N0018925Q00250001 Solicitation Amendment.pdf

1301215848

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to revise the PWS to eliminate the reference to required travel. If travel is necessary for contract performance, the Contractor must incorporate all associated pricing directly into the labor CLIN for each presentation. Additionally, the relevant Q&A response regarding travel has been updated to reflect this change. Please note that there w ill be no additional Q&A period for this solicitation extension.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 11

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 29-Jan-2025

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X N0018925Q0025

X 9B. DATED (SEE ITEM 11)

14-Jan-2025

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

29-Jan-2025

CODE

NAVSUP FLC NORFOLK CONTRACTING

NORFOLK OFFICE

ATTN: A BRADLEY

1968 GILBERT STREET STE600

NORFOLK VA 23511

N00189 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N0018925Q0025

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 1449 - CONTINUATION SHEET

SOLICITATION/CONTRACT FORM

The required response date/time has changed from 23-Jan-2025 11:00 AM to 04-Feb-2025 10:00 AM.

The following have been modified:

PWS

PERFORMANCE WORK STATEMENT FOR

SUICIDE PREVENTION PRESENTATIONS AND OFFICE HOURS

1. INTRODUCTION:

The purpose of this requirement is to support the Surface Warfare Schools Command (SWSC) in developing shipboard leaders by providing specialized suicide prevention training.

2. BACKGROUND:

SWSC mission is to ready sea-bound warriors to serve on surface combatants as officers, enlisted engineers, and enlisted navigation professionals in order to fulfill the Navy's mission to maintain global maritime superiority.

3. SCOPE:

3.1 The period of performance for the contract will be a 12-month base period, with three (3) twelve-month option periods.

3.2 The Contractor shall provide three (3) presentations for the base period, and four (4) presentations for each option period, on-site in Newport RI, per year, for the SWSC Department Head, Prospective Executive and Commanding Officers and staff.

3.2.1 For each presentation, the Contractor shall conduct one 60-90 minute presentation with follow on office hours (private counseling) of two to three hours focused on suicide prevention and intervention.

3.2.2 The presentation will be taught to approximately 250-300 of personnel per session.

3.3 The presentations shall include:

3.3.1 The presentation shall help Senior Naval Officers with the knowledge and skills to proactively navigate stress, support one another and respond appropriately in the event of a crisis. Educate Senior Officers on suicide risk factors, warning signs and how to intervene appropriately; promote actions to strengthen protective factors, practice self-care and foster supportive command climates, lethal means safety, post-vention and resources available for support. Proactive planning for crisis intervention, addressing the process for identification, referral, access to treatment and follow-up procedures for personnel who are at imminent risk of suicide. Timely and appropriate support for Sailors experiencing a psychological health or suicidal crisis, as well as those affected by suicide (including junior Sailors and families).

3.4 The Contractor shall provide personnel who are qualified, to present to large groups of Senior Naval Officers and trained to current suicide prevention methods processes following accepted industry best practices and methodologies.

4. PERIOD OF PERFORMANCE:

4.1 The Contractor shall provide a single presentation during each month as stated within the contract period detailed below, annually. The Contractor will coordinate with SWSC N73 Director for specific timing of individual workshops within the periods specified. The convenings of the Department Head course of instruction govern the schedule. The following are the anticipated dates for each presentation relative to the period of performance:

Base Period: May, July, September 2025.

Option Period 1: January, May, July, September 2026.

Option Period 2: January, May, July, September 2027.

Option Period 3: January, May, July, September 2028.

5. PERSONNEL REQUIREMENTS:

5.1 The contractor shall be responsible for employing technically qualified personnel to perform the work specified in this performance work statement. The contractor shall maintain the personnel, organization, and administrative control necessary to ensure that the work delivered meets the contract specifications and requirements.

5.2 Specific Personnel Qualifications Requirements – The Contractor shall provide personnel who are experienced in presentations to large groups of Senior Naval Officers and current suicide prevention methods processes following accepted industry/DoD best practices and methodologies. Personnel assigned to or utilized by the contractor in the performance of this contract shall, as a minimum, be a United States Citizen, needed for building access, and meet the experience, educational, or other background requirements set forth in the job description below and shall be fully capable of performing in an efficient, reliable, and professional manner.

