ITB 2023-157-DF PreQual for GC_REPOST_PREQUAL.pdf

INVITATION TO BID (ITB) 2023-157-DF

PREQUALIFICATION POOL OF CONTRACTORS

FOR MINOR PROJECTS

TABLE OF CONTENTS

SECTIONS:

0100 GENERAL INFORMATION & SCOPE OF WORK

APPENDICES:

APPENDIX A PREQUALIFICATION APPLICATION

APPENDIX B SPECIAL CONDITIONS

APPENDIX C INSURANCE REQUIREMENTS

DEFINITIONS:

Applicant means bidder. The term applicant and bidder may be used interchangeably.

Bidder means any firm or individual submitting an application in response to this ITB. The term bidder may be used interchangeably with applicant and proposer. The term bidder and applicant may be used interchangeably.

Construction means work intended to build, improve, renovate, restore, alter, repair or demolish a city building or physical infrastructure asset.

Minor project means a construction project whose estimated value is less than the threshold established in Section 255.05 for performance and payment bonds (currently $200,000 or as amended).

SECTION 0100: GENERAL INFORMATION & SCOPE OF WORK

1. PURPOSE. The City of Miami Beach is seeking applications from qualified general contractors for minor projects to participate in a pool of prequalified general contractors for minor projects. Minor projects are defined as those projects under the thresholds stipulated in Section 255.20, Florida Statutes.

Pursuant to Section 255.20, Florida Statutes, construction-type projects exceeding $300,000 may not be awarded pursuant this ITB.

To be considered for the pool of pre-qualified contractors, interested parties must submit a complete Bidder Pre-Qualification Application (Appendix A).

The City utilizes Bidnet Direct (Government Bids Opportunities and RFP | BidNet Direct) for automatic notification of competitive solicitation opportunities and document fulfillment, including the issuance of any addendum to this ITB. Any prospective Bidder who has received this ITB by any means other than through Bidnet Direct must register immediately with Bidnet Direct to ensure it receives any addendum issued to this ITB. Failure to receive an addendum may result in disqualification of the proposal submitted.

2. BACKGROUND AND SCOPE. The City is seeking responses from State of Florida Certified General Contractor OR State of Florida Certified Building Contractor OR Miami-Dade County Licensed General Contractor OR Miami-Dade County Licensed Building Contractor interested in being prequalified to perform minor construction projects as required by City departments. Minor projects, as defined herein, may include any construction work for which the prequalified contractor is licensed by the State or certified by the County to perform and may include, without limitation, any of the following project types (or others).

• General Construction

• Concrete Slab Sawing & Core Drilling

• Decorative Concrete & Masonry Fence

• Door

• Drywall

• Fence

• Finish Carpentry

• Flooring

• Gypsum Drywall Installer

• Gypsum Drywall Finisher

• Insulation and Acoustical Tile

• Lathing and Plastering

• Master Lawn Sprinkler

• Master Swimming Pool Piping

• Master Gasoline Tank and Pump

• Roof Deck

• Structural Steel Erection

3. OVERVIEW OF PREQUALIFICATION PROCESS. The figure below is a general overview of the process that the City will utilize to award work pursuant to the prequalification process.

4. APPROVAL OF PREQUALIFIED STATUS. Following the review and evaluation of applications by staff, the responsive, responsible bidder(s) meeting all terms and conditions of the ITB will be recommended for award, as deemed in the best interest of the City, to the City Manager for her https://www.bidnetdirect.com/ consideration. It is important to note that an application deemed to not meet the qualifications for prequalification does not eliminate the bidder from resubmitting a subsequent application during the contract term. Once the bidder has corrected the deficiency, a new application may be submitted for the City’s consideration.

After considering the staff recommendation for award, the City Manager shall exercise her due diligence and recommend to the Mayor and City Commission the bid(s) that the City Manager deems to be in the best interest of the City. The City Commission shall consider the City Manager’s recommendation(s) and may approve or reject the City Manager’s recommendation(s). The City Commission may also reject all bids received. In addition to the criteria established in the application, pursuant to Section 2-369 of the City Code, the City may consider the following:

• The ability, capacity and skill of the bidder to perform the Contract.

• Whether the bidder can perform the Contract within the time specified, without delay or interference.

• The character, integrity, reputation, judgment, experience and efficiency of the bidder.

• The quality of performance of previous contracts.

