AmendmentNo.01.pdf

1 | P a g e Amendment No. 1

NOTWASHINGTON METROPOLITAN TRANSIT AUTHORITY

600 FIFTH STREET, NW

WASHINGTON, DC 20001

Tender Number: IFB-FQ19162/KKB Date of Issuance: May 14, 2019 Tender Bid Opening Date May 29, 2019

AMENDMENT NO. 01

TO

INVITATION FOR BIDS

FOR

Replacement of Chiller and Cooling Towers at Five (5) Metro-rail Stations:

DC and VA

IFB-FQ19162/KKB

TO WHOM IT MAY CONCERN:

The Invitation for Bids Documents accompanying IFB FQ19162/KKB requesting proffers for above procurement action are herewith changed in part as listed below. The changes are bolded and denoted with ## signs.

1. Volume 1-Specifications, Division 00

DELETE SUBSTITUTE DESCRIPTION

Cover Page Cover Page Fixed the Typo

Amendment No.: 01

DELETE SUBSTITUTE DESCRIPTION

Section 00100, Invitation Section 00100, Invitation Fixed the Typo For Bids, Page Section For Bids, Page Section, 00100-1. 00100-1, Amendment No.: 01

Section 00300, Information Section 00300, Information Fixed the Typo Available To Bidders, Page Available To Bidders, Page Section 00300-1. Section 00300-1, Amendment No.: 01

DELETE SUBSTITUTE DESCRIPTION

Section 00611, Performance Section 00611, Performance Fixed the Typo Bond, Page Section 00611-1 Bond, Page Section 00611-1, . Amendment No.: 01

DELETE SUBSTITUTE DESCRIPTION

Section 00612, Payment Section 00612, Payment Fixed the Typo Bond, Page Section 00612-1 Bond, Page Section 00612-1, . Amendment No.: 01

2. Volume 1-Specifications, Division 00-Supplementary Conditions

Supplementary Conditions, Supplementary Conditions, Revised Wage

Pages Appendix D-2, B-23, Pages Appendix D-(1-13) D-(4-7), D-7, & (D-(15-20), Amendment No.: 01 in its entirety.

3. There are no further changes.

Rate

4. THE SOLICITATION PROVISIONS ENTITLED "SOLICITATION AMENDMENT" IS

APPLICABLE TO THIS AMENDMENT. THE CHANGES SET FORTH ARE HEREWITH

INCORPORATED INTO THE ABOVE CITED SOLICITATION. THE HOUR AND DATE

SPECIFIED FOR RECEIPT OF PROFFERS IS NOT CHANGED AND WILL REMAIN MAY

29, 2019, AT 2:00 PM EST.

5. Acknowledgement: Bidders are required to acknowledge receipt of this amendment on Bid Form in the space provided. Failure to acknowledge all Amendments may cause the proffer to be considered non-responsive to the invitation for bids, which may cause its rejection.

'"......,l<:Y"'-'. Calvert, Contracting Officer, Office of Procurement and Materials

21Page Amendment No. 1

WASHINGTON METROPOLITAN AREA TRANSIT

AUTHORIT

Invitation For Bid Federal

REPLACEMENT OF CHILLER AND

COOLING TOWERS AT FIVE (5)

METRO-RAIL STATIONS: DC & VA

IFB NO.: FQ19162/KKB

IFB Publicized Date: March 25, 2019

IFB Due Date: May 29, 2019

MINORITY BUSINESS ENTERPRISES ARE

ENCOURAGED TO RESPOND TO THIS

SOLICITATION ## PROCLAMATION ##

Volume 1, Specifications, Divisions 00-03, 05, 07, 09, 15 & 16

Amendment No.: 01

INVITATION FOR BIDS Section 00100–1

DBB V1 8/2013

Washington Metropolitan Area Transit Authority Contract No.: FQ19162 IFB No.: FQ19162/KKB Date: March 2019

SECTION 00100

INVITATION FOR BIDS

This Section includes Project information for Bidders.

