N0018320Q0040.docx

N0018320Q0040

Section A - Solicitation/Contract Form

THIS IS AN INFORMATION NOTICE ONLY – NO AWARD WILL BE MADE FROM THIS NOTIFICATION. This is an announcement that the Government intends to issue a call against an existing Blanket Purchase Agreement (BPA) for Ophthalmology Clinic intraocular lenses used at the the Naval Medical Center Portsmouth Virginia. The call will be placed against Naval Medical Center Portsmouth’s BPA N0018320A0001. The Call will be issued for a total amount of $10,500.00 covering the period of April, May, and June 2020.

Section B - Supplies or Services and Prices

Consignment for intraocular lenses for

FFP

Intraocular lenses for the period 01 Apr 2020 through 30 Jun 2020 FOB: Destination

MILSTRIP: N0018320RCH4P05

PURCHASE REQUEST NUMBER: N0018320RCH4P05

PSC CD: 6515

NET AMT

Section C - Descriptions and Specifications

Contractor Unclassified Access to Federally Controlled Facilities, Sensitive Information, Information Technology (IT) Systems or Protected Health Information (Jan 2017)

Homeland Security Presidential Directive (HSPD)-12, requires government agencies to develop and implement Federal security standards for Federal employees and contractors. The Deputy Secretary of Defense Directive-Type Memorandum (DTM) 08-006 – “DoD Implementation of Homeland Security Presidential Directive – 12 (HSPD-12)” dated November 26, 2008 (or its subsequent DoD instruction) directs implementation of HSPD-12. This clause is in accordance with HSPD-12 and its implementing directives.

APPLICABILITY

This text applies to contractor employees requiring physical access to any area of a federally controlled base, facility or activity and/or requiring access to a DoN or DoD computer/network/system to perform certain unclassified sensitive duties. This clause also applies to contractor employees who access Privacy Act and Protected Health Information, provide support associated with fiduciary duties, or perform duties that have been identified as National Security Position, as advised by the command security manager. It is the responsibility of the responsible security officer of the command/facility where the work is performed to ensure compliance.

Each contractor employee providing services at a Navy Command under this contract is required to obtain a Department of Defense Common Access Card (DoD CAC). Additionally, depending on the level of computer/network access, the contract employee will require a successful investigation as detailed below.

ACCESS TO FEDERAL FACILITIES

Per HSPD-12 and implementing guidance, all contractor employees working at a federally controlled base, facility or activity under this clause will require a DoD CAC. When access to a base, facility or activity is required contractor employees shall in-process with the Command’s Security Manager upon arrival to the Command and shall out-process prior to their departure at the completion of the individual’s performance under the contract.

ACCESS TO DOD IT SYSTEMS

In accordance with SECNAV M-5510.30, contractor employees who require access to DoN or DoD networks are categorized as IT-I, IT-II, or IT-III. The IT-II level, defined in detail in SECNAV M-5510.30, includes positions which require access to information protected under the Privacy Act, to include Protected Health Information (PHI). All contractor employees under this contract who require access to Privacy Act protected information are therefore categorized no lower than IT-II. IT Levels are determined by the requiring activity’s Command Information Assurance Manager.

Contractor employees requiring privileged or IT-I level access, (when specified by the terms of the contract) require a Single Scope Background Investigation (SSBI) or T5 or T5R equivalent investigation , which is a higher level investigation than the National Agency Check with Law and Credit (NACLC)/T3/T3R described below. Due to the privileged system access, an investigation suitable for High Risk national security positions is required. Individuals who have access to system control, monitoring, or administration functions (e.g. system administrator, database administrator) require training and certification to Information Assurance Technical Level 1, and must be trained and certified on the Operating System or Computing Environment they are required to maintain.

Access to sensitive IT systems is contingent upon a favorably adjudicated background investigation. When access to IT systems is required for performance of the contractor employee’s duties, such employees shall in-process with the Navy Command’s Security Manager and Information Assurance Manager upon arrival to the Navy command and shall out-process prior to their departure at the completion of the individual’s performance under the contract. Completion and approval of a System Authorization Access Request Navy (SAAR-N) form is required for all individuals accessing Navy Information Technology resources. The decision to authorize access to a government IT system/network is inherently governmental. The contractor supervisor is not authorized to sign the SAAR-N; therefore, the government employee with knowledge of the system/network access required or the COR shall sign the SAAR-N as the “supervisor”.

