EXHIBIT A - Global Lease Template L100 (Oct. 2024)_HIGHLIGHTED.pdf

In Witness Whereof, the parties to this Lease evidence their agreement to all terms and conditions set forth herein by their signatures below, to be effective as of the date of delivery of the fully executed Lease to the Lessor.

[TYPE IN NAME OF LESSOR SIGNATORY AND TITLE, ENTITY NAME AND LEASE CONTRACTING OFFICER (LCO) NAME]

FOR THE LESSOR:

Name: ____________________________________________

Title: ____________________________________________

Entity: ____________________________________________

Date: ____________________________________________

FOR THE GOVERNMENT:

Title: Lease Contracting Officer

General Services Administration, Public Buildings Service

WITNESSED FOR THE LESSOR BY:

Title: ____________________________________________

The information collection requirements contained in this Solicitation/Contract, that are not required by regulation, have been approved by the Office of Management and Budget pursuant to the Paperwork Reduction Act and assigned the OMB Control No. 3090-0086.

LEASE NO. GS-XXP-LXXXXXXX, PAGE 1 GSA TEMPLATE L100

REV (10/24)

Copy and Paste the below link into your Chrome browser for instructions on enabling macros.

https://docs.google.com/document/d/13c5ixtcRB1dWVZ0qwtwf8esGnd-DAM20feilDNyWPFg/edit?pli=1#identifier

This document contains macros designed to assist in RLP/Lease preparation by answering a few basic questions. The macros will delete paragraphs and sub-paragraphs which are inapplicable, based on the answers you provide. LCOs may choose to skip the macros and instead modify the document manually; however when using the macro we recommended answering all questions. Note that once the macro is used, the process cannot be undone. Also, note that the questions are NOT exhaustive;

LCOs must still manually choose among the remaining paragraphs and sub-paragraphs and fill in blanks as appropriate.

Global Express Editor

LEASE NO. GS-XXP-LXXXXXXX

BUILDING NO. XXXXXX

Global Lease

GSA TEMPLATE L100 (10/2024)

INSTRUCTIONS TO LEASING SPECIALIST: DELETE RED TEXT BELOW (INSTRUCTIONS TO OFFERORS) PRIOR TO FINALIZING LEASE DOCUMENT. ADDITIONAL RED Xs OR BLANKS THROUGHOUT THE DOCUMENT INDICATE REQUIRED INFORMATION TO BE INPUT BY THE

LEASING SPECIALIST – CHANGE RED TEXT TO BLACK TEXT AFTER INPUT IS COMPLETE.

INSTRUCTIONS TO OFFEROR: Do not attempt to complete this lease (GSA Lease Template L100, hereinafter Lease Template). Upon selection for award, GSA will transcribe the successful Offeror's final offered rent and other price data included on Offeror’s submitted GSA Lease Proposal Form 1364, (hereinafter Lease Proposal Form) into a Lease Template, and transmit the completed Lease Template, together with appropriate attachments, to the successful Offeror for execution.

A. This Lease is made and entered into between

Lessor’s Name [INSERT LESSOR'S FULL LEGAL NAME EXACTLY AS PROVIDED BY LESSOR AND REGISTERED IN THE SYSTEM FOR AWARD

MANAGEMENT (SAM).]

THE TEMPLATE ASSUMES THE LESSOR OWNS THE PROPERTY. HOWEVER, IF THERE ARE ANY UNUSUAL SITE-CONTROL ISSUES, SUCH AS SUBLEASES, GROUND LEASES, ETC., PLEASE CONSULT WITH REAL ESTATE ACQUISITION DIVISION SUBJECT MATTER EXPERTS AND REGIONAL COUNSEL, AS NEEDED. IN THE RARE INSTANCE OF A LEASE AWARD CONTINGENT UPON THE LESSOR’S SUBSEQUENT PURCHASE OF THE PROPERTY, YOU MUST SEEK REGIONAL COUNSEL’S ADVICE ON DRAFTING ADDITIONAL “CONTINGENCY” LANGUAGE

THAT PROTECTS THE GOVERNMENT’S INTERESTS.

(Lessor), whose principal place of business is [ADDRESS], [INSERT LESSOR'S ADDRESS] and whose interest in the Property described herein is that of Fee Owner, and

The United States of America

(Government), acting by and through the designated representative of the General Services Administration (GSA), upon the terms and conditions set forth herein.

LEASE NO. GS-XXP-LXXXXXXX, PAGE 2 LESSOR: ________ GOVERNMENT: ________ GSA TEMPLATE L100

B. Witnesseth: The parties hereto, for the consideration hereinafter mentioned, covenant and agree as follows:

Lessor hereby leases to the Government the Premises described herein, being all or a portion of the Property located at

[Address] and more fully described in Section 1 and Exhibit XX, together with rights to the use of parking and other areas as set forth herein, to be used for such purposes as determined by GSA.

C. LEASE TERM

ACTION REQUIRED: THERE ARE 2 VERSIONS OF THIS INTRODUCTORY PHRASE. THIS FIRST OPTION IS THE DEFAULT LANGUAGE FOR ALL OTHER THAN SUCCEEDING LEASES. LEASING SPECIALIST TO INPUT THE REQUIRED LEASE TERM

VERSION 1:

To Have and To Hold the said Premises with its appurtenances for the term beginning upon acceptance of the Premises as required by this Lease and continuing for a period of

VERSION 2:

ACTION REQUIRED: INCLUDE THIS INTRODUCTORY PHRASE FOR SUCCEEDING LEASE. LEASING SPECIALIST TO INPUT THE ESTIMATED LEASE TERM COMMENCEMENT DATE (THE NEXT DAY AFTER THE CURRENT LEASE EXPIRES).

NOTE: LANGUAGE ALSO ALLOWS FOR LATER ACCEPTANCE, IN INSTANCES WHERE WORK MUST BE COMPLETED PRIOR TO

ACCEPTANCE.

ACTION REQUIRED: LEASING SPECIALIST TO INPUT THE REQUIRED LEASE TERM.

To Have and To Hold the said Premises with its appurtenances for the term beginning either upon MONTH DAY, YEAR or upon acceptance of the Premises as required by this Lease, whichever is later, and continuing for a period of

X Years, X Years Firm, subject to termination and renewal rights as may be hereinafter set forth. The commencement date of this Lease, along with any applicable termination and renewal rights, shall be more specifically set forth in a Lease Amendment upon substantial completion and acceptance of the Space by the Government.