6. PLACE OF PERFORMANCE:

Surface Warfare Schools Command (SWSC) 446 Cushing Rd Newport, RI 02841

Wage Determination: **Wage Determination 2015-4089 Revision No. 29 Dated 12/23/2024 is incorporated into this contract**

8. SECURITY AND ACCESS REQUIREMENTS:

Not applicable.

9. GOVERNMENT FURNISHED RESOURCES (GFR):

There is no government furnished equipment for this requirement.

10. SUPTXT204-9400(8-22) CONTRACTOR UNCLASSIFIED ACCESS TO FEDERALLY CONTROLLED

FACILITIES, SENSITIVE INFORMATION, INFORMATION TECHNOLOGY SYSTEMS OR PROTECTED

HEALTH INFORMATION

(1) SUPTXT204-9400(4-22) CONTRACTOR UNCLASSIFIED ACCESS TO FEDERALLY CONTROLLED

FACILITIES, SENSITIVE INFORMATION, INFORMATION TECHNOLOGY (IT) SYSTEMS OR

PROTECTED HEALTH INFORMATION

The security text does not apply in cases where the contractor/vendor does not have access to Navy Marine Corps Intranet (NMCI) computers, is not issued a Common Access Card (CAC) and is involved in training or other short term duties of less than 30 days duration that allow for the use of a visitor request. In these cases, the government employee must submit a Visitor Access Request (VAR) to the main gate or applicable processing entity for your facility and assume responsibility to escort those without CAC Credentials.

This local text does not apply to non-United States (U.S.) Nationals (foreign nationals) who are contactor employees performing work overseas. This text is applicable to the U.S. Nationals living in the U.S. or overseas who are performing work on a Navy contract.

The investigation of a non-U.S. national at a foreign location must be consistent with a National Agency Check with Written Inquiries (NACI), to the extent possible and include a fingerprint check against the Federal Bureau of Investigation (FBI) criminal history database, an FBI investigations file (name check) search and a name check against the terrorist screening database. Also, the above cited reference notes that Foreign Nationals may not be granted CAC credentials until completion of their investigation and not in the interim.

Per Department of Defense Memorandum (DoDM) 5200.2, Department of Defense (DoD) components must initiate and ensure completion of a background investigation before applying the credentialing standards to a non-U.S.

national at a foreign location. The background investigation must be favorably adjudicated before a CAC can be issued to a non-U.S. national at a foreign location. The type of background investigation may vary based on standing reciprocity treaties concerning identity assurance and information exchanges that exist between the U.S. and its allies or agency agreements with the host country.

CONTRACTOR UNCLASSIFIED ACCESS TO FEDERALLY CONTROLLED FACILITIES, SENSITIVE

INFORMATION, IT SYSTEMS OR PROTECTED HEALTH INFORMATION

Executive Order 13467, Reforming Processes Related to Suitability for Government Employee, Fitness for Contractor Employees and Eligibility for Access to Classified National Security Information, Homeland Security Presidential Directive (HSPD)-12, requires government agencies to develop and implement Federal security standards for Federal employees and contractors. The 5 CFR 32 Part 157 in concert with DoD Manual 1000.13, Vol 1, implements the Federal Standards.

APPLICABILITY

This text applies to all DoD sponsored individuals who require CAC eligibility (or login and P/W if acceptable per contract) for: Physical access to DoD facilities or non-DoD facilities on behalf of DoD; Logical access to information systems (whether on site or remotely); or remote access to DoD networks that use only the CAC logon for user authentication, or access to sensitive and protected information. This applies to the Office of the Secretary of Defense (OSD), the Military Departments, the Office of the Chairman of the Joint Chiefs of Staff and the Joint Staff, the Combatant Commands, the Office of the Inspector General of the DoD, the Defense Agencies, the DoD Field Activities and all other organizational entities within the DoD (hereinafter referred to collectively as the "DoD Components").