The SAAR-N shall be forwarded to the Command’s Security Manager at least 30 days prior to the individual’s start date. Failure to provide the required documentation at least 30 days prior to the individual’s start date may result in delaying the individual’s start date.

When required to maintain access to required IT systems or networks, the contractor shall ensure that all employees requiring access complete annual Information Assurance (IA) training, and maintain a current requisite background investigation. The Contractor’s Security Representative shall contact the Command Security Manager for guidance when reinvestigations are required.

INTERIM ACCESS

The Command's Security Manager may authorize issuance of a DoD CAC and interim access to a DoN or DoD unclassified computer/network upon a favorable review of the investigative questionnaire and advance favorable fingerprint results. When the results of the investigation are received and a favorable determination is not made, the contractor employee working on the contract under interim access will be denied access to the computer network and this denial will not relieve the contractor of his/her responsibility to perform.

DENIAL OR TERMINATION OF ACCESS

The potential consequences of any requirement under this clause including denial or termination of physical or system access in no way relieves the contractor from the requirement to execute performance under the contract within the timeframes specified in the contract. Contractors shall plan ahead in processing their employees and subcontractor employees. The contractor shall insert this clause in all subcontracts when the subcontractor is permitted to have unclassified access to a federally controlled facility, federally-controlled information system/network and/or to government information, meaning information not authorized for public release.

CONTRACTOR’S SECURITY REPRESENTATIVE

The contractor shall designate an employee to serve as the Contractor’s Security Representative. Within three work days after contract award, the contractor shall provide to the requiring activity’s Security Manager and the Contracting Officer, in writing, the name, title, address and phone number for the Contractor’s Security Representative. The Contractor’s Security Representative shall be the primary point of contact on any security matter. The Contractor’s Security Representative shall not be replaced or removed without prior notice to the Contracting Officer and Command Security Manager.

BACKGROUND INVESTIGATION REQUIREMENTS AND SECURITY APPROVAL PROCESS FOR CONTRACTORS ASSIGNED TO NATIONAL SECURITY POSITIONS OR PERFORMING SENSITIVE DUTIES

Navy security policy requires that all positions be given a sensitivity value based on level of risk factors to ensure appropriate protective measures are applied. Contractor employees under this contract are recognized as Non-Critical Sensitive [ADP/IT-II] positions when the contract scope of work require physical access to a federally controlled base, facility or activity and/or requiring access to a DoD computer/network, to perform unclassified sensitive duties. This designation is also applied to contractor employees who access Privacy Act and Protected Health Information (PHI), provide support associated with fiduciary duties, or perform duties that have been identified as National Security Positions. At a minimum, each contractor employee must be a US citizen and have a favorably completed NACLC or T3 or T3R equivalent investigation to obtain a favorable determination for assignment to a non-critical sensitive or IT-II position. The investigation consists of a standard NAC and a FBI fingerprint check plus law enforcement checks and credit check. Each contractor employee filling a non-critical sensitive or IT-II position is required to complete:

· SF-86 Questionnaire for National Security Positions (or equivalent OPM investigative product)

· Two FD-258 Applicant Fingerprint Cards (or an electronic fingerprint submission)

· Original Signed Release Statements

Failure to provide the required documentation at least 30 days prior to the individual’s start date shall result in delaying the individual’s start date. Background investigations shall be reinitiated as required to ensure investigations remain current (not older than 10 years) throughout the contract performance period. The Contractor’s Security Representative shall contact the Command Security Manager for guidance when reinvestigations are required.

Regardless of their duties or IT access requirements ALL contractor employees shall in-process with the Command’s Security Manager upon arrival to the command and shall out-process prior to their departure at the completion of the individual’s performance under the contract. Employees requiring IT access shall also check-in and check-out with the Navy Command’s Information Assurance Manager. Completion and approval of a System Authorization Access Request Navy (SAAR-N) form is required for all individuals accessing Navy Information Technology resources. The SAAR-N shall be forwarded to the Navy Command’s Security Manager at least 30 days prior to the individual’s start date. Failure to provide the required documentation at least 30 days prior to the individual’s start date shall result in delaying the individual’s start date.

