P4009111 Specs..pdf

EXTEND FLOATING DOCK 4009111

CG BSU BOSTON, BOSTON, MA

SECTION 01 11 00 Page 2

1.5.1 Contractor’s Daily Log

The Contractor shall be complete the USCG Daily Log form at the end of each working day and deliver it to the Government Inspector. The Government Inspector will attest to its accuracy by initialing the form and forwarding that form to CEU Providence. The form will be provided to the Contractor by the Contracting Officer’s Representative.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

N ot used.

--End of Section--

PROJECT TABLE OF CONTENTS

DIVISION 01 GENERAL REQUIRMENTS

01 11 00 Summary of Work 01 14 00 Work Restrictions 01 32 00 Construction Schedule 01 33 00 Submittals 01 50 00 Temporary Facilities 01 57 19 Temporary Environmental Controls 01 77 00 Closeout Procedures 01 78 23 Operation and Maintenance Data

DIVISION 05 METALS

05 12 00 Structural Steel

DIVISION 06 WOOD, PLASTICS, AND COMPOSITES

06 13 33 Pier Timberwork

DIVISION 35 WATERWAY AND MARINE CONSTRUCTION

35 1 13.00 Floating Docks for Smallcraft

--End of Table of Contents--

SECTION 01 11 00

SUMMARY OF WORK

11/07

PART 1 GENERAL

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

The work includes adding one dock module to an existing floating dock.

1.1.2 Location

The work is located at Coast Guard BSU Boston, Boston, MA approximately as indicated.

1.2 EXISTING WORK

In addition to "FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements":

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work shall be in a condition equal to or better than that which existed before new work started.

1.3 SUPERVISION

Have at least one qualified supervisor capable of reading, writing, and conversing fluently in the English language on the job site during working hours.

1.4 PRECONSTRUCTION CONFERENCE

After award of the contract but prior to commencement of any work at the site, meet with the Contracting Officer to discuss and develop a mutual understanding relative to the administration of the value engineering and safety program, preparation of the schedule prices, shop drawings, and other submittals, scheduling programming, and prosecution of the work. Major subcontractors who will engage in the work shall also attend. A Notice to Proceed (NTP) will be issued at the completion of the meeting.

1.5 INSPECTION

The Contractor shall keep the Contracting Officer or duly appointed representative fully informed of contract operations and plans so that a representative may arrange to be present at various times that work is being performed.

SECTION 01 11 00 Page 1

SECTION 01 14 00

WORK RESTRICTIONS

1.1 SPECIAL SCHEDULING REQUIREMENTS

a. Have materials, equipment, and personnel required to perform the work at the site prior to commencement of the work.

b. All piers, walkways, and ramps shall remain in operation during the entire construction period, except as noted. Conduct work so as to cause the least possible amount of interference with normal Coast Guard operations.

c. The work under this contract requires special attention to the scheduling and conduct of the work in connection with existing operations. Identify on the construction schedule each factor which constitutes a potential disruption to operations.

d. All work shall be completed within 2 weeks after work commences on site.

At the end of this time period the floating dock will be fully constructed and operational.

1.2 CONTRACTOR ACCESS AND USE OF PREMISES

1.2.1 Activity Regulations

Ensure that Contractor personnel employed on the Activity become familiar with and obey Activity regulations including safety, fire, traffic and security regulations. Keep within the limits of the work and avenues of ingress and egress. Do not enter any restricted areas unless required to do so and until cleared for such entry. The Contractor's equipment shall be conspicuously marked for identification.

1.2.2 Working Hours

Regular working hours shall consist of an 8 1/2 hour period established by the Contractor Officer Monday through Friday, excluding Government holidays.

1.2.3 Work Outside Regular Hours

Work outside regular working hours requires Contracting Officer approval.

Make application 15 calendar days prior to such work to allow arrangements to be made by the Government for inspecting the work in progress, giving the specific dates, hours, location, type of work to be performed, contract number and project title. Based on the justification provided, the Contracting Officer may approve work outside regular hours. During periods of darkness, the different parts of the work shall be lighted in a manner approved by the Contracting Officer.

SECTION 01 14 00 Page 1

SECTION 01 14 00 Page 2

1.2.4 Occupied Buildings

The Contractor shall be working around existing occupied buildings. Do not enter the buildings without prior approval of the Contracting Officer.

1.3 SECURITY REQUIREMENTS

1.3.1 Areas Not Covered by Contract

The Contractor will not be permitted to enter buildings or areas not covered by the work included in this contract, except by prior approval of the Officer-in-Charge of the facility.

1.3.2 Parking

Prohibited on any piers and waterfront areas. An exception may be made for vehicles which are part of the equipment needed to do the required work and are attached or connected to the pier of ship; for example, a truck which uses a mounted generator or a vehicle with built-in equipment.

1.4 CONTRACTOR PERSONNEL

Follow security procedures established by Coast Guard BSU Boston for identifying contractor personnel, equipment, and vehicles.

SECTION 01 32 00

CONSTRUCTION SCHEDULE/SCHEDULE OF VALUES

1. SUBMITTALS 1

Submit the following in accordance with Section 01 33 00, "Submittal Procedures."

