Amendment_0002_12_April_2017.pdf

1. CONTRACT ID CODE PAGE OF PAGES

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1 5

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

0002 April 12, 2017 625157

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE Contracting Officer USCG CEU Oakland 1301 Clay Street 7th Floor, Suite 700N Oakland, CA 94612-5203

Same as Block 6

8. NAME AND ADRESS OF CONTRACTOR (no., street, county, State and ZIP Code) √ 9.A AMENDMENT OF SOLICITATION NO.

ALL PROSPECTIVE BIDDERS

X HSCG88-17-B-PQQ104

9B. DATE (SEE ITEM 11)

March 20, 2017

10A. MODIFICATION OF CONTRACT/ORDER

NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended. Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods: (a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the Offer submitted: or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEGEMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT/.ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc) SET FORTH IN ITEM 14, PURSUANT TO AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority).

E. IMPORTANT: Contractor is not, is required to sign this document and return 1 copy to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

The purpose of this amendment is to provide responses to questions from prospective bidders, include a requirement for tug service, revise the schedule of prices, revise paragraphs M.2 and M.3 of the IFB and revise the bid submission dates.

(1) The following responses are provided to questions from prospective bidders.

QUESTION: The Table on Page 6 of the Letter of Agreement for Consistency, Amendment No. 6 indicates a work period of August 1st to November 30th, this is in conflict with the in water work dates indicated in the Technical Specifications. Which work window prevails in this situation?

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

JASON DUGAN

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070 30-105 STANDARD FORM 30 (REV. 10-83)PREVIOUS

EDITION UNUSABLE Prescribed by GSA, FAR (48 CFR) 53.243

Invitation for Bid Number HSCG88-17-B-PQQ104 Amendment 0002 April 12, 2107

RESPONSE: The in-water work window approved by all regulatory agencies is June 1- November 30th. However, due to the vessel schedules, the preferred dredging work window is between July 17 and August 28th, as there will only be one vessel docked during that time; therefore limiting disruption to CG operations.

QUESTION: Technical Specifications Section 35 20 23 – 1.2.1 indicates that the removal of hard (previously undisturbed) material is included in the unpaid overdepth dredging prism. Current depths shown on the survey on Sheet 2 of 3 of the Coast Guard Island Berth Dredging Project Plans shows sounding in this area as high as 28’. This would indicate 8’ of material has infilled in this area. Further, the depths in the center of the Federal Navigation Channel are even shallower. Can you confirm that all the material above -36’ is maintenance material? Is there any geotechnical data available in this area? Is the post-dredge survey from the previous dredging episode available? How will the Contracting Officer address material sloughing from the Channel into the dredge template?

RESPONSE: The latest hydrographic survey, dated September 2016, was provided with the solicitation. The last dredging episode was conducted in 2008. During that dredging episode, the basin was dredged to -30 feet MLLW.

Therefore, the material in the dredge prism above -30 feet may be considered maintenance, while the material between 30 feet to 36 feet is considered new dredging. Attached is the post-dredge hydrographic survey from 2008.

Vibracore sampling was conducted in 2014. The results are available in the Tier 1 Evaluation Report, dated February 2017 and were provided in Amendment 0001. Sloughing material will be handled in accordance with Section

DREDGING 35 20 23-1.4.4.

QUESTION: Is the Dredge Boundary shown on Sheet 2 of 3 of the Coast Guard Island Berth Dredging Project Plans the toe-to-toe limit, the limit at the top of slopes, or at the theoretical daylight line? Are any other sections available for this area?

RESPONSE: The Dredge Boundary is the toe-to-toe limit. The limit at the top of slopes is the daylight intersection with the existing channel bottom surrounding the berth area. The section on Sheet 3 of 3 is the only section provided.

The side slope along the face of the wharf is 2 to 1 and the side slope in all other areas is 3 to 1.

QUESTION: If more material is required to go to Montezuma Wetlands Project than indicated in CLIN 0002 & 0003 will the Contractor be compensated at the rates indicated in CLIN 0002 & 0003 respectively?