The contractor shall ensure that each contract employee requiring access to IT systems or networks complete annual Information Assurance (IA) training, and maintain a current requisite background investigation. Contractor employees shall accurately complete the required investigative forms prior to submission to the Command Security Manager. The Command’s Security Manager will review the submitted documentation for completeness prior to submitting it to the Office of Personnel Management (OPM); Potential suitability or security issues identified may render the contractor employee ineligible for the assignment. An unfavorable determination is final (subject to SF-86 appeal procedures) and such a determination does not relieve the contractor from meeting any contractual obligation under the contract. The Command’s Security Manager will forward the required forms to OPM for processing. Once the investigation is complete, the results will be forwarded by OPM to the DoD Central Adjudication Facility (CAF) for a determination.

If the contractor employee already possesses a current favorably adjudicated investigation, the contractor shall submit a Visit Authorization Request (VAR) via the Joint Personnel Adjudication System (JPAS) or a hard copy VAR directly from the contractor’s Security Representative. Although the contractor will take JPAS “Owning” role over the contractor employee, the Command will take JPAS "Servicing" role over the contractor employee during the hiring process and for the duration of assignment under that contract. The contractor shall include the IT Position Category per SECNAV M-5510.30 for each employee designated on a VAR. The VAR requires annual renewal for the duration of the employee’s performance under the contract.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLAUSES INCORPORATED BY REFERENCE

Section F - Deliveries or Performance

DELIVERY INFORMATION

30-JUN-2020

RECEIVING OFFICER

54 LEWIS MINOR STREET

BLDG. 250

PORTSMOUTH VA 23708-2297

757-953-5770 FOB: Destination N00183

Section G - Contract Administration Data

CLAUSES INCORPORATED BY FULL TEXT

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) Definitions. As used in this clause—

“Department of Defense Activity Address Code (DoDAAC)” is a six position code that uniquely identifies a unit, activity, or organization.

“Document type” means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

“Local processing office (LPO)” is the office responsible for payment certification when payment certification is done external to the entitlement system.

“Payment request” and “receiving report” are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall—

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items—

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

____________COMBO FOR SUPPLIES________________________________________________

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact. edward.r.gollon.civ@mail.mil ; patricia.a.stephens58.civ@mail.mil ; felishe.k.flax.civ@mail.mil ; julia.m.foster.civ@mail.mil

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity’s WAWF point of contact.

usn.detrick.navmedlogcomftdmd.list.nmlc-wawf@mail.mil

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

Section H - Special Contract Requirements

Vendormate Credentialing Requirement Naval Medical Center, Portsmouth (NMCP) has instituted a Credentialing Program which is designed to streamline the collection and management of key information regarding the regulatory and compliance status as well as business operations of our suppliers.

The program requires all vendors and their representatives to register in order to gain base access to NMCP. One nominal annual credentialing fee covers your company as well as all representatives of your company that interact with NMCP.

The price ranges from $25 to $250 per year depending on your company’s risk profile and is paid directly to our partner, Vendormate Credentialing. It is imperative that each representative registers individually to maintain their personal credentials and ensure ongoing base access to our facility.

A Federal Tax Identification Number and a credit card are required to complete the initial registration. Additional representatives only need the Federal Tax Identification Number.

Register for Vendormate Credentialing at https://nmcp.vendormate.com.

For technical questions, go to https://ghx.com/customer-care.

Kiosks are located on the first and second floor entrances of Building two (2). Your representatives who visit NMCP may be required to sign in electronically to obtain an identification badge. With a valid appointment and current credentials, your representative will be able to print a single-use badge that is to be worn throughout the visit to any NMCP facility. Badges are required for all vendors on premises.

Please note that GHX Vendormate Credentialing is in addition to RapidGate for Base Access. Vendors are required to register for both programs in order to come onboard the NMCP base.

Contractor Unclassified Access to Federally Controlled Facilities, Sensitive Information, Information Technology (IT) Systems or Protected Health Information (Jan 2017)

Homeland Security Presidential Directive (HSPD)-12, requires government agencies to develop and implement Federal security standards for Federal employees and contractors. The Deputy Secretary of Defense Directive-Type Memorandum (DTM) 08-006 – “DoD Implementation of Homeland Security Presidential Directive – 12 (HSPD-12)” dated November 26, 2008 (or its subsequent DoD instruction) directs implementation of HSPD-12. This clause is in accordance with HSPD-12 and its implementing directives.

