W912EP-11-D-0006-DW01_Charleston_Harbor_110113.pdf

6 . ISSUED BY CODE

W912EP-11-D-0006

1 . CO N TRA CT/P U RCH . O RD E R/

A G RE E M E N T N O .

W 912H P

2 . D E L IVE RY O RD E R/ CA L L N O .

DW01

11P AGE 1 OF

5 . P RIO RITY

CODE

8 . DELIVERY FOB

DEST INAT IONX

OT HER

(See Schedule if o t h er)

OR D ER FOR SUPPLIES OR SER VICES

3 . D A TE O F O RD E R/CA L L

2013 Oc t 25

4 . RE Q ./ P U RCH . RE Q U E ST N O .

W81D 4A32949791

SEE IT EM 6

U .S. AR MY C OR PS OF EN GIN EER S, C H AR LESTON

D ISTR IC T, C ON TR AC TIN G D IVISION

69-A H AGOOD AVEN U E

C H AR LESTON SC 29403

7 . ADM INIST ERED BY (if o ther tha n 6 )

( YYYYM M M D D )

1 0 . D E L IVE R TO FO B P O IN T BY (D ate)

( YYYYM M M D D )

MAN SON C ON STR U C TION C O.

SEATTLE, W A

5209 E MAR GIN AL W AY S

SEATTLE W A 98134-2409

CODE 0FCP99 . CONT RACT OR FACILIT Y

SEE SCHEDULE

1 2 . D ISCO U N T TE RM S

N et 14 days

M A RK IF BU SIN E SS IS1 1 .

SM A L L

SM A L L

D ISA D VA N TA G E D

W O M E N -O W N E D

1 3 . M AIL INVOICES T O T HE ADDRESS IN BLOCK

See Item 15

2 5 . T OT AL $6,702,200.00 EST

LOW C OU N TR Y R ESID EN T OF F IC E

KEVIN D . W ID N ER

1050 R EMOU N T R OAD BLD G 3555

N OR TH C H AR LESTON SC 29406

X

17 . ACCOUNT ING AND AP P ROP RIAT ION DAT A/ LOCAL USE

CODE

18 . IT EM NO. 19 . SCHEDULE OF SUP P LIES/ SERVICES

* If q u a n t i t y a ccep ted b y th e G o ver n m en t is s a m e a s q u a n t i ty a ccep ted b elo w q u a n t i t y o r d er ed a n d en ci r cle.

DELIVERY/1 6 .

14 . SHIP T O

Se e Sche dule

W 912H P 964145

MARK ALL

PAC KAG ES AND

PAPERS W ITH

IDENTIFIC ATIO N

NUMB ERS IN

B LO C KS 1 AND 2 .

2 3 . AM OUNT

15 . P AYM ENT W ILL BE M ADE BY CODE

U S AR MY C OR PS OF EN GR S F IN AN C E C EN TER

U SAED (H QU SAC E)

5722 IN TEGR ITY D R IVE

MILLIN GTON TN 38054-5005

Th is d el iv ery o rd er/cal l i s i s s u ed o n an o th er G o v ern men t ag en cy o r in acco rd an ce w i th an d s u b ject to terms an d co n d i t io n s o f ab o v e n u mb ered co n tract .

T YP E CALL

OF P URCHASE

ORDER

SEE SCHEDULE

24. UNITED STATES OF AMERICA

TEL: 843-329-8088

EMAIL: henry.wigfall@usace.army.mil

CONTRACTING / ORDERING OFFICER

q u a n t i ty o r d er ed , in d ica te b y X . If d i f f er en t , en ter a ctu a l

BY: HENRY WIGFALL

If t h is box is m arked, sup p lier m ust sign Accep t an ce and ret urn t he fo llowin g num ber o f cop ies:

NAM E OF CONT RACT OR SIGNAT URE T YP ED NAM E AND T IT LE

( YYYYM M M D D )

DAT E SIGNED

ACCEP T ANCE. T HE CONT RACT OR HEREBY ACCEP T S T HE OFFER REP RESENT ED BY T HE NUM BERED P URCHASE ORDER AS IT M AY P REVIOUSLY HAVE BEEN OR IS NOW M ODIFIED, SUBJECT T O ALL OF T HE T ERM S

AND CONDIT IONS SET FORT H, AND AGREES T O P ERFORM T HE SAM E.

Referen ce y o u r q u o te d ated

Fu rn is h th e fo l lo w in g o n terms s p eci fied h erein . REF :

2 0 . QUANT IT Y

ORDERED/

ACCEP T ED*

21 . UNIT 22 . UNIT P RICE

D IFFE RE N CE S

2 6 .

