ITB_CIGP_6TH_STREET_EP.pdf
PDF 142 KB Posted
- Attached to
- 6th Street Widening and Resurfacing CIGP
- Solicitation number
- 50192285
- Issued by
- Franklin County, Florida
About this file
This is an Advertisement for Bids issued by the Franklin County Board of County Commissioners in Florida for the 6th Street Widening and Resurfacing CIGP project. The project encompasses the widening and resurfacing of 6th Street in Eastpoint, Florida for approximately 0.149 miles extending from U.S. Highway 98 to Avenue A, along with necessary drainage improvements, upgraded signage and pavement markings, and safety improvements. All bidders must be FDOT qualified in the work classes of Grading, Drainage, Flexible Paving, and Hot Plant mix-Bituminous Course per Section 2-1 of the FDOT Standard Specifications for Road and Bridge Constructions. Sealed bids must be submitted to the Franklin County Clerk's Office, Franklin County Courthouse, 33 Market Street, Suite 203, Apalachicola, Florida 32320-2317, no later than 4:30 p.m. eastern time on December 15, 2026. Bids will be opened and read aloud on Wednesday, December 16, 2026, at the County Commission meeting held at 34 Forbes Street, Apalachicola, Florida. The project has a Substantial Completion date of 90 calendar days from the Notice to Proceed, with liquidated damages assessed at $750.00 per day for failure to meet the specified completion date. All bids must remain firm for sixty days after opening, and technical questions must be submitted in writing to Josh Stephens at jstephens@dewberry.com no later than November 16, 2026.
The Franklin County Board of County Commissioners reserves the right to waive informalities, accept or reject any or all bids, and select the bid determined to be in the best interest of Franklin County. All bidders must comply with Section 287.133(3) Florida Statutes regarding public entity crimes and all applicable State and local laws concerning contractor licensing, registration, and regulation. Plans and specifications are available from Shannon Renfro at Dewberry (srenfro@dewberry.com). No set-asides, incumbent information, or specific pricing terms are identified in this advertisement.
View the file
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
ADVERTISEMENT FOR BIDS-00010
6TH STREET WIDENING AND RESURFACING CIGP PROJECT #50192285
NOTICE TO RECEIVE SEALED BIDS
The Franklin County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing:
6TH STREET WIDENING AND RESURFACING CIGP
FPID NO. 457424-1-54-01
The project is the widening and resurfacing of 6TH Street (Eastpoint, Fl) for approximately 0.149 miles from U.S. Highway 98 to Avenue A. Other work includes necessary drainage improvements, upgraded signage and pavement markings and safety improvements.
Plans and specifications can be obtained by contacting Shannon Renfro with Dewberry at srenfro@dewberry.com. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
All bidders shall be FDOT qualified per Section 2-1 of the FDOT Standard Specifications for Road and Bridge Constructions, latest edition in the following work classes: Grading, Drainage, Flexible Paving, and Hot Plant mix-Bituminous Course.
Substantial Completion date for this project will be 90 calendar days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $750.00 per day.
Please indicate on the envelope that this is a sealed bid, for “6TH STREET WIDENING AND
RESURFACING CIGP”.
Bids will be received until 4:30 p.m. eastern time, on December 15, 2026, at the Franklin County Clerk's Office, Franklin County Courthouse, 33 Market Street, Suite 203, Apalachicola, Florida 32320-2317, and will be opened and read aloud on Wednesday, December 16, 2026, at the County Commission meeting at 34 Forbes Street, Apalachicola, FL.
The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin County. All bids shall remain firm for a period of sixty days after the opening.
All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.
All technical questions must be addressed in writing and emailed to Josh Stephens at jstephens@dewberry.com no later than November 16, 2026.
mailto:srenfro@dewberry.com mailto:jstephens@dewberry.com
File details come from the government source that posted it. Updated .