LEASE NO. GS-XXP-LXXXXXXX, PAGE 3 LESSOR: ________ GOVERNMENT: ________ GSA TEMPLATE L100

SECTION 1 THE PREMISES, RENT, AND OTHER TERMS

1.01 THE PREMISES (OCT 2024)

1.02 EXPRESS APPURTENANT RIGHTS (SEP 2013)

1.03 RENT AND OTHER CONSIDERATION (OCT 2023)

1.04 BROKER COMMISSION AND COMMISSION CREDIT (OCT 2016)

1.05 TERMINATION RIGHTS (OCT 2016)

1.06 RENEWAL RIGHTS (OCT 2016)

1.07 DOCUMENTS INCORPORATED IN THE LEASE (OCT 2023)

1.08 TENANT IMPROVEMENT RENTAL ADJUSTMENT (OCT 2016)

1.09 TENANT IMPROVEMENT AND BSAC FEE SCHEDULE (OCT 2024)

1.10 BUILDING SPECIFIC AMORTIZED CAPITAL (SEP 2012)

1.11 BUILDING SPECIFIC AMORTIZED CAPITAL RENTAL ADJUSTMENT (SEP 2013)

1.12 PERCENTAGE OF OCCUPANCY FOR TAX ADJUSTMENT (OCT 2024)

1.13 REAL ESTATE TAX BASE (SEP 2013)

1.14 OPERATING COST BASE (OCT 2016)

1.15 RATE FOR ADJUSTMENT FOR VACANT LEASED PREMISES (SEP 2013)

1.16 HOURLY OVERTIME HVAC RATES (OCT 2016)

1.17 PERIODIC LEASE ABOVE-STANDARD SERVICES (LASS) RATES – OTHER THAN HVAC (OCT 2024)

1.18 ADJUSTMENT FOR REDUCED SERVICES (OCT 2018)

1.19 BUILDING IMPROVEMENTS (OCT 2023)

1.20 LESSOR’S UNIQUE ENTITY IDENTIFIER (OCT 2022)

SECTION 2 GENERAL TERMS, CONDITIONS, AND STANDARDS

2.01 DEFINITIONS AND GENERAL TERMS (OCT 2023)

2.02 AUTHORIZED REPRESENTATIVES (OCT 2016)

2.03 ALTERATIONS REQUESTED BY THE GOVERNMENT (OCT 2022)

2.04 WAIVER OF RESTORATION (OCT 2023)

2.05 PAYMENT OF BROKER (OCT 2021)

2.06 CHANGE OF OWNERSHIP/NOVATION (OCT 2024)

2.07 REAL ESTATE TAX ADJUSTMENT (OCT 2023)

2.08 GSAR 552.270-16 ADJUSTMENT FOR VACANT PREMISES (DEVIATION) (SEP 2022)

2.09 OPERATING COSTS ADJUSTMENT (JUN 2012)

2.10 ADDITIONAL POST-AWARD FINANCIAL AND TECHNICAL DELIVERABLES (OCT 2023)

2.11 RELOCATION ASSISTANCE ACT (APR 2011)

2.12 ENTITY NAME (OCT 2023)

SECTION 3 CONSTRUCTION STANDARDS AND SHELL COMPONENTS

3.01 LABOR STANDARDS (OCT 2024)

3.02 WORK PERFORMANCE (JUN 2012)

3.03 EXISTING FIT-OUT, SALVAGED, OR REUSED BUILDING MATERIAL (OCT 2024)

3.04 CONSTRUCTION WASTE MANAGEMENT (OCT 2021)

3.05 WOOD PRODUCTS (OCT 2023)

3.06 ADHESIVES AND SEALANTS (OCT 2022)

3.07 BUILDING SHELL REQUIREMENTS (OCT 2016)

3.08 RESPONSIBILITY OF THE LESSOR AND LESSOR’S ARCHITECT/ENGINEER (OCT 2022)

3.09 QUALITY AND APPEARANCE OF BUILDING (JUN 2012)

3.10 VESTIBULES (OCT 2020)

3.11 MEANS OF EGRESS (MAY 2015)

3.12 AUTOMATIC FIRE SPRINKLER SYSTEM (OCT 2023)

3.13 FIRE ALARM SYSTEM (SEP 2013)

3.14 ENERGY INDEPENDENCE AND SECURITY ACT (OCT 2024)

3.15 ELEVATORS (OCT 2020)

3.16 BUILDING DIRECTORY (OCT 2021)

3.17 FLAGPOLE (SEP 2013)

3.18 DEMOLITION (JUN 2012)

3.19 ACCESSIBILITY (OCT 2024)

3.20 CEILINGS (OCT 2022)

3.21 EXTERIOR AND COMMON AREA DOORS AND HARDWARE (SEP 2013)

3.22 DOORS: IDENTIFICATION (APR 2011)

3.23 WINDOWS (OCT 2020)

3.24 PARTITIONS: GENERAL (OCT 2023)

3.25 PARTITIONS: PERMANENT (OCT 2023)

3.26 INSULATION: THERMAL, ACOUSTIC, AND HVAC (OCT 2022)

3.27 WALL FINISHES – SHELL (SEP 2015)

3.28 PAINTING – SHELL (OCT 2022)

3.29 FLOORS AND FLOOR LOAD (OCT 2019)

3.30 FLOOR COVERING AND PERIMETERS – SHELL (OCT 2022)

3.31 MECHANICAL, ELECTRICAL, PLUMBING: GENERAL (APR 2011)

3.32 BUILDING SYSTEMS (APR 2011)

LEASE NO. GS-XXP-LXXXXXXX, PAGE 4 LESSOR: ________ GOVERNMENT: ________ GSA TEMPLATE L100

3.33 ELECTRICAL (OCT 2023)

3.34 ADDITIONAL ELECTRICAL CONTROLS (JUN 2012)

3.35 PLUMBING (JUN 2012)

3.36 DRINKING FOUNTAINS (OCT 2023)

3.37 RESTROOMS (OCT 2022)

3.38 PLUMBING FIXTURES: WATER CONSERVATION (OCT 2022)

3.39 JANITOR CLOSETS (SEP 2015)

3.40 HEATING, VENTILATION, AND AIR CONDITIONING - SHELL (OCT 2023)

3.41 TELECOMMUNICATIONS: DISTRIBUTION AND EQUIPMENT (OCT 2023)

3.42 TELECOMMUNICATIONS: LOCAL EXCHANGE ACCESS (JUN 2012)

3.43 LIGHTING: INTERIOR AND PARKING - SHELL (OCT 2023)

3.44 ACOUSTICAL REQUIREMENTS (OCT 2022)

3.45 SECURITY FOR NEW CONSTRUCTION (OCT 2022)

3.46 SEISMIC SAFETY FOR NEW CONSTRUCTION (OCT 2020)

3.47 FIRE PROTECTION FOR NEW CONSTRUCTION (APR 2015)

3.48 GREEN BUILDING RATING CERTIFICATION FOR NEW CONSTRUCTION (OCT 2016)

3.49 GREEN BUILDING RATING CERTIFICATION FOR TENANT INTERIORS (OCT 2023)

3.50 INDOOR AIR QUALITY DURING CONSTRUCTION (OCT 2021)

3.51 SYSTEMS COMMISSIONING (OCT 2023)

3.52 DUE DILIGENCE AND NATIONAL ENVIRONMENTAL POLICY ACT REQUIREMENTS – LEASE (OCT 2023)

3.53 NATIONAL HISTORIC PRESERVATION ACT REQUIREMENTS - LEASE (SEP 2014)

SECTION 4 DESIGN, CONSTRUCTION, AND POST AWARD ACTIVITIES

4.01 SCHEDULE FOR COMPLETION OF SPACE (OCT 2024)

4.02 CONSTRUCTION DOCUMENTS (OCT 2023)

4.03 TENANT IMPROVEMENTS PRICE PROPOSAL (OCT 2023)

4.04 BUILDING SPECIFIC AMORTIZED CAPITAL (BSAC) PRICE PROPOSAL (OCT 2023)

4.05 GREEN LEASE SUBMITTALS (OCT 2023)

4.06 CONSTRUCTION SCHEDULE AND INITIAL CONSTRUCTION MEETING (OCT 2024)

4.07 PROGRESS REPORTS (OCT 2023)

4.08 CONSTRUCTION INSPECTIONS (OCT 2023)

4.09 ACCESS BY THE GOVERNMENT PRIOR TO ACCEPTANCE (OCT 2022)

4.10 ACCEPTANCE OF SPACE AND CERTIFICATE OF OCCUPANCY (OCT 2021)

4.11 LEASE TERM COMMENCEMENT DATE AND RENT RECONCILIATION (OCT 2021)

4.12 AS-BUILT DRAWINGS (OCT 2021)

4.13 GSAR 552.270-15 LIQUIDATED DAMAGES (DEVIATION) (SEP 2022)

4.14 SEISMIC RETROFIT (OCT 2020)

4.15 LESSOR’S PROJECT MANAGEMENT RESPONSIBILITIES (OCT 2023)

4.16 GOVERNMENT PROJECT MANAGEMENT SYSTEM (OCT 2023)

SECTION 5 TENANT IMPROVEMENT COMPONENTS

5.01 TENANT IMPROVEMENT REQUIREMENTS (OCT 2016)

5.02 TENANT IMPROVEMENT SPECIFICATIONS (SEP 2015)

5.03 FINISH SELECTIONS (SEP 2015)

5.04 WINDOW COVERINGS (OCT 2023)

5.05 DOORS: SUITE ENTRY (OCT 2022)

5.06 DOORS: INTERIOR (OCT 2022)

5.07 DOORS: HARDWARE (SEP 2013)

5.08 DOORS: IDENTIFICATION (JUN 2012)

5.09 PARTITIONS: SUBDIVIDING (OCT 2023)