SD-01 Preconstruction Submittals

Construction Schedule/Schedule of Values

1. C2

ONSTRUCTION SCHEDULE

At the Pre-Construction Conference, submit a Construction Schedule and Schedule of Values in accordance with FAR Clause 52.236-15. The Schedule of Values shall be based on the actual breakdown of the bid price. The cost of insurance shall not be listed as a separate item but included as part of each item of work. The actual cost of bonds may be paid as the first progress payment when a receipt from the bonding company is presented to the Contracting Officer. For contracts under $25,000, a Schedule of Values is not required. In addition, keep the Government Inspector informed daily of the expected delivery dates for major pieces of equipment and materials.

Construction Schedule and Schedule of Values shall be incorporated into one form which clearly indicates the start and completion dates and unit value of all major work components.

Construction Schedule/Schedule of Values form shall incorporate at a minimum the following activities:

a. Bonds

b. Mobilization

c. Demobilization

d. Pre-Construction Submittals

e. Work Activities

f. In-Progress Submittals

g. Final Government Inspection

h. Close-Out Submittals; i.e. Testing Balancing Reports, Warranties, Operation and Maintenance Manuals, Posted Instructions

i. As-Built Drawings

j. Factors which Constitute Potential Interruptions to BSU Boston

Section 01 32 00 Page 1

Section 01 32 00 Page 2

Operations

Pre-Construction Submittals are those activities which encompass the obtaining, submission, review and approval of submittals necessary prior to the start of the related site work. Contractor shall annotate all such activities into the progress schedule with their forecasted time periods.

These activity periods shall not be exclusive of the contract performance period. No site work shall commence until the respective submittals have been approved.

The value of all major work components within the project shall be identified on the Construction Schedule/Schedule of Values on a unit quantity and unit cost basis, e.g. number of squares and cost per square of roofing, number of lineal feet and cost per lineal foot of conduit, number of panels and cost per panel etc. Lump sum items shall only be paid for when 100% complete.

The Construction Schedule/Schedule of Values as approved by the Government is not a substitute for quantities conveyed by the specification and drawings and those required for a complete job. Omissions and errors on the Construction Schedule/Schedule of Values are the responsibility of the Contractor.

Payments will not be made until the schedule of prices has been submitted to and approved by the Contracting Officer.

1.3 UPDATED SCHEDULES

Update the construction schedule and equipment delivery schedule at monthly intervals or when schedule has been revised. Reflect any changes occurring since the last update. Submit copies of the purchase orders and confirmation of the delivery dates as directed.

3.1 PROGRESS UPDATES

3.1.1 General

A revised Construction Schedule/Schedule of Values shall be issued by the Contractor on a monthly basis. In addition, any revisions to the Construction Schedule/Schedule of Values such as modifications or delays shall be reflected by Contractor submission of an updated Construction Schedule/Schedule of Values.

3.1.2 Modifications

When a modification is issued by the Government, record the modification as the last activity of the Construction Schedule/Schedule of Values and include the value of the modification. Adjust the Schedule of Values to reflect the inclusion of the modification. Revise the Construction Schedule portion of the form to annotate the progress change. Enter all modifications in this manner in sequential order.

SECTION 01 33 00

SUBMITTAL PROCEDURES

1.1 DEFINITIONS

1.1.1 Submittal

Shop drawings, product data, samples, and administrative submittals presented for review and approval. Contract Clauses "FAR 52.236-5, Material and Workmanship," paragraph (b) and "FAR 52.236-21, Specifications and Drawings for Construction," paragraphs (d), (e), and (f) apply to all "submittals."

1.1.2 Types of Submittals

All submittals are classified as indicated in paragraph "Submittal Descriptions (SD)". Submittals also are grouped as follows:

a. Shop drawings: As used in this section, drawings, schedules, diagrams, and other data prepared specifically for this contract, by contractor or through contractor by way of subcontractor, manufacturer, supplier, distributor, or other lower tier contractor, to illustrate portion of work.

b. Product data: Preprinted material such as illustrations, standard schedules, performance charts, instructions, brochures, diagrams, manufacturer's descriptive literature, catalog data, and other data to illustrate portion of work, but not prepared exclusively for this contract.

c. Samples: Physical examples of products, materials, equipment, assemblies, or workmanship that are physically identical to portion of work, illustrating portion of work or establishing standards for evaluating appearance of finished work or both.

d. Administrative submittals: Data presented for reviews and approval to ensure that administrative requirements of project are adequately met but not to ensure directly that work is in accordance with design concept and in compliance with contract documents.

1.1.3 Submittal Descriptions (SD)

Construction Progress Schedule Submittal register Schedule of values Health and safety plan Work plan Quality control plan Environmental protection plan

SECTION 01 33 00 Page 1

SD-02 Shop Drawings

Drawings, diagrams and schedules specifically prepared to illustrate some portion of the work.

Diagrams and instructions from a manufacturer or fabricator for use in producing the product and as aids to the contractor for integrating the product or system into the project.

Drawings prepared by or for the contractor to show how multiple systems and interdisciplinary work will be coordinated.

SD-03 Product Data

Catalog cuts, illustrations, schedules, diagrams, performance charts, instructions and brochures illustrating size, physical appearance and other characteristics of materials or equipment for some portion of the work.

