M6700123Q0008 AMMENDED DUE DATE AND TIME.pdf

SEE ADDENDUM

(No Collect Calls)

M6700123Q0008 18-Aug-2023

b. TELEPHONE NUMBER

910451-1244

8. OFFER DUE DATE/LOCAL TIME

02:00 PM 18 Sep 2023

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

M670019. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

NICHOLAS M ROMER

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

M126603287478

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

M67001MARINE CORPS FIELD CONTRACTING SYS

ATTN: NICHOLAS ROMER

PO BOX 8368

CAMP LEJEUNE NC 28542

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE M27110 16. ADMINISTERED BY

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

2D FSSG

JENNIFER PICAZO

BLDG 1012 2ND SUP BD STORAGE

CAMP LEJEUNE NC 28542

TEL: 910-451-6867 FAX:

910-451-1275FAX:

TEL: 910-451-1244

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

NAICS:

337126

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF49

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

M6700123Q0008

Section SF 1449 - CONTINUATION SHEET

NOTICE TO OFFERORS

SUBMISSION OF QUOTES: Quotes may be submitted via email (no larger than 2 MB) to nicholas.m.romer@usmc.mil; (PREFERRED METHOD) or via hand delivery/courier to Contracting Department, Bldg. 316 G Street, Camp Lejeune, NC 28542. It is solely the Offeror’s responsibility to ensure quotes are submitted in accordance with the FAR provision 52.212-1 including its addenda and received by the offer due date and time in block eight (8) of the RFQ. All quotes, if timely received, will be considered for award. The information submitted shall be clear and legible.

QUESTIONS: Questions related to this Request for Quote (RFQ) shall be received by the Contracting Department by 25 August 2023 at 1:00 PM (Eastern Standard Time). Responses to questions received will be provided via an Amendment to the RFQ.

mailto:nicholas.m.romer@usmc.mil

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 268 Each Microfridge / Freezer / Microwave

FFP

MicroFridge

10.3 CuFt Refrigerator/Freezer/Microwave Combo

-Width: 22" to 24"

-Height: 68" to 72"

-Depth: 25" to 27"

-Total capacity of the refrigerator and freezer shall not exceed 10.3 Cu Ft

-Two separate doors for each compartment

-Must be Energy Star Compliant

-Finish: Black

-Refrigerator Section Minimum Requirements:

--2 full-width wire shelves, 3 full-width door shelves, 2-liter bottle storage, temperature control, transparent crisper, Auto-Defrost, white interior

-Freezer Section Minimum Requirements:

--1 full-width wire shelf, 2 full-width door shelves, Auto-Defrost, white interior

-Cabinet Minimum Requirements:

--integrated door handle, reversible door hinge, leveling legs

--power cord length: 5ft – 8 ft

-Microwave Minimum Requirements:

--removable glass turntable

--0.9 – 1.0 Cu Ft capacity

--Microwave Wattage: 800 Watts

--Technology such that the refrigerator/freezer component is plugged into the microwave’s rear outlet for 1-plug operation that provides protection against power surges and circuit overloads.

FOB: Destination

PURCHASE REQUEST NUMBER: M126603287478

PSC CD: 7195

NET AMT

0002 536 Each Ergonomic Chair

FFP

Ergonomic chair

-Five-star base multi-functional task chair without arms, 360 swivel-tilt, tilt lock control, adjustable tilt tension and height adjustment function

-Weight Cap: minimum of 175 pounds

-Hard surface casters

-Seat padding shall be custom molded, contoured high-density polyurethane foam

1-5/8 Inches thick minimum

-Upholstery shall be vinyl, minimum of 140,000 double rubs

-Vinyl Specification must be provided at time of submission

-Meets CA bulletin 117 Class 1 Fire Codes

-Color: Black

-Manufacturer’s Warranty: 10 years

FOB: Destination

0003 536 Each Mattresses

FFP

-Width: 36 inches to 38 inches

-Length: 78 inches to 80 inches

-Thickness: 8 inches to 10 inches

-Provide two-sided Twin XL mattress with minimum 364 double, heat-tempered steel, Bonnell innerspring coils (12.75 gauge minimum), each coil with minimum one turn per inch.

-Edge support with 6-gauge minimum border wire secured to the outer row of perimeter coils by helicals to protect the edges from premature breakdown.

-Wire border must be butt-welded at ends (support seating usage).

-All sides shall be completely enclosed with adequate padding so no sharp edges or coils can be felt through sides.