NOTICE TO BIDDERS

## Contract No.: FQ19162 includes IFB Documents for: ##

Project Name: Replacement of Chiller and Cooling Towers at Five (5) Metro-Rail Stations

Bids for the Work described herein shall be submitted before 2:00 PM (local time) on May 29, 2019. Questions may be directed to the Contract Administrator, Mr. Kamoru Banjo at (202) 962-1395 or kkbanjo@wmata.com.

See Section 00200, INSTRUCTIONS FOR BIDDERS, for Bid submittal instructions.

DIRECTIONS TO SUBMITTING BIDDER: Read and comply with the Invitation Instructions. In addition to other submission requirements set forth in this Invitation for Bids and all Amendments, the following must be properly executed, completed, and submitted as part of the Bid:

A. BID:

1. Bid Form, Section 00413 (properly executed)

2. Bid Price Schedule, Section 00434

3. Bid Guarantee, Section 00431

4. Completed and signed Representations and Certifications, Section 00451

5. Compliance Information, Section 00432

6. Buy America Certification

7. List of DBE Certified Firms

8. DBE Data, Section 00453

BID(S) MUST SET FORTH FULL, ACCURATE, AND COMPLETE INFORMATION AS REQUIRED BY THIS

INVITATION FOR BIDS, INCLUDING ALL AMENDMENTS

00101 GENERAL STATEMENT OF WORK:

A. This invitation is for the submittal of Bids for Replacement of Chiller and Cooling Towers at Five (5) Metro-Rail Stations

00102 GENERAL SCOPE OF WORK:

This section specifies the furnishing and installation of the chillers, cooling towers, refrigerant leak detection systems and chilled/ condenser water system accessories at CWPA2-Woodley Park-Zoo Adams Morgan, CWPA4-Tentleytown AU (A07), CWPB2-Union Station, CWPC4-Pentagon Station, and CWPG7-Benning Road. The Contractor shall furnish all labor, tools, permits, coordination, materials, transportation, and other items necessary to satisfactorily complete this Project as written in the Specifications and as indicated on the Contract Drawings.

Contractor shall be responsible for all permits and inspections. Contractor shall comply with Federal and jurisdictional requirements and codes pertaining to this project. Contractor shall also comply with all safety requirements and permits required by WMATA.

Amendment No. 01

Washington Metropolitan Area Transit Authority Contract No.: FQ19162 IFB No.: FQ19162/KKB Date: March 2019

Information Available to Bidders Section 00300–1

DBB V1 8/2013

SECTION 00300

INFORMATION AVAILABLE TO BIDDERS

This Section includes information made available to the Bidders.

00301 INVITATION FOR BID (IFB) DOCUMENTS

A. The IFB Documents, including General Conditions, Supplementary Conditions, General ## Requirements, Specifications, Drawings, reports, safety and security requirements, and quality requirements of this Invitation IFB No: FQ19162/KKB and referenced in this Section establish requirements for the construction of the Project. These IFB Documents shall be used by the Bidder to prepare the Bid. ##

00302 GENERAL CONDITIONS, SUPPLEMENTARY CONDITIONS, AND GENERAL REQUIREMENTS

A. The General Conditions, Supplementary Conditions, and General Requirements contain requirements for the administration and construction of the Project.

00303 CONTRACT SPECIFICATIONS

A. Specifications (Divisions 00-01, 02, 05, 07, 09, 15 & 16 of the Contract Specifications) are the parts of the Contract Documents containing written directions or requirements that specify the requirements, which must be fulfilled for the completion of the Work.

B. The WMATA Manual of Design Criteria establishes general design criteria for the Project that shall govern the design of temporary works as defined in the Specifications unless jurisdictional codes and regulations are more stringent, in which case the codes and regulations shall govern.

00304 CONTRACT DRAWINGS

A. Contract Drawings are the plans, profiles, typical cross sections, general cross sections, elevations, schedules, and details listed or included in the Contract Documents, which represent requirements for the Project.