Samples of warranty language when the contract requires extended product warranties.

SD-04 Samples

Physical examples of materials, equipment or workmanship that illustrate functional and aesthetic characteristics of a material or product and establish standards by which the work can be judged.

Color samples from the manufacturer's standard line (or custom color samples if specified) to be used in selecting or approving colors for the project.

Field samples and mock-ups constructed on the project site establish standards by which the ensuring work can be judged. Includes assemblies or portions of assemblies which are to be incorporated into the project and those which will be removed at conclusion of the work.

SD-05 Design Data

Calculations, mix designs, analyses or other data pertaining to a part of work.

SD-06 Test Reports

Report signed by authorized official of testing laboratory that a material, product or system identical to the material, product or system to be provided has been tested in accord with specified requirements. (Testing must have been within three years of date of contract award for the project.)

Report which includes findings of a test required to be performed by the contractor on an actual portion of the work or prototype prepared for the project before shipment to job site.

Report which includes finding of a test made at the job site or on sample taken from the job site, on portion of work during or after installation.

Investigation reports

SECTION 01 33 00 Page 2

Daily checklists

Final acceptance test and operational test procedure

SD-07 Certificates

Statements signed by responsible officials of manufacturer of product, system or material attesting that product, system or material meets specification requirements. Must be dated after award of project contract and clearly name the project.

Document required of Contractor, or of a supplier, installer or subcontractor through Contractor, the purpose of which is to further quality of orderly progression of a portion of the work by documenting procedures, acceptability of methods or personnel qualifications.

Confined space entry permits.

SD-08 Manufacturer's Instructions

Preprinted material describing installation of a product, system or material, including special notices and Material Safety Data sheets concerning impedances, hazards and safety precautions.

SD-09 Manufacturer's Field Reports

Documentation of the testing and verification actions taken by manufacturer's representative to confirm compliance with manufacturer's standards or instructions.

Factory test reports.

SD-10 Operation and Maintenance Data

Data intended to be incorporated in operations and maintenance manuals.

SD-11 Closeout Submittals

Documentation to record compliance with technical or administrative requirements or to establish an administrative mechanism.

As-built drawings

Special warranties

Posted operating instructions

Training plan

1.1.4 Approving Authority

Person authorized to approve submittal.

1.1.5 Work

As used in this section, on- and off-site construction required by contract documents, including labor necessary to produce construction and materials, SECTION 01 33 00 Page 3 products, equipment, and systems incorporated or to be incorporated in such construction.

1.2 SUBMITTALS

Submit the following in accordance with the requirements of this section.

Submittal register

1.3 USE OF SUBMITTAL REGISTER

Prepare and maintain submittal register, as the work progresses. Do not change data in columns (c), (d), (e), and (f) as delivered by government.

1.3.1 Submittal Register

Submit submittal register. Do not change data in columns (c), (d), (e), and

(f) as delivered by the government. Verify that all submittals required for project are listed and add missing submittals. Complete the following on the register:

Column (a) Activity Number: Activity number from the project schedule.

Column (b) Transmittal Number: Contractor assigned list of consecutive numbers.

Column (g) Contractor Submit Date: Scheduled date for approving authority to receive submittals.

Column (h) Contractor Approval Date: Date contractor needs approval of submittal.

Column (i) Contractor Material: Date that contractor needs material delivered to contractor control.

1.4 PROCEDURES FOR SUBMITTALS

1.4.1 Reviewing, Certifying, Approving Authority

Government organization shall be responsible for reviewing and certifying that submittals are in compliance with contract requirements. Approving authority on submittals is the Project Manager unless otherwise specified for specific submittal.

1.4.2 Constraints

a. Submittals listed or specified in this contract shall conform to provisions of this section, unless explicitly stated otherwise.

b. Submittals shall be complete for each definable feature of work;

components of definable feature interrelated as a system shall be submitted at same time.

SECTION 01 33 00 Page 4

c. When acceptability of a submittal is dependent on conditions, items, or materials included in separate subsequent submittals, submittal will be returned without review.

d. Approval of a separate material, product, or component does not imply approval of assembly in which item functions.

1.4.3 Scheduling

a. Coordinate scheduling, sequencing, preparing and processing of submittals with performance of work so that work will not be delayed by submittal processing. Allow for potential requirements to resubmit.

b. Except as specified otherwise, allow review period, beginning with receipt by approving authority, that includes at least 10 working days. Period of review for each resubmittal is the same as for initial submittal.

1.4.4 Variations

Variations from contract requirements require Government approval pursuant to contract Clause entitled "FAR 52.236-21, Specifications and Drawings for Construction" and will be considered where advantageous to government.

1.4.4.1 Considering Variations

Discussion with contracting officer prior to submission, will help ensure functional and quality requirements are met and minimize rejections and resubmittals. When contemplating a variation which results in lower cost, consider submission of the variation as a Value Engineering Change Proposal

(VECP).

1.4.4.2 Proposing Variations

When proposing variation, deliver written request to the contracting officer, with documentation of the nature and features of the variation and why the variation is desirable and beneficial to government. If lower cost is a benefit, also include an estimate of the cost saving. In addition to documentation required for variation, include the submittals required for the item. Clearly mark the proposed variation in all documentation.