-Smooth, dark- colored, outer-cover of breathable, soft, and comfortable polyurethane-coated nylon fabric or similar Polybrominated Diphenyl Ether

(PDBE) and Polyvinyl Chloride (PVC) material and shall have inverted seams to resist raveling and zippering if stitches are broken or cut.

-Mattress shall have a bonded, flame resistant and chemical-free insulation pad or fire retardant fiber (laminated to the outer cover) on top and bottom as a fire barrier.

-Beneath the fire barrier, a minimum of 1.5 thick High Resilience (HR) polyurethane high density foam with an unfilled density of at least 1.5 pounds per cubic foot and minimum Indentation Load Deflection (ILD) of 30 on both sides of mattress

-Product must be fluid proof, hypoallergenic, bug resistant, antimicrobial, antistatic, crack resistant, and flame retardant Flame retardant chemicals shall not be used to meet FR requirements Meet CPSC 16 CFR 1632 and 16 CFR 1633

-Manufacturer’s warranty at least 5 years

FOB: Destination

0004 16 Each Bar Height Stools

FFP

Armless Metal Barstool with Pad Seat and Metal Back

-Width: 17.5 inches (+/- 2 inches)

-Depth: 20 inches (+/- 2 inches)

-Height: 42 inches (+/- 2 inches)

-Heavy Duty Square 18-gauge Steel Frame, joints fully welded, no tack or spot welds, standard powder coat finish

-Minimum 300 pounds capacity

-Seat: solid plywood construction with minimum 1 inch foam padding

-Stool Back: metal ladder-style with minimum 3 horizontal crossbars welded to outer frame (no screws)

-Seat cover fabric:

--Beige

--Vinyl or Polyurethane: 100%

--Backing: Polyester

--Durability: minimum 100,000 double rubs

--Minimum 50 percent Dyed Solution

--Advanced soil, stain protection, anti-microbial, anti-bacterial, fluid barrier

--PVC Free, BPA Free

-Steel Frame: Color to be determined at Pre-Installation Meeting

-Harden screws

-Vinyl Floor Glides

-Flammability

--California TB 133, Flammability Test Procedure for Seating and Foam to meet

Flame Retardant standards FAR 25.853-25 (BF)

-Manufacturer’s Warranty: 5 years

FOB: Destination

0005 4 Each Bar Height Round Table

FFP

Table Top: 36-inch Diameter

-Overall table height 40-44 inches

-Table Top: High-density recycled engineered core, use of phenolic backing sheet to prevent delamination

-Laminate Top: Minimum Grade 2, Maximum Grade 3; color/beige

-Minimum 1.25-inch Urethane Edge Profile

-Urethane Edge Finish, Standard grade, color to be determined at Pre-Installation

Meeting

-Table Base: Shall be X base

-Metal Finish

-Solid cast iron (non-hollow) or 16–18 gauge steel tubing Base and Column

-Welded Construction

-Molded Plastic Glides

-Manufacturer’s Warranty: 5 years

FOB: Destination

0006 1 Each Removal, Disposal, and Installation

FFP

Removal and disposal of like items, and the installation of new items purchased under this contract per the Installation and Removal Instructions.

FOB: Destination

PSC CD: N072

INSTALLATION AND REMOVAL

Removal, Disposal, Delivery, and Installation of BEQ Items for Barracks WC130 and WC135

1.0 GENERAL REQUIREMENT. This is an acquisition of Bachelor Enlisted Quarters (BEQ) items to include associated delivery/installation services and the removal/disposal of existing BEQ items for Barracks WC130 and

WC135 aboard Marine Corps Base (MCB) Camp Lejeune, NC.

2.0 REQUIREMENT. The contractor shall provide all personnel, supervision, supplies, materials, equipment, tools, and transportation necessary to provide the removal and disposal of BEQ items. The contractor will then install the requested items in the barracks.

3.0 LOCATION. BEQs WC130 and WC135 are located on Endurance Drive aboard MCB Camp Lejeune, NC. The BEQ has five (5) floors, two exterior staircases to the left and right of buildings, and one interior staircase located in the center of each building. All staircases connect each floor and lead to exterior cat-walks. There are

NO elevators/lifts available for use by the contractor. The dimensions of the entry doors to each building are 6ft wide by 7ft tall. The stairs are 3.9ft wide by 13.5ft tall. The door to enter the stairway is 3ft wide by 7ft tall.

Currently, the building is OCCUPIED. Installation shall be conducted in such a manner to prevent displacement of occupants. A phasing plan can be discussed to effectively install the items. Due to high tempo of operations, there could be times where the barracks are less occupied than others.