B. The WMATA CAD Manual shall be adhered to for the preparation of As-built Drawings by the Contractor.

00310 EXISTING CONDITIONS

A. Bidder should visit the site and take such other steps as may be reasonably necessary to ascertain the nature and location of the work and general and local conditions which can affect the work or the cost thereof.

B. Failure to do so will not relieve bidders from the responsibility for estimating properly the difficulty or associated risks and cost of successfully performing the work.

00320 GEOTECHNICAL INFORMATION – NOT APPLICABLE

A. Geotechnical Information is NOT included in the IFB Documents.

00330 ENVIRONMENTAL REPORT – NOT APPLICABLE

A. An Environmental Report is not included in the IFB Documents.

00340 WMATA SAFETY AND SECURITY REQUIREMENTS

A. This Section lists the safety and security related documents that establish the safety requirements for the Project.

Performance Bond Section 00611–1

DBB V1 8/2013

SECTION 00611

PERFORMANCE BOND

BIDDER’S INFORMATION NOTICE: The following is included for the Bidder’s information and use in the event Bidder is awarded the Contract. It is not required to be submitted with the Bid.

## Contract Number: FQ19162 ## Date: _________________

Penal Sum of Bond: $_____________________ Date Bond Executed: ___________________

KNOW ALL PERSONS BY THESE PRESENTS, that we, the Principal and Surety(ies) hereto, are firmly bound to the Washington Metropolitan Area Transit Authority (hereinafter called the Authority) in the above penal sum for the payment of which we bind ourselves, our heirs, executors, administrators, and successors, jointly and severally: Provided, that, where the Sureties are corporations acting as co-sureties, we, the Sureties, bind ourselves in such sum “jointly and severally” as well as “severally” only for the purpose of allowing a joint action or actions against any or all of us, and for all other purposes each Surety binds itself, jointly and severally with the Principal, for the payment of such sum only as set forth opposite the name of such Surety, but if no limit of liability is indicated, the limit of liability shall be the full amount of the penal sum.

THE CONDITION OF THIS OBLIGATION IS SUCH that whereas the Principal entered into the Contract identified above:

NOW, THEREFORE, if the Principal shall perform and fulfill all the undertakings, covenants, terms, conditions and agreements of said Contract during the original term of said Contract and any extensions thereof that may be granted by the Authority, with or without notice to the Surety(ies), and during the life of any guaranty required under the contract, and shall also perform and fulfill all the undertakings, covenants, terms, conditions, and agreements of any and all duly authorized modifications of said Contract that may hereafter be made, notice of which modifications to the Surety(ies) being hereby waived, then the above obligation shall be void and of no effect. Surety acknowledges Authority can advance the date of payments to Contractor, and by so doing the Surety remains liable under the terms of the bond.

IN WITNESS WHEREOF, the Principal and Surety(ies) have executed this performance bond and have affixed their seals on the date set forth above.

Principals

1. Firm Name: ______________________________________

Firm Address: ____________________________________

Signature: ______________________________________

Name and Title: __________________________________

State of Inc.: ____________

Corporate Seal

2. Firm Name: ______________________________________

Firm Address: ____________________________________

Signature: _______________________________________

Name and Title: __________________________________

State of Inc.:____________

Corporate Seal

Payment Bond Section 00612–1

DBB V1 8/2013

SECTION 00612

PAYMENT BOND

## Contract Number: FQ19162 ## Date: _______________________

Penal Sum of Bond: $________________________ Date Bond Executed: __________________

KNOW ALL MEN BY THESE PRESENTS, that we, the Principal and Surety(ies) hereto, are firmly bound to the Washington Metropolitan Area Transit Authority (hereinafter called the Authority) in the above penal sum for the payment of which we bind ourselves, our heirs, executors, administrators, and successors, jointly and severally:

Provided, that, where the Sureties are corporations acting as co-sureties, we, the Sureties, bind ourselves in such sum “jointly and severally” as well as “severally” only for the purpose of allowing a joint action or actions against any or all of us, and for all other purposes each Surety binds itself, jointly and severally with the Principal, for the payment of such sum only as set forth opposite the name of such Surety, but if no limit of liability is indicated, the limit of liability shall be the full amount of the penal sum.