1.4.4.3 Warranting That Variation Are Compatible

When delivering a variation for approval, contractor warrants that this contract has been reviewed to establish that the variation, if incorporated, will be compatible with other elements of work.

1.4.4.4 Review Schedule Is Modified

In addition to normal submittal review period, a period of 5 working days will be allowed for consideration by the Government of submittals with variations.

SECTION 01 33 00 Page 5

1.4.5 Contractor's Responsibilities

a. Determine and verify field measurements, materials, field construction criteria; review each submittal; and check and coordinate each submittal with requirements of the work and contract documents.

b. Transmit submittals to Contracting Officer in accordance with schedule on approved Submittal Register, and to prevent delays in the work, delays to government, or delays to separate contractors.

c. Advise contracting officer of variation, as required by paragraph entitled "Variations."

d. Correct and resubmit submittal as directed by approving authority.

When resubmitting disapproved transmittals or transmittals noted for resubmittal, the contractor shall provide copy of that previously submitted transmittal including all reviewer comments for use by approving authority. Direct specific attention in writing or on resubmitted submittal, to revisions not requested by approving authority on previous submissions.

e. Furnish additional copies of submittal when requested by contracting officer, to a limit of 20 copies per submittal.

f. Complete work which must be accomplished as basis of a submittal in time to allow submittal to occur as scheduled.

g. Ensure no work has begun until submittals for that work have been returned as "approved," except to the extent that a portion of work must be accomplished as basis of submittal.

1.4.6 Government Responsibilities

a. Note date on which submittal was received from contractor on each Contract Item Approval Request Form.

b. Review each submittal; and check and coordinate each submittal with requirements of work and contract documents.

c. Review submittals for conformance with project design concepts and compliance with contract documents.

d. Ensure that material is clearly legible.

e. Review submittals for approval within scheduling period specified and only for conformance with project design concepts and

f. Identify returned submittals with one of the actions defined in paragraph entitled "Actions Possible" and with markings appropriate for action indicated.

1.4.7 Actions Possible

Submittals will be returned with one of the following notations:

SECTION 01 33 00 Page 6

a. Submittals marked "approved" "approved as submitted" authorize contractor to proceed with work covered.

b. Submittals marked "approved" "see below" authorize contractor to proceed with work as noted provided contractor takes no exception to the notations.

c. Submittals marked "disapproved" indicate submittal is incomplete or does not comply with design concept or requirements of the contract documents and shall be resubmitted with appropriate changes. No work shall proceed for this item until resubmittal is approved.

1.5 FORMAT OF SUBMITTALS

1.5.1 Transmittal Form

Transmit electronically each submittal, unless otherwise noted in the submittal register and/or where electronic submission is not feasible (i.e.

samples), to office of approving authority. The maximum file size that may be emailed is 10 MB; anything larger must be submitted hard copy or on a CD.

Transmit submittals with transmittal form prescribed by contracting officer and standard for project. The transmittal form shall identify contractor, indicate date of submittal, and include information prescribed by transmittal form and required in paragraph entitled "Identifying Submittals." Process transmittal forms to record actions regarding sample panels and sample installations. Note: Submittals requiring hard copy submission shall be provided with carbon copy transmittal form provided by the government.

1.5.2 Identifying Submittals

Identify submittals, except sample panel and sample installation, with the following information on each separate component of each submittal and transmittal form. The maximum file size for electronic submittals shall be no larger than 10 MB. Identify each copy of each submittal identically, with the following:

a. Project title and location.

b. Construction contract number.

c. Section number of the specification section by which submittal is required.

d. Submittal description (SD) number of each component of submittal.

e. When a resubmission, alphabetic suffix on submittal description, for example, SD-10A, to indicate resubmission.

f. Name, address, and telephone number of subcontractor, supplier, manufacturer and any other second tier contractor associated with submittal.

g. Product identification and location in project.

SECTION 01 33 00 Page 7

1.5.3 Format for Product Data

a. Present product data submittals for each section. Include table of contents, listing page and catalog item numbers for product data.

b. Indicate, by prominent notation, each product which is being submitted; indicate specification section number and paragraph number to which it pertains.

c. Supplement product data with material prepared for project to satisfy submittal requirements for which product data does not exist. Identify this material as developed specifically for project.

1.5.4 Format for Shop Drawings

a. Shop drawings shall not be less than 8 1/2 by 11 inches nor more than 30 by 42 inches.

b. Present 8 1/2 by 11 inches sized shop drawings as part of the submittals required by section. Present larger drawings in sets.

c. Include on each drawing the drawing title, number, date, and revision numbers and dates, in addition to information required in paragraph entitled "Identifying Submittals."

d. Dimension drawings, except diagrams and schematic drawings; prepare drawings demonstrating interface with other trades to scale. Shop drawing dimensions shall be the same unit of measure as indicated on the contract drawings. Identify materials and products for work shown.

1.5.5 Format of Samples

a. Furnish samples in sizes below, unless otherwise specified or unless the manufacturer has prepackaged samples of approximately same size as specified:

(1) Sample of Equipment or Device: Full size.