• The previous and existing compliance by the bidder with laws and ordinances relating to the Contract.

PREQUALIFIED STATUS IS VALID FOR FIVE (5) YEARS FROM DATE OF THE NOTICE OF

PREQUALIFICATION ISSUED BY THE CITY, OR AS OTHERWISE APPROVED BY THE CITY

MANAGER. NOTWITHSTANDING THE CITY MAY VERIFY COMPLIANCE WITH THE

REQUIREMENTS ESTABLISHED HEREIN AT ANY TIME.

5. ADDITIONAL PREQUALIFIED FIRMS TO BE ADDED TO POOL. After the initial pool of firms is established, the City reserves the right to continue to receive prequalification applications and prequalify additional consultants. The City may also limit the number of firms prequalified and, in doing so, shall select the firm(s) it deems, in its sole discretion, through its City Manager, to be best qualified.

6. PROCESS OF AWARDING SERVICE ORDERS. Inclusion in the contractor pool is a prerequisite for having an opportunity to submit proposals and obtain work through this Pool. However, there is no guarantee that any or all prequalified firms will obtain work through this pool. When a project arises, the department will prepare a scope of work and invite all prequalified firms in good standing to provide a quote in response to the request.

Following the review of bids and application of vendor preferences, the lowest responsive, responsible bidder(s) meeting all terms, conditions, and specifications of the ITB will be recommended for award by bid item, bid group, or for the entirety of all bid items, as deemed in the best interest of the City, to the City Manager for his consideration. After considering the staff recommendation for award, the City Manager shall exercise his due diligence and recommend to the Mayor and City Commission the bid that the City Manager deems to be in the best interest of the City. The City Commission shall consider the City Manager's recommendation(s) and, may approve or reject the City Manager's recommendation(s).

The City Commission may also reject all bids received. In determining the lowest and best Bidder, and in addition to price, Section 2-369 of the City Code provides that the City may consider the following:

• The ability, capacity and skill of the bidder to perform the contract.

• Whether the bidder can perform the contract within the time specified, without delay or interference.

• The character, integrity, reputation, judgment, experience and efficiency of the bidder.

• The quality of performance of previous contracts.

• The previous and existing compliance by the bidder with laws and ordinances relating to the contract.

7. REMOVAL FROM THE PREQUALIFIED POOL. At the City Manager’s discretion, Contractors may be removed from the pool for: lack of participation, which shall include failure over a reasonable time to propose on quote requests offered through the pool; poor performance on a previous or current awarded project; being in arrears in obligations to the City; delays in completion of work on a prior awarded project;

for any of the reason stated in Sub-section 2.2 and Section 2-369 of the City Code; or for any other reason deemed to be in the City’s best interest.

8. PROCUREMENT CONTACT. Any questions or clarifications concerning this solicitation shall be submitted to the Procurement Contact noted below. The Bid title/number shall be referenced on all correspondence.

Procurement Contact: Telephone: Email:

Julissa Perez 305-673-7490x26943 julissaperez@miamibeachfl.gov

The City Clerk is to be copied on all communications via e-mail at: RafaelGranado@miamibeachfl.gov;

or via facsimile: 786-394-4188.

9. SERVICE DELIVERY EXPECTATIONS. The City places an emphasis on excellent customer service delivery and expects the prequalified bidder to provide the best possible customer service to any and all awarded projects throughout the term of the contract. The prequalified bidder’s project manager is responsible for monitoring the customer service provided to City by prequalified bidder’s staff, sales and support teams, and employing, as necessary, corrective measures, to ensure that the prequalified bidder will provide and maintain the highest quality of customer service possible during completion of the project(s). Project-specific deliverables and expectations shall be defined on a project-by-project basis, as specified in each ITQ.

10. VOLUME OF WORK TO BE RECEIVED BY BIDDER. No promise of work is given, or should be understood, as a result of a pre-qualification. The City reserves the right to purchase any goods and/or services awarded from any resulting agreement, or another governmental contract, or on an as-needed basis through the City’s spot market purchase provisions.