The 2nd Battalion 8th Marines BEQ manager will be physically present during the installation and removal of all furniture.

4.0 TASKS.

4.1 PRE-INSTALLATION MEETING. The contractor shall arrange Pre-Installation meeting(s) with an the

Government Representative within three (3) business days of contract award. The purpose of this meeting is to coordinate delivery/installation schedules and finalize colors, fabrics, and patterns in accordance with the contract.

All material samples, care instructions, and warranties will be provided at this time.

4.2 DELIVERY. Delivery shall be coordinated with the Government Representative. A DELIVERY

NOTIFICATION SHALL BE PROVIDED A MINIMUM OF ONE WEEK PRIOR TO

DELIVERY/INSTALLATION to the Government Representative and Contract Administrator. The contractor shall provide a Project Manager to be on site throughout the entire project. The Project Manager shall have authority to represent the company to coordinate all services and issues through the Contracting Office and

Government Representative. All work will be conducted during normal operating hours. Normal operating hours are 7:30 AM EST – 4:00 PM EST, Monday through Friday. Closed on weekends and Federal Holidays.

Deliver all items directly to the required buildings at time of installation. All items delivered on site will remain as contractor property until items are fully installed into quarters or lounge areas.

4.2.1 PARKING. Parking of equipment and vehicles will be in designated areas or in authorized parking lots

(normally not on the grass or lawn). If additional parking is needed coordinate with the Government Representative.

An area will be marked off for the delivery vehicles to park that is closest to both BEQs.

4.2.2 EQUIPMENT. The contractor shall provide all necessary material handling equipment, tools, and vehicles required to support this requirement to include non-marking, rubber-wheeled hand trucks, dollies, carts, and forklifts. No Government owned toole, forklifts, warehousing, or storage facilities will be provided. The contractor shall be responsible for securing all material handling equipment.

4.3 INSTALLATION. Installation of items shall be coordinated with the Government Representative in accordance with the floor plans. BEQ furniture items must be installed and set-up as functional. The contractor shall notify the Government representative if any items are found to be damaged/inoperable as they must be replaced. Hallway, door frames, flooring, and individual rooms shall be protected with some form of padding.

4.3.1 FLOOR PLANS.

4.3.1.1 Sleeping Space Items.

WC 130

Quantity Per Room Item Total

2 Mattresses 268

2 Ergonomic Task Chair 268

1 Refrigerator/ Freezer/ Microwave Combo 134

WC 135

Quantity Per Room Item Total

2 Mattresses 268

2 Ergonomic Task Chair 268

1 Refrigerator/ Freezer/ Microwave Combo 134

4.3.1.2 1st Floor Lounge Items.

WC-130

Quantity Item

4 Bar Height Round Tables

16 Bar Height Stools

WC-135

Quantity Item

4 Bar Height Round Tables

16 Bar Height Stools

4.4 REMOVAL AND DISPOSAL. The contractor shall be responsible for the removal and disposal of like items being provided under this contract that have reached their end of useful life.

Refrigeration equipment must be certified free of freeon by base enviromental before disposal.

Note: The contractor will abide by the contract clause under 52.223-12 for implementing proper recovery, recycling, and responsible disposal. The Government will not bear responsibility of any executed removal/disposal conducted by the contractor. The contractor becomes fully responsible for removal/disposal of equipment in their possession.

4.4.1 REMOVAL AND DISPOSAL OF PACKING MATERIALS. The contractor shall remove all packing materials including plastics, tape, cardboard packaging, zip ties, and styrofoam from the items and properly dispose of all materials and debris. Once a day (maximum), the contractor may take debris to the Materials Recycling

Facility/Landfill located on Piney Green Road aboard Camp Lejeune. Materials must be sorted as cardboard

(broken-down), plastic, and wood. Driver must have a copy of the contract and placard provided by the Government

Representative to enter the site and drop off materials.

5.0 JOB SITE. The contractor shall be responsible for cleaning the installation area and disposing of all trash and materials to include drill dust and dirt from foot traffic to the satisfaction of the Government’s representative or designated inspectors before completion of each work day and upon completion of the project. At the end of the project, the contractor shall restore any disturbed or damaged areas at the direction of the Contracting Officer.

6.0 WARRANTY. The contractor shall provide all warranty information and documents in the quote package to include information and documentation for any manufacturer's warranty.

