Attachment A3-WHS PFGS Ver 1-2.pdf

WHS Facility Guide Specifications Project Name Version 1.2 12/15

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

a description of work covered in this contract and is required for use in all projects

01 33 00 SUBMITTAL PROCEDURES

general procedures regarding submittals, data normally submitted for review to establish conformance with the design concept and contract documents

01 33 29 SUSTAINABILITY REQUIREMENTS

providing sustainable documentation for Guiding Principles Validation (GPV), and Third Party Certification (TPC)

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

listing of organizations whose publications are referenced in other sections of the specifications.

01 45 00.00 10 QUALITY CONTROL

Contractor Quality Control for construction projects or design-build construction projects

01 62 35 RECYCLED/RECOVERED/BIOBASED MATERIALS

use of products containing recycled or recovered materials. Include a properly edited version of this guide specification in every design-bid-build and design-build project. EPA recycled content requirements must be addressed in all projects regardless of optional LEED/other recycled content goals

01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT

the management of non-hazardous construction and demolition waste materials

01 75 00 STARTING AND ADJUSTING

system testing and acceptance.

01 78 00 CLOSEOUT SUBMITTALS

closeout submittals including: revised project documents, warranty management, testing, adjusting and balancing, O & M manuals, and final cleaning

01 78 23 OPERATION AND MAINTENANCE DATA

operation and maintenance (O&M) data normally shipped by a manufacturer at the same time as his associated piece of equipment is shipped. The requirements specified herein are intended to require those items of O&M data normally expected from the manufacturer of the associated equipment

01 79 00 DEMONSTRATION AND TRAINING

01 83 50 SYSTEM OPERATION AND MAINTENANCE MANUALS

01 91 00 COMMISSIONING

PROJECT TABLE OF CONTENTS Page 1

Sustainability and U.S. Green Building Council (USGBC) requirements for Commissioning

DIVISION 02 - EXISTING CONDITIONS

02 41 00 [DEMOLITION][ AND ][DECONSTRUCTION]

demolition, deconstructon, dismantling, reconditioning and disposal of existing building materials, equipment and utilities as a part of new construction or renovation work

02 42 51 CARPET REMOVAL AND RECLAMATION

removal and reclamation of used carpet, including EPA Affirmative Procurement requirements and Carpet America Recovery Efforts (CARE)

02 42 91 REMOVAL AND SALVAGE OF HISTORIC BUILDING MATERIALS

removal and salvage of historic building materials of historic buildings and structures

DIVISION 03 - CONCRETE

03 01 30.71 CONCRETE REHABILITATION

repair of portland cement concrete using epoxy resin grouts, mortars and concretes

03 30 53 MISCELLANEOUS CAST-IN-PLACE CONCRETE

projects involving amounts of concrete less than 380 cubic meters (500 cubic yards)

03 35 00.00 10 CONCRETE FINISHING

cast-in-place concrete finishing

03 45 00 PRECAST ARCHITECTURAL CONCRETE

architectural precast concrete products, that through their finish, shape, color, or texture contribute to a structure’s architectural expression

DIVISION 04 - MASONRY

04 20 00 MASONRY

reinforced and nonreinforced masonry

DIVISION 05 - METALS

05 05 23 WELDING, STRUCTURAL

(1) qualifying welding procedures, welders and welding operators, and (2) the fabrication, welding and inspection of carbon steel, low alloy steel, extra-high-strength quenched and tempered low alloy steels, and austenitic stainless steel materials for structural steel for buildings, other structures and non-structural use

PROJECT TABLE OF CONTENTS Page 2

05 50 13 MISCELLANEOUS METAL FABRICATIONS

miscellaneous metalwork

05 51 00 METAL STAIRS

steel stair systems which are not a part of any other metals system of the specification

05 52 00 METAL RAILINGS

metal railing systems which are not a part of any other metals system of the specification

05 72 00 DECORATIVE METAL SPECIALTIES

decorative metal products used in building construction for architectural and decorative effects

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 10 00 ROUGH CARPENTRY

framing, grounds, nailers, blocking, and sheathing of light wooden structures and includes the use of preassembled components and plastic lumber

06 20 00 FINISH CARPENTRY

covers general exterior and interior finish carpentry

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 13 53 ELASTOMERIC SHEET WATERPROOFING

sheet-applied elastomeric waterproofing

07 14 00 FLUID-APPLIED WATERPROOFING

fluid-applied elastomeric waterproofing systems for building decks over occupied space where membrane is protected of a separate wearing course

07 21 16 BUILDING INSULATION

mineral fiber blanket thermal insulation in attics, ceilings, walls, and floors

07 22 00 ROOF AND DECK INSULATION

insulation materials used below built-up roofing and single ply roofing systems

07 31 26 SLATE ROOFING

slate roofing on new construction and on historic buildings which require replacement, reinstallation, or repair of slate roofs

07 42 13 METAL WALL PANELS

both factory color and mill finish aluminum or steel non-structural metal wall panels

07 60 00 FLASHING AND SHEET METAL

flashing and sheet metal work including gutters and downspouts, scuppers, splash pans, and sheet metal roofing

07 81 00 SPRAY-APPLIED FIREPROOFING

PROJECT TABLE OF CONTENTS Page 3 spray-applied fire protection.

07 84 00 FIRESTOPPING

firestopping using tested and listed firestop systems to form an effective barrier against the spread of fire, smoke and gases, and to maintain the integrity of fire resistance rated construction

07 92 00 JOINT SEALANTS

sealants for normal building construction

DIVISION 08 - OPENINGS

08 11 13 STEEL DOORS AND FRAMES

steel doors and frames

08 14 00 WOOD DOORS

wood doors

08 33 13 METAL ROLLING COUNTER DOORS

metal rolling counter doors

08 33 23 OVERHEAD COILING DOORS AND GRILLS

manually-operated, power-operated overhead coiling doors, and overhead coiling counter doors

08 34 73 SOUND CONTROL DOOR ASSEMBLIES

flush steel and wood sound retardant doors with Sound Transmission Classification (STC) ranging from 25 to 45

08 41 13 ALUMINUM-FRAMED ENTRANCES AND STOREFRONTS

Aluminum Entrances, glass and glazing, door hardware and components.