INSP ECT ED RECEIVED ACCEP T ED, AND CONFORM S T O T HE

CONT RACT EXCEP T AS NOT ED

27a. QUANT IT Y IN COLUM N 20 HAS BEEN

( YYYYM M M D D )

c. DAT E d. P RINT ED NAM E AND T IT LE OF AUT HORIZED

GOVERNM ENT REP RESENT AT IVE

b. SIGNAT URE OF AUT HORIZED GOVERNM ENT REP RESENT AT IVE

e. M AILING ADDRESS OF AUT HORIZED GOVERNM ENT REP RESENT AT IVE

36. I ce r tify th is account is cor re ct and prope r for paym e nt.

g. E -M AIL ADDRESSf. T ELEP HONE NUM BER

a. DAT E

( YYYYM M M D D )

b. SIGNAT URE AND T IT LE OF CERT IFYING OFFICER

28 . SHIP NO. 29 . DO VOUCHER NO. 30 .

INIT IALS

32 . P AID BY 33 . AM OUNT VERIFIED

CORRECT FOR

35 . BILL OF LADING NO.

34 . CHECK NUM BER

3 7 . RECEIVED AT 38 . RECEIVED BY

( YYYYM M M D D )

31 . P AYM ENT

COM P LET E

P ART IAL

FINAL

P ART IAL

FINAL

DD For m 1155, DEC 2001 P REVIOUS EDIT ION IS OBSOLET E.

39 . DAT E RECEIVED 40 . T OT AL

CONT AINERS

41 . S/R ACCOUNT NO. 42 . S/R VOUCHER NO.

AD D R ESS

AN D

N AME

DW01

Section 00010 - Solicitation Contract Form

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Lump Sum $975,000.00 $975,000.00 Mobilization and Demoblization Dredging in Charleston Harbor Entrance Channel

FOB: Destination

MILSTRIP: W81D4A32949791

NET AMT $975,000.00

ACRN AA

CIN: W81D4A329497910001

$975,000.00

0002 1,469,000 Cubic

Yard

$3.80 $5,582,200.00 EST

Dredging of Unclassified Material in Charleston Entrance Channel Shoals 5-8 (Main Channel 49', 1' OD).

NET AMT $5,582,200.00 (EST.)

$5,582,200.00

0003 1 Lump Sum $85,000.00 $85,000.00 Compliance with Endangered Species Act and Marine Mammal Act (Charleston

Entrance Channel)

NET AMT $85,000.00

$85,000.00

0004 10 Days $6,000.00 $60,000.00 Non-Capture Trawl Sweeping (12 Hour Days) Charleston Entrance Channel

NET AMT $60,000.00

$60,000.00

0005 711,000 Cubic

Yard

$3.20 $2,275,200.00 EST

OPTION Dredging Unclassified Material in Charleston Entrance Channel Shoals 5-8 (Channel Wing 44', 1' OD).

NET AMT $2,275,200.00 (EST.)

0006 448,000 Cubic

Yard

$0.00 $0.00 EST

OPTION Dredging for an Additional 1' Overdepth for shoals 5-8

NET AMT $0.00 (EST.)

0007 38,000 Cubic

Yard

$2.65 $100,700.00 EST

OPTION Dredging Unclassified Material in Charleston Entrance Channel Shoal 1 (Main Channel 49',Wings 44', 1' OD).

NET AMT $100,700.00 (EST.)

0008 11,000 Cubic

Yard

$2.65 $29,150.00 EST

OPTION Dredging Unclassified Material in Charleston Entrance Channel Shoal 2 (Main Channel 49', Wings 44', 1' OD).

NET AMT $29,150.00 (EST.)

0009 47,000 Cubic

Yard

$2.35 $110,450.00 EST

OPTION Dredging Unclassified Material in Charleston Entrance Channel Shoal 3 (Main

NET AMT $110,450.00 (EST.)

0010 31,000 Cubic

Yard

$2.30 $71,300.00 EST

OPTION Dredging Unclassified Material in Charleston Entrance Channel Shoal 4 (Main

NET AMT $71,300.00 (EST.)

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

Attachment 1 Addendum to SF1442 2 25-OCT-2013

Section 00800 - Special Contract Requirements

ACCOUNTING AND APPROPRIATION DATA

AA: 96X31230000 082443 2540461D4L002980 NA 96382

AMOUNT: $6,702,200.00

CIN W81D4A329497910001: $6,702,200.00

CLAUSES INCORPORATED BY REFERENCE

52.249-4001 TIME EXTENSIONS FOR UNUSUALLY SEVERE

WEATHER

DEC 1999

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within SEE SUPPLEMENTAL INSTRUCTIONS after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and

(c) complete the entire work ready for use not later than 31 March 2014* The time stated for completion shall include final cleanup of the premises.

*The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $ 2,059.00 [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

WAGE RATES

General Decision Number: SC130011 01/04/2013 SC11

Superseded General Decision Number: SC20120011

State: South Carolina

Construction Type: Heavy Dredging

DREDGING

Counties: South Carolina Statewide.