RESPONSE: Federal Acquisition Regulation Contract Clause Number 52.211-18 will apply for any increases in quantities for CLINs 0002AA, 0002AB, 0003AA, 0003AB, 0004AA, 0004AB and 0006

52.211-18 -- Variation in Estimated Quantity.

Variation in Estimated Quantity (Apr 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract.

Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

(End of Clause)

April 12, 2107

QUESTION: Per the Technical Specifications for the Coast Guard Island Berth Dredging Project Section 01 32 23 –

1.3.2.2 ‘The Government will accept a reach within 8 days of being notified of reach completion.’ Technical Specification Section 01 32 23 – 1.3.2 indicates ‘Working in the next reach or next portion of a reach is unauthorized until the after-dredge survey is accepted.’ The result of these specification is the potential for over 8 days of standby time while waiting for reach acceptance. Should this potential standby time be included in the Contractor’s bid price for the corresponding line items?

RESPONSE: The language in the specification 01 32 23 – 1.3.2 is hereby amended to read: “As soon as practicable after completion of a reach, the Contractor will perform after-dredge surveys.” The language in the specification 01 32 23- 1.3.2.2 is hereby amended to read: “Acceptance of Reach (es) will be in writing from the Contracting Officer Representative based on the Contractor After-dredge survey data.

QUESTION: Per Technical Specification 35 20 23 – 3.2.6.3 ‘Dredged material will be passed through a debris grid with a maximum opening size of 10 inches by 10 inches.’ The standard grid size (and the grid size required at USCG Station Golden Gate) is 12 inches by 12 inches. Will a 12 inches by 12 inches grid be acceptable for Coast Guard Island Berth Dredging?

RESPONSE: A 12 inches by 12 inches grid is acceptable as reflected in Technical Specification 35 20 23 – 3.2.1.1 and 3.2.6.3.

QUESTION: Per Technical Specification 35 20 23 – 3.2.6.3 ‘Material that does not pass through the grid will be considered solid debris and shall be disposed in areas outside of Corps Jurisdiction.’ Often new work dredge material will not pass through a grid, how is the Contractor to handle dredge material that does not pass through the grid?

RESPONSE: The Corps of Engineers does not expect Contractors to encounter any debris that is not acceptable at a Class II landfill. Contractors should bid accordingly

QUESTION: At Coast Guard Island, if necessary will the moored vessels be repositioned to different berths to accommodate the dredge schedule.

RESPONSE: See Section DREDGING 35 20 23-3.2.4 Order of Work. CG expects only one vessel will be moored during the July 17- August 28th time frame. The Contractor will be required to provide tug services to move the vessel between berths. See Schedule of Prices CLIN 0006.

QUESTION: Technical Specification Section 01 32 23 – 3.2.5 indicates that the Government will assess liquidated damages. What are the liquidated damages for this contract?

RESPONSE: Liquidated Damages does not apply to this contract.

QUESTION: CLIN 0005: Option Line Item for Station Golden Gate Dredging is a lump sum item in which the variations in quantities clause does not apply. The Bid quantity is based on survey data from 2/14/2014. Does the Government intend to make an up to date survey available to potential bidders?

RESPONSE: The environmental permits allow a maximum of 4,600cy of sediment to be removed and disposed of.

Sediment in excess of 4,600cy would violate the permits. If the pre-dredge hydrographic survey indicates a greater volume and the permit can be amended a contract modification may be processed for the additional quantity.

QUESTION: At USCG Station Golden Gate is the Contractor required to achieve grade below the footprint of the floating dock?

RESPONSE: The contractor is required to achieve grade below the footprint of the floating docks to the maximum extent practicable.

April 12, 2107

QUESTION: At USCG Station Golden Gate will the floating docks be removed to allow the Contractor access to material in the footprint of the floating dock and in the settling basin?

RESPONSE: The Coast Guard station crew can remove the floating jet docks upon prior request, and only if the Contractor cannot access the material beneath. The contractor shall provide a seven day notice to the Contracting Officer Representative if the floating docks require removal.

QUESTION: What is the criteria for acceptance for dredging at USCG Station Golden Gate?

RESPONSE: Acceptance of dredging at Station Golden Gate is based on meeting the design criteria, the conditions in the scope of work and specifications, adherence to the conditions in the environmental permits, and the reporting requirements.

