17Q1270_Solicitation.docx

M6700117Q1270

Section SF 1449 - CONTINUATION SHEET

4.8 CU.FT. REFRIGERATOR/MICROWAVE COMBO

FFP

-Width: 18" to 20" -Height: 58" to 60" -Depth: 22" to 24" -Total capacity of the refrigerator and freezer shall equal 4.8 Cu Ft (3.4 Cu Ft for fresh food compartment, min 1.4 Cu Ft freezer compartment) -Two separate doors for each compartment -0.9 to 1.0 Cu Ft microwave capacity with glass turntable -Microwave Wattage: 850 min

- Finish: Black

- Have technology such that when microwave is in use, the refrigerator/freezer unit does not overload the system

- Must be Energy Star Compliant -Manufacturers warranty must be specified FOB: Origin (Shipping Point)

MILSTRIP: MMP20017SS00073

PURCHASE REQUEST NUMBER: MMP20017SS00073

NET AMT

INSTALLATION

INSTALLATION OF THE REFRIG/MICROWAVE COMBOS IN BARRACKS 1340.

Number of employees_______________________________

Total Hours ___________________________ FOB: Origin (Shipping Point)

MILSTRIP: MMP20017SS00073

PURCHASE REQUEST NUMBER: MMP20017SS00073

NET AMT

FREIGHT

Freight from ________________________ to Camp Lejeune NC.

FOB: Origin (Shipping Point)

NET AMT

4.8 CU.FT. REFRIGERATOR/MICROWAVE COMBO

-Width: 18" to 20" -Height: 58" to 60" -Depth: 22" to 24" -Total capacity of the refrigerator and freezer shall equal 4.8 Cu Ft (3.4 Cu Ft for fresh food compartment, min 1.4 Cu Ft freezer compartment) -Two separate doors for each compartment -0.9 to 1.0 Cu Ft microwave capacity with glass turntable -Microwave Wattage: 850 min

- Finish: Black

- Have technology such that when microwave is in use, the refrigerator/freezer unit does not overload the system

- Must be Energy Star Compliant -Manufacturers warranty must be specified FOB: Origin (Shipping Point)

MILSTRIP: MMP20017SS00055

PURCHASE REQUEST NUMBER: MMP20017SS00055

NET AMT

INSTALLATION

INSTALLATION OF REFRIGERATOR/MICROWAVE COMBOS IN BARRACKS HP-185.

Number of employees_______________________________

Total Hours ___________________________ FOB: Origin (Shipping Point)

MILSTRIP: MMP20017SS00055

PURCHASE REQUEST NUMBER: MMP20017SS00055

NET AMT

FREIGHT

Freight from ____________________________ to Camp Lejeune. NC.

NET AMT

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

STATEMENT OF WORK

1. BACKGROUND

This is an acquisition of BEQ Refrigerator/ Microwave Combination Appliances and associated delivery/ installation services. Items listed in the Purchase Request shall be delivered and installed in the above designated building. Building has (3) floors, (2) exterior stairways to left and right of building, and (1) interior stairway located center of building. All stairways connect each floor and lead to exterior cat-walks. There are NO elevators/lifts.

Currently, building is OCCUPIED. Installation will be conducted in such a manner to prevent displacement of occupants. The contractor will be required to deliver and install the items as well as remove and dispose of all packaging and installation debris.

2. SCOPE OF WORK

2.1 REQUIREMENT

Contractor shall provide the Appliances as indicated in schedule and 2.2.3. Installation. Contractor shall perform per all specifications and contract requirements.

2.2 CONTRACTOR SPECIFICATIONS

Contractor Shall:

2.2.1 Arrange Pre-Installation meeting(s) with a Base Property (Government) representative within (3) business days of contractor award. Purpose of this meeting is to coordinate both conduct of and delivery/installation schedules. Base Property Government Points of Contact are as follows:

Contact Information will be released post award

2.2.2 DELIVERY

Delivery shall be coordinated with Base Property (Government) representative. REQUEST DELIVERY NOTIFICATION A MINIMUM OF ONE

WEEK PRIOR TO DELIVERY/INSTALLATION. The successful offer or shall provide a Project Manager to be on site throughout the entire project. The Project Manager shall have authority to represent the company to coordinate all services and issues through the Contracting and Base Property Offices. All work will be conducted during the normal operating hours listed above.