THE CONDITION OF THIS OBLIGATION IS SUCH that, whereas the Principal entered into the Contract identified above:

NOW, THEREFORE, if the Principal shall promptly make payment to all claimants as hereinafter defined supplying services, labor, material, and/or equipment in the prosecution of the Work provided for in said Contract, and any and all duly authorized modifications of said Contract that may hereafter be made, notice of which modifications to the Surety(ies) being hereby waived, then the above obligation shall be void and of no effect, otherwise it shall remain in full force and effect, subject, however, to the following conditions:

1. A claimant is defined as one having a direct contract with the Principal or with a subcontractor of the Principal for labor, material, or both, used or reasonably required for use in the performance of the Contract, labor and material being construed to include that part of water, gas, power, light, heat, oil, gasoline, telephone service, or rental of equipment directly applicable to the Contract.

2. The above-named Principal and Surety hereby jointly and severally agree with the Authority that every claimant as herein defined, who has not been paid in full before the expiration of a period of 90 Days after the date on which the last of such claimant’s work or labor was done or performed, or materials were furnished by such claimant, may sue on this bond for the use of such claimant, prosecute the suit to final judgment for such sum or sums as may be justly due the claimant, and have execution thereon.

The Authority shall not be liable for the payment of any costs or expenses of any such suit.

3. No suit or action shall be commenced hereunder by any claimant:

a. Unless claimant, other than one having a direct contract with the Principal, shall have given written notice to the Principal within 90 Days after such claimant did or performed the last of the work or labor, or furnished the last of the materials for which said claim is made, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were furnished, or for whom the work or labor was done or performed. Such notice shall be served by mailing the same by registered mail or certified mail, postage prepaid, in an envelope addressed to the Principal at any place where it maintains an office or conducts business, or its residence or such notice shall be served in any manner in which legal process may be served in the state or District of Columbia in which the aforesaid Project is located, save that such service need not be made by a public officer.

b. After the expiration of one year following the date of final settlement of said Contract, it being understood, however, that if any limitation embodied in this bond is prohibited by any law controlling the construction hereof, such limitation shall be deemed to be amended so as to be equal to the minimum period of limitation permitted by such law.

c. Other than in a state court of competent jurisdiction in and for the county or other political subdivision of the state in which the Project, or any part thereof, is situated or in the United States District Court for the district in which the Project, or any part thereof, is situated, and not elsewhere.

Supplementary Conditions APPENDIX D-1

DBB V1 8/2013

Amendment No.: 01

General Decision Number: DC190002 05/10/2019 DC2

Superseded General Decision Number: DC20180002

State: District of Columbia

Construction Type: Building

County: District of Columbia Statewide.

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.60 for calendar year 2019 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.60 (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2019.

If this contract is covered by the EO and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5

(a) (1) (ii) (or the EO minimum wage rate, if it is higher than the conformed wage rate). The EO minimum wage rate will be adjusted annually. Please note that this E0 applies to the above –mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date

0 01/04/2019 1 01/11/2019 2 02/08/2019 3 03/22/2019 4 04/05/2019 5 05/03/2019 6 05/10/2019

ASBE0024-007 10/01/2017

Rates Fringes ASBESTOS WORKER/HEAT & FROST INSULATOR $ 35.13 16.22+a Includes the application of all insulating materials, protective coverings, coatings and finishes to all types of mechanical systems

a. PAID HOLIDAY: New Year’s Day, Martin Luther King Day, Memorial Day, Independence Day, Labor Day, Veterans’ Day, Thanksgiving Day, the day after Thanksgiving and Christmas Day provided the employee works the regular work day before and after the paid holiday.