5.10 WALL FINISHES (OCT 2019)

5.11 PAINTING – TI (OCT 2022)

5.12 FLOOR COVERINGS AND PERIMETERS (OCT 2023)

5.13 HEATING AND AIR CONDITIONING (JUN 2012)

5.14 ELECTRICAL: DISTRIBUTION (SEP 2015)

5.15 TELECOMMUNICATIONS: DISTRIBUTION AND EQUIPMENT (JUN 2012)

5.16 TELECOMMUNICATIONS: LOCAL EXCHANGE ACCESS (AUG 2008)

5.17 DATA DISTRIBUTION (OCT 2020)

5.18 ELECTRICAL, TELEPHONE, DATA FOR SYSTEMS FURNITURE (OCT 2022)

5.19 LIGHTING: INTERIOR AND PARKING – TI (SEP 2015)

5.20 AUTOMATIC FIRE SPRINKLER SYSTEM - TI (OCT 2016)

SECTION 6 UTILITIES, SERVICES, AND OBLIGATIONS DURING THE LEASE TERM

6.01 PROVISION OF SERVICES, ACCESS, AND NORMAL HOURS (OCT 2022)

6.02 UTILITIES (OCT 2024)

6.03 UTILITIES SEPARATE FROM RENTAL/BUILDING OPERATING PLAN (OCT 2020)

6.04 GSAR 552.270-99 LESSOR REPORTING OF GREEN BUILDING EFFICIENCY (SEP 2023)

6.05 HEATING AND AIR CONDITIONING (OCT 2024)

6.06 OVERTIME HVAC USAGE (OCT 2023)

LEASE NO. GS-XXP-LXXXXXXX, PAGE 5 LESSOR: ________ GOVERNMENT: ________ GSA TEMPLATE L100

6.07 PERIODIC LEASE ABOVE-STANDARD SERVICES (LASS) – OTHER THAN HVAC (OCT 2024)

6.08 JANITORIAL SERVICES (OCT 2021)

6.09 SELECTION OF CLEANING PRODUCTS (OCT 2022)

6.10 SELECTION OF PAPER PRODUCTS (OCT 2022)

6.11 SNOW REMOVAL (OCT 2020)

6.12 MAINTENANCE AND TESTING OF SYSTEMS (OCT 2022)

6.13 MAINTENANCE OF PROVIDED FINISHES (OCT 2016)

6.14 ASBESTOS ABATEMENT (OCT 2021)

6.15 ONSITE LESSOR MANAGEMENT (APR 2011)

6.16 IDENTITY VERIFICATION OF PERSONNEL (OCT 2022)

6.17 SCHEDULE OF PERIODIC SERVICES (OCT 2020)

6.18 LANDSCAPING (OCT 2022)

6.19 LANDSCAPE MAINTENANCE (APR 2011)

6.20 RECYCLING AND COMPOSTING (OCT 2023)

6.21 RANDOLPH-SHEPPARD COMPLIANCE (SEP 2013)

6.22 SAFEGUARDING AND DISSEMINATION OF CONTROLLED UNCLASSIFIED INFORMATION (CUI) BUILDING INFORMATION (OCT 2022)

6.23 INDOOR AIR QUALITY (OCT 2024)

6.24 RADON IN AIR (OCT 2023)

6.25 RADON IN WATER (JUN 2012)

6.26 HAZARDOUS MATERIALS (OCT 2023)

6.27 MOLD AND WATER INTRUSION (OCT 2023)

6.28 OCCUPANT EMERGENCY PLANS (OCT 2020)

6.29 FLAG DISPLAY (OCT 2016)

SECTION 7 ADDITIONAL TERMS AND CONDITIONS

7.01 SECURITY REQUIREMENTS (OCT 2021)

7.02 MODIFIED LEASE PARAGRAPHS (OCT 2016)

7.03 NO FEDERALLY ELECTED OFFICIALS TO BENEFIT (OCT 2023)

7.04 DAILY OCCUPANCY DATA (OCT 2021)

7.05 SWING SPACE – LEASE (OCT 2022)

LEASE NO. GS-XXP-LXXXXXXX, PAGE 6 LESSOR: ________ GOVERNMENT: ________ GSA TEMPLATE L100

INSTRUCTIONS FOR CREATING LEASE AND REQUEST FOR LEASE PROPOSALS (RLP) DOCUMENTS

• ALL INSTRUCTIONS FOR CREATING THESE DOCUMENTS ARE TYPED IN BLUE HIDDEN TEXT. YOU SHOULD CREATE THE

DOCUMENTS WITH THE HIDDEN TEXT SHOWING, AND THEN [TURN IT OFF] WHEN PRINTING THE FINISHED DOCUMENT.

THIS TEMPLATE WAS UPDATED AS OF THE DATE SHOWN IN THE HEADER. THE DATE WILL NOT PRINT IF YOU TURN OFF THE HIDDEN

TEXT PER THE INSTRUCTIONS BELOW. THE MOST UP-TO-DATE LEASE REFORM TEMPLATES ARE LOCATED ON THE OFFICE OF LEASING

GOOGLE SITE OR G-REX.

TO REVEAL HIDDEN TEXT IN THE DOCUMENT—

1. CLICK ON THE FILE TAB AT THE TOP LEFT OF THE COMPUTER SCREEN.

2. CLICK ON “OPTIONS” AT THE LEFT OF THE SCREEN, NEAR THE BOTTOM.

3. CLICK ON “DISPLAY” IN THE LEFT-HAND COLUMN OF THE SCREEN, NEAR THE BOTTOM.

4. IN THE RIGHT-HAND COLUMN, UNDER “ALWAYS SHOW THESE FORMATTING MARKS ON THE SCREEN,”—IF THERE IS NO

CHECKMARK IN THE “HIDDEN TEXT” BOX—CLICK ON THE “HIDDEN TEXT” BOX. NOTE: A CHECKMARK WILL APPEAR IN THE

BOX.

5. CLICK ON “OK.” TO CLOSE OUT THE WORD OPTIONS SCREEN.

TO TURN OFF HIDDEN TEXT: FOLLOW INSTRUCTIONS (1) THRU (5), ABOVE. WHEN YOU CLICK ON THE “HIDDEN TEXT” BOX, THE

CHECKMARK WILL DISAPPEAR AND THE HIDDEN TEXT WILL NOT SHOW ON SCREEN OR IN PRINTED VERSIONS OF THE LEASE.

TO INPUT DATA: IF A PARAGRAPH HAS BOLD RED Xs, A DOLLAR SIGN ($) FOLLOWED BY UNDERSCORING, OR EMPTY UNDERSCORING

(_______), INPUT THE REQUIRED INFORMATION.

TO DELETE AND MODIFY PARAGRAPHS—*

ALL PARAGRAPHS ARE STANDARDIZED AND MANDATORY UNLESS OTHERWISE NOTED IN THE HEADING “ACTION REQUIRED,”

“OPTIONAL,” OR “NOTE.” MANDATORY PARAGRAPHS MAY ONLY BE ALTERED AT THE DISCRETION OF THE LCO ONLY AFTER

CONSULTATION WITH REGIONAL COUNSEL AND THE APPROPRIATE SUBJECT MATTER EXPERT, E.G., REGIONAL FIRE PROTECTION

ENGINEER, REGIONAL NATIONAL ENVIRONMENTAL POLICY ACT (NEPA) PROGRAM MANAGER OR THE REGIONAL NEPA SPECIALIST, REGIONAL HISTORIC PRESERVATION OFFICER, BUT THE MANDATORY PARAGRAPHS MUST CONTAIN SUBSTANTIALLY THE SAME

INFORMATION. IF IT IS DETERMINED TO DELETE A PARAGRAPH OR SUB-PARAGRAPH, TAKE THE FOLLOWING STEPS:

TO DELETE A PARAGRAPH (FOR EXAMPLE, 1.02)—

1. USING YOUR CURSOR, CAREFULLY SELECT THE PARAGRAPH TEXT. (NOTE: DO NOT SELECT THE PARAGRAPH NUMBER.)

2. CLICK ON THE DELETE KEY TO DELETE THE TEXT

3. YOU HAVE A CHOICE REGARDING THE TITLE. YOU MAY EITHER STRIKE THROUGH THE TITLE AND ADD THE WORDS

“INTENTIONALLY DELETED” AFTER THE STRICKEN TITLE, OR YOU MAY DELETE THE TITLE AND REPLACE IT WITH

“INTENTIONALLY DELETED.” IN EITHER CASE, LEAVE THE PARAGRAPH NUMBER INTACT SO THE PARAGRAPH NUMBERING WILL

REMAIN THE SAME FOR THE PARAGRAPHS THAT FOLLOW.

4. TO STRIKE THROUGH THE TITLE, USING YOUR CURSOR, CAREFULLY SELECT THE PARAGRAPH TITLE. (NOTE: DO NOT SELECT

THE PARAGRAPH NUMBER.) CLICK ON THE “STRIKETHROUGH” KEY (abc). THEN PLACE THE CURSOR TO THE RIGHT OF THE

STRUCK-OUT PARAGRAPH TITLE AND TYPE “INTENTIONALLY DELETED.” NOTE: THE TEXT WILL BE DELETED AND THE

PARAGRAPH NUMBER AND STRUCK-OUT TITLE WILL REMAIN.

EXAMPLE: 2.05 OPERATING COST ADJUSTMENT INTENTIONALLY DELETED

5. ALTERNATELY, YOU MAY DELETE THE TITLE ALTOGETHER. USING YOUR CURSOR, CAREFULLY SELECT THE PARAGRAPH

TITLE. OVERTYPE WITH THE WORDS “INTENTIONALLY DELETED.”