Each contractor employee providing services at a Navy command under this contract is required to obtain a DoD CAC. Additionally, depending on the level of computer/network access, the contract employee will require a successful investigation as detailed below.

ACCESS TO FEDERAL FACILITIES

Definition. As used in this clause - Military installation means a base, camp, post, station, yard, center, or other activity under the jurisdiction of the Secretary of a military department, or, in the case of an activity in a foreign country, under the operational control of the Secretary of a military department or the Secretary of Defense (see 10 U.S.C. 2801(c)(4)).

Per HSPD-12 and implementing guidance, all contractor employees working at a federally controlled base, facility or activity under this clause will require a DoD CAC. When access to a base, facility or activity is required contractor employees shall in-process with the Command's Security Manager (CSM) upon arrival to the command and shall out-process prior to their departure at the completion of the individual's performance under the contract.

Training. Contractor employees who require routine physical access to a Federally controlled facility or military installation shall complete “Level I Antiterrorism Awareness Training” prior to gaining access to a facility and annually thereafter in accordance with DoDI O-2000.16 Vol. 1. In accordance with Department of Defense Instruction O-2000.16 Volume 1, DoD Antiterrorism (AT) Program Implementation: DoD AT Standards, Level I Antiterrorism Awareness Training shall be completed by:

1. Completion of “Level I Antiterrorism Awareness Training” available at https://jkodirect.jten.mil/pdf/atl1/launch.html; or

2. Under the instruction of a qualified Level I Antiterrorism Awareness instructor; or

3. By providing a training certificate for “Level I Antiterrorism Awareness Training” training showing completion within the last calendar year.

The contractor will submit certificates of completion for each affected contractor employee and subcontractor employee to the COR or to the contracting officer, if a COR is not assigned, prior to being granted access to a Federally controlled facility or military installation.

Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (d), in subcontracts, including subcontracts for commercial items, when subcontractor performance requires routine physical access to a Federally-controlled facility or military installation.

OPERATION SECURITY (OPSEC)

It is DoD policy according to DoD Directive 5205.02E, “DoD Operations Security (OPSEC) Program,” June 20, 2012, as amended to establish and maintain OPSEC programs to ensure national security-related missions and functions are protected.

Training: Contractor employees shall comply with all DoD OPSEC requirements and complete “OPSEC Awareness for Military Members, DoD Employees and Contractor” training within 30 days of onboarding the contract and annual refresher training thereafter. Training shall be completed through a DoD sponsored and certified computer or web-based learning instruction available at https://securityawareness.usalearning.gov/opsec/index.htm.

The contractor will submit certificates of completion for each affected contractor employee and subcontractor employee to the COR or to the contracting officer, if a COR is not assigned, within 30 calendar days after training is completed by all employees and subcontractor personnel.

START-UP PERIOD

All contractor resource onboarding documents must be submitted via the prime contractor. The prime contractor shall make all necessary preparations to assume full responsibility for productive performance as of the performance start date.

Definition of "productive":

a. OF-306 signed by contractor employee

b. FD-258 Fingerprint Card (Contingent upon availability of electronic fingerprinting submission)

c. Completed Electronic Investigation (e-QIP)

d. All contractor employees with need for a Common Access Card (CAC) must have an active Defense Information System for Security (DISS) profile.

e. Common Access Card (CAC)

f. DISS Visit Request submitted (Contingent upon classification of work being performed, Confidential, Secret, Top Secret).

Note (1): Invoicing by the contractor will begin as of the commencement of the performance period of services and no reimbursement will be paid by the government for efforts expended during the start-up period.

Note (2): Foreign Nationals are not allowed access to the functional/system side of Enterprise Resource Planning

(ERP).

ACCESS TO DOD INFORMATION TECHNOLOGY (IT) SYSTEM

In accordance with DON CIO Memorandum (IT LEVEL DESIGNATION ON DD FORM 2875 SYSTEM AUTHORIZATION ACCESS REQUEST) 08 September 2020, contractor employees who require access to Department of the Navy (DoN) or DoD networks are categorized as Privileged, Enhanced, or Authorized users. All user level accesses may include positions which require access to Controlled Unclassified Information (CUI). CUI includes sensitive information protected under the Privacy Act, to include Protected Health Information (PHI). IT System levels are determined by the requiring activity's Command Information System Security Manager (ISSM)/Information Assurance Manager (IAM).