Deliver all Appliances directly to the required building at time of installation. Forklift(s), temporary storage containers, trailers, and/or vehicles may be set up in vicinity of buildings, with locations as directed by the government representative. Cost of forklift and above storage means to include properly locking is the full responsibility of the contractor. NO GOVERNMENT-OWNED FORKLIFTS, WAREHOUSING, OR STORAGE FACILITIES WILL BE PROVIDED.

2.2.3 Installation

Installation of Appliances shall be coordinated with Base Property (Government) representative and IAW floor plans (provided at Pre-Installation Meeting if not received by Contract Award). Building is (3) floors, ground-load following to total (85) rooms:

Building 1340

· located on Michael Rd.

· (1) Refrigerator/Microwave Combo per room = Total (85)

Building HP-185

· located between A and C Streets

· (1) Refrigerator/Microwave Combo per room = (90)

Hallways, door frames, and individual rooms shall be protected with some form of padding. Items needed to be installed and set-up as functional. Notify a Base Property Representative if any items are found damaged/inoperable; they must be replaced.

Deviations or modifications will be redirected to the attention of the Operations Branch Head, Supply Management Division and may require approval by the Contracting Officer via a signed modification on a Standard Form 30 (SF30).

2.2.4 REMOVAL

Contractor is responsible for removal of all old refrigerator/ microwave combination to include packing materials and debris from delivery and installation to include drill dust and foot traffic (e.g. dirt, sand, mud, grass, water).

2.2.5 DISPOSAL

Contractor at own expense will return old refrigerator/microwave combination units empty of all food to warehouse/building 1212 and Clean-up/remove from the Combination Appliances all plastics, tape, card board packaging, zip ties, Styrofoam, etc.

Once a week (maximum), debris may be taken to the Materials Recycling Facility (MRF)/Landfill located on Piney Green Road (materials must be sorted as cardboard, plastic, and wood). Driver must have a copy of the contract and placard provided by Base Property to enter the site.

2.2.6 FACILITY DAMAGE

Contractor shall be responsible for all damages to buildings or surrounding areas (including lawns) when moving or installing the appliances. Damages shall be repaired by contractor at contractor’s expense before final invoicing.

2.2.7 PARKING/CONTAINERS

Contractor must provide any containers if storage is necessary. Contractor shall be responsible for ensuring all storage containers maintained on the job site are locked. Parking of equipment and vehicles will be in designated areas or in authorized parking lots (normally not on the grass or lawn).

Contractor shall provide all necessary material handling equipment and tools required to support this requirement to include non-marking, rubber-wheeled hand trucks, dollies, and carts. Contractor shall be responsible for securing all material handling equipment. The Government will not be liable for any stolen or damaged property that is left unsecured by the Contractor.

3.0 BASE ACCESS

1. In order to gain access to Marine Corps Base (MCB), Camp Lejeune and/or Marine Corps Air Station (MCAS), New River, non-Federal Government and non-DoD issued ID cardholders require identity proofing and vetting to determine fitness and eligibility for access. Specifically, a check of records through the National Crime Information Center (NCIC) Interstate Identification Index (III) is the installation’s minimum background check for access to MCB, Camp Lejeune and/or MCAS, New River for non-Common Access Card holders, to include entrance of visitors.