EXAMPLE: 2.05 INTENTIONALLY DELETED

TO DELETE A SUB-PARAGRAPH—

LEASE NO. GS-XXP-LXXXXXXX, PAGE 7 LESSOR: ________ GOVERNMENT: ________ GSA TEMPLATE L100

1. USING YOUR CURSOR, CAREFULLY SELECT THE SUB-PARAGRAPH TEXT. (NOTE: DO NOT SELECT THE SUB-PARAGRAPH

NUMBER, LETTER, OR TITLE, IF ANY.) DELETE THE TEXT BY CLICKING ON THE “DELETE” KEY.

2. CHANGE LETTERING OR NUMBERING AS NECESSARY.

TO MODIFY ALL OR PART OF A PARAGRAPH

1. GO TO THE LAST SECTION OF THIS LEASE TITLED "ADDITIONAL TERMS AND CONDITIONS."

2. CREATE A LIST OF “MODIFIED PARAGRAPHS” WITH THE HEADING: “THE FOLLOWING PARAGRAPHS HAVE BEEN MODIFIED IN

THIS LEASE:”

3. SELECT AND COPY THE MODIFIED PARAGRAPH TITLE AND PARAGRAPH NUMBER).

4. GO TO THE END OF THE LAST PARAGRAPH AND CLICK ON YOUR MOUSE TO PLACE THE CURSOR BELOW THE LAST ENTRY).

5. PASTE THE TITLE YOU JUST COPIED.

6. MAKE YOUR CHANGES, ADDITIONS, DELETIONS, ETC., TO THE PARAGRAPH IN ITS ORIGINAL LOCATION IN THE DOCUMENT.

7. SAVE YOUR CHANGES.

TO UPDATE THE “TABLE OF CONTENTS” AND “PAGE REFERENCES” WHEN YOU ARE FINISHED REVISING A DOCUMENT:

1. GO TO AND CLICK IN THE TABLE OF CONTENTS.

2. RIGHT CLICK TO VIEW DROP-DOWN WINDOW.

3. FROM THE DROP-DOWN MENU, CLICK ON “UPDATE FIELD.”

4. CLICK ON “UPDATE ENTIRE TABLE.” NOTE: TABLE WILL UPDATE ANY HEADINGS THAT WERE CHANGED DURING THE REVIEW.

NOTE: YOU SHOULD VERIFY ONE OR TWO CHANGES TO CONFIRM THE TOC WAS UPDATED PROPERLY.

*THE ABOVE PRACTICES WILL INCREASE STANDARDIZATION AND FAMILIARITY OF THE DOCUMENT FOR THE PRACTITIONER BY

ALLOWING CONSISTENT NUMBERING THROUGHOUT THE DOCUMENT.

TO ADD SECURITY REQUIREMENTS

ATTACH THE APPROPRIATE DOCUMENT TITLED “SECURITY REQUIREMENTS” AFTER CONSULTING WITH FPS AND THE AGENCY TO DETERMINE THEIR SPECIFIC REQUIREMENTS USING THE APPROPRIATE FACILITY SECURITY LEVEL (FSL) I, II, III, OR IV. FOR ACTIONS 10,000 RSF OR LESS, DO NOT CONTACT FPS BUT INSTEAD USE FSL I UNLESS CLIENT AGENCY REQUESTS A HIGHER LEVEL. IF THE AGENCY REQUIRES A HIGHER FSL, THE RESPONSIBLE PBS ASSOCIATE SHOULD REACH OUT TO FPS TO CONFIRM THAT THIS HIGHER

FSL IS APPROPRIATE.

NOTE: FOR SUCCEEDING OR SUPERSEDING LEASES AT THE CURRENT LOCATION, THE ISC REQUIREMENTS ARE NOT REQUIRED, BUT ARE RECOMMENDED. THE LEASING SPECIALIST MUST CONSULT WITH THE TENANT AGENCY TO DETERMINE THE APPROPRIATE

SECURITY COUNTERMEASURES, IF ANY.

LEASE NO. GS-XXP-LXXXXXXX, PAGE 8 LESSOR: ________ GOVERNMENT: ________ GSA TEMPLATE L100

THE GLOBAL RLP AND LEASE TEMPLATES (GSA TEMPLATE R100 AND L100) REPLACE THE FOLLOWING LEASE MODEL DOCUMENTS:

• GSA TEMPLATES R101B AND L201B (STREAMLINED MODEL)

• GSA TEMPLATES R101C AND L201C (STANDARD MODEL)

• GSA TEMPLATES R102 AND L202 (SUCCEEDING/SUPERSEDING MODEL)

THE GLOBAL LEASE TEMPLATE (L100) COMBINES LANGUAGE FROM THESE 3 MODELS INTO ONE DOCUMENT.

UNLIKE FORMER MODEL TEMPLATES, THIS GLOBAL TEMPLATE ALLOWS THE LS/LCO GREATER FLEXIBILITY TO CHOOSE AMONG PARAGRAPHS AND SUBPARAGRAPHS TO MEET THE REQUIREMENTS OF EACH INDIVIDUAL LEASE ACQUISITION.

FOLLOWING THE BLUE “HIDDEN” TEXT, THE LS/LCO SHALL SELECT THE APPROPRIATE PARAGRAPH AND/OR SUBPARAGRAPH TO

ALLOW FOR SUCH DIFFERENCES AS:

• TI PRICING: EITHER TURNKEY OR ALLOWANCE BASED

• METHOD OF AWARD: COMMUNICATING INTENT TO SEEK EITHER SOLE SOURCE OR COMPETITIVE PROCUREMENT*

• TYPE OF DID DELIVERY SYSTEM (GOVERNMENT –PROVIDED, LESSOR PROVIDED, WORKSHOP, PRE-AWARD)

• LEVEL OF BUILD-OUT REQUIRED

*NOTE: PER LEASING DESK GUIDE (LDG) CHAPTER 5, THERE MAY BE INSTANCES WHERE DISCLOSURE OF THE GOVERNMENT’S INTENT TO SECURE A SOLE SOURCE LEASE WOULD IMPOSE UNDUE FINANCIAL RISK ON THE GOVERNMENT. IN THESE INSTANCES, THE LS/LCO

SHOULD SELECT PARAGRAPHS THAT IMPLY COMPETITION.

ALL PARAGRAPHS ARE STANDARDIZED FOR THIS MODEL AND MANDATORY UNLESS OTHERWISE NOTED IN THE HEADING.

MANDATORY PARAGRAPHS MAY BE ALTERED AT THE DISCRETION OF THE LCO ONLY AFTER CONSULTATION WITH REGIONAL COUNSEL AND THE APPROPRIATE SUBJECT MATTER EXPERT, E.G., REGIONAL FIRE PROTECTION ENGINEER, REGIONAL NATIONAL ENVIRONMENTAL POLICY ACT (NEPA) PROGRAM MANAGER OR THE REGIONAL NEPA SPECIALIST, REGIONAL HISTORIC PRESERVATION OFFICER, BUT THE MANDATORY PARAGRAPHS MUST CONTAIN SUBSTANTIALLY THE SAME INFORMATION.

FOR THIS SECTION, DO NOT FILL IN ANY XX’S OR BLANKS PRIOR TO AWARD, EXCEPT AS FOLLOWS:

• FILL IN BROKER NAME UNDER PARAGRAPH 1.04, IF APPLICABLE

• FILL IN TERMINATION NOTICE UNDER PARAGRAPH 1.05

• ADJUST THE LIST OF ATTACHED DOCUMENTS UNDER PARAGRAPH 1.07

PRIOR TO AWARD, FILL IN REMAINING XX’S/BLANKS BASED ON SUCCESSFUL OFFEROR’S PROPOSAL

NOTE: DRAFT RLPS MUST BE REVIEWED PRIOR TO ISSUANCE, AS FOLLOWS:

BY OL ZONE MANAGER:

• PROSPECTUS-LEVEL

BY REGIONAL COUNSEL:

• PROSPECTUS-LEVEL

• BEST VALUE TRADE-OFF ABOVE SLAT

• AGGREGATE VALUE OF $20M OR MORE

PRE-AWARD REVIEW OF PROPOSED CONTRACT AWARDS IS REQUIRED AS FOLLOWS:

BY OL ZONE MANAGER (ABSTRACT ONLY):

• PROSPECTUS-LEVEL

BY REGIONAL COUNSEL:

• PROSPECTUS-LEVEL

• BEST VALUE TRADE-OFF ABOVE SLAT

• AGGREGATE VALUE OF $20M OR MORE

LEASE NO. GS-XXP-LXXXXXXX, PAGE 9 LESSOR: ________ GOVERNMENT: ________ GSA TEMPLATE L100

SECTION 1 THE PREMISES, RENT, AND OTHER TERMS

1.01 THE PREMISES (OCT 2024)

The Premises are described as follows:

ACTION REQUIRED:

KEEP BOTH VERSIONS OF SUB-PARAGRAPH A WHEN ISSUING THE RLP;

ACTION REQUIRED: SELECT THE APPROPRIATE SUB-PARAGRAPH A WHEN DRAFTING FINAL LEASE. DELETE THE ALTERNATE VERSION.