08 51 13 ALUMINUM WINDOWS

R, LC, CW and AW performance class aluminum windows

08 71 00 DOOR HARDWARE

finish hardware for permanent structures

08 81 00 GLAZING

normal glazing

08 91 00 METAL [WALL] [AND] [DOOR] LOUVERS

average metal wall louvers, metal louvers in wood doors, screens and frames, and accessories

DIVISION 09 - FINISHES

09 22 00 SUPPORTS FOR PLASTER AND GYPSUM BOARD (LIGHTGAUGE METAL

FRAMING)

non-loadbearing cold-formed metal framing, furring, and ceiling suspension systems for the attachment of lath, plaster, stucco, and wallboard

09 29 00 GYPSUM BOARD

gypsum board, cementitious backer units, and accessories

PROJECT TABLE OF CONTENTS Page 4 intended for use in drywall construction

09 30 00 CERAMIC TILE, QUARRY TILE, AND PAVER TILE

ceramic tile for walls and floors, porcelain tile, quarry tile, paver tile, and marble thresholds

09 51 00 ACOUSTICAL CEILINGS

conventional and impact/abrasion resistant acoustical ceiling tile and panels, unit acoustical absorbers, hangers, and suspension system grid for installation in commercial-type work

09 64 29 WOOD STRIP FLOORING

wood strip flooring for gymnasiums, handball and squash courts, and other special purpose applications

09 65 00 RESILIENT FLOORING

resilient floor coverings, base materials, and accessory items

09 66 23 RESINOUS TERRAZZO FLOORING

resinous terrazzo flooring and conductive resinous terrazzo flooring

09 68 00 CARPET

broadloom carpet, modular tile carpet, and entrance carpet.

09 69 13 RIGID GRID ACCESS FLOORING

rigid grid access flooring

09 83 13 ACOUSTICAL WALL TREATMENT

fabric covered acoustical wall panel systems

09 90 00 PAINTS AND COATINGS

painting of new and existing, interior and exterior substrates, including masonry, concrete, metal, wood and other miscellaneous materials

09 97 30 PREPARATION OF HISTORIC WOOD AND METAL SURFACES FOR

PAINTING

preparation for painting wood and metal surfaces in historic structures

DIVISION 10 - SPECIALTIES

10 14 00.20 INTERIOR SIGNAGE

common types of signs, dimensional letters, and metal plaques used inside buildings

10 22 19 DEMOUNTABLE MOVABLE PARTITIONS

demountable and movable partitions

10 26 13 WALL AND CORNER GUARDS

corner guards, wall guards (bumper guards), door protectors, and wall panels

10 44 16 FIRE EXTINGUISHERS AND VALVE CABINETS

PROJECT TABLE OF CONTENTS Page 5 portable fire extinguishers, including wall brackets, accessories, maintenance servicing and inspection tagging requirements

DIVISION 21 - FIRE SUPPRESSION

21 12 00 STANDPIPE SYSTEMS

dry and wet standpipe and hose systems for fire extinguishing in multi-story and multi-level buildings

21 13 13.00 10 WET PIPE SPRINKLER SYSTEM, FIRE PROTECTION

wet pipe fire protection sprinkler systems

21 13 17.00 10 DRY PIPE SPRINKLER SYSTEM, FIRE PROTECTION

dry pipe fire protection sprinkler systems

DIVISION 22 - PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

general purpose plumbing systems

22 07 19 PLUMBING PIPING INSULATION

field-applied insulation for hot and cold water and steam piping

22 13 29 SANITARY SEWERAGE PUMPS

sewage and sludge pumps for domestic type waste

22 14 29 SUMP PUMPS

automatic, electric-motor-driven, centrifugal, wet-pit and submersible sump pumps

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING

23 00 00 AIR SUPPLY, DISTRIBUTION, VENTILATION, AND EXHAUST SYSTEMS

air supply, distribution, ventilation, and exhaust portions of an HVAC system

23 01 30 HVAC SYSTEM CLEANING

cleaning of HVAC systems, including applicable industry standards, qualifications of cleaning contractor, cleaning methodology, and performance verification

23 05 15 COMMON PIPING FOR HVAC

standard basic mechanical work

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC AND PLUMBING

testing, adjusting, and balancing (TAB) of heating, ventilating, and air-conditioning (HVAC) air and water distribution systems

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

field applied thermal insulation on HVAC and plumbing systems located within, on, under, and adjacent to buildings; above and below ground

PROJECT TABLE OF CONTENTS Page 6

23 09 23 CONTROL SYSTEMS FOR HVAC

direct digital control (DDC) of heating, ventilating, and air conditioning (HVAC) systems complying with ANSI/ASHRAE Standard 135, "BACnet - A Data Communication Protocol for Building Automation and Control Networks."