QUESTION: Can CLIN 0005 Option Line Item for Station Golden Gate Dredging be decoupled from the Coast Guard Island Berth Dredging Project CLIN 0001 – CLIN 0004?

RESPONSE: No

QUESTION: Per the Letter of Agreement for Consistency, Amendment No. 2 ‘Silt curtains and/or light monitoring may be required to minimize negative impacts on the eelgrass beds.’ However, the Specification for Maintenance Dredging at Station Golden Gate, Silt curtain shall be deployed during dredging operations, and there is no requirement for Light Monitoring. How and when will the determination be made as to whether light monitoring is required, and is the Contractor to include the potential for these costs in their bid price?

RESPONSE: The requirement for the use of a silt curtain is included in the USACE permit and based on consultation between USACE, NMFS, and the EPA. The deployment of the silt curtain needs to be included in the Dredge Operations Plan, which will be submitted to the regulatory agencies prior to dredging activities. The requirement for light monitoring is dependent on the results of the pre-dredge eelgrass survey and is a requirement of the BCDC permit.

Therefore, the Contractor is advised to anticipate the requirement to deploy a silt curtain and monitor activities; and include the associated costs in the bid.

QUESTION: Does the Government have any indication as to the amount or type of debris that the Contractor can expect in either of the dredge sections?

RESPONSE: There are no indications of the type of debris beyond sediment that may be expected at either of the dredge sections. Logs, wood piles, cables, and other navigational related debris were encountered at previous dredging episodes at other Coast Guard facilities; therefore, the contractor may encounter the same material at either dredge sections.

(2) CLIN 0006 is added to the Schedule of Prices to provide Tug Services. Work shall include the following:

Provide two tugs to assist ship(s) with moving berths at Base Alameda. The tugs are to arrive on scene 30 minutes prior to commencement of the shifting of berths and remain affixed until dismissed from the bridge of the ships. The ships will be in a “Cold Iron” status and will not have the ability to assist with propulsion or movement. The movement evolution should not take more than three (3) hours to complete. Tug boats shall have covers for the fenders. The ship’s approximate characteristics are as follows:

LENGTH OVERALL: 418FT/127.4M

LENGTH AT WATERLINE: 390FT/94M

BEAM: 54FT/16.15M

DRAFT: 24FT/7.3M

HEIGHT: 147FT/46M

FLT DECK HEIGHT: 25FT/7.6M ABOVE WATERLINE

FANTAIL HEIGHT: 15FT/4.6M ABOVE WATERLINE

April 12, 2107

(3) The Schedule of Prices is revised with the attached Schedule of Prices dated 12 April 2017, 3 pages

(4) Paragraph M.2 of the Invitation for Bid is revised to read:

“M.2 BID EVALUATION

For evaluation purposes only, the Government will determine the low bid based on the TOTAL AMOUNT FOR ITEMS 0001, 0002AA, 002AB, 0003AA, 003AB, 0004AA, 0004AB, 0005 and 0006.”

(5) Paragraph M.3 of the Invitation for Bid is revised to read:

“M.3 AWARD

The low bidder shall be determined by taking the lowest total price for items 0001, 0002AA, 002AB, 0003AA, 003AB, 0004AA, 0004AB, 00005 and 0006. Contract award shall be made to the responsible bidder submitting the lowest aggregate price, whose bid is responsive to all the terms and conditions in this solicitation.”

(6) Paragraph 3a. of the standard form 1442 is revised to read: (Revised SF 1442 attached)

“13. ADDITIONAL SOLICITATIONREQUIREMENTS:

a. Sealed offers in original and 0 opies to perform the work required are due at the place specified in Item 8 by 2:00 P.M. local time 28 April 2017. If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.”