ACTION REQUIRED: INSERT AMOUNT OF SPACE STATED IN FINAL PROPOSAL REVISIONS, NOT THE RANGE REQUESTED IN THE RLP. USE WHOLE NUMBERS FOR RSF AND ABOA SF; ROUND CAF TO NEAREST PERCENTAGE (E.G., 12 PERCENT).

EXHIBIT XX REFERS TO THE FLOOR PLANS PROVIDED BY THE SUCCESSFUL OFFEROR AND MUST DELINEATE THE SPACE UNDER LEASE.

FOR NEWLY CONSTRUCTED SPACE, SITE PLANS SHOULD ALSO BE ATTACHED.

A. VERSION 1: USE WHEN ACCEPTING AN OFFER THAT DOES NOT INCLUDE FREE SPACE. Office and Related Space. XX rentable square feet (RSF), yielding XX ANSI/BOMA Occupant Area (ABOA) square feet (SF) of office and related Space located on the XX floor(s) and known as Suite(s) XX, of the Building, as depicted on the floor plan(s) attached hereto as Exhibit XX.

A. VERSION 2: USE WHEN ACCEPTING AN OFFER THAT INCLUDES FREE SPACE (NOTE THAT THIS IS NOT THE SAME AS FREE RENT)

Office and Related Space. XX rentable square feet (RSF), yielding XX ANSI/BOMA Occupant Area (ABOA) square feet (SF) of office and related Space and an additional XX RSF, yielding XX ABOA SF of free space (for which the Government will not be charged rent, including real estate taxes and operating cost escalations) in excess of the total XX RSF/XX ABOA SF indicated above, for a total of XX RSF (yielding XX ABOA SF), located on the XX floor(s) and known as Suite(s) XX, of the Building, as depicted on the floor plan(s) attached hereto as Exhibit XX. All rights, responsibilities, and obligations that bind the Lessor and Government under this lease agreement, including the General Clauses, and any other attachments hereto, shall pertain to the entire space under lease, including the free space.

ACTION REQUIRED: CALCULATE THE COMMON AREA FACTOR (CAF) AS A PERCENTAGE (%) OF THE DIFFERENCE BETWEEN THE AMOUNT OF RENTABLE SF AND ABOA SF, DIVIDED BY THE ABOA SF. FOR EXAMPLE, 11,500 RSF AND 10,000 ABOA SF WILL HAVE A CAF OF 15% [(11,500 RSF-10,000 ABOA SF)/10,000 ABOA SF]. DO NOT INSERT THIS AS AN R/U FACTOR [E.G., 1.15]. SEE DEFINITIONS UNDER

SECTION 2.

B. Common Area Factor. The Common Area Factor (CAF), defined under Section 2 of the Lease, is established as XX percent. This factor, rounded to the nearest whole percentage, shall be used for purposes of rental adjustments in accordance with the Payment Clause of the General Clauses.

ACTION REQUIRED: INCLUDE THIS SUB-PARAGRAPH C ONLY FOR SOLE SOURCE SUCCEEDING OR SUPERSEDING LEASES WITH MINOR

OR NO ALTERATIONS AT THE CURRENT LOCATION. OTHERWISE, DELETE.

C. Unless otherwise noted, the Government accepts the Premises and tenant improvements in their existing condition, except where specifications or standards are contained elsewhere in this Lease. These standards include, but are not limited to, security improvements, Fire Protection and Life Safety requirements, ABAAS compliance, as well as compliance with all local codes and ordinances. Such acceptance by the Government of existing Premises shall not relieve Lessor of continuing obligations for cleaning, janitorial, maintenance, repair, etc. as set forth in the Lease paragraphs and attached General Clauses.

1.02 EXPRESS APPURTENANT RIGHTS (SEP 2013)

The Government shall have the non-exclusive right to the use of Appurtenant Areas and shall have the right to post Rules and Regulations Governing Conduct on Federal Property, Title 41, CFR, Part 102-74, Subpart C within such areas. The Government will coordinate with Lessor to ensure signage is consistent with Lessor’s standards. Appurtenant to the Premises and included in the Lease are rights to use the following:

ACTION REQUIRED: INSERT TOTAL NUMBER OF PARKING SPACES AND SPECIFY WHETHER THEY ARE “STRUCTURED/INSIDE” OR “SURFACE/OUTSIDE.” IF PARKING SPACES ARE OFF-SITE, LESSOR MUST PROVIDE PROOF THAT IT OWNS THAT SITE OR HAS A LEASE

FOR IT.

NOTE: ATTACH THE SITE PLAN, PARKING PLAN, OR DRAWING SHOWING THE LOCATION OF SPACES AS A LEASE EXHIBIT. A SITE PLAN IS PREFERABLE SHOWING PEDESTRIAN AND VEHICULAR INGRESS AND EGRESS TO THE LEASED PREMISES.

A. Parking. XX parking spaces as depicted on the plan attached hereto as Exhibit XX, reserved for the exclusive use of the Government, of which

XX shall be structured/inside parking spaces, and XX shall be surface/outside parking spaces. In addition, the Lessor shall provide such additional parking spaces as required by the applicable code of the local government entity having jurisdiction over the Property.

ACTION REQUIRED: USE SUB-PARAGRAPH B IF THE AGENCY’S SPACE REQUIREMENTS INCLUDE TELECOMMUNICATIONS DEVICES SUCH

AS SATELLITE DISHES, ANTENNAS, AND RELATED TRANSMISSION DEVISES. IF NOT, DELETE.

B. Antennas, Satellite Dishes, and Related Transmission Devices. (1) Space located on the roof of the Building sufficient in size for the installation and placement of telecommunications equipment, (2) the right to access the roof of the Building, and (3) use of all Building areas (e.g., chases, plenums, etc.) necessary for the use, operation, and maintenance of such telecommunications equipment at all times during the term of this Lease.

LEASE NO. GS-XXP-LXXXXXXX, PAGE 10 LESSOR: ________ GOVERNMENT: ________ GSA TEMPLATE L100

ACTION REQUIRED: ADJUST THE RENTAL RATES IN THE TABLE TO REFLECT THE RENTAL RATES OF THE LEASE AND ADJUST THE TIA

AND BUILDING SPECIFIC AMORTIZED CAPITAL (BSAC) AMORTIZATION. ADD ADDITIONAL TABLES AS NECESSARY FOR MULTIPLE

STEP RENTS.

TABLE DEFAULTS TO TI AND BSAC RENT DROPPING AFTER FIRM TERM.

NOTE: THE INCLUSION OF THE AMORTIZED TI AND BSAC CANNOT CAUSE THE FULLY-SERVICED RENT TO EXCEED THE HIGH END OF

THE MARKET, IN WHICH INSTANCE AN RWA IS NEEDED TO FUND THE EXCESS.

NOTE FOR TI TURNKEY PRICING: CONFIRM WHETHER THE TENANT IMPROVEMENT COSTS LISTED IN THE PROPOSAL EXCEED THE

AGENCY’S AUTHORIZED TI TIER. IN ACCORDANCE WITH PRICING POLICY, TI COSTS IN EXCESS OF THE TIER CANNOT BE AMORTIZED INTO THE RENT UNLESS A DEVIATION IS GRANTED BY PORTFOLIO. IF THE TI COSTS EXCEED THE AUTHORIZED TIER, THE LEASING SPECIALIST MUST EITHER GAIN APPROVAL TO INCREASE THE TI ALLOWANCE, OR OBTAIN AN RWA FOR THE EXCESS TI COSTS. IN ADDITION, THE 1364 MUST BE REVISED TO REFLECT TO LOWER TI PRINCIPAL AND RENT RATE. INCLUDE

LUMP SUM PAYMENT LANGUAGE UNDER SECTION 7.

NOTE FOR TIA AND/OR BSAC PLACEHOLDER ESTIMATE PRICING: IF THE ACTUAL POST-AWARD TI OR BSAC PRICING IS LESS THAN THE ALLOWANCE/PLACEHOLDER ESTIMATES STATED BELOW, THEN THE FINAL TI AND/OR BSAC RENT, AS REFLECTED IN THE LEASE TERM COMMENCEMENT LEASE AMENDMENT, MUST BE ADJUSTED DOWNWARDS IN ACCORDANCE WITH THE TERMS OF THE LEASE. THE AMOUNT OF REDUCTION CANNOT BE USED TOWARDS ANY OTHER RENTAL COMPONENT (E.G., SHELL CREDIT).

ALSO, THE TI ALLOWANCE MAY NOT BE INCREASED THROUGH THE USE OF WARM-LIT SHELL CREDITS.