23 11 25 FACILITY GAS PIPING

low pressure facility gas piping systems conforming to NFPA 54 for non-industrial uses

23 22 23 STEAM CONDENSATE PUMPS

condensate return pump units and condensate steam pumps

23 25 00 CHEMICAL TREATMENT OF WATER FOR MECHANICAL SYSTEMS

chemical treatment of water for mechanical systems

23 31 13 METAL DUCTS

low, medium, and high pressure ductwork for air conditioning systems

23 34 23 HVAC POWER VENTILATORS

power roof ventilators designed to exhaust air from a building by means of a motor-driven fan

23 36 00 AIR TERMINAL UNITS

fan-powered induction air terminal units (FPIU) and shutoff single-duct air terminal units (variable air volume (VAV) terminal units)

23 37 13 DIFFUSERS, REGISTERS, AND GRILLS

air-diffusion devices that are connected to ductwork or mounted in equipment

23 41 13 PANEL FILTERS

basic types of filters for use with air handling equipment

23 57 10 FORCED HOT WATER HEATING SYSTEMS USING WATER AND STEAM

HEAT EXCHANGERS

forced hot water heating system using a steam or high temperature water heat exchanger

23 73 13 MODULAR INDOOR CENTRAL-STATION AIR-HANDLING UNITS

manufacturer's standard low-(AMCA Class A), medium- (AMCA Class B), and high-pressure (AMCA Class C), low- and high-velocity, factory fabricated and assembled, central station, air handling units

23 81 23 COMPUTER ROOM AIR CONDITIONING UNITS

heating, ventilating, and cooling (HVAC) equipment for computer room air conditioning Units (CRACUs)

23 82 19 FAN COIL UNITS

fan-coil units for temperature-control assemblies

23 82 46 ELECTRIC UNIT HEATERS

electric unit heaters

DIVISION 25 - INTEGRATED AUTOMATION

PROJECT TABLE OF CONTENTS Page 7

25 10 10 UTILITY MONITORING AND CONTROL SYSTEM (UMCS) FRONT END

AND INTEGRATION

Utility Monitoring and Control System (UMCS) Front End using Open protocols (LonWorks, BACnet, Modbus, DNP and OPC), a UMCS using the Niagara Framework, and the integration of field control systems.

DIVISION 26 - ELECTRICAL

26 00 00 BASIC ELECTRICAL MATERIALS AND METHODS

electrical general requirements, complete

26 05 13 MEDIUM-VOLTAGE CABLES

medium voltage cables, including shielded and nonshielded single-and multiple-conductor power cables, portable cables, cable splices and terminations, single- and multiple-conductor potheads, and fireproofing cables in manholes and utility tunnels

26 09 13 POWER MONITORING SYSTEM

power monitoring systems

26 11 13 MEDIUM VOLTAGE METAL-CLAD SWITCHGEAR

for primary substations and associated load break switches and switchgear

26 11 14 SPOT NETWORK EQUIPMENT

PRIMARY SWITCH FOR LIQUID TRANSFORMERS

NETWORK TRANSFORMERS, LIQUID

-TYPE

NETWORK PROTECTORS

26 11 16 SECONDARY UNIT SUBSTATIONS

secondary unit substations for step-down operation at primary voltages of 601 volts through 38 kilovolts, and secondary voltages, of 600 volts or less

26 12 19 PAD-MOUNTED, LIQUID-FILLED, MEDIUM-VOLTAGE TRANSFORMERS

three-phase pad-mounted transformers of the dead-front and live-front types for exterior applications

26 13 13 MEDIUM VOLTAGE GENERATOR PARALLELING SWITCHGEAR AND

CONTROL SYSTEM

Generator Paralleling Switchgear and control systems

26 20 00 INTERIOR DISTRIBUTION SYSTEM

procurement, installation, electrical Low Voltage wiring systems,Grounding and bonding, raceways and boxes, cable trays,wiring devices, Integrated Facility Switchboards (IFS),Busways/Enclosed bus Assemblies, Dry type transformers(1000V or less), Panelboards, Power Distribution Units(PDU), LV Disconnects, LV molded case circuit breakers

26 23 00 SWITCHGEAR

Free standing UL 1558 assemblies rated 6000 amperes or less, 600 volts or less, metal-enclosed low-voltage power

PROJECT TABLE OF CONTENTS Page 8 circuit-breaker switchgear assemblies in either interior or exterior locations

26 24 19 MOTOR CONTROL CENTERS

motor control centers and switchboards by formal advertising, using a SUPPLY-type contract

26 28 01 COORDINATED POWER SYSTEM PROTECTION

the coordinated protection of power systems

26 29 23 VARIABLE FREQUENCY DRIVE SYSTEMS UNDER 600 VOLTS

variable frequency drive for motors rated up to 575 volts, for use on electric power systems of 600 volts or less, 50/60 hertz

26 32 15 DIESEL-GENERATOR SET STATIONARY 100-2500 KW, WITH

AUXILIARIES

stationary diesel-driven generator sets in the 100 to 2500 kilowatt capacity

26 36 00 AUTOMATIC TRANSFER SWITCH AND BY-PASS/ISOLATION SWITCH

low voltage applications of automatic transfer switches (ATS) and ATS with by-pass/isolation switches

26 60 13 LOW VOLTAGE MOTORS

alternating current wattage fractional and integral horsepower motors rated up to190 kilowatt 250 hp when used on a 120-, 208- or 240-volt, single-or three-phase, 60-hertz power source and up to 225 kilowatt 300 hp when used on a 480-volt and 600-volt, three-phase, 60-hertz power source

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 05 26 GROUNDING AND BONDING FOR ELECTRONIC SAFETY AND SECURITY

electrical system and equipment grounding including ground rods, grounding conductors, connectors, and other accessories

28 31 76 INTERIOR FIRE ALARM AND MASS NOTIFICATION SYSTEM

integrated fire detection, fire alarm evacuation and mass notification system

28 33 00 GAS DETECTION AND ALARM

equipment, performance, and testing of stationary electrical instruments used for sensing the presence of combustible gases, or the deficiency of oxygen, in ambient air

DIVISION 33 - UTILITIES

33 58 00 LEAK DETECTION SYSTEM

leak detection systems - cable-type leak detection and location system consisting of a microprocessor based monitoring unit, sensor cable, probes, system layout map and auxiliary equipment required to provide continuous monitoring of the sensing string(s) for leaks, shorts, PROJECT TABLE OF CONTENTS Page 9 breaks and probe activation.