(2) Sample of Materials Less Than 2 by 3 inches: Built up to 8 1/2 by 11 inches.

(3) Sample of Materials Exceeding 8 1/2 by 11 inches: Cut down to 8 1/2 by 11 inches and adequate to indicate color, texture, and material variations.

(4) Sample of Linear Devices or Materials: 10 inch length or length to be supplied, if less than 10 inches. Examples of linear devices or materials are conduit and handrails.

(5) Sample of Non-Solid Materials: Pint. Examples of non-solid materials are sand and paint.

(6) Color Selection Samples: 2 by 4 inches.

(7) Sample Panel: 4 by 4 feet.

SECTION 01 33 00 Page 8

(8) Sample Installation: 100 square feet.

b. Samples Showing Range of Variation: Where variations are unavoidable due to nature of the materials, submit sets of samples of not less than three units showing extremes and middle of range.

c. Reusable Samples: Incorporate returned samples into work only if so specified or indicated. Incorporated samples shall be in undamaged condition at time of use.

d. Recording of Sample Installation: Note and preserve the notation of area constituting sample installation but remove notation at final clean up of project.

e. When color, texture or pattern is specified by naming a particular manufacturer and style, include one sample of that manufacturer and style, for comparison.

1.5.6 Format of Administrative Submittals

a. When submittal includes a document which is to be used in project or become part of project record, other than as a submittal, do not apply contractor's approval stamp to document, but to a separate sheet accompanying document.

b. Operation and Maintenance Manual Data: Submit in accordance with

Section 01781, "Operation and Maintenance Data." Include components required in that section and the various technical sections.

1.6 QUANTITY OF SUBMITTALS

1.6.1 Number of Copies of Product Data

a. When hard copy submission is required, submit four copies of submittals of product data.

1.6.2 Number of Copies of Shop Drawings

Submit shop drawings in compliance with quantity requirements specified for product data.

1.6.3 Number of Samples

a. Submit two sets of samples showing range of variation, of each required item. One approved sample or set of samples will be retained by approving authority and one will be returned to contractor.

b. Submit one sample panel. Include components listed in technical section or as directed.

c. Submit one sample installation, where directed.

d. Submit one sample of non-solid materials.

SECTION 01 33 00 Page 9

SECTION 01 33 00 Page 10

1.6.4 Number of Copies of Administrative Submittals

a. Unless otherwise specified, submit administrative submittals compliance with quantity requirements specified for product data.

b. Submit administrative submittals required under "SD-19 Operation and Maintenance Manuals" to conform to Section 01 78 23, "Operation and Maintenance Data."

SECTION 01 33 00

SUBMITTAL PROCEDURES

1.1 DEFINITIONS

1.1.1 Submittal

Shop drawings, product data, samples, and administrative submittals presented for review and approval. Contract Clauses "FAR 52.236-5, Material and Workmanship," paragraph (b) and "FAR 52.236-21, Specifications and Drawings for Construction," paragraphs (d), (e), and (f) apply to all "submittals."

1.1.2 Types of Submittals

All submittals are classified as indicated in paragraph "Submittal Descriptions (SD)". Submittals also are grouped as follows:

a. Shop drawings: As used in this section, drawings, schedules, diagrams, and other data prepared specifically for this contract, by contractor or through contractor by way of subcontractor, manufacturer, supplier, distributor, or other lower tier contractor, to illustrate portion of work.

b. Product data: Preprinted material such as illustrations, standard schedules, performance charts, instructions, brochures, diagrams, manufacturer's descriptive literature, catalog data, and other data to illustrate portion of work, but not prepared exclusively for this contract.

c. Samples: Physical examples of products, materials, equipment, assemblies, or workmanship that are physically identical to portion of work, illustrating portion of work or establishing standards for evaluating appearance of finished work or both.

d. Administrative submittals: Data presented for reviews and approval to ensure that administrative requirements of project are adequately met but not to ensure directly that work is in accordance with design concept and in compliance with contract documents.

1.1.3 Submittal Descriptions (SD)

Construction Progress Schedule Submittal register Schedule of values Health and safety plan Work plan Quality control plan Environmental protection plan

SECTION 01 33 00 Page 1

SD-02 Shop Drawings

Drawings, diagrams and schedules specifically prepared to illustrate some portion of the work.

Diagrams and instructions from a manufacturer or fabricator for use in producing the product and as aids to the contractor for integrating the product or system into the project.

Drawings prepared by or for the contractor to show how multiple systems and interdisciplinary work will be coordinated.

SD-03 Product Data

Catalog cuts, illustrations, schedules, diagrams, performance charts, instructions and brochures illustrating size, physical appearance and other characteristics of materials or equipment for some portion of the work.

Samples of warranty language when the contract requires extended product warranties.

SD-04 Samples

Physical examples of materials, equipment or workmanship that illustrate functional and aesthetic characteristics of a material or product and establish standards by which the work can be judged.

Color samples from the manufacturer's standard line (or custom color samples if specified) to be used in selecting or approving colors for the project.

Field samples and mock-ups constructed on the project site establish standards by which the ensuring work can be judged. Includes assemblies or portions of assemblies which are to be incorporated into the project and those which will be removed at conclusion of the work.