1.03 RENT AND OTHER CONSIDERATION (OCT 2023)

A. The Government shall pay the Lessor annual rent, payable in monthly installments in arrears, at the following rates:

FIRM TERM NON FIRM TERM

ANNUAL RENT ANNUAL RENT

SHELL RENT1 $XXX,XXX.XX $XXX,XXX.XX

OPERATING COSTS2 $ XXX,XXX.XX $ XXX,XXX.XX

TENANT IMPROVEMENTS RENT3 $ XXX,XXX.XX $0.00

BUILDING SPECIFIC AMORTIZED CAPITAL (BSAC)4 $ XXX,XXX.XX $0.00

PARKING5 $ XXX,XXX.XX $ XXX,XXX.XX

TOTAL ANNUAL RENT6 $XXX,XXX.XX $XXX,XXX.XX

1Shell rent reflects rental rates as follows:

(Firm Term) $XX per RSF, as rounded to the nearest penny.

(Non Firm Term) $XX per RSF, as rounded to the nearest penny.

2Operating Costs reflects a rate of $XX per RSF, as rounded to the nearest penny.

3Tenant Improvements of $XX are amortized at a rate of X percent per annum over XX years.

4Building Specific Amortized Capital (BSAC) of $XX are amortized at a rate of X percent per annum over XX years.

5Parking costs described under sub-paragraph B below.

6Total Annual Rent does not reflect reduction for free rent (if applicable). See subparagraph C below.

ACTION REQUIRED: IF PARKING IS CHARGED SEPARATELY, USE SUB-PARAGRAPH B, AS APPROPRIATE. OTHERWISE, DELETE. NOTE:

PARKING RATE IS TYPICALLY ON A PER MONTH BASIS.

B. Parking shall be provided at a rate of $XX per parking space per month (structured/inside), and $XX per parking space per month

(surface/outside).

ACTION REQUIRED: INSERT THIS SUB-PARAGRAPH ONLY WHEN ACCEPTING AN OFFER THAT INCLUDES FREE RENT. OTHERWISE

DELETE.

ACTION REQUIRED: DEFINE THE FREE RENT COMPONENTS (E.G., SHELL, OPERATING, TI, BSAC, PARKING RENT). ALTERNATIVELY, FREE RENT CAN BE EXPRESSED AS A DOLLAR AMOUNT. DELETE LAST SENTENCE IF FREE RENT DOES NOT INCLUDE ALL RENTAL

COMPONENTS OR IF EXPRESSED AS A DOLLAR AMOUNT.

C. The Lessor has offered free rent for the first XX (X) months of the Lease (free rent includes shell, operating, TI, BSAC and parking rent).

Therefore, the first XX (X) months of the Lease shall be provided at no cost to the Government.

ACTION REQUIRED: USE SUB-PARAGRAPH D ONLY WHEN AMORTIZING TI OR BSAC BEYOND THE FIRM TERM OF THE LEASE.

OTHERWISE, DELETE.

D. In instances where the Lessor amortizes either the TI or Building Specific Amortized Capital (BSAC) for a period exceeding the Firm Term of the

Lease, should the Government terminate the Lease after the Firm Term or does not otherwise renew or extend the term beyond the Firm Term, the Government shall not be liable for any costs, including unamortized costs beyond the Firm Term.

ACTION REQUIRED:

INPUT ABOA SF AS STATED UNDER LEASE PARAGRAPH 1.01

DELETE E FOR LEASE ACTIONS WHERE THE SPACE WILL NOT BE RE-MEASURED (FOR EXAMPLE, SUCCEEDING OR SUPERSEDING

LEASES WITH NO CHANGE IN SQUARE FOOTAGE)

E. Rent is subject to adjustment based upon a mutual on-site measurement of the Space upon acceptance, not to exceed XX ABOA SF based upon the methodology outlined under the “Payment” clause of GSA 3517, General Clauses.

LEASE NO. GS-XXP-LXXXXXXX, PAGE 11 LESSOR: ________ GOVERNMENT: ________ GSA TEMPLATE L100

ACTION REQUIRED: SELECT THE APPROPRIATE SUB-PARAGRAPH F. DELETE THE ALTERNATE VERSION.

F.

VERSION 1: USE FOR TI ALLOWANCE PRICING.

F. Rent is subject to adjustment based upon the final Tenant Improvement (TI) cost to be amortized in the rental rate, as agreed upon by the parties subsequent to the Lease Award Date.

VERSION 2: USE FOR TI TURNKEY PRICING, WHERE ALLOWING FOR ADJUSTMENT BASED UPON TI UNIT PRICES. Rent is subject to adjustment upon reconciliation from quantities in the Lease to the approved DIDs and post-DID change orders, based on unit prices negotiated and agreed upon prior to Lease award.

ACTION REQUIRED: INCLUDE SUB-PARAGRAPH G FOR FSL II, III AND IV (BSAC PRICING BASED ON PLACEHOLDER DOLLAR ESTIMATE;

ACTUAL PRICING AFTER AWARD). OTHERWISE, DELETE FOR FSL I OR TURNKEY BSAC PRICING.

G. Rent is subject to adjustment based on the final Building Specific Amortized Capital (BSAC) cost to be amortized in the rental rate, as agreed upon by the parties subsequent to the Lease Award Date.

H. If the Government leases the Premises for less than a full calendar month, then rent shall be prorated based on the actual number of days leased for that month.

I. Rent shall be paid to Lessor by electronic funds transfer (EFT) in accordance with the provisions of the General Clauses. Rent shall be payable using the EFT information contained in the System for Award Management (SAM). In the event the EFT information changes, the Lessor shall be responsible for providing the updated information to SAM. Failure by the Lessor to maintain an active registration in SAM may result in delay of rental payments until such time as the SAM registration is activated.

J. Lessor shall provide to the Government, in exchange for the payment of rental and other specified consideration, the following:

1. The leasehold interest in the Property described herein in the paragraph entitled “The Premises.”

2. All costs, expenses and fees to perform the work required for acceptance of the Premises in accordance with this Lease, including all costs for labor, materials, and equipment, professional fees, subcontractor fees, attorney fees, permit fees, inspection fees, and similar such fees, and all related expenses.ACTION REQUIRED: SELECT THE APPROPRIATE SUB-PARAGRAPH 3.

VERSION 1: USE FOR A “FULLY SERVICED” LEASE

3. Performance or satisfaction of all other obligations set forth in this Lease; and all services, utilities, and maintenance required for the proper operation of the Property, the Building, and the Premises in accordance with the terms of the Lease, including, but not limited to, all inspections, modifications, repairs, replacements, and improvements required to be made thereto to meet the requirements of this Lease.

VERSION 2: USE FOR A “LEASE NET OF UTILITIES.” IDENTIFY WHICH UTILITIES (ELECTRIC AND/OR GAS) ARE NET, AND DELETE

ONE OF THE UTILITIES PARAGRAPHS IN THE “UTILITIES, SERVICES, AND OBLIGATIONS DURING THE LEASE TERM” SECTION

OF THIS LEASE ACCORDINGLY.

NOTE: FOR LEASES THAT ARE NET OF JANITORIAL ONLY; SELECTION AND ADJUSTMENTS TO THE TEXT MUST BE DONE

MANUALLY; NOT THROUGH THE GEE MACRO.

Performance or satisfaction of all other obligations set forth in this Lease; and all services, utilities (with the exclusion of XX), maintenance required for the proper operation of the Property, the Building, and the Leased Premises, in accordance with the terms of the Lease, including, but not limited to, all inspections, modifications, repairs, replacements and improvements required to be made thereto to meet the requirements of this Lease. The Government shall be responsible for paying the cost of XX directly to the utility provider. The Lessor shall ensure that such utilities are separately metered. The Lessor shall provide and install as part of shell rent, separate meters for utilities. Sub-meters are not acceptable. The Lessor shall furnish in writing to the LCO, prior to occupancy by the Government, a record of the meter numbers and verification that the meters measure Government usage only. Proration is not permissible. In addition, an automatic control system shall be provided to assure compliance with heating, ventilation, and air conditioning requirements.

K. For succeeding Leases with an incumbent Lessor where the Government is currently in occupancy and possession of the leased Premises and where the Lease requires the Lessor to perform alterations using either the TIA or BSAC, the amortized tenant improvement rent and/or BSAC rent will not commence until the alterations are complete and accepted by the Government. Upon acceptance of these improvements, the Government will commence payment of the tenant improvement and/or BSAC rent as stipulated under the Lease, in addition to payment of the tenant improvement and/or BSAC rent for the period starting from the Lease Term Commencement Date to the date of tenant improvements/BSAC acceptance by the Government (such rent payment will not include any additional interest). Alternatively, the Government may elect to re-amortize the tenant improvements/BSAC over the remaining Firm Term of the Lease, at the amortization rate stipulated in the Lease. In the event the Government does not use all the TIA or BSAC, then the rental payments will be adjusted in accordance with the provisions of the Lease (e.g., de-amortization).