33 71 02 UNDERGROUND ELECTRICAL DISTRIBUTION

underground electrical distribution systems

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 10

USACE / NAVFAC / AFCEC / NASA UFGS-01 11 00 (August 2011) Preparing Activity: NAVFAC Superseding UFGS-01 11 00 (January 2008)

UNIFIED FACILITIES GUIDE SPECIFICATIONS

References are in agreement with UMRL dated July 2013

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00

SUMMARY OF WORK

08/11 a description of work covered in this contract and is required for use in all projects

PART 1 GENERAL

1.1 SUMMARY

1.2 REFERENCES

1.3 DEFINITIONS

1.4 SUBMITTALS

1.5 WORK COVERED BY CONTRACT DOCUMENTS

1.5.1 Project Description

1.5.2 Location

1.6 CONTRACT DRAWINGS

1.7 WORK RESCHEDULING

1.8 PROJECT ENVIRONMENTAL GOALS

1.8.1 Independent Verification

1.8.1.1 US Green Building Council (USGBC) - LEED(tm) Rating System

1.8.1.2 Green Globes US

1.8.1.3 Energy and Water Efficiency

1.8.1.4 EPA Energy Performance Rating

1.9 OCCUPANCY OF PREMISES

1.10 CONTRACTOR'S USE OF PREMISES

1.10.1 General

1.10.2 Core drilling or jack hammering

1.10.3 Noise Protection

1.10.4 Utility shutoffs

1.11 ITEMS FURNISHED BY GOVERNMENT AND INSTALLED BY CONTRACTOR

1.11.1 Government responsibilities

1.11.2 Contractor Responsibilities

1.12 PARTIAL OCCUPANCY

1.13 EXISTING WORK

1.14 ON-SITE PERMITS

1.14.1 Utility Outage Requests and Utility Connection Requests

1.14.2 Building Permits

1.15 LOCATION OF UNDERGROUND UTILITIES

01 11 00 For Official Use Only 1

1.15.1 Notification Prior to Excavation

1.16 SALVAGE MATERIAL AND EQUIPMENT

1.17 Additional Provisions

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

01 11 00 For Official Use Only 2

USACE / NAVFAC / AFCEC / NASA UFGS-01 11 00 (August 2011) Preparing Activity: NAVFAC Superseding UFGS-01 11 00 (January 2008)

UNIFIED FACILITIES GUIDE SPECIFICATIONS

References are in agreement with UMRL dated July 2013

SECTION 01 11 00

SUMMARY OF WORK

08/11

NOTE: This guide specification covers the requirements for a description of work covered in this contract and is required for use in all projects.

Adhere to UFC 1-300-02 Unified Facilities Guide Specifications (UFGS) Format Standard when editing this guide specification or preparing new project specification sections. Edit this guide specification for project specific requirements by adding, deleting, or revising text. For bracketed items, choose applicable items(s) or insert appropriate information.

Remove information and requirements not required in respective project, whether or not brackets are present.

Comments, suggestions and recommended changes for this guide specification are welcome and should be submitted as a Criteria Change Request (CCR).

NOTE: When using this section, a Project Information Form should be filled out for the Contract Specialist. This form is available from the Construction Criteria Base website at http://www.wbdg.org/ccb. The form is found in the Specification Library, NAVFAC Specifications Category, Project Information Form.

NOTE: Include on the drawing:

1. Location of project.

2. Limits of contractor's work area.

3. Location of Government-furnished work.

01 11 00 For Official Use Only 3

4. Location of Government installed work.

5. Contractor's on-base route to site.

NOTE: See "FAC 5252.211-9301, Phased Construction Schedule."

PART 1 GENERAL

1.1 SUMMARY

This section includes the requirements for a description of work covered in this contract and is required for use in all projects

Drawings and general provisions of the Contract, including General and Supplementary Conditions and Division 01 Specification Sections apply to this Section.

1.2 REFERENCES

NOTE: Issue (date) of references included in project specifications need not be more current than provided by the latest guide specification. Use of SpecsIntact automated reference checking is recommended for projects based on older guide specifications.

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only. All work shall comply with the most recent applicable codes and manufacturer's recommended practices at the time of the contract award, unless otherwise specified.

ASTM INTERNATIONAL (ASTM)

ASTM E2114 (2008) Standard Terminology for Sustainability Relative to the Performance of Buildings

GREEN BUILDING INITIATIVE (GBI)

GBI/ANSI 01 (2010 Green Building Assessment Protocol for Commercial Buildings

U.S. ENVIRONMENTAL PROTECTION AGENCY (EPA)

Energy Star (1992; R 2006) Energy Star Energy Efficiency Labeling System

WASHINGTON HEADQUARTERS SERVICES

WHS Building Code Washington Headquarters Services Building Code, 105.0 Permits

01 11 00 For Official Use Only 4

1.3 DEFINITIONS

Definitions pertaining to sustainable development are as defined in ASTM E2114, [Section 01 35 40.00 20 ENVIRONMENTAL MANAGEMENT][Section 01 57 20.00 10 ENVIRONMENTAL PROTECTION], and as specified.

a. "Environmentally preferable products" have a lesser or reduced effect on the environment in comparison to conventional products and services. This comparison may consider raw materials acquisition, production, manufacturing, packaging, distribution, reuse, operation, maintenance, or disposal of the product.

b. "Indoor environmental quality" is the physical characteristics of the building interior that impact occupants, including air quality, illumination, acoustics, occupant control, thermal comfort, daylighting, and views.

c. "Operational performance" is the functional behavior of the building as a whole or of the building components.

d. "Sustainability" is the balance of environmental, economic, and societal considerations.

e. "Premises" is the entirety of the campus or building where the project is taking place.

f. "Contract Limits" refers to the specific location of the project work site indicated in the drawings.

1.4 SUBMITTALS

NOTE: Review Submittal Description (SD) definitions in Section 01 33 00 SUBMITTAL PROCEDURES and edit the following list to reflect only the submittals required for the project.