SD-05 Design Data

Calculations, mix designs, analyses or other data pertaining to a part of work.

Report signed by authorized official of testing laboratory that a material, product or system identical to the material, product or system to be provided has been tested in accord with specified requirements. (Testing must have been within three years of date of contract award for the project.)

Report which includes findings of a test required to be performed by the contractor on an actual portion of the work or prototype prepared for the project before shipment to job site.

Report which includes finding of a test made at the job site or on sample taken from the job site, on portion of work during or after installation.

Investigation reports

SECTION 01 33 00 Page 2

Daily checklists

Final acceptance test and operational test procedure

Statements signed by responsible officials of manufacturer of product, system or material attesting that product, system or material meets specification requirements. Must be dated after award of project contract and clearly name the project.

Document required of Contractor, or of a supplier, installer or subcontractor through Contractor, the purpose of which is to further quality of orderly progression of a portion of the work by documenting procedures, acceptability of methods or personnel qualifications.

Confined space entry permits.

SD-08 Manufacturer's Instructions

Preprinted material describing installation of a product, system or material, including special notices and Material Safety Data sheets concerning impedances, hazards and safety precautions.

SD-09 Manufacturer's Field Reports

Documentation of the testing and verification actions taken by manufacturer's representative to confirm compliance with manufacturer's standards or instructions.

Factory test reports.

SD-10 Operation and Maintenance Data

Data intended to be incorporated in operations and maintenance manuals.

Documentation to record compliance with technical or administrative requirements or to establish an administrative mechanism.

Special warranties

Posted operating instructions

Training plan

1.1.4 Approving Authority

Person authorized to approve submittal.

1.1.5 Work

As used in this section, on- and off-site construction required by contract documents, including labor necessary to produce construction and materials, SECTION 01 33 00 Page 3 products, equipment, and systems incorporated or to be incorporated in such construction.

Submit the following in accordance with the requirements of this section.

Submittal register

1.3 USE OF SUBMITTAL REGISTER

Prepare and maintain submittal register, as the work progresses. Do not change data in columns (c), (d), (e), and (f) as delivered by government.

1.3.1 Submittal Register

Submit submittal register. Do not change data in columns (c), (d), (e), and

(f) as delivered by the government. Verify that all submittals required for project are listed and add missing submittals. Complete the following on the register:

Column (a) Activity Number: Activity number from the project schedule.

Column (b) Transmittal Number: Contractor assigned list of consecutive numbers.

Column (g) Contractor Submit Date: Scheduled date for approving authority to receive submittals.

Column (h) Contractor Approval Date: Date contractor needs approval of submittal.

Column (i) Contractor Material: Date that contractor needs material delivered to contractor control.

1.4 PROCEDURES FOR SUBMITTALS

1.4.1 Reviewing, Certifying, Approving Authority

Government organization shall be responsible for reviewing and certifying that submittals are in compliance with contract requirements. Approving authority on submittals is the Project Manager unless otherwise specified for specific submittal.

1.4.2 Constraints

a. Submittals listed or specified in this contract shall conform to provisions of this section, unless explicitly stated otherwise.

b. Submittals shall be complete for each definable feature of work;

components of definable feature interrelated as a system shall be submitted at same time.

SECTION 01 33 00 Page 4

c. When acceptability of a submittal is dependent on conditions, items, or materials included in separate subsequent submittals, submittal will be returned without review.

d. Approval of a separate material, product, or component does not imply approval of assembly in which item functions.

1.4.3 Scheduling

a. Coordinate scheduling, sequencing, preparing and processing of submittals with performance of work so that work will not be delayed by submittal processing. Allow for potential requirements to resubmit.

b. Except as specified otherwise, allow review period, beginning with receipt by approving authority, that includes at least 10 working days. Period of review for each resubmittal is the same as for initial submittal.

1.4.4 Variations

Variations from contract requirements require Government approval pursuant to contract Clause entitled "FAR 52.236-21, Specifications and Drawings for Construction" and will be considered where advantageous to government.

1.4.4.1 Considering Variations

Discussion with contracting officer prior to submission, will help ensure functional and quality requirements are met and minimize rejections and resubmittals. When contemplating a variation which results in lower cost, consider submission of the variation as a Value Engineering Change Proposal

(VECP).

1.4.4.2 Proposing Variations

When proposing variation, deliver written request to the contracting officer, with documentation of the nature and features of the variation and why the variation is desirable and beneficial to government. If lower cost is a benefit, also include an estimate of the cost saving. In addition to documentation required for variation, include the submittals required for the item. Clearly mark the proposed variation in all documentation.

1.4.4.3 Warranting That Variation Are Compatible

When delivering a variation for approval, contractor warrants that this contract has been reviewed to establish that the variation, if incorporated, will be compatible with other elements of work.

1.4.4.4 Review Schedule Is Modified

In addition to normal submittal review period, a period of 5 working days will be allowed for consideration by the Government of submittals with variations.