11. TERMS & CONDITIONS

FORMAL SOLICITATIONS TERMS & CONDITIONS – GOODS AND SERVICES. By virtue of submitting a Proposal in response to this solicitation, proposer agrees to be bound by and in compliance with the Formal Solicitations Terms and Conditions for Goods and Services (dated October 27, 2022), incorporated herein, which may be found at the following link:

https://www.miamibeachfl.gov/city-hall/procurement/standard-terms-and-conditions/

GENERAL CONDITIONS FOR CONSTRUCTION CONTRACTS. By virtue of submitting a Proposal in response to this solicitation, proposer agrees to be bound by and in compliance with the general conditions for construction contracts (dated April 13, 2020), incorporated herein, which may be found at the following link:

https://www.miamibeachfl.gov/city-hall/procurement/standard-terms-and-conditions/

12. BINDING AGREEMENT. By virtue of submitting an application for the City’s consideration, the bidder agrees that the application shall be considered an offer on the part of the bidder, which offer shall be deemed accepted upon approval of bidder’s prequalification status by City Manager or City Commission.

mailto:RafaelGranado@miamibeachfl.gov https://www.miamibeachfl.gov/city-hall/procurement/standard-terms-and-conditions/ https://www.miamibeachfl.gov/city-hall/procurement/standard-terms-and-conditions/

Further, bidder agrees that, upon approval of the bidder’s application by the City Manager or City Commission, a binding Agreement shall be established between the City and the approved contractor.

Pursuant to this section, bidder agrees that, if its application is accepted, the ITB (inclusive of all attachments, appendixes, exhibits and addenda) and the Proposal (Application) shall constitute a binding Agreement, and all work shall be performed in accordance with the Agreement. The selected bidder may not include terms or conditions that are additional to this ITB without the written consent of the City. The agreement will be supplemented, upon specific project need, only by individual Service Orders specifying project scopes and payments. Selection into the Pool does not guarantee work and does not provide for exclusive rights to provide these services to the City.

The Agreement shall be comprised of the following documents, and in the following order:

First, the Purchase Order issued by the City; then, Second, the signed Contractor Service Order; then, Third, the Invitation to Quote (ITQ) awarded to the vendor; then, Fourth the ITB, including all documents released in connection with the ITB, including all appendixes, whether included herein or released under separate cover.

In case of default on the part of the Successful Bidder, after said award, the City may take such action as it deems appropriate, including legal action, for damages or specific performance.

[THE REMAINDER OF THIS PAGE IS LEFT INTENTIONALLY BLANK]

APPENDIX A

Prequalification

Application

ITB 2023-157-DF

Prequalification Pool of Contractors for Minor Projects

PROCUREMENT DEPARTMENT

1755 Meridian Avenue, 3rd Floor

Miami Beach, Florida 33139

Prequalification Application & Instructions

Section 1. SUBMITTAL INSTRUCTIONS - ELECTRONIC RESPONSES ONLY. The Prequalification Application will not be considered until it has been submitted completed and executed by a principal of the bidder. Incomplete applications cannot be processed. If requested information is not applicable, please indicate ''N/A'' or ''None. '' If answers to questions are lengthier than the spaces that are provided in the application, the answers may be provided on additional pages, which must be attached to the application. All requested documents must also be attached to the application. Failure to attach all requested documents will delay review and approval of the application.

Submit one (1) electronic copy of the application to Julissa Perez at julissaperez@miamibeachfl.gov.

The City reserves the right to request clarifications or additional information as deemed necessary to evaluate a bidder’s qualifications. When clarifications or additional information is requested by the City, bidder will have three (3) business days to provide, in full, all the requested information. Failure to provide the information within the prescribed time will delay the review process and may result in denial of prequalification.

Section 2. DEADLINE FOR SUBMITTAL. There is no deadline for the submittal of applications.

However, the initial review of applications shall take place 21 days after issuance of this ITB. Applications submitted after this date will be reviewed periodically on an on-going basis. The City will endeavor to complete the review of each application within 60 days of receipt.

Section 3. MINIMUM ELIGIBILITY REQUIREMENTS. The Minimum Eligibility Requirements for this solicitation are listed below. Bidders that fail to comply with minimum requirements shall be deemed non-responsive and shall not have its application considered.

3.1 Licensure. Bidder shall be State of Florida Certified General Contractor OR State of Florida Certified Building Contractor OR Miami-Dade County Licensed General Contractor OR Miami- Dade County Licensed Building Contractor to be considered for award. The City may consider alternative licenses as acceptable providing that proof is submitted by the bidder documenting that construction work (as defined in the solicitation) and related permits may be completed, in accordance with State of Florida or Miami-Dade County regulations, with the alternative license.

Submittal Requirement: Provide a copy of certification or license number.