The Guide Specification technical editors have designated those items that require Government approval, due to their complexity or criticality, with a "G". Generally, other submittal items can be reviewed by the Contractor's Quality Control System. Only add a “G” to an item, if the submittal is sufficiently important or complex in context of the project.

For submittals requiring Government approval on Army projects, a code of up to three characters within the submittal tags may be used following the "G" designation to indicate the approving authority.

Codes for Army projects using the Resident Management System (RMS) are: "AE" for Architect-Engineer; "DO" for District Office (Engineering Division or other organization in the District Office); "AO" for Area Office; "RO" for Resident Office; and "PO" for Project Office. Codes following the "G" typically are not used for Navy projects.

01 11 00 For Official Use Only 5

Submittal items not designated with a "G" are considered as being for information only for Army projects and for Contractor Quality Control approval for Navy projects.

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for [Contractor Quality Control approval.] [information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government.] The following shall be submitted in accordance with Section

01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Upon receipt of Government Furnished Equipment, the Contractor shall submit records in accordance with paragraph entitled, "Government Furnished Property," of this section.

Submit the following items to the Contracting Officer:

Utility Outage Requests Utility Connection Requests Borrow PermitsExcavation Permits Welding Permits Burning Permits

[ SD-07 Certificates

Energy Performance Rating]

1.5 WORK COVERED BY CONTRACT DOCUMENTS

1.5.1 Project Description

NOTE: Describe the project and the types of work involved in sufficient detail so as to present a general picture which is self contained but does not refer to the drawings or to other parts of the specification. Mention peculiar or hazardous work, and monitoring of archaeological resources. Do not provide quantities in the description.

The work includes [Insert Description of Work] and incidental related work.

1.5.2 Location

NOTE: Include station name and geographic location in the blank provided.

The work shall be located at the The Pentagon, Arlington, VA[_____], approximately as indicated. The exact location will be shown by the Contracting Officer.

01 11 00 For Official Use Only 6

1.6 CONTRACT DRAWINGS

NOTE: Use this Paragraph for NASA only.

The following drawings accompany this specification and are a part thereof.

Drawing No. [_____] Sheets 1 through [_____]

[Five] [_____] sets of full size contract drawings, maps, and specifications will be furnished to the Contractor without charge.

Reference publications will not be furnished.

Contractor shall immediately check furnished drawings and notify the Government of any discrepancies.

1.7 WORK RESCHEDULING

Contractor shall allow for a maximum of [_____insert number of calendar days ] calendar days where construction activity is prohibitiveed. Further allowance for [_____] calendar days of excavation and subsurface activity abeyance shall be imposed where other construction activities are permitted. Government will provide 24 hour notification each time the restrictions are invoked.

Normal duty hours for work shall be from [_____] a.m. to [_____] p.m., Monday through Friday. Requests for additional work shall require written approval from the Contracting Officer 7 days in advance of the proposed work period.

1.8 PROJECT ENVIRONMENTAL GOALS

NOTE: Project environmental goals cannot be enforced, but are identified here to guide contractor means and methods, which may have significant environmental impacts. Additionally, it may help the Contractor propose alternatives that are consistent with the project environmental goals.

Contractor shall distribute copies of the Environmental Goals to each subcontractor and the Contracting Officer. The overall goal for design, construction, and operation is to produce a building that meets the functional program needs and incorporates the principles of sustainability.

The Conractor shall obtain and complete the WHS Compliance Checklists for Implementing Sustainability Requirements at WHS Facilities. Specifically:

a. Preserve and restore the site ecosystem and biodiversity; avoid site degradation and erosion. Minimize offsite environmental impact.

b. Use the minimum amount of energy, water, and materials feasible to meet the design intent. Select energy and water efficient equipment and strategies.

c. Use environmentally preferable products and decrease toxicity level of materials used.

d. Use renewable energy and material resources.

01 11 00 For Official Use Only 7

e. Optimize operational performance (through commissioning efforts) in order to ensure energy efficient equipment operates as intended.

Consider the durability, maintainability, and flexibility of building systems.

f. Manage construction site and storage of materials to ensure no negative impact on the indoor environmental quality of the building.

g. Reduce construction waste through reuse, recycling, and supplier take-back.

h. All new equipment, appliances, or fixtures shall be Federal Energy Management Program (FEMP)-designated, ENERGY STAR qualified, or WaterSense labeled, where applicable.

i. Projects must comply with the DOD Sustainable Buildings Policy and UFC 1-200-02. All new building design and construction and repair/renovation projects shall conform to the guiding principles in the High Performance and Sustainable Buildings MOU.

j. All applicable new building design and construction and repair/renovation projects shall be certified to Silver level of LEED, or equivalent level in Green Globes certification system. Projects are applicable for certification if the LEED minimum program requirements are met. Projects that are not applicable must still adhere to the Guiding Principles.

k. Incorporate life cycle cost /benefit analysis into design decisions, especially for aspects that impact energy and water consumption.

1.8.1 Independent Verification

NOTE: There are multiple ways of certifying green buildings.

NOTE: Army projects shall use the LEED rating system. Include the following paragraph and delete other independent verification systems.

[1.8.1.1 US Green Building Council (USGBC) - LEED(tm) Rating System

Provide [completed project in compliance] [work consistent] with USGBC LEED -NC(tm) [v2.2][_____] (LEED NC), level [certified] [silver] [gold] [platinum] requirements.

For new construction or major renovation projects that meet the minimum program requirements for LEED NC, the project must achieve a minimum of LEED Silver rating or equivalent.

01 11 00 For Official Use Only 8

[1.8.1.2 Green Globes US

NOTE: Green Globes US is the newest addition to the BREEAM/Green Leaf suite of environmental assessment tools. BREEAM (BRE Environmental Assessment Method) is one of the world's most widely used means of reviewing and improving the environmental performance of buildings.

Provide [completed project in compliance] [work consistent] with GBI/ANSI 01 US level [Two Globes] [Three Globes] [_____] requirements.