STATEWIDE

DREDGING

Modification Number Publication Date 0 01/04/2013

* ENGI0025-002 10/01/2009

Rates Fringes

Dredging :

CLASS A.....................$ 28.20 6.60+a CLASS B1....................$ 24.70 6.60+a CLASS B2....................$ 23.81 6.60+a CLASS C1....................$ 22.58 6.50+a CLASS C2....................$ 21.63 6.50+a CLASS D.....................$ 18.26 6.40+a Hydraulic Dredges Under 20" Cook........................$ 8.11 1.73+b Deckhand....................$ 7.77 1.73+b Engineer....................$ 9.59 1.73+b Launchman...................$ 8.19 1.73+b Leverman....................$ 10.03 1.73+b Mate........................$ 8.82 1.73+b Mess Cook...................$ 7.71 1.73+b Messman & Janitor...........$ 7.53 1.73+b Oiler & Fireman.............$ 8.11 1.73+b Shoreman....................$ 7.82 1.73+b Spider Barge Operator.......$ 8.68 1.73+b Spill Barge Operator........$ 8.68 1.73+b Welder......................$ 9.79 1.73+b

CLASSIFICATIONS:

CLASS A: Leverman, Operator.

CLASS B1: Licensed Tug Operator over 1000 HP, Derrick Operator, Spider/Spill Barge Operator, Timber Fork Operator, Dozer Operator, Engineer, Blaster/Driller, Fill Placer, Electrician.

CLASS B2: Licensed Boat Operator, Certified Welder.

CLASS C1: Mate, Drag Barge Operator, Welder, Assistant Fill Placer, Steward.

CLASS C2: Boat Operator.

CLASS D: Shoreman, Deckhand, Rodman, Scowman, Cook, Messman, Oiler, Janitor.

PREMIUMS: Additional 20% for hazardous material work

FOOTNOTE APPLICABLE TO ABOVE CRAFTS:

a. New Year's Day, Good Friday, Memorial Day, Independence Day, Labor Day, Thanksgiving Day and Christmas Day.

Vacation Contribution of 8% of straight time rate multiplied by the total hours worked.

b. New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Christmas Day. Plus Vacation contribution of 8% of straight time pay for all hours worked.

INCENTIVE PAY : (Add to Hourly Rate)

Operator (NCCCO License/Certification) $0.50; Licensed Tug Operator over 1000 HP (Assigned as Master) USCG licensed Master of Towing Vessels (MOTV) $1.00; Licensed Boat Operator (assigned as lead boat captain) USCG licensed boat operator $0.50; Engineer (QMED and Tankerman endorsement or licensed engineer (USCG) $0.50; Oiler QMED and Tankerman endorsement (USCG) $0.50; All classifications Tankerman endorsement only (USCG) $0.50; Deckhand or Mater AB w/Lifeboatman only (USCG) $0.25; Welder (ABS certification) $0.50

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is union or non-union.

Union Identifiers

An identifier enclosed in dotted lines beginning with characters other than "SU" denotes that the union classification and rate have found to be prevailing for that classification. Example: PLUM0198-005 07/01/2011. The first four letters , PLUM, indicate the international union and the four-digit number, 0198, that follows indicates the local union number or district council number where applicable , i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination.

The date, 07/01/2011, following these characters is the effective date of the most current negotiated rate/collective bargaining agreement which would be July 1, 2011 in the above example.

Union prevailing wage rates will be updated to reflect any changes in the collective bargaining agreements governing the rates.

0000/9999: weighted union wage rates will be published annually each January.

Non-Union Identifiers

Classifications listed under an "SU" identifier were derived from survey data by computing average rates and are not union rates; however, the data used in computing these rates may include both union and non-union data. Example: SULA2004-007 5/13/2010. SU indicates the rates are not union majority rates, LA indicates the State of Louisiana; 2004 is the year of the survey; and 007 is an internal number used in producing the wage determination. A 1993 or later date, 5/13/2010, indicates the classifications and rates under that identifier were issued as a General Wage Determination on that date.

Survey wage rates will remain in effect and will not change until a new survey is conducted.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

SUPPLEMENTAL INSTRUCTIONS

Supplemental Instructions:

Charleston Entrance Channel - Prosecution of Work

The dredging work required shall be performed in its entirety, including cleanup and demobilization between 15 December 2013 and 31 March 2014.

The Contractor shall provide the Government a schedule not later than 10 calendar days after date of contract award depicting, at a minimum, the following information.

- Date mobilization is to commence

- Date dredging shall begin

- Duration of dredging (must at least meet specified minimums)

- Date dredging is to be completed

- Anticipated schedule of earnings

Once this schedule is approved, it will be incorporated into the contract by a no cost modification and become the performance period for the contract.

Liquidated damages will be assessed for every day work continues beyond this incorporated scheduled completion date (as adjusted for excusable delays as allowed per other provisions within the contract).

In conjunction with the above, the Contractor shall comply with the clause, LIQUIDATED DAMAGES - CONSTRUCTION found in SPECIAL CONTRACT

REQUIREMENTS.

(End of supplemental instructions)