3.2 Bonding Capacity. General and Building Contractors shall submit proof of bonding capacity of no less than $500,000. Proof of bonding capacity letter shall be from an A-rated Financial Class V Surety Company, at a minimum.

Section 4. NON-RESPONSIVENESS Failure to submit the following requirements shall result in a determination of non-responsiveness. Non-responsive applications will not be considered.

1. Prequalification Application

2. Minimum Eligibility Requirements as stated in Section 3 above.

mailto:julissaperez@miamibeachfl.gov

Part A – General Bidder Information.

FIRM NAME:

NO. OF YEARS IN BUSINESS:

NO. OF YEARS IN BUSINESS

LOCALLY:

NO. OF EMPLOYEES:

OTHER NAME(S) BIDDER HAS OPERATED UNDER IN THE LAST 10 YEARS:

FIRM PRIMARY ADDRESS (HEADQUARTERS):

CITY:

STATE:

ZIP CODE:

TELEPHONE NO.:

TOLL FREE NO.:

FAX NO.:

FIRM LOCAL ADDRESS:

CITY:

STATE:

ZIP CODE:

PRIMARY ACCOUNT REPRESENTATIVE FOR THIS ENGAGEMENT:

ACCOUNT REP TELEPHONE NO.:

ACCOUNT REP TOLL FREE NO.:

ACCOUNT REP EMAIL:

FEDERAL TAX IDENTIFICATION NO.:

BIDDER IS:

_____CORPORATION / _____PARTNERSHIP / _____SOLE PROPRIETORSHIP / _____OTHER (If other, specify:________________________)

Part B – Operational & Management Information.

1. Provide the names of each owner (stockholder, sole proprietor, and partner), director, or officer of the company, below. Submit additional names on a separate sheet if required.

Owner Ownership percentage Directorship/Office type

2. Construction Past Experience (General). Bidder shall submit at least five (5) project references for minor construction projects. Reference. See below form required for each submitted project reference.

Project Location Project Value (dollar amount)

Year of Work Duration of Engagement Project Lead

Entity Contact Person Contact Information

Email:

Tel #:

Project Description (include awarding agency and work-type category)

Additional references may be attached separately with the bidder’s package.

3. Is the bidder currently barred by a governmental agency, from bidding as a prime or subcontractor?

YES NO

If yes, state debarment period and the reason(s) for debarment?

4. Has the bidder or any of its owners, directors, officers, or agents been convicted of a crime or had a claim that was filed in a court and mediated or arbitrated during the last five (5) years?

If yes, why?

5. Is an affiliate of the bidder prequalified by the City of Miami Beach for any work?

If yes, state the name of the affiliate?

6. Is the bidder a parent, subsidiary, or holding company for another company?

If the answer is "yes," identify the company and type of relationship(s), below:

Company Type of affiliation (parent or subsidiary) Period of affiliation

7. Is an owner, director, officer, or agent of the bidder affiliated with another company?

If the answer is "yes," provide the following information for each individual and the affiliated company below:

Individual´s name Affiliated company´s name Period of affiliation Type of affiliation (e.g.

officer, director, owner or employee)

8. Is the bidder currently the debtor in a bankruptcy case or file for bankruptcy during the last five (5) years?

If yes, explain and attach, as applicable, the relevant case and court documents, including (but not limited to): the original petition, including the case number and the date that the petition was filed;

a copy of the bankruptcy court's discharge order, and any other document that ended the case, if no discharge order was issued.

9. Has any owner, director, officer, or agent for the bidder, or has any business organization in which any such person was an owner, director, officer, or agent filed for or been discharged in bankruptcy within the past five (5) years?

If yes, explain and attach a copy of the discharge order, order confirming plan and if a Corporate Chapter 7 case, a copy of the notice of commencement.

10. Has any owner, director, officer, or agent of the bidder owned or managed a company under any other name in the last five (5) years?

If yes, explain.

11. Has the bidder been assessed or paid any fines on any contract during the past five (5) years, whether the project was publicly or privately owned?

12. Are there currently any liens, suits, or judgments of record pending against any owner, director, officer, or agent for the company that is related to the business activities of a business organization?

13. Has the bidder or any of its owners, officers, or partners ever been convicted (criminal) or found liable

(civil) for making either a false claim or material misrepresentation to any public agency or entity?