The sum of energy and water efficiency credits shall equal or exceed 40% of the points required to achieve LEED silver rating

1.8.1.3 Energy and Water Efficiency

a. Energy and Water Efficiency Per UFC 1-200-02, projects shall ensure energy and water efficiency such that the cost to operate the building is reduced over its lifetime.

b. Project shall employ the most energy efficient designs, systems, equipment, and controls that are life-cycle cost effective (EISA 434).

c. For new construction or major renovation projects, the project shall reduce building energy consumption by at least 30% below the most recent version of ASHRAE 90.1. The newest version of ASHRAE 90.1 should be used no later than one year after the approval date of each revision of ASHRAE (EPAct 2005).

d. For new construction or major renovation projects, during the design phase, perform a life-cycle cost analysis to determine the feasibility of installing solar hot water heaters to meet 30% of hot water demand

(EISA 532).

e. Applicable projects (new buildings or major renovations) must reduce potable water use by 20% compared to a water baseline for the building.

The water baseline for new buildings or major renovations is 120% of the Uniform Plumbing Codes 2006 or the International Plumbing Codes 2006 fixture performance requirements (Guiding Principles).

f. New buildings must be separately metered for each type of energy and water and data must report back to the existing energy monitoring system. Metering plans should be coordinated with the WHS energy program.

[1.8.1.4 EPA Energy Performance Rating

NOTE: Determine the energy use target rating that meets or exceeds Energy Star. Provide Energy Star target using EPA Target Finder. Use Target Finder to rate estimated energy use for the completed design. If design achieves a rating of 75 or higher, provide Statement of Energy Design Intent

01 11 00 For Official Use Only 9

(SEDI) generated from Target Finder to document results. Contracting Officer shall submit the SEDI to EPA and will receive the "Designed to Earn the Energy Star" graphic to place on drawings to show that the energy use for the design meets EPA criteria for energy efficiency. Include the following paragraph if graphic has been earned.

Provide work consistent with drawings in order to meet Energy Star in accordance with design.

1.9 OCCUPANCY OF PREMISES

Building(s) will be occupied during performance of work under this Contract.

[Occupancy notifications will be posted in a prominent location in the work area.]

Before work is started, the Contractor shall arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.10 CONTRACTOR'S USE OF PREMISES

1.10.1 General

a. Government will occupy premises during the Work, with the exception of areas under construction. Cooperate with Government in construction operations to minimize conflicts and to facilitate Government usage.

b. Limit use of the premises to work in areas indicated. Confine operations to areas within contract limits indicated. Do not disturb portions of the site beyond the areas in which the Work is indicated.

c. Where on-site storage is required, provide an on-site lock up (conex box) with list of contents and Point Of Contact with phone number.

1.10.2 Core drilling or jack hammering

a. Perform operations only between the hours of 6:00 p.m. - 6:00 a.m. on normal workdays (Monday- Friday) if the noise level exceeds 80 decibels.

b. Provide written notice to Government before core drilling or jack hammering: In unoccupied areas, provide at least 48 hours notice.In occupied areas, provide at least 72 hours notice.Obtain Government's written approval of schedule before proceeding.

1.10.3 Noise Protection

Noise Protection: Between the hours of 6:00 AM to 6:00 PM, Monday through Friday, maximum noise levels are not permitted to exceed 85 db.

1.10.4 Utility shutoffs

Perform utility shutoffs and disconnections affecting areas occupied by

01 11 00 For Official Use Only 10

Government only between the hours of 10:00 p.m. - 4:00 a.m. Restore utilities to full operating condition before 6:00am of the next business day. Provide 48 hours written notice to Government before utility shutoffs.

Obtain Government's written approval of schedule before proceeding.

An Outage Permit is required. See WHS Building Code for further information regarding utility shut-offs.

1.11 ITEMS FURNISHED BY GOVERNMENT AND INSTALLED BY CONTRACTOR

The Government will furnish equipment to be installed by the Contractor, listed elsewhere in the Contract Documents. The Work includes providing support systems to receive Government's equipment, and mechanical and electrical connections.

1.11.1 Government responsibilities

Arrange for and deliver necessary shop drawings, product data, and samples to the Contractor. Arrange and pay for delivery of Government-furnished items according to the Construction Schedule. Following delivery, the Government will inspect items delivered for damage and for compliance with Contract Documents. If Government-furnished items are damaged, defective, or missing, the Government will arrange for replacement. Arrange for manufacturer's field services and for the delivery of manufacturer's warranties to the appropriate Contractor.

1.11.2 Contractor Responsibilities

Designate delivery dates of Government-furnished items in the Construction Schedule. Review shop drawings, product data, and samples and return them to the Contracting Officer noting discrepancies or problems anticipated in use of the product.Receiving, unloading, and handling Government-furnished and Contractor-installed items at the site. Protecting Government-furnished and Contractor-installed items from damage, including damage from exposure to the elements. The Contractor shall repair or replace items damaged as a result of his operations.

1.12 PARTIAL OCCUPANCY

Partial Government Occupancy: The Government reserves the right to occupy and to place and install equipment in completed areas of the building prior to Substantial Completion, provided such occupancy does not interfere with completion of the Work. Such placing of equipment and partial occupancy shall not constitute acceptance of the total Work.

1.13 [EXISTING WORK

In addition to "FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements":

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work shall be in a condition equal to or better than that which existed before new work started.a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the

01 11 00 For Official Use Only 11 existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work shall be in a condition equal to or better than that which existed before new work started.

