TARC7_CSI_SALT WATER SERVICE SYSTEM CLEANING (5 A

0523 TARC7_CSI_INCINERATOR SERVICE (1 YR) A

0524 TARC7_CSI_AUXILIARY BOILER SERVICE (2.5YR) A

0530 HOS OVERHAUL AND PRESERVATION A

0531 HOS PUMP OVERHAUL A

0551 TARC7_CSI_HYDRAULIC HOSE REPLACEMENT (2.5 YR) A

TARC7_CCSI_INSPECT TEST AND CERTIFY MACHINERY SPACE CRANES

AND HOISTS (5 YR)

A

0557 TARC7_CCSI_INSPECT TEST AND CERTIFY DECK CRANES A

0561 TARC7_CCSI_GAUGE CALIBRATION (1YR) A

0562 TARC7_CCSI_SCBA ANNUAL INSPECTION (INTESPIRO) A

TARC7_CCSI_SCBA COMPRESSOR AND FILLING STATION INSPECTION

AND MAINTENANCE (1 YR)

A

0565 TARC7_CCSI_FIXED GAS FIRE EXTINGUISHING SYSTEM (1 A

0570 PORTABLE EXTINGUISHER TEST AND INSPECT A

0576 STERN VERTICAL & HORIZONTAL ROLLER A

0577 BOW & STERN FAIRING A

0578 PORT FWD CABLE DRUM PRESERVATION A

0579 FWD & AFT CABLE HANDLING SYSTEMS A

0590 SPARE SIMS AC COOLING PUMP REPAIRS A

600- HABITABILITY OUTFITTING AND FURNISHINGS

0601 ANNUAL ACOMM LADDER INSPECTION A

0602 0602_A_TARC7_CSI_GALLEY EQUIPMENT SERVICE (2.5 YR) A

0604 ANNUAL FIRE HOSE HYDRO A

0605 CARGO ELEVATOR INSPECTION AND CERTIFICATION A

0607 ANNUAL RESCUE BOAT AND DAVIT INSPECTION A

0608 TARC7_CCSI_ANNUAL LIFERAFT CERTIFICATION A

0613 STATEROOM AND SHOWER STALL REPLACEMENT A

0614 INSULATION INSTALLATION AT DESIGNATED LOCATIONS A

0662 TARC7_CCSI_DEEP FAT FRYER INSPECTION (1 YR) A

700- SPONSOR RELATED

0701 ADCP REFURBISHMENT A

0702 EA640 TRANSDUCER REPLACEMENT A

0703 HIPAP REFURBISHMENT A

0705 ROV WORKSHOP (2-47-2) OVERHAUL A

0706 ACOUSTIC SOURCE TEST CENTER (2-37-2) HABITABILITY IMPROVEMENTS A

0720 REPLACE JOINER SHOP SINK A

0799 SPONSOR CRANE LIFTS AND JLG SUPPORT A

800- HVAC

0804 FAN OVERHAUL S1-39-7 AND E1-45-1 A

0805 FAN ROOM NO 8 (1-39-2) OVERHAUL - REV A A

TARC7_CCSI_GALLEY VENTILATION SYSTEM AND GAYLORD HOOD

CLEANING

A

0852 TARC7_CCSI_LAUNDRY VENT CLEANING (2.5 YR) A

0853 TARC7_CSI_ACCOMMODATION VENT SYSTEM CLEANING A

900- DRYDOCKING

0901 DOCKING AND UNDOCKING A

0902 TARC7_CSI_PROPULSION SHAFT SURVEY (5 YR) A

0903 TARC7_CSI_BOW AND STERN THRUSTER OVERHAUL (5 YR) A

0905 RUDDER AND BILGE KEEL EXAMINATION A

0906 TARC7_CSI_DOPPLER SPEED LOG MAINTENANCE (2.5 YR) A

0909 TARC7_CSI_RENEW WASTER PIECES AND HULL PENETRATIONS A

0911 DRYDOCK EXTENSION B

0913 PROPULSION SHAFT BEARING REPLACEMENT B

0953 TARC7_CCSI_ANCHORS CHAINS AND LOCKERS (5YR) A

0955 TARC7_CCSI_STERN TUBE SEAL ASSEMBLY (5 YR) (SCSI) A

0956 TARC7_CCSI_OVERHAULING SEA VALVES (5 YR) A

0957 TARC7_CCSI_PROPELLER CLEAN AND POLISH - ON DOCK A

TARC7_CCSI_UNDERWATER HULL CLEANING AND PAINTING NEAR

WHITE BLAST

0960 SEA CHEST AND STRAINER PLATES A

0961 TARC7_CCSI_FREEBOARD PRESERVATION (2.5YR) A

0962 TARC7_CCSI_CATHODIC PROTECTION SYSTEM (2.5 YR) A

TARC7_CCSI_SHAFT ALIGNMENT AND BEARING REACTION CHECKS (2.5

YR)

A

TARC7_CCSI_SHAFT ALIGNMENT AND BEARING REACTION CHECKS (SETS

3 AND 4)

1000- UNREP / VERTREP (NOT USED)

N/A

SECTION F - DELIVERY AND PERFORMANCE

The following Delivery Schedule item for SUBCLIN 0001AA has been changed from:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

POP 19-JAN-2024 TO

23-MAY-2024

N/A N/A

FOB: Destination

To:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

POP 01-FEB-2024 TO

05-JUN-2024

The following Delivery Schedule item for SUBCLIN 0001AB has been changed from:

CAGE

POP 19-JAN-2024 TO

23-MAY-2024

CAGE

POP 01-FEB-2024 TO

05-JUN-2024

The following Delivery Schedule item for SUBCLIN 0002AA has been changed from:

CAGE

POP 19-JAN-2024 TO

23-MAY-2024

CAGE

POP 01-FEB-2024 TO

05-JUN-2024

The following Delivery Schedule item for SUBCLIN 0002AB has been changed from:

CAGE

POP 19-JAN-2024 TO

23-MAY-2024

CAGE

POP 01-FEB-2024 TO

05-JUN-2024

The following Delivery Schedule item for CLIN 0003 has been changed from:

CAGE

POP 19-JAN-2024 TO

23-MAY-2024

CAGE

POP 01-FEB-2024 TO

05-JUN-2024

The following Delivery Schedule item for CLIN 0004 has been changed from:

CAGE

POP 19-JAN-2023 TO

23-MAY-2024

CAGE

POP 01-FEB-2023 TO

05-JUN-2024

The following Delivery Schedule item for CLIN 0007 has been changed from:

CAGE

POP 19-JAN-2024 TO

23-MAY-2024

CAGE

POP 01-FEB-2024 TO

05-JUN-2024

The following Delivery Schedule item for CLIN 0008 has been changed from:

CAGE

POP 19-JAN-2024 TO

23-MAY-2024

CAGE

POP 01-FEB-2024 TO

05-JUN-2024

(End of Summary of Changes)