14. Has the bidder or any of its owners, officers, or partners ever been convicted of any a federal or state crime?

15. Is any officer, director, employee or agent, or immediate family member (spouse, parent, sibling, and child) of any officer, director, employee or agent, an employee of the City of Miami Beach?

If yes, state name, title and share of ownership

Name Title Share (%) of Ownership

16. Has the bidder, or any officer, director, employee or agent, contributed to the campaign either directly or indirectly, of a candidate who has been elected to the office of Mayor or City Commissioner for the City of Miami Beach?

If yes, provide details.

17. VENDOR CAMPAIGN CONTRIBUTIONS

Pursuant to Section 2-487 of the City Code, no vendor shall give a campaign contribution directly or indirectly to a candidate, or to the campaign committee of a candidate, for the offices of mayor or commissioner. Bidder must disclose Bidder, or any principal of the bidder, shall disclose the name of any candidate elected to the office of mayor or city commissioner to which the bidder has directly or indirectly, or to the campaign committee of an elected candidate, given a campaign contribution.

Name of Elected Candidate Contributor Amount of Contribution

Date of Contribution

18. SUSPENSION, DEBARMENT, OR CONTRACT CANCELLATION.

Has bidder ever been debarred, suspended or other legal violation, or had a contract cancelled due to non-performance by any public sector agency?

If answer to above is “YES,” bidder shall submit a statement detailing the reasons that led to action(s):

19. BYRD ANTI-LOBBYING AMENDMENT CERTIFICATION FORM

APPENDIX A, 44 C.F.R. PART 18 – CERTIFICATION REGARDING LOBBYING

Certification for Contracts, Grants, Loans, and Cooperative Agreements

The undersigned Contractor certifies, to the best of his or her knowledge, that:

1. No Federal appropriated funds have been paid or will be paid, by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of an agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement.

2. If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with this Federal contract, grant, loan, or cooperative agreement, the undersigned shall complete and submit Standard Form-LLL, “Disclosure Form to Report Lobbying,” in accordance with its instructions.

3. The undersigned shall require that the language of this certification be included in the award documents for all subawards at all tiers (including subcontracts, subgrants, and contracts under grants, loans, and cooperative agreements) and that all subrecipients shall certify and disclose accordingly.

This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction imposed by 31, U.S.C. § 1352 (as amended by the Lobbying Disclosure Act of 1995). Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure.

The undersigned Contractor certifies or affirms the truthfulness and accuracy of each statement of its certification and disclosure, if any. In addition, the Contractor understands and agrees that the provisions of 31 U.S.C. § 3801 et seq., apply to this certification and disclosure, if any.

By virtue of submitting bid, bidder certifies or affirms its compliance with the Byrd Anti-Lobbying Amendment Certification.

Name and Title of Bidder’s Authorized Representative:

Signature of Bidder’s Authorized Representative:

20. SUSPENSION AND DEBARMENT CERTIFICATION

The Contractor acknowledges that:

(1) This Contract is a covered transaction for purposes of 2 C.F.R. pt. 180 and 2 C.F.R. pt. 3000. As such the contractor is required to verify that none of the Contractor, its principals (defined at 2 C.F.R. § 180.995), or its affiliates (defined at 2 C.F.R. § 180.905) are excluded (defined at 2 C.F.R. § 180.940) or disqualified (defined at 2 C.F.R. § 180.935).

(2) The Contractor must comply with 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C and must include a requirement to comply with these regulations in any lower tier covered transaction it enters into.

(3) This certification is a material representation of fact relied upon by the City. If it is later determined that the Contractor did not comply with 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C, in addition to remedies available to the City, the Federal Government may pursue available remedies, including but not limited to suspension and/or debarment.

(4) The Contractor agrees to comply with the requirements of 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt.

3000, subpart C while this offer is valid and throughout the period of any contract that may arise from this offer. The Contractor further agrees to include a provision requiring such compliance in its lower tier covered transactions.”

By virtue of submitting bid, bidder certifies or affirms its compliance with the Suspension and Debarment

Certification.

Name and Title of Bidder’s Authorized Representative:

Signature of Bidder’s Authorized Representative:

21. SMALL AND DISADVANTAGED BUSINESS CERTIFICATION

Pursuant to Resolution 2020-31519, the City is tracking the Small and Disadvantaged Businesses, as certified by Miami-Dade County that have been certified as Small or Disadvantaged Business by Miami-Dade County.