ASBE0024-008 10/01/2017

Rates Fringes

ASBESTOS WORKER: HAZARDOUS MATERIAL HANDLER $ 22.81 7.34+a Includes preparation, wetting, stripping, removal, scrapping, vacuuming, bagging and disposing of all insulation materials, whether they contain asbestos or not, from mechanical systems

APPENDIX-D2 Supplementary Conditions

DBB V1 8/2013

Amendment No.: 01

a. PAID HOLIDAY: New Year’s Day, Martin Luther King Day, Memorial Day, Independence Day, Labor Day, Veterans’ Day, Thanksgiving Day, the day after Thanksgiving and Christmas Day provided the employee works the regular work day before and after the paid holiday.

ASBE0024-014 10/01/2017

Rates Fringes

FIRESTOPPER $ 28.01 7.78+a

Includes the application of materials or devices within or around penetrations and openings in all rated wall or floor assemblies, in order to prevent the pasage of fire, smoke of other gases. The application includes all components involved in creating the rated barrier at perimeter slab edges and exterior cavities, the head of gypsum board or concrete walls, joints between rated wall or floor components, sealing of penetrating items and blank openings.

a. PAID HOLIDAY: New Year’s Day, Martin Luther King Day, Memorial Day, Independence Day, Labor

Day, Veterans’ Day, Thanksgiving Day, the day after Thanksgiving and Christmas Day provided the employee works the regular work day before and after the paid holiday.

BRDC0001-002 04/28/2019

Rates Fringes

BRICKLAYER $ 32.00 11.57

CARP0197-011 05/01/2018

Rates Fringes

CARPENTER, Includes Drywall Hanging, Form Work, and Soft Floor Laying-Carpet $ 28.71 12.08

* CARP0441-001 05/01/2018

Rates Fringes

PILEDRIVERMAN $ 30.94 11.45

CARP0219-001 05/01/2019

Rates Fringes

MILLWRIGHT $ 35.99 11.23

ELEC0026-016 11/05/2018

Rates Fringes

ELECTRICIAN, Includes Installation of HVAC/Temperature Controls $ 45.75 18.27

ELEC0026-017 09/03/2018

Rates Fringes

ELECTRICAL INSTALLER (Sound & Communication Systems) $ 28.05 10.91

SCOPE OF WORK: Includes low voltage construction, installation, maintenance and removal of teledata facilities (voice, data and video) including outside plant, telephone and data inside wire, interconnect, terminal equipment, APPENDIX-D3 Supplementary Conditions

DBB V1 8/2013

Amendment No.: 01 central offices, PABX, fiber optic cable and equipment, railroad communications, micro waves, VSAT, bypass, CATV, WAN (Wide area networks), LAN (Local area networks) and ISDN (Integrated systems digital network).

WORK EXCLUDED: The installation of computer systems in industrial applications such as assembly lines, robotics and computer controller manufacturing systems. The installation of conduit and/or raceways shall be installed by Inside Wiremen. On sites where there is no Inside Wireman employed, the Teledata Technician may install raceway or conduit not greater than 10 feet. Fire alarm work is excluded on all new construction sites or wherever the fire alarm system is installed in conduit. All HVAC control work.

ELEV0010-001 01/01/2018

Rates Fringes

ELEVATOR MECHANIC $ 45.53 33.705+a+b

a. PAID HOLIDAYS: New Year's Day, Memorial Day, Independence Day, Labor Day, Veterans' Day, Thanksgiving Day, Christmas Day and the Friday after Thanksgiving.

b. VACATIONS: Employer contributes 8% of basic hourly rate for 5 years or more of service; 6% of basic hourly rate for 6 months to 5 years of service as vacation pay credit.