Contractor employees requiring privileged access, (when specified by the terms of the contract) require a Tier 5 (T5) or T5R equivalent investigation, which is a higher level investigation than the Tier 3 (T3) and T3R described below.

Due to the privileged system access, an investigation suitable for High Risk national security positions is required.

Individuals who have access to system control, monitoring, or administration functions (e.g. system administrator, database administrator) require training and certification to Information Assurance (IA) Technical Level 1, and must be trained and certified on the Operating System or Computing Environment they are required to maintain.

Contractors requiring Enhanced access, (when specified by the terms of the contract) require a T3, T3R, or equivalent investigation, which is a higher level investigation than the Tier 1 (T1) described below. Due to the enhanced system access, an investigation suitable for Moderate Risk national security positions is required.

Access to sensitive IT systems is contingent upon a favorably adjudicated background investigation. When access to IT systems is required for performance of the contractor employee's duties, such employees shall in-process with the Navy CSM and ISSM/IAM manager upon arrival to the Navy command and shall out-process prior to their departure at the completion of the individual's performance under the contract. Completion and approval of a System Authorization Access Request Navy (SAAR-N) form is required for all individuals accessing Navy IT resources. The decision to authorize access to a government IT system/network is inherently governmental. The contractor supervisor is not authorized to sign the SAAR-N; therefore, the government employee with knowledge of the system/network access required or the Contracting Officers Representative (COR) shall sign the SAAR-N as the supervisor.

The SAAR-N shall be forwarded to the CSM upon contractor employee acquiring a Common Access Card (CAC) credential. Failure to obtain a CAC credential may result in delaying the individual's start date.

When required to maintain access to required IT systems or networks, the contractor shall ensure that all contractor employees requiring access complete annual Cyber Awareness training, and maintain a current requisite background investigation. The contractor's security representative shall contact the CSM for guidance when reinvestigations are required.

INTERIM ACCESS

The CSM may authorize issuance of a DoD CAC and interim access to a DoN or DoD unclassified computer/network upon a favorable review of the investigative questionnaire and advance favorable fingerprint results. When the results of the investigation are received and a favorable determination is not made, the contractor employee working on the contract under interim access will be denied access to the computer network and this denial will not relieve the contractor of his/her responsibility to perform.

DENIAL OR TERMINATION OF ACCESS

The potential consequences of any requirement under this clause including denial or termination of physical or system access in no way relieves the contractor from the requirement to execute performance under the contract within the timeframes specified in the contract. Contractors shall plan ahead in processing their employees and subcontractor employees. The contractor shall insert this clause in all subcontracts when the subcontractor is permitted to have unclassified access to a federally controlled facility, federally-controlled information system/network and/or to government information, meaning information not authorized for public release.

ACCESS TO CONTROLLED UNCLASSIFIED INFORMATION

Safeguarding sensitive unclassified information is critical to achieve NAVSUP Modernization efforts and deliver cutting-edge and uncompromised capabilities. The Secretary of Defense’s operations security (OPSEC) campaign plan stresses the importance of protecting controlled unclassified information (CUI). CUI encompasses OPSEC, critical technology, intelligence, and personally identifiable information that, if not properly identified, marked, and controlled, could impair NAVSUP’s ability to conduct its mission. Contractor employees with access to Controlled Unclassified Information (CUI) shall comply with DoDI 5200.48 - Controlled Unclassified Information (CUI) and complete DoD approved initial and annual refresher CUI training.

a. Whenever Government provides CUI to, or CUI is generated by, non-DoD entities, all CUI records must be handled as required by the approved mandatory disposition authority.

b. All CUI records must follow the approved mandatory disposition authority whenever the Government provides CUI to, or CUI is generated by, non-DoD entities in accordance with Section 1220-1236 of Title 36, CFR, Section 3301a of Title 44, U.S.C., and the DoDI 5200.48.

c. Contractor employees shall monitor CUI aggregation and compilation based on the potential to generate classified information pursuant to security classification guidance addressing the accumulation of unclassified data or information.

d. Contractor employees shall submit unclassified government information for review and approval for release in accordance with the Standard DoD Component Processes, DoDI 5230.09, and DoDM 5205.07, Volume 1.