LEASE NO. GS-XXP-LXXXXXXX, PAGE 12 LESSOR: ________ GOVERNMENT: ________ GSA TEMPLATE L100

ACTION REQUIRED: USE THE PARAGRAPH BELOW IF COMMISSION CREDIT IS APPLICABLE. OTHERWISE, DELETE.

NOTE: COMMISSIONS AND/OR COMMISSION CREDITS SHOULD BE TREATED AS CONFIDENTIAL FINANCIAL INFORMATION AND SHOULD

NOT BE DISCLOSED TO THE PUBLIC OR USED FOR ANY OTHER PURPOSE THAN THAT FOR WHICH IT WAS FURNISHED, WITHOUT

CONSENT OF THE LCO.

1.04 BROKER COMMISSION AND COMMISSION CREDIT (OCT 2016)

A. [Broker Name] (Broker) is the authorized real estate Broker representing GSA in connection with this Lease transaction. The total amount of the Commission is $XX and is earned upon Lease execution, payable according to the Commission Agreement signed between the Lessor and Broker. Only $XX of the Commission will be payable to [Broker Name] with the remaining $XX, which is the Commission Credit, to be credited to the shell rental portion of the annual rental payments due and owing to fully recapture this Commission Credit. The reduction in shell rent shall commence with the first month of the rental payments and continue until the credit has been fully recaptured in equal monthly installments over the shortest time practicable.

B. Notwithstanding the “Rent and Other Consideration” paragraph of this Lease, the shell rental payments due and owing under this Lease shall be reduced to recapture fully this Commission Credit. The reduction in shell rent shall commence with the first month of the rental payments and continue as indicated in this schedule for adjusted Monthly Rent:

(ADD AND DELETE MONTHS AS NECESSARY.)

Month X Rental Payment $XX,XXX minus prorated Commission Credit of $XX,XXX equals $XX,XXX adjusted X th Month’s Rent.*

Month X Rental Payment $XX,XXX minus prorated Commission Credit of $XX,XXX equals $XX,XXX adjusted X th Month’s Rent.*

Month X Rental Payment $XX,XXX minus prorated Commission Credit of $XX,XXX equals $XX,XXX adjusted X th Month’s Rent.* Subject to change based on adjustments outlined under the paragraph “Rent and Other Consideration.”

ACTION REQUIRED: USE IF TERMINATION RIGHTS ARE NEGOTIATED. OTHERWISE, DELETE.

1.05 TERMINATION RIGHTS (OCT 2016)

The Government may terminate this Lease, in whole or in parts, at any time effective after the Firm Term of this Lease, by providing not less than XX days’ prior written notice to the Lessor. The effective date of the termination shall be the day following the expiration of the required notice period or the termination date set forth in the notice, whichever is later. No rental shall accrue after the effective date of termination.

ACTION REQUIRED: ENTER THE COMPLETE SET OF RENEWAL OPTION TERMS BELOW.

NOTE: IF A RENEWAL OPTION IS OFFERED THAT CAN BE EXERCISED WITHOUT FURTHER CONGRESSIONAL ACTION (PROSPECTUS), WHETHER OR NOT IT WAS SOLICITED OR EVALUATED, THE OPTION MUST BE INCLUDED IN THE ORIGINAL SCORING ANALYSIS

(SEE LEASING DESK GUIDE CHAPTER 9 AND APPENDIX F).

NOTE: ANY UNEVALUATED RENEWAL OPTION MUST BE EVALUATED PRIOR TO EXERCISING SUCH OPTION (SEE LEASING DESK GUIDE

CHAPTER 9).

1.06 RENEWAL RIGHTS (OCT 2016)

A. This Lease may be renewed at the option of the Government for a term of XX YEARS at the following rental rate(s):

OPTION TERM, YEARS XX - XX

ANNUAL RENT ANNUAL RATE / RSF

SHELL RENTAL RATE $XX $XX

OPERATING COSTS

OPERATING COST BASE SHALL CONTINUE FROM THE EFFECTIVE YEAR OF THE LEASE. OPTION TERM IS SUBJECT

TO CONTINUING ANNUAL ADJUSTMENTS.

provided notice is given to the Lessor at least XX days before the end of the original Lease term or any extension thereof; all other terms and conditions of this Lease, as same may have been amended, shall remain in full force and effect during any renewal term.

NOTE: REVISE SUB-PARAGRAPH B IF THE INTENT IS TO SEEK FIRM TERM RENEWAL OPTIONS.

B. Termination rights outlined in the “Termination Rights” paragraph apply to all renewal terms.

ACTION REQUIRED:

THE LIST OF ATTACHMENTS IS NOT COMPREHENSIVE. ADJUST THE LIST AS APPROPRIATE FOR THE SPECIFIC TRANSACTION.

INCLUDE RELEVANT OFFEROR SUBMITTALS; EXAMPLES INCLUDE:

- APPROVED ASBESTOS MANAGEMENT PLAN

- SOURCE SELECTION AND/OR NEW CONSTRUCTION TECHNICAL SUBMISSIONS

- UNIT PRICE LISTS

FOR BROKER PROJECTS THE SIGNED COMMISSION AGREEMENT IS NOT INCLUDED AS AN ATTACHMENT TO THE LEASE

EXHIBITS SHOULD BE LABELED WITH SEQUENTIAL LETTERS.

ACTION REQUIRED:

DELETE ATTACHMENTS THAT ARE NOT APPLICABLE (FOR EXAMPLE, SEISMIC PRE-AWARD RETROFIT COMMITMENT, SMALL BUSINESS SUBCONTRACTING PLAN, DOL WAGE DETERMINATION, RLP AMENDMENTS, SECURITY AND/OR TI UNIT PRICE LISTS, ETC.).

NOTE: ONLY INCLUDE RLP AMENDMENTS AFFECTING THE LEASE (FOR EXAMPLE, CHANGE IN CLEANING SPECIFICATIONS) AND NOT THOSE AFFECTING THE OFFER PROCESS (FOR EXAMPLE, EXTENDING THE INITIAL OFFER DUE DATE). LCO MAY ALSO INCORPORATE

LEASE NO. GS-XXP-LXXXXXXX, PAGE 13 LESSOR: ________ GOVERNMENT: ________ GSA TEMPLATE L100

AMENDMENT CHANGES DIRECTLY INTO THE LEASE PARAGRAPHS, AS APPROPRIATE AND NOTE CHANGED PARAGRAPHS UNDER

SECTION 7.

NOTE: THE LCO MAY DECIDE IT IS MORE SUITABLE TO INCORPORATE SOME EXTENSIVE OR SENSITIVE DOCUMENTS BY REFERENCE

(FOR EXAMPLE, THE COURTS DESIGN GUIDE).

NOTE: FOR TURNKEY PRICING, THE ATTACHED REQUIREMENTS MUST BE AGENCY SPECIFIC REQUIREMENTS (ASR). ATTACH PRE-

AWARD DIDS, IF APPLICABLE.

NOTE: ONLY INCLUDE “FOREIGN OWNERSHIP AND FINANCING REPRESENTATION” FOR FSL III, IV OR V PROJECTS. OTHERWISE, DELETE.

YOU MUST NOTIFY CLIENT AGENCY PRIOR TO AWARD IF THE REPRESENTATION DISCLOSES FOREIGN OWNERSHIP OR

FINANCING.

1.07 DOCUMENTS INCORPORATED IN THE LEASE (OCT 2023)

The following documents are attached to and made part of the Lease:

DOCUMENT NAME NO. OF PAGES EXHIBIT

FLOOR PLAN(S)

PARKING PLAN(S)

AGENCY REQUIREMENTS

TENANT IMPROVEMENTS UNIT PRICE LIST [INCLUDE ONLY FOR TI TURNKEY PRICING]

SECURITY REQUIREMENTS

SECURITY UNIT PRICE LIST

GSA 3517B GENERAL CLAUSES

SEISMIC FORM C, BUILDING RETROFIT OR NEW CONSTRUCTION PREAWARD COMMITMENT

APPROVED SMALL BUSINESS SUBCONTRACTING PLAN [IF OFFEROR CERTIFIES ENTITY AS AN OTHER

THAN SMALL BUSINESS AND AGGREGATE RENT IS OVER $750,000]

DOL WAGE DETERMINATION [WHEN INCLUDING “LABOR STANDARDS” LEASE PARAGRAPH. THE OFFICIAL WEBSITE

FOR OBTAINING WAGE DETERMINATIONS IS SAM.GOV]

REVISION(S) TO LEASE ISSUED UNDER RLP AMENDMENT NUMBER(S) X

GSAR 552.270-33 FOREIGN OWNERSHIP AND FINANCING REPRESENTATION FOR HIGH-SECURITY LEASED

SPACE [FOR FSL III AND ABOVE PROJECTS ONLY]

ACTION REQUIRED: SELECT THE APPROPRIATE VERSION. DELETE ALTERNATE VERSIONS.