7.0 FACILITY DAMAGE. Contractor shall be responsible for all damages to buildings and/or surrounding areas (including grass/lawns) when moving or installing items. Hallway, door frames, flooring, and individual rooms shall be protected with some form of padding. Damages shall be repaired by the contractor at the contractor’s expense before final invoicing.

8.0 RESPONSIBILITY. The Government will not be responsible in any way for the contractor's personal supplies, equipment, materials, or belongings brought onto the grounds to perform services. This includes, but is not limited to loss or damage caused by fire, theft, hurricane, accident or other disaster.

9.0 CONTRACTOR UNAUTHORIZED WORK PERFORMANCE. The contractor shall not perform work that deviates from contract requirements and specifications. If the contractor deviates from contract requirements and specifications without approval of the CONTRACTING OFFICER, such deviation shall be at the risk of the contractor and any cost related thereto shall be borne by the contractor.

10.0 GOVERNMENT POINTS OF CONTACT. The Government points of contact are not warranted

Contracting Officers and do not have the authority to take any action, either directly or indirectly, that would change the pricing, quantity, place of performance, delivery schedule, or any other terms and conditions of the contract.

10.1 CONTRACT ADMINISTRATOR. To be provided at time of award.

10.2 GOVERNMENT REPRESENTATIVE. To be provided at time of award.

11.0 BASE ACCESS. -To gain initial access to the base, Contractors and/or Delivery Drivers must have in their possession: their contract number, delivery address, and sponsor’s contact information.

For SERVICES the Contracting Officer’s Representative (COR) is the sponsor.

For delivery of SUPPLIES the customer/delivery point of contact is the sponsor.

Contract Number:

Sponsor/COR: To be provide at time of award

Phone Number:

Delivery Address:

-Contractors must be registered in the Defense Biometrics Identification System (DBIDS). It is the Contractor’s responsibility to ensure all their employees and/or subcontractors are properly registered within DBIDS.

-DBIDS credentials will be valid for the duration of your contract, not to exceed three years; however, re-vetting of individuals' information will occur each year.

-Contractors requiring access for over 60 days will receive a credential valid for up to one year.

-Contractors requiring access for less than 60 days will receive a temporary paper pass.

-Contractor Common Access Card (CAC) Eligibility: Contractor personnel authorized CACs are exempt from

DBIDS enrollment.

-If you have questions regarding base access, Contractor CACs, or DBIDS requirements, contact the Contractor

Vetting Office (CVO). The CVO is located in Bldg. 818 adjacent to the Camp Lejeune Main Gate on Holcomb

Blvd, just off NC Highway 24. The CVO is open Monday through Friday from 6 a.m. to 2 p.m. and closed on weekends and holidays.

Contractor Vetting Office - :910-451-3353/3478/3220/3359 (For awarded contracts only)

Visitor Center Office - : 910-450-0283/0284/0287 (For any site visits, open 5am-9pm, must

(have the REAL ID)

Taxi Vetting: 910-449-4208

Vetting Office Email: lejeunecontractorvetting@usmc.mil

Visitor Center Email: lejeunevisitorcenter@usmc.mil mailto:lejeunecontractorvetting@usmc.mil

DBIDS email: https://dbids-global-enroll.dmdc.mil/preenrollui/#!/

-Contractors will report to the Contractor Vetting Office (CVO) to confirm their access requirements, undergo a background check and receive their credential/pass.

PLEASE NOTE: Individuals with active warrants may be subject to arrest on the spot.

**The Government will not be responsible for any contractor access delays. Delays that may result from inadequate planning are strictly the responsibility of the contractor.

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

0002 Destination Government Destination Government

0003 Destination Government Destination Government

0004 Destination Government Destination Government

0005 Destination Government Destination Government

0006 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 5 mths. ADC 268 2D FSSG

JENNIFER PICAZO

BLDG 1012 2ND SUP BD STORAGE

CAMP LEJEUNE NC 28542

910-451-6867

M27110

0002 5 mths. ADC 536 (SAME AS PREVIOUS LOCATION)

0003 5 mths. ADC 536 (SAME AS PREVIOUS LOCATION)

0004 5 mths. ADC 16 (SAME AS PREVIOUS LOCATION)

0005 5 mths. ADC 4 (SAME AS PREVIOUS LOCATION) https://dbids-global-enroll.dmdc.mil/preenrollui/#!/

0006 5 mths. ADC 1 (SAME AS PREVIOUS LOCATION)