CONTRACTOR'S SECURITY REPRESENTATIVE

The contractor shall designate an employee to serve as the contractor's security representative. Within three (3) work days after contract award, the contractor shall provide to the requiring activity's Security Manager and the Contracting Officer, in writing, the name, title, address and phone number for the contractor's security representative. The contractor's security representative shall be the primary point of contact on any security matter.

The contractor's security representative shall not be replaced or removed without prior notice to the Contracting Officer and CSM.

BACKGROUND INVESTIGATION REQUIREMENTS AND SECURITY APPROVAL PROCESS FOR

CONTRACTORS ASSIGNED TO NATIONAL SECURITY POSITIONS OR PERFORMING SENSITIVE

DUTIES

Navy security policy requires that all positions be given a sensitivity value based on level of risk factors to ensure appropriate protective measures are applied. If the Security Office validates the contractor’s position is Non-Critical Sensitive or if the IT system user level is determined to be Enhanced, at a minimum, each contractor employee must be a US citizen and have a favorably completed T3, T3R, or equivalent investigation to obtain a favorable determination for assignment to a non-critical sensitive or Enhanced position. The investigation consists of a standard National Agency Check and a FBI fingerprint check plus law enforcement checks and credit check. Each contractor employee filling a non-critical sensitive or Enhanced position is required to complete:

SF-86 Questionnaire for National Security Positions (or equivalent Office of Personnel Management (OPM) investigative product)

Two FD-258 Applicant Fingerprint Cards or electronic fingerprint submission (preferred)) Original Signed Release Statements

Failure to provide the required documentation at least thirty (30) days prior to the individual’s start date shall result in delaying the individual’s start date. Background investigations shall be reinitiated as required to ensure investigations remain current (not older than ten (10) years) throughout the contract performance period. The Contractor’s Security Representative shall contact the CSM for guidance when reinvestigations are required.

Regardless of their duties or IT access requirements ALL contractor employees shall in-process with the CSM upon arrival to the command and shall out-process prior to their departure at the completion of the individual’s performance under the contract. Employees requiring IT access shall also check-in and check-out with the Navy Command’s ISSM/IAM. Completion and approval of a System Authorization Access Request Navy (SAAR-N) form is required for all individuals accessing Navy IT resources. The SAAR-N shall be forwarded to the CSM upon the contractor employee acquiring a Common Access Card (CAC) credential. Failure to obtain a CAC credential or provide the required documentation shall result in delaying the individual’s start date.

The contractor shall ensure that each contract employee requiring access to IT systems or networks complete annual Cyber Awareness training and maintain a current requisite background investigation. Contractor employees shall accurately complete the required investigative forms prior to submission to the CSM. The CSM will review the submitted documentation for completeness prior to submitting it to the OPM. Potential suitability or security issues identified may render the contractor employee ineligible for the assignment. An unfavorable determination is final (subject to SF-86 appeal procedures) and such a determination does not relieve the contractor from meeting any contractual obligation under the contract. The CSM will forward the required forms to OPM for processing. Once the investigation is complete, the results will be forwarded by OPM to the DoD Central Adjudication Facility (CAF) for a determination.

For classified contracts, if the contractor employee already possesses a current favorably adjudicated investigation, the contractor shall submit a Visit Access Request (VAR) via the Defense Information Security System (DISS). If the contractor employee does not have a current favorably adjudicated investigation, the contractor shall submit the Visit Access Request in DISS until the contractor employee has at a minimum an interim clearance. If the contract only requires access to unclassified information, even if the contractor takes a DISS “owning” role over the contractor employee, the Navy Command will also take a DISS “owning” role over the contractor employee during the hiring process and for the duration of assignment under that contract. If the contract requires access to classified information, the contractor’s Facility Security Office (FSO) will take a DISS “ownership” role and the Navy command will take a DISS “servicing” role during the hiring process and the duration of assignment under that contract. All VARs requires annual renewal for the duration of the employee’s performance under the contract.