Does bidder possess Small or Disadvantaged Business certification by Miami-Dade County?

22. LGBT BUSINESS ENTERPRISE CERTIFICATION

Pursuant to Resolution 2020-31342, the City is tracking the utilization of LGBT owned firms that have been certified as an LGBT Business Enterprise by the National Gay and Lesbian Chamber of Commerce (NGLCC).

Does bidder possess LGBT Business Enterprise Certification by the NGLCC?

23. CONE OF SILENCE

Pursuant to Section 2-486 of the City Code, all procurement solicitations once advertised and until an award recommendation has been forwarded to the City Commission by the City Manager are under the “Cone of Silence.” The Cone of Silence ordinance is available at https://library.municode.com/fl/miami_beach/codes/code_of_ordinances?nodeId=SPAGEOR_CH2AD_A

RTVIISTCO_DIV4PR_S2-486COSI

Any communication or inquiry in reference to this solicitation with any City employee or City official is strictly prohibited with the of exception communications with the Procurement Director, or his/her administrative staff responsible for administering the procurement process for this solicitation providing said communication is limited to matters of process or procedure regarding the solicitation. Communications regarding this solicitation are to be submitted in writing to the Procurement Contact named herein with a copy to the City Clerk at rafaelgranado@miamibeachfl.gov .

Vendor attests that they have read, understand, and are in compliance with the Cone of Silence Ordinance, pursuant to Section 2-486 of the City Code?

24. CODE OF BUSINESS ETHICS

Pursuant to City Resolution No.2000-23789, the Bidder shall adopt a Code of Business Ethics prior to executing a contract with the City. The Code of Business Ethics shall be submitted to the Procurement Department with its response or within three (3) days of request by the City. The Code shall, at a minimum, require the Bidder, to comply with all applicable governmental rules and regulations including, among others, the conflict of interest, lobbying and ethics provision of the City Code. In lieu of submitting Code of Business Ethics, bidder may indicate that it will adopt, as required in the ordinance, the City of Miami Beach Code of Ethics, available at http://www.miamibeachfl.gov/city-hall/procurement/procurement-related-ordinance-and-procedures/

Bidder will submit firm’s Code of Business Ethics within three (3) days of request by the City?

https://library.municode.com/fl/miami_beach/codes/code_of_ordinances?nodeId=SPAGEOR_CH2AD_ARTVIISTCO_DIV4PR_S2-486COSI https://library.municode.com/fl/miami_beach/codes/code_of_ordinances?nodeId=SPAGEOR_CH2AD_ARTVIISTCO_DIV4PR_S2-486COSI mailto:rafaelgranado@miamibeachfl.gov http://www.miamibeachfl.gov/city-hall/procurement/procurement-related-ordinance-and-procedures/ http://www.miamibeachfl.gov/city-hall/procurement/procurement-related-ordinance-and-procedures/

Bidder adopts the City of Miami Beach Code of Business Ethics?

25. LOBBYIST REGISTRATION & CAMPAIGN CONTRIBUTION REQUIREMENTS

This solicitation is subject to, and all bidders are expected to be or become familiar with, all City lobbyist laws, including lobbyist registration requirements and prohibition on campaign contributions.

Lobbyists:

https://library.municode.com/fl/miami_beach/codes/code_of_ordinances?nodeId=SPAGEOR_CH2AD_

ARTVIISTCO_DIV3LO

Campaign Finance Reform:

https://library.municode.com/fl/miami_beach/codes/code_of_ordinances?nodeId=SPAGEOR_CH2AD_

ARTVIISTCO_DIV5CAFIRE

Has the bidder, or any officer, director, employee or agent, contributed to the campaign either directly or indirectly, of a candidate who has been elected to the office of Mayor or City Commissioner for the City of Miami Beach?

If yes, provide details.

By virtue of submitting bid, bidder certifies or affirms that they have read and understand the above Lobbyist Registration and Campaign Contribution Requirements.

26. PUBLIC ENTITY CRIMES

Please refer to Section 287.133(2)(a), Florida Statutes, available at:

https://www.flsenate.gov/Laws/Statutes/2012/287.133

By virtue of submitting bid, bidder agrees with the requirements of Section 287.133, Florida Statutes, and certifies it has not been placed on convicted vendor list.