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions JUN 2020

52.203-3 Gratuities APR 1984

52.203-11 Certification And Disclosure Regarding Payments To

Influence Certain Federal Transactions

SEP 2007

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

JUN 2020

52.203-18 Prohibition on Contracting With Entities That Require Certain

Internal Confidentiality Agreements or Statements--

Representation

JAN 2017

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-7 System for Award Management OCT 2018

52.204-13 System for Award Management Maintenance OCT 2018

52.204-16 Commercial and Government Entity Code Reporting AUG 2020

52.204-18 Commercial and Government Entity Code Maintenance AUG 2020

52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-22 Alternative Line Item Proposal JAN 2017

52.211-17 Delivery of Excess Quantities SEP 1989

52.212-1 Instructions to Offerors--Commercial Products and

Commercial Services

MAR 2023

ADDENDA TO 52.212-1

Addendum to paragraph (b)(4):

The offeror shall submit with their offer:

Technical Capability:

Descriptive literature outlining the specifications of the items quoted to include drawings, the manufacturer’s name, and manufacturer’s complete part numbers of all items offered.

Addendum to paragraph (b)(6):

The offeror shall submit with their offer:

Price:

The price offered must reflect unit prices, extended amounts per line item, and overall total. (Note:

All prices must be actual “face-value’ pricing having already accounted for any discounts offered and extended to the Government).

(End of Addenda to Provision)

CLAUSES INCORPORATED BY REFERENCE

52.212-4 Contract Terms and Conditions--Commercial Products and

Commercial Services

DEC 2022

52.219-1 Alt I (Dev) Small Business Program Representations (Deviation 2023-

O0002) Alternate I

SEP 2015

52.219-8 (Dev) Utilization of Small Business Concerns (Deviation 2023-

O0002)

DEC 2022

52.219-14 (Dev) Limitations on Subcontracting (DEVIATION 2021-O0008) FEB 2023

52.228-5 Insurance - Work On A Government Installation JAN 1997

52.232-17 Interest MAY 2014

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013

52.233-1 Disputes MAY 2014

52.237-2 Protection Of Government Buildings, Equipment, And

Vegetation

APR 1984

52.242-13 Bankruptcy JUL 1995

52.247-34 F.O.B. Destination NOV 1991

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights DEC 2022

252.203-7005 Representation Relating to Compensation of Former DoD

Officials

SEP 2022

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.204-7004 Antiterrorism Awareness Training for Contractors JAN 2023

252.204-7015 Notice of Authorized Disclosure of Information for Litigation

Support

JAN 2023

252.204-7018 Prohibition on the Acquisition of Covered Defense

Telecommunications Equipment or Services

JAN 2023

252.204-7024 Notice on the Use of the Supplier Performance Risk System MAR 2023

252.205-7000 Provision Of Information To Cooperative Agreement Holders JUN 2023

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of

Terrorism

MAY 2019

252.215-7007 Notice of Intent to Resolicit JUN 2012

252.215-7008 Only One Offer DEC 2022

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JAN 2023

252.223-7997 (Dev) Prohibition on Procurement of Certain Items Containing

Perfluorooctane Sulfonate or Perfluorooctanoic Acid -

Representation (DEVIATION 2022-O0010)

SEP 2022

252.223-7998 (Dev) Prohibition on Procurement of Certain Items Containing

Perfluorooctane Sulfonate or Perfluorooctanoic Acid

(DEVIATION 2022-O0010)

SEP 2022

252.225-7001 Buy American And Balance Of Payments Program--Basic JAN 2023

252.225-7002 Qualifying Country Sources As Subcontractors MAR 2022

252.225-7048 Export-Controlled Items JUN 2013

252.225-7052 Restriction on the Acquisition of Certain Magnets, Tantalum, and Tungsten.

JAN 2023

252.225-7055 Representation Regarding Business Operations with the

Maduro Regime

MAY 2022

252.225-7056 Prohibition Regarding Business Operations with the Maduro

Regime

JAN 2023

252.225-7059 Prohibition on Certain Procurements from the Xinjiang

Uyghur Autonomous Region - Representation

JUN 2023

252.225-7968 (Dev) Restriction on Acquisition of Personal Protective Equipment and Certain Other Items from Non-Allied Foreign Nations.

(DEVIATION 2022-O0008)

MAR 2022

252.225-7974 (Dev) Representation Regarding Business Operations with the

Maduro Regime (DEVIATION 2020-O0005)

FEB 2020

252.226-7001 Utilization of Indian Organizations, Indian-Owned Economic

Enterprises, and Native Hawaiian Small Business Concerns

JAN 2023

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.239-7098 (Dev) Prohibition on Contracting to Maintain or Establish a

Computer Network Unless Such Network is Designed to

Block Access to Certain Websites - Representation.