2. MCB, Camp Lejeune and MCAS, New River applies the following non-Federal Government cardholder criteria to determine the authorized type of access control credentials:

a. Contractors: RAPIDGate or 30-Day Pass followed by 4-DayPass*

b. Sub-Contractors: RAPIDGate or 30-Day Pass followed by 4-Day Pass*

c. Vendors: RAPIDGate or 30-Day Pass followed by 4-Day Pass*

d. Suppliers: RAPIDGate or 30-Day Pass followed by 4-Day Pass*

e. Service Providers: RAPIDGate or 30-Day Pass followed by 4-Day Pass*

f. Delivery Personnel: RAPIDGate or 30-Day Pass followed by 4-Day Pass*

g. Public-Private Venture (PPV) Housing and Installation Volunteers: Local Population Credential (The following are examples of Installation Volunteers: (Red Cross, Community College Instructors and Students, Commissary Baggers, Naval Hospital Volunteers, Family Readiness Volunteers, Wounded Warrior Volunteers, and any other organization approved by the Commanding General, Marine Corps Installation East-Marine Corps Base Camp Lejeune and Commanding Officer, MCAS, New River)

3. Contractor Common Access Card (CAC) Eligibility: Contractor personnel authorized CAC’s are exempt from RAPIDGate enrollment.

4. Contractor personnel who are ineligible for a CAC will be required to either obtain a 30-Day pass followed by a 4-Day pass* or enroll in the RAPIDGate Program. RAPIDGate is a voluntary program due to associated costs. For further information concerning contractor access, please contact the Contractor Vetting Office at 910-450-5978 or visit Marine Corps Base Camp Lejeune (http://www.lejeune.marines.mil/) or MCAS New River (http://www.newriver.marines.mil/) websites. For information concerning enrolling in RAPIDGate please visit their website at www.rapidgate.com.

The Government will not be responsible for any access delays. Delays that may result from inadequate planning are contractor responsibility.

Any and all costs associated with RAPIDGate are the sole responsibility of the contractor.

* Contractors will be issued a one-time pass for 30 days. Upon expiration of the 30 day pass, they will only be issued a 4 day pass every 4 days thereafter, for the duration of the contract.

DELIVERY INFORMATION

ROBERT RADEL

BLDG 1340 MICHAEL ROAD

CAMP LEJEUNE NC 28542

910-451-9488

MMP200

MMP200

MMP200

ROBERT RADEL

HP-185 A-STREET & C-STREET

CAMP LEJEUNE NC 28542

910-451-9488

MMP200

MMP200

MMP200

CLAUSES INCORPORATED BY REFERENCE

CLAUSES INCORPORATED BY FULL TEXT

52.212-2 EVALUATION--COMMERCIAL ITEMS (OCT 2014) (TAILORED)

(a) The Government will award a contract resulting from this solicitation to the responsible quoter whose quote conforming to the solicitation will be most advantageous to the Government, price and other factors considered.

This procurement is set-aside 100% for Small Business in accordance with FAR 19.5002-2(a).

The associated North American Industrial Classification System (NACIS) code for this procurement is 335228. The industry description for this NAICS code is Other Major Household Appliance Manufacturing. The size standard for this NACIS is 1,000 Employees.

Contracting Department, Marine Corps Installations East-Marine Corps Base, Camp Lejeune, NC, is to procure 175 4.8cu ft refrigerator/microwave combo units. This procurement is conducted in accordance with FAR Part 12, Acquisition of Commercial Items utilizing FAR Part 13, Simplified Acquisition Procedures.

Incorporated provisions and clauses are those in effect through Federal Acquisition Circular Looseleaf FAC 2005-94and95_1-19-17.pdf , effective 07-17-2017 and DFARS Change Notice (DCN) DEFENSE FAR SUPPLEMENT (DFARS) Publication Notice 20161222 effective 20161222.

BASIS OF AWARD. Award will be made to the Lowest Price Technically Acceptable (LPTA) quote.

EVALUATION. The Government intends to make a single Firm Fixed Price award to satisfy this requirement. Award will be made on the initial evaluation of quotes received in response to this RFQ. Therefore, quoters are cautioned to ensure that initial quotes contain your best terms from a technical and price standpoint. The following factor shall be used to evaluate quotes:

Technical acceptability:

Delivery : BUILDING HP 185 is 30 AUGUST 2017 and Delivery: BUILDING 1340 is 29 SEPTEMBER 2017

Price. All quotes must be the Contractor’s Best Pricing.