SECTION 01 33 00 Page 5

1.4.5 Contractor's Responsibilities

a. Determine and verify field measurements, materials, field construction criteria; review each submittal; and check and coordinate each submittal with requirements of the work and contract documents.

b. Transmit submittals to Contracting Officer in accordance with schedule on approved Submittal Register, and to prevent delays in the work, delays to government, or delays to separate contractors.

c. Advise contracting officer of variation, as required by paragraph entitled "Variations."

d. Correct and resubmit submittal as directed by approving authority.

When resubmitting disapproved transmittals or transmittals noted for resubmittal, the contractor shall provide copy of that previously submitted transmittal including all reviewer comments for use by approving authority. Direct specific attention in writing or on resubmitted submittal, to revisions not requested by approving authority on previous submissions.

e. Furnish additional copies of submittal when requested by contracting officer, to a limit of 20 copies per submittal.

f. Complete work which must be accomplished as basis of a submittal in time to allow submittal to occur as scheduled.

g. Ensure no work has begun until submittals for that work have been returned as "approved," except to the extent that a portion of work must be accomplished as basis of submittal.

1.4.6 Government Responsibilities

a. Note date on which submittal was received from contractor on each Contract Item Approval Request Form.

b. Review each submittal; and check and coordinate each submittal with requirements of work and contract documents.

c. Review submittals for conformance with project design concepts and

d. Ensure that material is clearly legible.

e. Review submittals for approval within scheduling period specified and only for conformance with project design concepts and

f. Identify returned submittals with one of the actions defined in paragraph entitled "Actions Possible" and with markings appropriate for action indicated.

1.4.7 Actions Possible

Submittals will be returned with one of the following notations:

SECTION 01 33 00 Page 6

a. Submittals marked "approved" "approved as submitted" authorize contractor to proceed with work covered.

b. Submittals marked "approved" "see below" authorize contractor to proceed with work as noted provided contractor takes no exception to the notations.

c. Submittals marked "disapproved" indicate submittal is incomplete or does not comply with design concept or requirements of the contract documents and shall be resubmitted with appropriate changes. No work shall proceed for this item until resubmittal is approved.

1.5 FORMAT OF SUBMITTALS

1.5.1 Transmittal Form

Transmit electronically each submittal, unless otherwise noted in the submittal register and/or where electronic submission is not feasible (i.e.

samples), to office of approving authority. The maximum file size that may be emailed is 10 MB; anything larger must be submitted hard copy or on a CD.

Transmit submittals with transmittal form prescribed by contracting officer and standard for project. The transmittal form shall identify contractor, indicate date of submittal, and include information prescribed by transmittal form and required in paragraph entitled "Identifying Submittals." Process transmittal forms to record actions regarding sample panels and sample installations. Note: Submittals requiring hard copy submission shall be provided with carbon copy transmittal form provided by the government.

1.5.2 Identifying Submittals

Identify submittals, except sample panel and sample installation, with the following information on each separate component of each submittal and transmittal form. The maximum file size for electronic submittals shall be no larger than 10 MB. Identify each copy of each submittal identically, with the following:

a. Project title and location.

b. Construction contract number.

c. Section number of the specification section by which submittal is required.

d. Submittal description (SD) number of each component of submittal.

e. When a resubmission, alphabetic suffix on submittal description, for example, SD-10A, to indicate resubmission.

f. Name, address, and telephone number of subcontractor, supplier, manufacturer and any other second tier contractor associated with submittal.

g. Product identification and location in project.

SECTION 01 33 00 Page 7

1.5.3 Format for Product Data

a. Present product data submittals for each section. Include table of contents, listing page and catalog item numbers for product data.

b. Indicate, by prominent notation, each product which is being submitted; indicate specification section number and paragraph number to which it pertains.

c. Supplement product data with material prepared for project to satisfy submittal requirements for which product data does not exist. Identify this material as developed specifically for project.

1.5.4 Format for Shop Drawings

a. Shop drawings shall not be less than 8 1/2 by 11 inches nor more than 30 by 42 inches.

b. Present 8 1/2 by 11 inches sized shop drawings as part of the submittals required by section. Present larger drawings in sets.

c. Include on each drawing the drawing title, number, date, and revision numbers and dates, in addition to information required in paragraph entitled "Identifying Submittals."

d. Dimension drawings, except diagrams and schematic drawings; prepare drawings demonstrating interface with other trades to scale. Shop drawing dimensions shall be the same unit of measure as indicated on the contract drawings. Identify materials and products for work shown.

1.5.5 Format of Samples

a. Furnish samples in sizes below, unless otherwise specified or unless the manufacturer has prepackaged samples of approximately same size as specified:

(1) Sample of Equipment or Device: Full size.

(2) Sample of Materials Less Than 2 by 3 inches: Built up to 8 1/2 by 11 inches.

(3) Sample of Materials Exceeding 8 1/2 by 11 inches: Cut down to 8 1/2 by 11 inches and adequate to indicate color, texture, and material variations.

(4) Sample of Linear Devices or Materials: 10 inch length or length to be supplied, if less than 10 inches. Examples of linear devices or materials are conduit and handrails.

(5) Sample of Non-Solid Materials: Pint. Examples of non-solid materials are sand and paint.

(6) Color Selection Samples: 2 by 4 inches.

(7) Sample Panel: 4 by 4 feet.