1.14 ON-SITE PERMITS

1.14.1 Utility Outage Requests and Utility Connection Requests

a. Notify the Contracting Officer at least [48 hours] [72 hours] prior to starting excavation work.

b. Contractor is responsible for marking and verifying all utilities that are not marked.

c. The Contractor shall verify the elevations of existing piping, utilities, and any type of underground obstruction not indicated or specified to be removed. But Iindicated in locations to be transversed by piping, ducts, and other work to be installed. [Verify elevations bB efore installing new work closerverify elevation of the than nearest manhole or other structure at which an adjustment in grade can be made.]

d. Work shall be scheduled to hold outages to a minimum.

e. [Utility outages and connections required during the prosecution of work that affect existing systems shall be arranged for at the convenience of the Government and shall be scheduled outside the regular working hours or on weekends.]

f. [Contracting Officer may permit utility outages at his discretion.]

g. [Contractor shall not be entitled to additional payment for utility outages and connections required to be performed outside the regular work hours.]

h. [Requests for utility outages and connections shall be made in writing to the Contracting Officer at least [_____] calendar days in advance of the time required. Each request shall state the system involved, area involved, approximate duration of outage, and the nature of work involved.]

1.14.2 Borrow, Excavation, Welding, and BurningBuilding Permits

Required permits may be found in WHS BC 105.0 Permits

ACTIVITY SUBMISSION DATE SUBMISSION FORM

[Borrow Permits] [[_____] calendar days prior to work]

[Burning Permits] [[_____] calendar days prior to work]

01 11 00 For Official Use Only 12

ACTIVITY SUBMISSION DATE SUBMISSION FORM

[Excavation Permits] [[_____] calendar days prior to work]

[Welding Permits] [[_____] calendar days prior to work]

Permits shall be posted at a conspicuous location in the construction area.

Burning of trash or rubbish is [not] permitted at [_____] [on project site].

[Any burning of trash or rubbish shall be done in strict compliance with requirements established by the authority having jurisdiction.]

1.15 LOCATION OF UNDERGROUND UTILITIES

NOTE: For projects at Pearl Harbor Shipyard, include the bracketed option for Ground Penetrating Radar.

[Obtain digging permits prior to start of excavation by contacting the Contracting Officer [15] [_____] calendar days in advance.] [Scan the construction site with [Ground Penetrating Radar and] electromagnetic or sonic equipment, and mark the surface of the ground[, pier deck or paved surface] where existing underground utilities [or utilities encased in pier structures] are discovered. Verify the elevations of existing piping, utilities,and any type of underground [or encased] obstruction not indicated to be specified or removed but indicated or discovered during scanning in locations to be traversed by piping, ducts, and other work to be conducted or installed.] [Verify elevations before installing new work closer than nearest manhole or other structure at which an adjustment in grade can be made.]

1.15.1 Notification Prior to Excavation

NOTE: For projects in the Tidewater, Virginia area, use 15 days and include the bracketed sentence.

Notify the Contracting Officer at least [48 hours] [15 days] prior to starting excavation work. [Contact Miss Utility 48 hours prior to excavating. Contractor is responsible for marking all utilities not marked by Miss Utility.]

1.16 [GOVERNMENT-FURNISHED MATERIAL AND EQUIPMENT

NOTE: There are situations in which equipment installation data or templates would allow the Contractor to prepare rough-in and proceed with construction prior to taking delivery of

01 11 00 For Official Use Only 13

Government-furnished equipment. This paragraph may be expanded to include scheduling delivery of installation data or templates as well as the equipment itself, if the data can be made available more quickly than the Government-furnished equipment and if advanced delivery would be helpful to the Government. Obtain listing of material from the Government.

NOTE: Include this paragraph only when the contractor will be required to install Government-Furnished Materials and Equipment or provide utilities for same. Obtain information to identify the items from the Government. Select FAR 52-245-2 when the value of the Government-furnished property is greater than $100,000. Select FAR 52.245-4 when the value of the Government-furnished property is $100,000 or less.

Pursuant to Contract Clause ["FAR 52.245-2, Government Property (Fixed Price Contracts)"] ["FAR 52-245-4, Government-Furnished Property (Short Form)"], the Government will furnish the following materials and equipment for installation by the Contractor:

NOTE: Provide complete description and quantities for Government-furnished Contractor and installed material and equipment. Identify manufacturer, make, model and operating characteristics. Avoid generic descriptions especially for equipment requiring utilities such as water service, drains, natural gas, steam, or electricity. This information should be made available by the activity furnishing the material or equipment to be installed through the Government. When a utility is required to serve the Government-furnished item, ensure that the appropriate Section for the utility needed is included in the project specification.

NOTE: Salvage property to be removed and reused in the general work area shall be handled as a Contractor service and not listed here.

DESIGNATION NO. DESCRIPTION QUANTITY

Quantities indicated for the above-listed items marked with an asterisk are estimates. It is the intention of the Government to furnish all quantities of the asterisk items required to complete the work as specified and the various quantities will be adjusted when necessary.

Quantities stated for the above items not marked with an asterisk are all

01 11 00 For Official Use Only 14 that will be furnished by the Government. Contractor shall furnish any additional quantities required.

1.16.1 Delivery Schedule

NOTE: Choose the version of this paragraph which best satisfies the project conditions. The first alternative is best suited for projects requiring careful scheduling of Government-furnished equipment. The number of calendar days required for notification or that have elapsed before availability should be established after considering

(1) a reasonable time between the Contract Award and the first need for Government-furnished equipment and (2) the lead time required for Government procurement. The storage rate should be set at the commercial rate in the area of storage.

[Notify the Contracting Officer in writing at least [_____] calendar days in advance of the date on which the materials and equipment are required.

Pick up materials and equipment no later than 30 calendar days after such date. When materials and equipment are not picked up by the 30th day, the Contractor will be charged for storage at the rate of [_____] per 100 [pounds] [cubic feet]per month or fraction thereof.]

[Materials and equipment will be available on or after [_____] calendar days after the award of contract.]

1.16.2 Delivery Location

The materials and equipment [are located at [_____]][are located within [_____] miles of the jobsite] [will be delivered to [_____]][the salvage receiving point [_____]].