SAM. Offerors must be registered in the System for Award Management (SAM) database. Information in SAM should be current, if not; completion of the attached FAR Provision 52.212-3, Certifications and Representations is required with quotation. Information on registering in SAM may be obtained from www.sam.gov or calling 866-606-8220.

WIDE-AREA WORKFLOW (WAWF)/ iRAPT RECEIPT AND ACCEPTANCE. As a condition of receipt of any resulting order, the Contractor agrees to implement the Department of Defense (DoD) web-based application. Information on registering in WAWF/iRAPT may be obtained from https://wawf.eb.mil/xhtml/unauth/registration/notice.xhtml or calling 866-618-5988.

SUBMISSION REQUIREMENTS.

QUESTIONS. Questions related to this RFQ shall be received by the Contracting Department by 07/24/2017 @ 1:00PM EST. Responses to questions will be provided via Amendment to the RFQ.

SUBMISSION OF QUOTES. Quotes related to this RFQ shall be received by the Contracting Department by the date and time indicated in block 8 on the front page of the solicitation to be considered for award. The information submitted shall be clear and legible. Quotes may be submitted via email to, Margaret Velez, margaret.velez@usmc.mil , 910.451.9034 or Fax: 910-451-2332. It is solely the Contractor’s responsibility to ensure quotes are received within the required timeframe. Submission of quotation shall include the following:

Technical capability to meet or exceed the requirements outlined in RFQ to evaluate compliance with the requirement, including product literature;

Clearly state ability to meet specified Delivery Date Delivery : BUILDING HP 185 is 30 AUGUST 2017 and Delivery: BUILDING 1340 is 29 SEPTEMBER 2017.

Quoter has completed the annual representations and certification electronically on System for Award Management (SAM) account, if not complete FAR provision 52.212-3 paragraphs (c) through (p);

Confirm pricing is open market and not on GSA Schedule; and

Provide quoter’s CAGE Code and DUNS Number.

(End of Provision)

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (JAN 2017)

The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision --

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means—

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: ``Guidance for Executive Order 13673, `Fair Pay and Safe Workplaces' ''. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) Concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for--

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

"Forced or indentured child labor" means all work or service-

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of ``labor laws''.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except--

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Predecessor” means an entity that is replaced by a successor and includes any predecessors of the predecessor.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate--

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology--

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically--

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

Service-disabled veteran-owned small business concern--

(1) Means a small business concern--

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

"Small business concern" means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern”, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned--

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Successor” means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

“Veteran-owned small business concern” means a small business concern--

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

"Women-owned business concern" means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

"Women-owned small business concern" means a small business concern--

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of its stock is owned by one or more women; or

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127)”, means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: ``Administrative merits determination'', ``Arbitral award or decision'', paragraph (2) of ``Civil judgment'', ``DOL Guidance'', ``Enforcement agency'', ``Labor compliance agreement'', ``Labor laws'', and ``Labor law decision''. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(b) (1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted electronically on the SAM website.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications--Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ___ .

[Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any.) These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on ORCA.]

(c) Offerors must complete the following representations when the resulting contract will be performed in the United States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a small business concern.

(2) Veteran-owned small business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a veteran-owned small business concern.

(3) Service-disabled veteran-owned small business concern. (Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.) The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a service-disabled veteran-owned small business concern.

(4) Small disadvantaged business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents that it ( ___ ) is, ( ___ ) is not a small disadvantaged business concern as defined in 13 CFR 124.1002.

(5) Women-owned small business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents that it ( ___ ) is, ( ___ ) is not a women-owned small business concern.

Note to paragraphs (c)(8) and (9): Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold.

(6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that--

(i) It [ ___ ] is, [ ___ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: ___ .] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that--

(i) It [ ___ ] is, [ ___ ] is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: ___ -.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(8) Women-owned business concern (other than small business concern). (Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents that it ( ___ ) is, a women-owned business concern.

