FA4407-17-R-0007_(Amendment_1).pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to:

1) change and extend the proposal due date to 18 September 2017.

2) change the completion date located in FAR clause 52.211-10 Alt I to 10 February 2018.

3) The higlighted changes in the SOWs (CLIN 0001, 0002, and 0003) to reflect the RFI #2 questions and answ ers.

All other terms and conditions in this solicitation w ill remain the same.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 11-Sep-2017

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X FA440717R0007

X 9B. DATED (SEE ITEM 11)

08-Aug-2017

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

11-Sep-2017

CODE

375 CONS/LGC

201 E WINTERS STREET BLDG 50

SCOTT AFB IL 62225-5015

FA4407 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

FA440717R0007

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been modified:

ATTENTION TO OFFERORS

CONTINUATION PAGE

A. Project Title: Demolition of Buildings 155, 500, and 4900, Scott AFB, IL.

B. Proposals are due by 18 September 17 at 01:00 PM (CDT).

C. All questions must be submitted NLT 10 calendar days before the RFP due date.

D. Period of Performance is the total number of days following the issue of the Notice to Proceed (NTP).

E. Bid Bond of 20% of the total proposed price shall be submitted with the Proposal.

F. See Section L "Instructions, Conditions, and Notices to Offerors", and Section M "Evaluation Factors for Award" for Proposal preparation, submission, and evaluation requirements for this solicitation.

G. A pre-proposal conference/site visit will be held on 17 August 2017 at 09:00 AM (CDT). All parties will meet at Building 155, located at 398 Symington Dr, Scott AFB, IL 62225

H. Sections K, L and M will not be physically included in the awarded contract.

I. Project magnitude is between $500,000.00 and $1,000,000.00

J. This solicitation is a total small business and HubZone set-aside. NAICS code is 238910.

K. Notice to Offerors: Funds are not presently available for this project. No award will be made until funds are available.

FUNDS UNAVAILABLE AT THIS TIME

Notice to Offerors: funds are not presently available for this effort. No award will be made under this solicitation until funds are available. The government reserves the right to cancel this solicitation, either before or after the closing date. In the event the government cancels this solicitation, the government has no obligation to reimburse an offeror for any costs.

SITE VISIT INSTRUCTIONS

A pre-proposal conference and site visit will be held at Building 155 near the Essex Pool on Scott

Air Force Base on 17 AUGUST 2017 at 9:00 a.m. CDT. The address for this site visit is 398

Symington Dr, Scott AFB, IL 62225. All building sites will be shown directly after the initial briefing. All prospective offerors are highly encouraged to attend this conference.

FA440717R0007

NOTE: these sites are not co-located; the site visit is expected to last at least four hours. The contractor must provide reliable transportation to/from each site. Parking is available, but may be limited contingent on the number of attendees.

Submit names of all conference attendees to SSgt Sylvester Nzekwe at sylvester.nzekwe@us.af.mil no later than 2:00 p.m. CDT on 15 AUGUST 2017. This information must be provided in advance in order to access the military base/conference site. On the day of the conference, it is highly recommended that you allow a minimum of 60 minutes to obtain your base passes and complete access to the base.

Base Access: Scott AFB is not an open base and you must have a current and valid government issued ID to obtain access. Anyone who does not have the necessary identification to enter the base must make arrangements with 375 Contracting Squadron office to be vouched onto the installation. It is your responsibility to confirm that someone will be available to vouch you onto the base. For further information contact SSgt Sylvester Nzekwe at sylvester.nzekwe@us.af.mil. For access to Scott AFB, please provide the first and last name of each person attending the site visit. All names must match your

Government issued ID exactly. If a vehicle will also require base access, please provide the vehicle make, model, plate state, and plate number. Send this information to SSgt Sylvester Nzekwe at sylvester.nzekwe@us.af.mil, no later than 15 AUGUST 2017 @ 2:00 P.M. CDT.

All contractors who do not have base access privileges must process through the Visitor’s Center at the

Scott AFB Shiloh Gate, located at 10 Siebert Road, Scott AFB, IL.

SECTION F - DELIVERIES OR PERFORMANCE

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the

Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 10 February 2018. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 10

October 2017. The completion date will be extended by the number of calendar days after the above date that the

Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

(End of Summary of Changes) mailto:sylvester.nzekwe@us.af.mil mailto:sylvester.nzekwe@us.af.mil