IRON0005-011 06/01/2017

Rates Fringes

IRONWORKER, STRUCTURAL AND ORNAMENTAL $ 31.15 20.63

LABO0011-009 06/01/2018

Rates Fringes

LABORER: Skilled $ 24.22 8.32

FOOTNOTE: Potmen, power tool operator, small machine operator, signalmen, laser beam operator, waterproofer, open caisson, test pit, underpinning, pier hole and ditches, laggers and all work associated with lagging that is not expressly stated, strippers, operator of hand derricks, vibrator operators, pipe layers, or tile layers, operators of jackhammers, paving breakers, spaders or any machine that does the same general type of work, carpenter tenders, scaffold builders, operators of towmasters, scootcretes, buggymobiles and other machines of similar character, operators of tampers and rammers and other machines that do the same general type of work, whether powered by air, electric or gasoline, builders of trestle scaffolds over one tier high and sand blasters, power and chain saw operators used in clearing, installers of well points, wagon drill operators, acetylene burners and licensed powdermen, stake jumper, demolition.

MARB0002-004 04/29/2018

Rates Fringes

MARBLE/STONE MASON $ 37.91 17.08

INCLUDING pointing, caulking and cleaning of All types of masonry, brick, stone and cement EXCEPT pointing, caulking, cleaning of existing masonry, brick, stone and cement (restoration work)

MARB0003-006 04/29/2018

Rates Fringes

TERRAZZO WORKER/SETTER $ 28.20 11.67

MARB0003-007 04/29/2018

APPENDIX-D4 Supplementary Conditions

DBB V1 8/2013

Amendment No.: 01

Rates Fringes

TERRAZZO FINISHER $ 23.28 10.72

MARB0003-008 04/29/2018

Rates Fringes

TILE SETTER $ 28.20 11.67

MARB0003-009 04/29/2018

Rates Fringes

TILE FINISHER $ 23.28 10.72

PAIN0051-014 06/01/2018

Rates Fringes

GLAZIER

Glazing Contracts $2 million and under $ 26.07 12.15 Glazing Contracts over $2 million $ 30.31 12.15

PAIN0051-015 06/01/2018

Rates Fringes

PAINTER

Brush, Roller, Spray and Drywall Finisher $ 25.06 9.76

PLAS0891-005 07/01/8

Rates Fringes

PLASTERER $ 29.53 6.80

PLAS0891-006 02/01/2019

Rates Fringes

CEMENT MASON/CONCRETE FINISHER $ 28.45 11.28

PLAS0891-007 08/01/2016

Rates Fringes

FIREPROOFER

Handler $ 16.50 4.89 Mixer/Pump $ 18.50 4.89 Sprayer $ 23.00 4.89

Spraying of all Fireproofing materials. Hand application of Fireproofing materials. This includes wet or dry, hard or soft. Intumescent fireproofing and refraction work, including, but not limited to, all steel beams, columns, metal decks, vessels, floors, roofs, where ever fireproofing is required. Plus any installation of thermal and acoustical insulation.

All that encompasses setting up for Fireproofing, and taken down. Removal of fireproofing materials and protection.

Mixing of all materials either by hand or machine following manufactures standards.

Supplementary Conditions APPENDIX D-5

DBB V1 8/2013

Amendment No.: 01

PLUM0005-010 08/01/2018

Rates Fringes

PLUMBER $ 42.92 18.15+a

. PAID HOLIDAYS: Labor Day, Veterans' Day, Thanksgiving Day and the day after Thanksgiving, Christmas

Day, New Year's Day, Martin Luther King's Birthday, Memorial Day and the Fourth of July.

PLUM0602-008 08/01/2018

Rates Fringes

PIPEFITTER, Includes HVAC Pipe Installation $ 41.64 21.57+a

a. PAID HOLIDAYS: New Year's Day, Martin Luther King's Birthday, Memorial Day, Independence Day, Labor Day, Veterans' Day, Thanksgiving Day and the day after Thanksgiving and Christmas Day.