APPLICABILITY

This text applies to contractor employees requiring physical access to any area of a federally controlled base, facility or activity and/or requiring access to a DoN or DoD computer/network/system to perform certain unclassified sensitive duties. This clause also applies to contractor employees who access Privacy Act and Protected Health Information, provide support associated with fiduciary duties, or perform duties that have been identified as National Security Position, as advised by the command security manager. It is the responsibility of the responsible security officer of the command/facility where the work is performed to ensure compliance.

Each contractor employee providing services at a Navy Command under this contract is required to obtain a Department of Defense Common Access Card (DoD CAC). Additionally, depending on the level of computer/network access, the contract employee will require a successful investigation as detailed below.

ACCESS TO FEDERAL FACILITIES

Per HSPD-12 and implementing guidance, all contractor employees working at a federally controlled base, facility or activity under this clause will require a DoD CAC. When access to a base, facility or activity is required contractor employees shall in-process with the Command’s Security Manager upon arrival to the Command and shall out-process prior to their departure at the completion of the individual’s performance under the contract.

ACCESS TO DOD IT SYSTEMS

In accordance with SECNAV M-5510.30, contractor employees who require access to DoN or DoD networks are categorized as IT-I, IT-II, or IT-III. The IT-II level, defined in detail in SECNAV M-5510.30, includes positions which require access to information protected under the Privacy Act, to include Protected Health Information (PHI). All contractor employees under this contract who require access to Privacy Act protected information are therefore categorized no lower than IT-II. IT Levels are determined by the requiring activity’s Command Information Assurance Manager.

Contractor employees requiring privileged or IT-I level access, (when specified by the terms of the contract) require a Single Scope Background Investigation (SSBI) or T5 or T5R equivalent investigation , which is a higher level investigation than the National Agency Check with Law and Credit (NACLC)/T3/T3R described below. Due to the privileged system access, an investigation suitable for High Risk national security positions is required. Individuals who have access to system control, monitoring, or administration functions (e.g. system administrator, database administrator) require training and certification to Information Assurance Technical Level 1, and must be trained and certified on the Operating System or Computing Environment they are required to maintain.

Access to sensitive IT systems is contingent upon a favorably adjudicated background investigation. When access to IT systems is required for performance of the contractor employee’s duties, such employees shall in-process with the Navy Command’s Security Manager and Information Assurance Manager upon arrival to the Navy command and shall out-process prior to their departure at the completion of the individual’s performance under the contract. Completion and approval of a System Authorization Access Request Navy (SAAR-N) form is required for all individuals accessing Navy Information Technology resources. The decision to authorize access to a government IT system/network is inherently governmental. The contractor supervisor is not authorized to sign the SAAR-N; therefore, the government employee with knowledge of the system/network access required or the COR shall sign the SAAR-N as the “supervisor”.

The SAAR-N shall be forwarded to the Command’s Security Manager at least 30 days prior to the individual’s start date. Failure to provide the required documentation at least 30 days prior to the individual’s start date may result in delaying the individual’s start date.

When required to maintain access to required IT systems or networks, the contractor shall ensure that all employees requiring access complete annual Information Assurance (IA) training, and maintain a current requisite background investigation. The Contractor’s Security Representative shall contact the Command Security Manager for guidance when reinvestigations are required.

INTERIM ACCESS

The Command's Security Manager may authorize issuance of a DoD CAC and interim access to a DoN or DoD unclassified computer/network upon a favorable review of the investigative questionnaire and advance favorable fingerprint results. When the results of the investigation are received and a favorable determination is not made, the contractor employee working on the contract under interim access will be denied access to the computer network and this denial will not relieve the contractor of his/her responsibility to perform.

DENIAL OR TERMINATION OF ACCESS

The potential consequences of any requirement under this clause including denial or termination of physical or system access in no way relieves the contractor from the requirement to execute performance under the contract within the timeframes specified in the contract. Contractors shall plan ahead in processing their employees and subcontractor employees. The contractor shall insert this clause in all subcontracts when the subcontractor is permitted to have unclassified access to a federally controlled facility, federally-controlled information system/network and/or to government information, meaning information not authorized for public release.