BACKGROUND INVESTIGATION REQUIREMENTS AND SECURITY APPROVAL PROCESS FOR

CONTRACTORS ASSIGNED TO OR PERFORMING NON-SENSITIVE DUTIES

Contractor employee whose work is unclassified and non-sensitive (e.g., performing certain duties such as lawn maintenance, vendor services, etc...) and who require physical access to publicly accessible areas to perform those duties shall meet the following minimum requirements:

Must be either a U.S. citizen or a U.S. permanent resident with a minimum of 3 years of legal residency in the U.S. (as required by the Deputy Secretary of Defense DTM 08-006 or its subsequent DoD Instruction (INST)) and

Must have a favorably completed NACI or T1 investigation or equivalent including a FBI fingerprint check prior to installation access.

To be considered for a favorable trustworthiness determination, the CSR must submit for all employees each of the following:

SF-85 Questionnaire for Non-Sensitive Positions Two FD-258 Applicant Fingerprint Cards (or the preferred method - electronic fingerprint submission) Original Signed Release Statements

The contractor shall ensure each individual employee has a current favorably completed NACI or T1 equivalent investigation, or ensure successful FBI fingerprint results have been gained and investigation has been processed with OPM.

Failure to provide the required documentation at least thirty (30) days prior to the individual's start date may result in delaying the individual's start date.

11. AbilityOne

NAVSUP FLCN may utilize contractor support through the AbilityOne Program, as needed, to perform contract closeout functions for this acquisition. Information, including business sensitive/confidential or proprietary data, that the offeror provides to the Government or information already in the possession of the Government may be viewed and utilized by the AbilityOne Program support contractor personnel during the course of its contract performance.

The information that may be made available to the support contractor may include, for example, pricing and technical proposals, historical contract, pricing and performance information, Commercial Asset Visibility (CAV) reporting information and similar data/information.

By submission of a proposal in response to this solicitation, the offeror and its subcontractors consent to a release of their business sensitive/confidential or proprietary data to the Government's AbilityOne Program support contractor personnel in order to perform close out services. Prior to the release of any such information to the support contractor, the support contractor will have in place with the Government a Non-Disclosure/Non-Use Agreement in accordance with the terms of the AbilityOne Program support contract.

Offerors may execute their own Non-Disclosure Agreement with the AbilityOne Program (AbilityOne contact information available from the contracting point of contact). The support contractor must provide copies of the executed agreements to the Contracting Officer and the Contracting Officer's Representative (COR) for the support contract; and the offeror/contractor for this acquisition must provide copies of the executed Agreement to the Contracting Officer for this acquisition. If the offeror/contractor seeks such a Non-Disclosure Agreement with the AbilityOne Program support contractor, the Agreement must be executed no later than the date of final delivery under the resulting NAVSUP FLCN contract.

12. AUTHORIZED CHANGES ONLY BY THE CONTRACTING OFFICER

(a) Except as specified in paragraph (b) below, no order, statement, or conduct of Government personnel who visit the Contractor's facilities or in any other manner communicate with Contractor personnel during the performance of this contract shall constitute a change under the "Changes" clause of this contract.

(b) The Contractor shall not comply with any order, direction or request of Government personnel unless it is issued in writing and signed by the Contracting Officer or is pursuant to specific authority otherwise included as a part of this contract.

(c) The Contracting Officer is the only person authorized to approve changes in any of the requirements of this contract and notwithstanding provisions contained elsewhere in this contract, the said authority remains solely with the Contracting Officer. In the event the Contractor effects any change at the direction of any person other than the Contracting Officer, the change will be considered to have been made without authority and no adjustment will be made in the contract price to cover any increase in charges incurred as a result thereof. The address and telephone number of the Contracting Officer is:

NAME: Amber Bradley EMAIL ADDRESS: amber.v.bradley.civ@us.navy.mil

TELEPHONE: 757-443-1968

(End of Summary of Changes)