ROOF0030-016 07/01/2018

Rates Fringes

ROOFER $ 29.75 12.74

SFDC0669-002 04/01/2018

Rates Fringes

SPRINKLER FITTER (Fire Sprinklers) $ 35.60 20.24

SHEE0100-015 07/01/2018

Rates Fringes

SHEET METAL WORKER (Including HVAC Duct Installation) $ 40.27 20.34+a

a. PAID HOLIDAYS: New Year's Day, Martin Luther King's Birthday, Memorial Day, Independence Day, Labor Day, Veterans Day, Thanksgiving Day and Christmas Day

SUDC2009-003 05/19/2009

Rates Fringes

LABORER: Common or General $ 13.04 2.80 LABORER: Mason Tender - Cement/Concrete $ 15.40 2.85 LABORER: Mason Tender for pointing, caulking, cleaning of existing masonry, brick, stone and cement structures (restoration work);

excludes pointing, caulking and cleaning of new or replacement masonry, brick, stone and cement $ 11.67

POINTER, CAULKER, CLEANER, Includes pointing, caulking, cleaning of existing masonry, brick, stone and cement structures (restoration work); excludes pointing, caulking, cleaning of new or replacement masonry, brick, stone or cement $ 18.88 WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

APPENDIX D-6 Supplementary Conditions

DBB V1 8/2013

Amendment No.: 01

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year. Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than "SU" or "UAVG" denotes that the union classification and rate were prevailing for that classification in the survey. Example: PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the "SU" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE:

UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

Supplementary Conditions APPENDIX D-7

DBB V1 8/2013

Amendment No.: 01

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.) and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7).

Write to:

Wage and Hour Administrator U.S. Department of Labor

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative

Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

AppendixD-8 Supplementary Conditions

DBB V1 8/2013

Amendment No.: 01

General Decision Number: VA190013 04/05/2019 VA13

Superseded General Decision Number: VA20180013

State: Virginia

Construction Type: Building

County: Arlington County in Virginia. Includes the independent city of Alexandria*

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.60 for calendar year 2019 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.60 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2019. If this contract is covered by the EO and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers I that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5 (a) (1) (ii) (or the EO minimum wage rate, if it is higher than the conformed wage rate). The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date

0 01/04/2019 1 04/05/2019

* ASBE0024-006 10/01/2017

Rates Fringes

ASBESTOS WORKER/HEAT & FROST INSULATOR – MECHANICAL

(Duct, Pipe & Mechanical System Insulation) $ 35.13 16.22+a

a. PAID HOLIDAYS: New Year’s Day, Martin Luther King Day, Memorial, Independence Day, Labor Day, Veterans’ Day, Thanksgiving Day, the day after Thanksgiving and Christmas Day provided the employee works the regular work day before and after the paid holiday.

* ASBE0024-009 10/01/2017

Rates Fringes FIRESTOPPER $ 28.01 7.78+a

Includes the application of materials or devices within or around penetrations and openings in all rated wall or floor assemblies, in order to prevent the pasage of fire, smoke of other gases. The application includes all components involved in creating the rated barrier at perimeter slab edges and exterior cavities, the head of gypsum board or concrete walls, joints between rated wall or floor components, sealing of penetrating items and blank openings.

Contract No.: FQ19162 Washington Metropolitan Area Transit Authority Date: March 2019 IFB No.: FQ19162/KKB

Supplementary Conditions APPENDIX D-9

DBB V1 8/2013

Amendment No.: 01

a. PAID HOLIDAYS: New Year’s Day, Martin Luther King Day, Memorial, Independence Day, Labor Day, Veterans’ Day, Thanksgiving Day, the day after Thanksgiving and Christmas Day provided the employee works the regular work day before and after the paid holiday.