27. VETERAN BUSINESS ENTERPRISES PREFERENCE

Pursuant to City of Miami Beach Ordinance No. 2011- 3748, https://library.municode.com/fl/miami_beach/codes/code_of_ordinances?nodeId=SPAGEOR_CH2AD _ARTVIPR_DIV3COPR_S2-374PRPRPRVECOGOCOSE the City shall give a preference to a responsive and responsible bidder which is a small business concern owned and controlled by a veteran(s) or which is a service-disabled veteran business enterprise, and which is within five percent (5%) of the lowest and best bidder, by providing such bidder an opportunity of providing said goods or contractual services for the lowest responsive bid amount. Whenever, as a result of the foregoing preference, the adjusted prices of two (2) or more bidders which are a small business concern owned and controlled by a veteran(s) or a service-disabled veteran business enterprise constitute the lowest bid pursuant to an ITB, RFP, RFQ, ITN or oral or written request for quotation, and such bids are responsive, responsible and otherwise equal with respect to quality and service, then the award shall be made to the service-disabled veteran business enterprise.

https://library.municode.com/fl/miami_beach/codes/code_of_ordinances?nodeId=SPAGEOR_CH2AD_ARTVIISTCO_DIV3LO https://library.municode.com/fl/miami_beach/codes/code_of_ordinances?nodeId=SPAGEOR_CH2AD_ARTVIISTCO_DIV3LO https://library.municode.com/fl/miami_beach/codes/code_of_ordinances?nodeId=SPAGEOR_CH2AD_ARTVIISTCO_DIV5CAFIRE https://library.municode.com/fl/miami_beach/codes/code_of_ordinances?nodeId=SPAGEOR_CH2AD_ARTVIISTCO_DIV5CAFIRE https://www.flsenate.gov/Laws/Statutes/2012/287.133 https://library.municode.com/fl/miami_beach/codes/code_of_ordinances?nodeId=SPAGEOR_CH2AD_ARTVIPR_DIV3COPR_S2-374PRPRPRVECOGOCOSE https://library.municode.com/fl/miami_beach/codes/code_of_ordinances?nodeId=SPAGEOR_CH2AD_ARTVIPR_DIV3COPR_S2-374PRPRPRVECOGOCOSE

Is the bidder a service-disabled veteran business enterprise certified by the State of Florida?

Is the bidder a service-disabled veteran business enterprise certified by the United States Federal Government?

Suspension, Debarment, or Contract Cancellation. Has the bidder ever been debarred, suspended (or other legal violation), or had a contract cancelled due to non-performance by any public sector agency?

If yes, submit a statement detailing the reasons that led to action(s).

BIDDER AFFIDAVIT

The undersigned agrees that s/he: 1) is a principal of the bidder duly authorized to execute the foregoing Contractor Prequalification Certification Application, and that the contents of said document(s) are complete, true, and correct to the best of his/her knowledge and belief; 2) s/ certifies that the application and supporting documents include all of the material information necessary to validate the status of the company for prequalification purposes; 3) s/ shall notify the Procurement Department within fifteen (15) days and provide a notarized statement whenever a change occurs in the ownership, management, or financial condition of the company. Further, any prequalified contractor, including its principal(s), director(s), and any affiliate, who is a party to any misrepresentation to obtain business or contracts with the City of Miami Beach shall be declared delinquent and have its certificate suspended or revoked and will be subject to debarment and any other penalties prescribed by law.

The undersigned affirms that the bidder agrees: 1) to complete and unconditional acceptance of the terms and conditions of this document, inclusive of attachments, exhibits and appendices; 2) that it has not colluded, nor will collude, with any other bidder; 3) that all information contained herein is part of the public domain as defined by the State of Florida Sunshine and Public Records Laws; 4) that all responses, data and information contained in the bid are true and accurate.

Name:

Title (must be a principal of the bidder):

Signature:

Date:

APPENDIX B

Special Conditions

1. LICENSE/CERTIFICATION. Prospective bidder shall maintain in current status the adequate license or certification, to pull all permits necessary to successfully complete the work. Awarded vendor(s) shall remain fully informed of and in compliance with all ordinances and regulations pertaining to the lawful provision of services under the contract.

2. METHOD OF PAYMENT. The City shall provide periodic payments for services rendered by the Contractor. In order for the City to provide payment, the Contractor shall submit a fully documented invoice within thirty (30) calendar days after the service has been rendered. It shall be understood that such invoices shall not be submitted for payment until such time as the service has been completed and a City representative has reviewed and approved the service.