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NUMBER

HSCG88-17-B-PQQ104

2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED

20 March 2017

PAGE

OF PAGES

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

625157

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SEE BLOCK 7

United States Coast Guard Civil Engineering Unit 1301 Clay Street, 7th Floor, Suite 700NOakland CA 94612-5203

9. FOR INFORMATION

CALL:

a. NAME

Jason Dugan

b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

510-637-5583

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

COAST GUARD DREDGING PROJECT:

PROJECT DESCRIPTION: (1) CONDUCT MAINTENANCE DREDGING OF THE BERTHING AREAS LOCATED ON THE SOUTH SIDE OF COAST GUARD ISLAND, ALAMEDA, CALIFORNIA. (2) CONDUCT MAINTENANCE DREDGING OF SEDIMENT WITHIN THE U.S. COAST GUARD STATION GOLDEN GATE BOAT BASIN AND ENTRANCE CHANNEL, LOCATED IN HORESHOE COVE, SAUSALITO, MARIN COUNTY, CALIFORNIA

THIS REQUIREMENT IS SOLICITED ON AN UNRESTRICED BASIS. IT WILL BE ISSUED AS AN INVITATION FOR BID (IFB) WHICH WILL RESULT IN THE

AWARD OF A SINGLE FIRM FIXED PRICE (FFP) CONTRACT.

THE CONTRACTOR MAY BEGIN PERFORMANCE NO EARLIER THAN 1 JUNE 2017 AND COMPLETE THE WORK BY 30 NOVEMBER 2017. THE IN- WATER WORK WINDOW IS FROM 1 JUNE 2017 TO 30 NOVEMBER 2017. AWARD OF THE CONTRACT CONSTITUTES NOTICE TO PROCEED FOR CONSTRUCTION; HOWEVER, NO ONSITE WORK MAY BEGIN UNTIL THE CONTRACTING OFFICER HAS APPROVED YOUR INSURANCE

CERTIFICATE, PERFORMANCE AND PAYMENT BONDS AND DRAFT SCHEDULE.

THE NORTH AMERICAN INDUSTRY CLASSIFICATION SYSTEM (NAICS) CODE APPLICABLE TO THIS AQUISITION IS: 237990

MAGNITUDE OF CONSTRUCTION: $1,000,000.00 - $5,000,000.00.

BIDDERS WILL ACKNOWLEDGE ALL AMENDMENTS, SIGN BLOCK 20B, AND FILL-IN ALL INFORMATION IN BLOCKS 14-20C ON PAGE 2 OF THIS FORM.

BIDDERS WILL ALSO FILL-IN ALL ITEMS IN THE BID SCHEDULE.

ALL QUESTION PERTAINING TO THIS SOLICITATION MUST BE SUBMITTED IN WRITING TO JASON DUGAN AT THE ADDRESS IN BLOCK #7 OR EMAIL TO jason.e.dugan@uscg.mil. PLEASE USE THE ATTACHED "REQUEST FOR CLARIFICATION" FORM FOR THIS PURPOSE. (SEE SECTION J OF THIS

SOLICITATION.)

11. The contractor shall begin performance within calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. SEE BLOCK 10

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and 0 opies to perform the work required are due at the place specified in Item 8 by 2:00 P.M. (hour) (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

b. An offer guarantee is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

12b. CALENDAR DAYS

YES NO

X

X local time 28 April 2017

X 10

AMOUNTS

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

DUNS:__________________________

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

Commanding Officer (1224) USCG Finance Center 1430A Kristina Way Chesapeake, VA 23326-1224 (757)523-6940

SEE BLOCK 7

Invitation For Bid HSCG88-17-B-PQQ104

April 12, 2017

SECTION B

SCHEDULE OF PRICES

THE CONTRACTOR SHALL FURNISH ALL PLANT, LABOR, MATERIAL, EQUIPMENT, ETC.,

NECESSARY TO PERFORM ALL WORK IN STRICT ACCORDANCE WITH THE TERMS AND

CONDITIONS SET FORTH IN THE CONTRACT TO INCLUDE ALL ATTACHMENTS

THERETO.