]1.17 [GOVERNMENT-INSTALLED WORK

NOTE: Include this paragraph if the Government is to install equipment or perform other work at the job site, excluding inspection and testing. Define the extent and type of Government work that may impact on the operations of the Contractor.

][1.18 Navy and Marine Corps (NMCI) Coordination Requirements

NOTE: For Navy projects only. In addition to the EIA/TIA standards for telecommunications, the architectural, structural, mechanical, plumbing, electrical and fire protection designs must comply with the guidance in the latest version of UFC 3-580-10.

01 11 00 For Official Use Only 15

1.18.1 NMCI Contractor Access

The NMCI Contractor must be allowed access to the facility towards the end of construction (finishes 90 percent complete, rough-in 100 percent complete, Inside Plant (ISP)/Outside Plant (OSP) infrastructure in place) to provide equipment in the telecommunications rooms and make final connections.

Coordinate efforts with the NMCI contractor to facilitate joint use of building spaces during the final phases of construction. After the Contracting Officer has facilitated coordination meetings between the two contractors, the construction contractor must, within one week, incorporate the effort of additional contractor coordination into construction schedule to demonstrate plan for maintaining the contract duration.

]1.16 SALVAGE MATERIAL AND EQUIPMENT

Items designated by the Contracting Officer to be salvaged shall remain the property of the Government.

The salvaged property shall be segregated, itemized, delivered, and off-loaded at the [Government designated] storage area located within [_____] miles of the construction site.Contractor shall maintain property control records for material or equipment designated as salvage.

Contractor's system of property control may be used if approved by the Contracting Officer. Contractor shall be responsible for storage and protection of salvaged materials and equipment until disposition by the Contracting Officer.

1.17 Additional Provisions

a. Government review, inspection, approval or acceptance of any work, submittal, drawing, deliverable or other similar document is for the Government's benefit only and does not waive or alter the contract requirements. The contractor remains solely responsible for ensuring that all work performed by the contractor complies with all contract requirements notwithstanding any review, approval or acceptance by the Government.

b. The Government's rights and remedies stated in these specifications are in addition to any other rights or remedies the Government may have under the contract or applicable law. The Government's rights and remedies stated in these specifications are not exclusive and do not limit, waive or alter any other Government rights or remedies under the contract or applicable law.

c. Reference documents in these specifications include the most current version of the document or reference in existence on the contract date.

PART 2 PRODUCTS

Not used.

01 11 00 For Official Use Only 16

PART 3 EXECUTION

Not used.

-- End of Section --

01 11 00 For Official Use Only 17

USACE / NAVFAC / AFCEC / NASA UFGS-01 33 00 (May 2011) Change 2 - 11/12 Preparing Activity: NASA Superseding UFGS-01 33 00 (February 2011)

UNIFIED FACILITIES GUIDE SPECIFICATIONS

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 33 00

SUBMITTAL PROCEDURES

05/11 general procedures regarding submittals, data normally submitted for review to establish conformance with the design concept and contract documents

PART 1 GENERAL

1.1 SUMMARY

1.2 DEFINITIONS

1.2.1 Submittal Descriptions (SD)

1.2.2 Approving Authority

1.2.3 Work

1.2.4 Electronic Data Standards (EDS)

1.3 SUBMITTALS

1.4 SUBMITTAL CLASSIFICATION

1.4.1 Designer of Record Approved (DA)

1.4.2 Government Approved [G]

1.4.3 Government Conformance Review of Design (CR)

1.4.4 Designer of Record Approved/Government Conformance Review

(DA/CR)

1.4.4.1 Deviations to the Accepted Design

1.4.4.2 Substitutions

1.4.5 Designer of Record Approved/Government Approved (DA/GA)

1.4.6 Information Only

1.5 PREPARATION

1.5.1 Transmittal Form

1.5.2 Identifying Submittals

1.5.3 Format for SD-02 Shop Drawings

1.5.4 Format of SD-03 Product Data and SD-08 Manufacturer's

Instructions

1.5.5 Format of SD-04 Samples

1.5.6 Format of SD-05 Design Data and SD-07 Certificates

1.5.7 Format of SD-06 Test Reports and SD-09 Manufacturer's Field

Reports

1.5.8 Format of SD-10 Operation and Maintenance Data (O&M)

1.5.9 Format of SD-01 Preconstruction Submittals and SD-11 Closeout

Submittals

1.6 QUANTITY OF SUBMITTALS

01 33 00 For Official Use Only 1

1.6.1 Number of Copies of SD-02 Shop Drawings

1.6.2 Number of Copies of SD-03 Product Data and SD-08

Manufacturer's Instructions

1.6.3 Number of Samples SD-04 Samples

1.6.4 Number of Copies SD-05 Design Data and SD-07 Certificates

1.6.5 Number of Copies SD-06 Test Reports and SD-09 Manufacturer's

Field Reports

1.6.6 Number of Copies of SD-10 Operation and Maintenance Data

1.6.7 Number of Copies of SD-01 Preconstruction Submittals and SD-11

Closeout Submittals

1.7 INFORMATION ONLY SUBMITTALS

1.8 SUBMITTAL REGISTER AND DATABASE

1.8.1 Use of Submittal Register

1.8.2 Contractor Use of Submittal Register

1.8.3 Approving Authority Use of Submittal Register

1.8.4 Action Codes

1.8.4.1 Government Review Action Codes

1.8.4.2 Contractor Action Codes

1.8.5 Copies Delivered to the Government

1.9 SCHEDULING

1.9.1 Government Reviewed Design

1.10 GOVERNMENT APPROVING AUTHORITY

1.10.1 Review Notations

1.11 DISAPPROVED SUBMITTALS

1.12 APPROVED SUBMITTALS

1.13 APPROVED SAMPLES

1.14 PROGRESS SCHEDULE

1.14.1 Bar Chart

1.14.2 Project Network Analysis

1.15 STATUS REPORT ON MATERIALS ORDERS

1.16 STAMPS

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

01 33…