CONTRACTOR’S SECURITY REPRESENTATIVE

The contractor shall designate an employee to serve as the Contractor’s Security Representative. Within three work days after contract award, the contractor shall provide to the requiring activity’s Security Manager and the Contracting Officer, in writing, the name, title, address and phone number for the Contractor’s Security Representative. The Contractor’s Security Representative shall be the primary point of contact on any security matter. The Contractor’s Security Representative shall not be replaced or removed without prior notice to the Contracting Officer and Command Security Manager.

BACKGROUND INVESTIGATION REQUIREMENTS AND SECURITY APPROVAL PROCESS FOR CONTRACTORS ASSIGNED TO NATIONAL SECURITY POSITIONS OR PERFORMING SENSITIVE DUTIES

Navy security policy requires that all positions be given a sensitivity value based on level of risk factors to ensure appropriate protective measures are applied. Contractor employees under this contract are recognized as Non-Critical Sensitive [ADP/IT-II] positions when the contract scope of work require physical access to a federally controlled base, facility or activity and/or requiring access to a DoD computer/network, to perform unclassified sensitive duties. This designation is also applied to contractor employees who access Privacy Act and Protected Health Information (PHI), provide support associated with fiduciary duties, or perform duties that have been identified as National Security Positions. At a minimum, each contractor employee must be a US citizen and have a favorably completed NACLC or T3 or T3R equivalent investigation to obtain a favorable determination for assignment to a non-critical sensitive or IT-II position. The investigation consists of a standard NAC and a FBI fingerprint check plus law enforcement checks and credit check. Each contractor employee filling a non-critical sensitive or IT-II position is required to complete:

· SF-86 Questionnaire for National Security Positions (or equivalent OPM investigative product)

· Two FD-258 Applicant Fingerprint Cards (or an electronic fingerprint submission)

· Original Signed Release Statements

Failure to provide the required documentation at least 30 days prior to the individual’s start date shall result in delaying the individual’s start date. Background investigations shall be reinitiated as required to ensure investigations remain current (not older than 10 years) throughout the contract performance period. The Contractor’s Security Representative shall contact the Command Security Manager for guidance when reinvestigations are required.

Regardless of their duties or IT access requirements ALL contractor employees shall in-process with the Command’s Security Manager upon arrival to the command and shall out-process prior to their departure at the completion of the individual’s performance under the contract. Employees requiring IT access shall also check-in and check-out with the Navy Command’s Information Assurance Manager. Completion and approval of a System Authorization Access Request Navy (SAAR-N) form is required for all individuals accessing Navy Information Technology resources. The SAAR-N shall be forwarded to the Navy Command’s Security Manager at least 30 days prior to the individual’s start date. Failure to provide the required documentation at least 30 days prior to the individual’s start date shall result in delaying the individual’s start date.

The contractor shall ensure that each contract employee requiring access to IT systems or networks complete annual Information Assurance (IA) training, and maintain a current requisite background investigation. Contractor employees shall accurately complete the required investigative forms prior to submission to the Command Security Manager. The Command’s Security Manager will review the submitted documentation for completeness prior to submitting it to the Office of Personnel Management (OPM); Potential suitability or security issues identified may render the contractor employee ineligible for the assignment. An unfavorable determination is final (subject to SF-86 appeal procedures) and such a determination does not relieve the contractor from meeting any contractual obligation under the contract. The Command’s Security Manager will forward the required forms to OPM for processing. Once the investigation is complete, the results will be forwarded by OPM to the DoD Central Adjudication Facility (CAF) for a determination.

If the contractor employee already possesses a current favorably adjudicated investigation, the contractor shall submit a Visit Authorization Request (VAR) via the Joint Personnel Adjudication System (JPAS) or a hard copy VAR directly from the contractor’s Security Representative. Although the contractor will take JPAS “Owning” role over the contractor employee, the Command will take JPAS "Servicing" role over the contractor employee during the hiring process and for the duration of assignment under that contract. The contractor shall include the IT Position Category per SECNAV M-5510.30 for each employee designated on a VAR. The VAR requires annual renewal for the duration of the employee’s performance under the contract.

Section I - Contract Clauses

CLAUSES INCORPORATED BY FULL TEXT

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these addresses:

FAR Clauses http://acquisition.gov/far/

DFARS Clauses http://www.acq.osd.mil/dpap/dars/dfars/index.htm

(End of clause) image1.wmf image2.wmf