U.S. COAST GUARD ISLAND (USCG) BERTHS – DREDGING WITH DISPOSAL

AT SF-DODS, AND AT MONTEZUMA WETLAND BENEFICAL USE UPLAND

SITE

CLIN 0001: Mobilization and Demobilization for Dredging Base Alameda

CLIN Description Unit of Issue

QTY Unit Price Total Amount

0001 Mobilization and Demobilization

JOB 1 $ $

CLIN 0002: Dredging, USCG BERTH AREA A (STA 0+00 to STA 4+50) to -35-ft (MLLW) including 1-foot of Paid Overdepth with disposal at Montezuma Wetland beneficial use upland site

Issue

EST

QTY

Unit Price Total Amount

0002AA Required Dredging to -35-ft MLLW in USCG Berth Area A

CY 15,500 $ $

0002AB Overdepth Dredging to -36-ft MLLW in USCG Bertha Area A

CY 2,500 $ $

CLIN 0003: Dredging, USCG BERTH AREA B (STA 4+50 to STA 7+70) to -35-ft (MLLW) including 1-foot of Paid Overdepth with disposal at Montezuma Wetland beneficial use upland site.

Issue

EST

QTY

Unit Price Total Amount

0003AA Required Dredging to -35-ft MLLW In USCG Berth Area B

CY 10,000 $ $

0003AB Overdepth Dredging to -36-ft MLLW in USCG Berth Area B

CY 2,000 $ $

CLIN 0004: Dredging, USCG BERTH AREA B (STA 7+70 to STA 15+76) to - 35-ft (MLLW) including 1-foot of Paid Overdepth with disposal at SF-DODS.

Issue

EST

QTY

Unit Price Total Amount

0004AA Required Dredging to -35-ft MLLW In USCG Berth Area B

CY 25,000 $ $

0004AB Overdepth Dredging to -36-ft MLLW in USCG Berth Area B

CY 4,500 $ $

CLIN 0005: Option Line Item for Station Golden Gate Dredging

OPTION

CLIN

Description Unit of Issue

QTY Unit Price Total Amount

0005 Dredging, USCG Station Golden Gate Horseshoe Cove, Sausalito, CA in accordance with specifications entitled ‘Station Golden Gate Dredge Spec 2017” dated 2 March 2017

JOB 1 $ $

CLIN 0006: Unit Price Line Item for Tug Service at Base Alameda (See Item 2 of Amendment 0002)

OPTION

CLIN

Description Unit of Issue

EST

QTY

Unit Price Total Amount

0006 Provide Tug Service for Base Alameda in accordance with item 2 of Amendment 0002

JOB 3 $ $

GRAND TOTAL ITEMS 0001- 0006 $

Notes:

*QUANTITIES FOR CLINS 0002AA, 0002AB, 0003AA, 0003AB, 0004AA , 0004AB

and 0006 ARE ESTIMATED AMOUNTS; SEE FAR 52.211-18 IN SECTION F

1. Prices must be submitted on all individual items within the Schedule of Prices. Failure to do so may be cause for rejection of bids.

2. CLIN 0005 Option Line Item. The exercise and award of CLIN 0005 will be made within 90 days after the award of the Base CLIN. Award of CLIN 0005 will be dependent on the availability of funds.

3. If a modification to a price based on unit price is submitted which provides for a lump sum adjustment to the total estimated price, the applications of the lump sum adjustment to each unit price in the Schedule of Prices must be stated. If it is not stated, the bidder agrees that the lump sum adjustment shall be applied on a pro rata basis to every unit price in the Schedule of Prices.

4. The term "Job", which appears on the Schedule of Prices under “Unit of Issue” for Bid Item No. 0001 and 0005 shall be considered as a Lump Sum. The Variation in Estimated Quantities contract clause, FAR 52.211-18, shall not apply to Bid Item No. 0001 and Option CLIN 0005

5. CLIN 0006 Unit Price Line Item:

i. This is an item of work of such nature that definite need or amount cannot be determined until other work is accomplished. The unit priced line item shall be activated and added by modification to the contract only when directed by the Contracting Officer.

ii. The unit price line item work will be paid for actual amounts ordered at the applicable unit prices, therefore, you must include the total price (material, labor, overhead, and profit) associated with unit price line items as no adjustments will be made later. Contract FAR clause 52.211-18 entitled “Variation in Estimated Quantity” applies if any adjustments to the estimated quantities are required.

iii. The estimated quantity shown for the unit line price item is a Government Estimate, and will not be awarded, unless needed, but will be used for evaluation purposes.

AWARD (To be completed by Government)