3. GUARANTEE AGAINST DEFECTS. The Contractor(s) shall, in addition to all other guarantees, be responsible for faulty labor and defective material within a period of one (1) year after the date of acceptance of labor and material by the City. Under this guarantee, the Contractor agrees to make good without delay, at its own expense, any failure of any part of the work after the City notifies the Contractor of such deficiencies in writing Payment in full for the work does not constitute a waiver of guarantee.

APPENDIX C

Insurance Requirements

TYPE 8 – CONSTRUCTION - SMALL

(INSTALLATION FLOATER)

INSURANCE REQUIREMENTS

The vendor shall maintain the below required insurance in effect prior to awarding the contract and for the duration of the contract. The maintenance of proper insurance coverage is a material element of the contract and failure to maintain or renew coverage may be treated as a material breach of the contract, which could result in withholding of payments or termination of the contract.

A. Workers' Compensation Insurance for all employees of the Contractor as required by Florida Statute Chapter 440 and Employer Liability Insurance with a limit of no less than $1,000,000 per accident for bodily injury or disease.

Should the Contractor be exempt from this Statute, the Contractor and each employee shall hold the City harmless from any injury incurred during performance of the Contract. The exempt contractor shall also submit (i) a written statement detailing the number of employees and that they are not required to carry Workers’ Compensation insurance and do not anticipate hiring any additional employees during the term of this contract or (ii) a copy of a Certificate of Exemption.

B. Commercial General Liability Insurance on an occurrence basis, including products and completed operations, property damage, bodily injury and personal & advertising injury with limits no less than $1,000,000 per occurrence, and $2,000,000 general aggregate.

C. Automobile Liability Insurance covering any automobile, if vendor has no owned automobiles, then coverage for hired and non-owned automobiles, with limit no less than $1,000,000 combined per accident for bodily injury and property damage.

D. Contractors’ Pollution Legal Liability (if project involves environmental hazards), with limits no less than $1,000,000 per occurrence or claim, and $2,000,000 policy aggregate.

E. Installation Floater Insurance against damage or destruction of the materials or equipment in transit to, or stored on or off the Project Site, which is to be used (installed into a building or structure) in the Project. (City of Miami Beach shall Named as a Loss Payee on this policy, as its interest may appear. This policy shall remain in force until acceptance of the project by the City.)

Additional Insured - City of Miami Beach must be included by endorsement as an additional insured with respect to all liability policies (except Professional Liability and Workers’ Compensation) arising out of work or operations performed on behalf of the contractor including materials, parts, or equipment furnished in connection with such work or operations and automobiles owned, leased, hired or borrowed in the form of an endorsement to the contractor’s insurance.

Notice of Cancellation - Each insurance policy required above shall provide that coverage shall not be cancelled, except with notice to the City of Miami Beach c/o EXIGIS Insurance Compliance Services.

Waiver of Subrogation – Vendor agrees to obtain any endorsement that may be necessary to affect the waiver of subrogation on the coverages required. However, this provision applies regardless of whether the City has received a waiver of subrogation endorsement from the insurer.

Acceptability of Insurers – Insurance must be placed with insurers with a current A.M. Best rating of A:VII or higher. If not rated, exceptions may be made for members of the Florida Insurance Funds (i.e. FWCIGA, FAJUA). Carriers may also be considered if they are licensed and authorized to do insurance business in the State of Florida.

Verification of Coverage – Contractor shall furnish the City with original certificates and amendatory endorsements, or copies of the applicable insurance language, effecting coverage required by this contract. All certificates and endorsements are to be received and approved by the City before work commences. However, failure to obtain the required documents prior to the work beginning shall not waive the Contractor’s obligation to provide them. The City reserves the right to require complete, certified copies of all required insurance policies, including endorsements, required by these specifications, at any time.

CERTIFICATE HOLDER MUST READ:

CITY OF MIAMI BEACH

c/o EXIGIS Insurance Compliance Services P.O. Box 4668 – ECM #35050 New York, NY 10163-4668

Kindly submit all certificates of insurance, endorsements, exemption letters to our servicing agent, EXIGIS, at:

Certificates-miamibeach@riskworks.com

Special Risks or Circumstances - The City of Miami Beach reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other special circumstances.

Compliance with the foregoing requirements shall not relieve the vendor of his liability and obligation under this section or under any other section of this agreement.

mailto:Certificates-miamibeach@riskworks.com