SECTION 01 33 00 Page 8

(8) Sample Installation: 100 square feet.

b. Samples Showing Range of Variation: Where variations are unavoidable due to nature of the materials, submit sets of samples of not less than three units showing extremes and middle of range.

c. Reusable Samples: Incorporate returned samples into work only if so specified or indicated. Incorporated samples shall be in undamaged condition at time of use.

d. Recording of Sample Installation: Note and preserve the notation of area constituting sample installation but remove notation at final clean up of project.

e. When color, texture or pattern is specified by naming a particular manufacturer and style, include one sample of that manufacturer and style, for comparison.

1.5.6 Format of Administrative Submittals

a. When submittal includes a document which is to be used in project or become part of project record, other than as a submittal, do not apply contractor's approval stamp to document, but to a separate sheet accompanying document.

b. Operation and Maintenance Manual Data: Submit in accordance with

Section 01781, "Operation and Maintenance Data." Include components required in that section and the various technical sections.

1.6 QUANTITY OF SUBMITTALS

1.6.1 Number of Copies of Product Data

a. When hard copy submission is required, submit four copies of submittals of product data.

1.6.2 Number of Copies of Shop Drawings

Submit shop drawings in compliance with quantity requirements specified for product data.

1.6.3 Number of Samples

a. Submit two sets of samples showing range of variation, of each required item. One approved sample or set of samples will be retained by approving authority and one will be returned to contractor.

b. Submit one sample panel. Include components listed in technical section or as directed.

c. Submit one sample installation, where directed.

d. Submit one sample of non-solid materials.

SECTION 01 33 00 Page 9

SECTION 01 33 00 Page 10

1.6.4 Number of Copies of Administrative Submittals

a. Unless otherwise specified, submit administrative submittals compliance with quantity requirements specified for product data.

b. Submit administrative submittals required under "SD-19 Operation and Maintenance Manuals" to conform to Section 01 78 23, "Operation and Maintenance Data."

SECTION 01 50 00

TEMPORARY FACILITIES AND CONTROLS

1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 70 (1999) National Electrical Code

NFPA 241 (1996) Safeguarding Construction, Alteration, and Demolition Operations

1.2 SUBMITTALS

Construction site plan

1.3 CONSTRUCTION SITE PLAN

Prior to the start of work, submit a site plan showing the locations of temporary facilities (including layouts and details, equipment and material storage area (onsite and offsite), and access and haul routes used for this contract. Show locations of safety and construction fences, site trailers, construction entrances, trash dumpsters, temporary sanitary facilities, and worker parking areas.

1.4 TEMPORARY UTILITIES

1.4.1 Contractor Utilities

The Contractor shall provide his own utilities when existing utilities are unavailable or of insufficient capacity to supply both BSU Boston and the contractor. Reasonable amounts of utilities will be made available without charge. The Contractor will be responsible for making connections, providing transformers and meters, and making disconnections; and for providing backflow preventer devices on connections to domestic water lines.

Under no circumstances will taps to base fire hydrants be allowed for obtaining domestic water.

1.5 WEATHER PROTECTION

Take precautions to minimize danger to persons, and protect the work and nearby Government property. Precautions shall include, but are not limited

Section 01 50 00 Page 1 to, closing openings; removing loose materials, tools and equipment from exposed locations; and removing or securing scaffolding and other temporary work. Close openings in the work when storms of lesser intensity pose a threat to the work or any nearby Government property.

1.6 STORAGE AREAS

Contractor shall be responsible for security of his property. The Contract Clause entitled "FAR 52.236-10, Operations and Storage Areas" and the following apply:

1.6.1 Storage Size and Location

The open site available for storage shall be as specified by the Engineering Officer at Coast Guard BSU Boston.

1.7 TEMPORARY SANITARY FACILITIES

Provide temporary sewer and sanitation facilities that are self-contained units with both urinals and stool capabilities. Ventilate the units to control odors and fumes and empty and clean them at least once a week or more often if required by the Contracting Officer. The doors shall be self-closing. Locate the facility behind the construction fence or out of the public view.

1.8 TEMPORARY BUILDINGS

Temporary facilities (including trailers) shall be in like new condition.

Locate these facilities where directed and within the indicated operations area. Storage of material/debris under such facilities is prohibited.

Contractor shall be responsible for the security of the stored property.

1.8.1 Maintenance of Temporary Facilities

Suitably paint and maintain the temporary facilities. Failure to do so will be sufficient reason to require their removal.

1.8.2 Trailers or Storage Buildings

Trailers or storage buildings will be permitted, where space is available, subject to the approval of the Contracting Officer. The trailers or buildings shall be in good condition, free from visible damage rust and deterioration, and meet all applicable safety requirements. Trailers shall be roadworthy and comply with all appropriate state and local vehicle requirements. Failure to maintain storage trailers or buildings to these standards shall result in the removal of non-complying units at the Contractor's expense. A sign not smaller than 24 by 24 inches shall be conspicuously placed on the trailer depicting the company name, business phone number, and emergency phone number. Trailers shall be anchored to resist high winds and must meet applicable state of local standards for anchoring mobile trailers.

2 PRODUCTS

Not Used.

Section…