ACTION REQUIRED: LEASING SPECIALIST TO INSERT OFFEROR’S TI COSTS AND AMORTIZATION RATE AS STATED ON GSA FORM 1364.

1.08 TENANT IMPROVEMENT RENTAL ADJUSTMENT (OCT 2016)

VERSION 1: FOR TI ALLOWANCE PRICING.

NOTE: AMORTIZATION PERIOD DEFAULTS TO FIRM TERM. REVISE IF RLP OR NEGOTIATED OFFER REFLECTS OTHERWISE.

A. The Tenant Improvement Allowance (TIA) for purposes of this Lease is $XX.XX per ABOA SF. The TIA is the amount that the Lessor shall make available for the Government to be used for TIs. This amount is amortized in the rent over the Firm Term of this Lease at an annual interest rate of X percent.

B. The Government, at its sole discretion, shall make all decisions as to the use of the TIA. The Government may use all or part of the TIA. The

Government may return to the Lessor any unused portion of the TIA in exchange for a decrease in rent according to the agreed-upon amortization rate over the Firm Term.

C. The Government may elect to make lump sum payments for any or all work covered by the TIA. That part of the TIA amortized in the rent shall be reduced accordingly. At any time after occupancy and during the Firm Term of the Lease, the Government, at its sole discretion, may elect to pay lump sum for any part or all of the remaining unpaid amortized balance of the TIA. If the Government elects to make a lump sum payment for the TIA after occupancy, the payment of the TIA by the Government will result in a decrease in the rent according to the amortization rate over the Firm Term of the Lease.

D. If it is anticipated that the Government will spend more than the identified TIA, the Government may elect to:

1. Reduce the TI requirements;

2. Pay lump sum for the overage upon substantial completion in accordance with the “Acceptance of Space and Certificate of Occupancy” paragraph;

3. Negotiate an increase in the rent.

VERSION 2: FOR TI TURNKEY PRICING, WITH POST-AWARD DIDS

NOTE: FOR TURNKEY PRICING, THE ATTACHED REQUIREMENTS MUST BE AGENCY SPECIFIC REQUIREMENTS (ASR).

NOTE: THE AMOUNT AMORTIZED IN EXCESS OF THE TIER CANNOT BE AMORTIZED INTO THE RENT UNLESS A DEVIATION IS GRANTED

BY PORTFOLIO.

NOTE: AMORTIZATION PERIOD DEFAULTS TO FIRM TERM. REVISE IF RLP OR NEGOTIATED OFFER REFLECTS OTHERWISE.

A. The Lessor has agreed to total TI pricing of $XX,XXX based on the Agency’s Requirements and design schematic included in Exhibit X. This amount is amortized in the rent over the Firm Term of this Lease at an interest rate of X percent per year.

LEASE NO. GS-XXP-LXXXXXXX, PAGE 14 LESSOR: ________ GOVERNMENT: ________ GSA TEMPLATE L100

B. The TI Unit Prices listed in Exhibit X will be used to make the adjustment for variances between TI turnkey pricing based on the Agency’s Requirements and the approved design intent drawings. The prices quoted will also be used to order alterations during the first year of the Lease. The prices quoted shall be the cost to furnish, install, and maintain each item, unless otherwise specified. These prices may be indexed or renegotiated to apply to subsequent years of the Lease upon mutual agreement of the Lessor and the Government. Final rent calculations will be reconciled and the Lease will be amended after acceptance of the Space.

C. The Government may elect to make lump sum payments for any or all work covered by the TI scope. That part of the TI amortized in the rent shall be reduced accordingly. At any time after occupancy and during the Firm Term of the Lease, the Government, at its sole discretion, may elect to pay lump sum for any part or all of the remaining unpaid amortized balance of the TI. If the Government elects to make a lump sum payment for the TI after occupancy, the payment of the TI by the Government will result in a decrease in the rent according to the amortization rate over the Firm Term of the Lease.

VERSION 3: FOR TI TURNKEY PRICING, PRE-AWARD DIDS.

NOTE: FOR TURNKEY PRICING, THE ATTACHED REQUIREMENTS MUST BE AGENCY SPECIFIC REQUIREMENTS (ASR).

NOTE: THE AMOUNT AMORTIZED IN EXCESS OF THE TIER CANNOT BE AMORTIZED INTO THE RENT UNLESS A DEVIATION IS GRANTED

BY PORTFOLIO.

NOTE: AMORTIZATION PERIOD DEFAULTS TO FIRM TERM. REVISE IF RLP OR NEGOTIATED OFFER REFLECTS OTHERWISE.

A. The Lessor has agreed to total TI pricing of $XX,XXX based on the approved DIDs included in Exhibit X. This amount is amortized in the rent over the Firm Term of this Lease at an interest rate of X percent per year.

B. The Government shall have the right to make lump sum payments for any or all work covered by the TI scope. That part of the TI amortized in the rent shall be reduced accordingly. At any time after occupancy and during the Firm Term of the Lease, the Government, at its sole discretion, may elect to pay lump sum for any part or all of the remaining unpaid amortized balance of the TI. If the Government elects to make a lump sum payment for the TI after occupancy, the payment of the TI by the Government will result in a decrease in the rent according to the amortization rate over the Firm Term of the Lease.

ACTION REQUIRED: USE FOR TI ALLOWANCE AND BUILDING SPECIFIC AMORTIZED CAPITAL (BSAC) PRICING AND ENTER THE DOLLAR

AMOUNT, DOLLAR RATE, OR PERCENTAGE. DELETE WHEN USING TI TURNKEY PRICING.

NOTE: THERE ARE 3 PRICING METHODS LISTED FOR A/E FEES:

• $ PER ABOA SF

• $ FLAT FEE

• % OF TI AND BSAC CONSTRUCTION COSTS (MOST COMMONLY USED)

LESSOR PM FEES ARE ALWAYS STATED AS A PERCENTAGE

ACTION REQUIRED: AT LEASE AWARD, CHOOSE THE APPROPRIATE METHOD AND DELETE THE OTHER TWO.

1.09 TENANT IMPROVEMENT AND BSAC FEE SCHEDULE (OCT 2024)

For pricing TI and BSAC costs, the following rates shall apply for the initial build-out of the Space.

INITIAL BUILD-OUT [CHOOSE ONE

APPLICABLE METHOD (E.G., %) AND

DELETE OTHER TWO]

ARCHITECT/ENGINEER (A/E) FEES ($ PER ABOA SF, $ FLAT FEE, OR % OF TI AND BSAC CONSTRUCTION

COSTS) [CHOOSE ONE APPLICABLE METHOD (E.G., % OF TI AND BSAC CONSTRUCTION

COSTS) AND DELETE OTHER TWO]

$XX PER ABOA SF, $XX FLAT FEE, OR XX%

LESSOR'S PROJECT MANAGEMENT FEE (% OF TI AND BSAC CONSTRUCTION COSTS) XX%

ACTION REQUIRED: MANDATORY FOR ACTIONS DESIGNATED AT FACILITY SECURITY LEVEL (FSL) II, III OR IV, WHICH REQUIRES

OFFERORS TO DETERMINE BSAC RENT BASED UPON AN ESTIMATED DOLLAR AMOUNT SUPPLIED BY THE GOVERNMENT.

OTHERWISE, DELETE FOR FSL I OR TURNKEY BSAC PRICING.

ACTION REQUIRED. LEASING SPECIALIST MUST ENTER THE BSAC AND AMORTIZATION RATE AT LEASE AWARD. FOR FSL II, INSERT $12.00 PER ABOA SF, FOR FSL III, INSERT $25.00 PER ABOA SF AND FOR FSL IV, INSERT $40.00 PER ABOA SF (UNLESS LEASE IS AWARDED TO CURRENT LOCATION USING A LOWER BSAC PLACEHOLDER AMOUNT). THESE NUMBERS ARE ESTIMATED BASED

ON THE FSL.

NOTE: AMORTIZATION PERIOD DEFAULTS TO FIRM TERM. REVISE IF RLP OR NEGOTIATED OFFER REFLECTS OTHERWISE.

1.10 BUILDING SPECIFIC AMORTIZED CAPITAL (SEP 2012)

For purposes of this Lease, the Building Specific Amortized Capital (BSAC) is $XX.XX per ABOA…