(9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:

(10) HUBZone small business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents, as part of its offer, that--

(i) It [ ___ ] is, [ ___ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and

(ii) It [ ___ ] is, [ ___ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: ___ .] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(d) Certifications and representations required to implement provisions of Executive Order 11246--

(1) Previous Contracts and Compliance. The offeror represents that--

(i) It ( ___ ) has, ( ___ ) has not, participated in a previous contract or subcontract subject either to the Equal Opportunity clause of this solicitation, the and

(ii) It ( ___ ) has, ( ___ ) has not, filed all required compliance reports.

(2) Affirmative Action Compliance. The offeror represents that--

(i) It ( ___ ) has developed and has on file, ( ___ ) has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 CFR Subparts 60-1 and 60-2), or

(ii) It ( ___ ) has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor.

(e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made.

(f) Buy American Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy American --Supplies, is included in this solicitation.)

(1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.” The terms “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American--Supplies.”

(2) Foreign End Products:

(List as necessary)

(3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(g)(1) Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms ``Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product,'' ``commercially available off-the-shelf (COTS) item,'' ``component,'' ``domestic end product,'' ``end product,'' ``foreign end product,'' ``Free Trade Agreement country,'' ``Free Trade Agreement country end product,'' ``Israeli end product,'' and ``United States'' are defined in the clause of this solicitation entitled ``Buy American--Free Trade Agreements--Israeli Trade Act.''

(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled ``Buy American--Free Trade Agreements--Israeli Trade Act'':

Free Trade Agreement Country End Products (Other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:

[List as necessary]

(iii) The offeror shall list those supplies that are foreign end products (other than those listed in paragraph (g)(1)(ii) of this provision) as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act." The offeror shall list as other foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.”

Other Foreign End Products:

(iv) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(2) Buy American Act-Free Trade Agreements-Israeli Trade Act Certificate, Alternate I (Jan 2004). If Alternate I to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products as defined in the clause of this solicitation entitled "Buy American -Free Trade Agreements-Israeli Trade Act":

Canadian End Products:

Line Item No.

(3) Buy American-Free Trade Agreements-Israeli Trade Act Certificate, Alternate II (Jan 2004). If Alternate II to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products or Israeli end products as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act":

Canadian or Israeli End Products:

(4) Buy American--Free Trade Agreements--Israeli Trade Act Certificate, Alternate III. If Alternate III to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled ``Buy American --Free Trade Agreements--Israeli Trade Act'':

Free Trade Agreement Country End Products (Other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:

(5) Trade Agreements Certificate. (Applies only if the clause at FAR 52.225-5, Trade Agreements, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(5)(ii) of this provision, is a U.S.-made or designated country end product, as defined in the clause of this solicitation entitled ``Trade Agreements''.

(ii) The offeror shall list as other end products those end products that are not U.S.-made or designated country end products.

Other End Products:

(iii) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. For line items covered by the WTO GPA, the Government will evaluate offers of U.S.-made or designated country end products without regard to the restrictions of the Buy American statute. The Government will consider for award only offers of U.S.-made or designated country end products unless the Contracting Officer determines that there are no offers for such products or that the offers for such products are insufficient to fulfill the requirements of the solicitation.

(h) Certification Regarding Responsibility Matters (Executive Order 12689). (Applies only if the contract value is expected to exceed the simplified acquisition threshold.) The offeror certifies, to the best of its knowledge and belief, that the offeror and/or any of its principals--

(1) [ ___ ] Are, [ ___ ] are not presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(2) [ ___ ] Have, [ ___ ] have not, within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a Federal, state or local government contract or subcontract; violation of Federal or state antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property; and

(3) [ ___ ] Are, [ ___ ] are not presently indicted for, or otherwise criminally or civilly charged by a Government entity with, commission of any of these offenses enumerated in paragraph (h)(2) of this clause; and

(4) [ ___ ] Have, [ ___ ] have not, within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied.

(i) Taxes are considered delinquent if both of the following criteria apply:

(A) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(B) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(ii) Examples.

(A) The taxpayer has received a statutory notice of deficiency, under I.R.C. §6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appear rights.

(B) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C.