(Deviation 2021-O0003)

APR 2021

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.243-7002 Requests for Equitable Adjustment DEC 2022

252.244-7000 Subcontracts for Commercial Products or Commercial

Services

JAN 2023

252.247-7023 Transportation of Supplies by Sea JAN 2023

CLAUSES INCORPORATED BY FULL TEXT

52.204-24 REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT (NOV 2021)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in paragraph (c)(1) in the provision at 52.204-26, Covered Telecommunications Equipment or Services--

Representation, or in paragraph (v)(2)(i) of the provision at 52.212-3, Offeror Representations and Certifications-

Commercial Products and Commercial Services. The Offeror shall not complete the representation in paragraph

(d)(2) of this provision if the Offeror has represented that it "does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services" in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3.

(a) Definitions. As used in this provision-

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause

52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or

Equipment.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM)

(https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services."

(d) Representations. The Offeror represents that--

(1) It [ ___ ] will, [ ___ ] will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The

Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that--

It [ ___ ] does, [ ___ ] does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)(2) of this section.

(e) Disclosures.

(1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as

OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered

(include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as

OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered

(include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(End of provision)

52.204-26 COVERED TELECOMMUNICATIONS EQUIPMENT OR SERVICES--REPRESENTATION (OCT

2020)

(a) Definitions. As used in this provision, “covered telecommunications equipment or services” and "reasonable inquiry" have the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain

Telecommunications and Video Surveillance Services or Equipment.

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM)

(https://www.sam.gov) for entities excluded from receiving federal awards for “covered telecommunications equipment or services”.

(c) Representations.

(1) The Offeror represents that it [ ___ ] does, [ ___ ] does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

https://www.sam.gov/

(2) After conducting a reasonable inquiry for purposes of this representation, the offeror represents that it [ ___ ] does, [ ___ ] does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian

Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a

Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than

$10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the

Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

52.212-2 EVALUATION--COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (NOV 2021)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

BASIS OF AWARD: Quotes will be evaluated based on price alone.

This acquisition will be conducted in accordance with FAR Part 12, Acquisition of Commercial Products and Commercial Services and FAR Part 13.5 Simplified Procedures for Certain Commercial Items.

(b) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s).

(c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer’s specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

(End of Provision)

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS - COMMERCIAL PRODUCTS AND

COMMERCIAL SERVICES (DEVIATION 2023-O0002) (DEC 2022) ALTERNATE I (OCT 2014)

The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically in the System for Award Management (SAM) accessed through https://www.sam.gov. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (v) of this provision.

(a) Definitions. As used in this provision -

Covered telecommunications equipment or services has the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

Economically disadvantaged women-owned small business (EDWOSB) concern means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127, and the concern is certified by SBA or an approved third-party https://www.sam.gov/ certifier in accordance with 13 CFR 127.300. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

Forced or indentured child labor means all work or service -

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

Highest-level owner means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

Immediate owner means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

Inverted domestic corporation means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

Manufactured end product means any end product in product and service codes (PSCs) 1000-9999, except -

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

Place of manufacture means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

Predecessor means an entity that is replaced by a successor and includes any predecessors of the predecessor.

Reasonable inquiry has the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain

Telecommunications and Video Surveillance Services or Equipment.

Restricted business operations means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the

Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment

Act of 2007) conducting the business can demonstrate -

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology -

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically -

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act

(50 U.S.C. 1702(b)(3)).

Service-disabled veteran-owned small business concern -

(1) Means a small business concern -

(i) Not less than 51 percent of which is owned by one or more service - disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

Small business concern –

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation, and qualified as a small business under the criteria in 13 CFR part 121 and size standards in this solicitation.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13

CFR 121.103.

Small disadvantaged business concern, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that -

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by -

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $850,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

Subsidiary means an entity in which more than 50 percent of the entity is owned -

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

Successor means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

Veteran-owned small business concern means a small business concern -

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

Women-owned business concern means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

Women-owned small business concern means a small business concern -

(1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least

51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127), means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the

United States, and the concern is certified by SBA or an approved third-party certifier in accordance with 13 CFR

127.300.

(b)(1) Annual Representations and Certifications. Any changes provided by the Offeror in paragraph (b)(2) of this provision do not automatically change the…