BOIL0045-003 01/01/2017

Rates Fringes

BOILERMAKER $ 32.72 25.26

BRDC0001-005 04/29/2017

Rates Fringes

TILE FINISHER $ 23.28 10.72

BRVA0001-008 04/29/2018

Rates Fringes

BRICKLAYER $ 31.36 10.78

BRVA0001-009 04/29/2017

Rates Fringes

MASON – STONE $ 37.91 17.08

* ELEC0026-003 11/05/2018

Rates Fringes

ELECTRICIAN (Includes Low Voltage Wiring and Installation of and Sound and Communication Systems) $ 45.75 18.27

IRON0005-010 06/01/2017

Rates Fringes

IRONWORKER $ 31.15 20.63

PAIN0051-034 06/01/2018

Rates Fringes

GLAZIER $ 26.07 12.15

PAIN0051-035 06/01/2018

Rates Fringes

PAINTER

Brush, Roller and Spray $ 25.06 9.76

PAIN0051-036 06/01/2018

Appendix D-10 Supplementary Conditions

DBB V1 8/2013

Amendment No.: 01

Rates Fringes

DRYWALL FINISHER/TAPER $ 25.06 9.76

PLUM0005-014 08/01/2018

Rates Fringes

PLUMBER $ 42.92 18.15+a

a. PAID HOLIDAYS: New Year's Day, Martin Luther King's Birthday, Memorial Day, Independence Day, Labor Day, Veterans' Day, Thanksgiving Day and the day after Thanksgiving and Christmas Day.

PLUM0602-016 08/01/2018

Rates Fringes

PIPEFITTER (Includes HVAC Pipe, Unit and Temperature Controls Installations) $ 41.64 21.57+a

a. PAID HOLIDAYS: New Year's Day, Martin Luther King's Birthday, Memorial Day, Independence Day, Labor Day, Veterans' Day, Thanksgiving Day and the day after Thanksgiving and Christmas Day.

SFVA0669-006 01/01/2018

Rates Fringes

SPRINKLER FITTER (Fire Sprinklers) $ 35.60 20.24

SHEE0100-004 07/01/2018

Rates Fringes

SHEET METAL WORKER (Includes HVAC Duct Installation) $ 40.27 20.34+a

a. PAID HOLIDAYS: New Year's Day, Martin Luther King's Birthday, Memorial Day, Independence Day, Labor Day, Veterans Day, Thanksgiving Day and Christmas Day

SUVA2013-025 01/11/2016

Rates Fringes

BRICK POINTER/CAULKER/CLEANER $ 19.68 0.00

CARPENTER, Includes Acoustical Ceiling Installation, Drywall Hanging, and Form Work $ 23.36 5.20

CEMENT MASON/CONCRETE FINISHER $ 21.94 3.36

FLOOR LAYER: SOFT FLOORS $ 18.75 0.00

IRONWORKER, REINFORCING $ 27.46 8.71

LABORER: Common or General, including brick mason tending and cement mason tending $ 15.55 2.44

Supplementary Conditions APPENDIX D-11

DBB V1 8/2013

Amendment No.: 01

LABORER: Pipelayer. $ 16.81 4.26

OPERATOR: Backhoe/Excavator/Trackhoe $ 23.50 4.50

OPERATOR: Bobcat/Skid Steer/Skid Loader $ 18.95 4.03

OPERATOR: Bulldozer $ 21.99 4.98

OPERATOR: Crane $ 30.45 4.14

OPERATOR: Forklift $ 21.56 7.57

OPERATOR: Loader $ 22.26 3.57

OPERATOR: Roller $ 16.25 4.88

ROOFER $ 15.83 3.06

TILE FINISHER $ 23.40 0.00

TILE SETTER $ 27.80 10.25

TRUCK DRIVER: Dump Truck $ 19.22 2.58

WATERPROOFER $ 21.75 1.57

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

Appendix D-12 Supplementary Conditions

DBB V1 8/2013

Amendment No.: 01

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than "SU" or "UAVG" denotes that the union classification and rate were prevailing for that classification in the survey. Example: PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014. Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the "SU" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE:

UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.) and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Supplementary Conditions APPENDIX D-13

DBB V1 8/2013

Amendment No.: 01

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator

200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the

Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION