ESBD_File_346557_RFP 24-1336 Electrical Vulnerability Assessment.pdf

RFP No. 24-1336 Electrical Vulnerability Assessment

Brazos River Authority

Request for Proposals for Professional Services

December 28, 2023 RFP No. 24-1336

Dear Prospective Respondent:

Statements of Qualifications hereafter referred to Request for Proposals (RFP or Proposal(s)) will be received by the Purchasing Agent or other designee of the Brazos River Authority no later than 10:00 AM, Thursday, January 25, 2024 for Electrical Vulnerability Assessment. All qualified firms including Small, Minority, Women Owned Businesses and Historically Underutilized Businesses are encouraged to submit proposals in response to this request.

Proposals must be submitted and received no later than the due date and time specified. Any Proposal received later than the specified time, shall not be considered. The BRA is NOT responsible for ensuring the delivery of Proposals.

Refer to Section 13. Delivery of Proposal Submittals for instructions on submitting a response to this solicitation.

Proposal must be clearly identified as follows on the outside of the sealed physical submission or the electronic submission subject line. The BRA shall not be responsible for submissions that are not properly identified. Proper identification of Respondent’s proposal is the sole responsibility of the Respondent and failure to do so may result in the submission not being included in the proposal opening:

RFP TITLE: Electrical Vulnerability Assessment

RFP NO: 24-1336

RFP DUE DATE: 10:00 AM, Thursday, January 25, 2024

The BRA shall have the right to accept or reject any or all Proposals, or any part thereof, and to waive any technicalities in the interest of the BRA.

BRA will evaluate all relevant, health, safety and business factors on all solicitations to determine when to initiate a notice to proceed on all projects, delivery of goods and/or services or procurement of construction related services to best attempt to balance BRA needs and to protect the health and safety of BRA employees, the employees of respondents and the public at large.

Sincerely, Victor Venegas Purchasing Agent

4600 Cobbs Drive • Waco, Texas 76710 254-761-3166

SUPPLIER DIVERSITY PURCHASING POLICY

The Brazos River Authority (BRA) will ensure that purchases of equipment, materials, supplies, and/or services conform with Texas Procurement law as applicable to the BRA, are cost effective, and contribute to the competitiveness of the BRA and its customers.

Procurement activities will be conducted in an open and fair manner with equal opportunity provided to all qualified parties. The BRA will provide equal contracting opportunities as provided by all applicable State and Federal laws to small business enterprises, Historically Underutilized Businesses and Disadvantaged Business enterprises.

GENERAL INSTRUCTIONS TO RESPONDENTS

The Work consists of the furnishing of all labor, materials, services, equipment, and appliances required for the delivery and the supplying of products and/or services as described herein and in the contract documents.

1. PROPOSAL SUBMISSION: Proposals must be received no later than the Proposal opening date and time specified above. All Proposals received after closing time will not be considered.

A. To be considered as eligible, a Respondent shall have complied with all legal requirements to permit them to operate in the State of Texas.

B. Proposals must be emailed, mailed or hand delivered to be considered.

2. WITHDRAWAL OF PROPOSALS: No Proposal may be withdrawn for a period of ninety (90) days after Proposal opening, except by: 1) mutual consent of the BRA and Respondent; or 2) a previously submitted Proposals may be withdrawn upon written request received from Respondent prior to time established for receipt of Proposals.

3. SIGNATURE ON PROPOSALS: To be valid, Proposals must be signed by an authorized person. By such signature, Respondent agrees to strictly abide by the terms, conditions, and Scope of Services embodied in this Request for Proposal.

4. EXAMINATION OF PROPOSAL DOCUMENTS: Before submitting a Proposal, all Respondents shall examine the complete Proposal documents, including Proposal Notice, Instruction to Respondent, and Scope of Services, all of which are part of the Proposal documents.

5. ADDENDA: Unless otherwise stated in the Proposal, answers to all questions, inquiries, and request for additional information will be issued in the form of Addenda. During the Proposal period, prospective Respondent may be advised by Addenda of additions, deletions from, or changes in the requirements of the Proposal documents. The BRA will not be responsible for the authenticity or correctness of oral interpretations of the Proposal documents or for information obtained in any other manner than through the media of Addenda. Receipt of each Addendum shall be acknowledged by the Respondent.

Any questions concerning this Proposal should be emailed to Victor Venegas, Purchasing Agent no later than five (5) days prior to the opening of the Proposal at submissions@brazos.org. This is to allow the BRA sufficient time to respond to inquiries and provide information to all interested Respondents by Addendum. Unless otherwise stated in the Proposal, Addenda will be posted on the BRA web site at www.brazos.org, Doing Business, Purchasing and Professional Services, Request for Proposals.

Respondent is responsible for checking the BRA web site (www.brazos.org) for updates and Addenda until the time at which the submission is due. Failure to respond to all requirements, including those Addenda, shall be grounds for rejection of your Proposal.

6. TAXATION: The BRA is exempt under the Texas Sales Tax and Use Tax Laws, and the Respondent shall not include such taxes in the Proposal.

7. QUALIFICATION OF RESPONDENTS: The BRA reserves the right to reject any Proposal if the evidence submitted by, or investigation of, such Respondent fails to satisfy the BRA that such Respondent is properly qualified to carry out the obligations of the contract and to complete the Services contemplated herein.

Conditional Proposals will not be accepted.

8. CONSIDERATION OF PROPOSALS: Unless stated otherwise in the Advertisement or Request for Proposal, the properly identified Proposals received on time will be opened publicly and only the names of the Respondent will be read aloud. Respondents are invited to be present.

9. COMPLIANCE WITH SCOPE OF SERVICES AND RIGHT OF

SELECTION: The Respondent shall abide by and comply with the true intent of the scope of services and not take advantage of any unintentional error or omission.

10. DEVIATION FROM SCOPE OF SERVICES: All deviations from the scope of services must be noted in detail by the Respondent, in writing, at the time of submittal of the formal Proposal. The absence of a written list of deviations at the time of submittal of the Proposal will be considered acceptance of the Scope of Services as written.

Any deviations from the Scope of Services as written not previously submitted, as required by the above, will be grounds for rejection of the material and/or item when delivered.

In case of ambiguity or lack of clarity, the BRA reserves the right to consider the most advantageous Proposal or reject the Proposal.

11. REPRESENTATIONS: By execution and submission of this Proposal, the Respondent hereby represents and warrants to the BRA that Respondent has read and understands the Proposal Documents and this Proposal is made in accordance with the Proposal Documents.

12. INDEMNIFICATION:

THE RESPONDENT SHALL COMPLY WITH THE REQUIREMENTS

OF ALL APPLICABLE LAWS, RULES, AND REGULATIONS AND

SHALL EXONERATE, INDEMNIFY AND HOLD HARMLESS THE

BRA FROM ANY AND ALL LIABILITY OR DAMAGES RESULTING

FROM FAILURE TO DO SO.

IN ADDITION, THE RESPONDENT AGREES TO INDEMNIFY,

KEEP, SAVE AND HOLD THE BRA HARMLESS FROM ANY AND

ALL ACTIONS, LIABILITIES, DAMAGES, JUDGMENTS, COSTS

AND EXPENSES INCLUDING REASONABLE ATTORNEY’S FEES,

IN CASE AN ACTION IS FILED OR DOES IN ANY WAY ACCRUE

AGAINST THE BRA, ITS OFFICIALS, OFFICERS, AND

EMPLOYEES IN CONSEQUENCE OF THE AWARDED CONTRACT

FOR ANY NEGLIGENT ACT OR OMISSION OF THE RESPONDENT

IN THE PROVISION OF SERVICES UNDER THE AWARDED

CONTRACT, OR THAT MAY RESULT FROM THE CARELESSNESS

OR LACK OF SKILL OF THE RESPONDENT OR THE

RESPONDENT’S OFFICERS, AGENT, CONTRACTORS, ASSIGNS

OR EMPLOYEES. IN THE EVENT A JUDGMENT IS RECOVERED

mailto:submissions@brazos.org

AGAINST THE BRA FOR ANY SUCH LIABILITY, COSTS OR

EXPENSES, SUCH JUDGMENT SHALL BE CONCLUSIVE

AGAINST THE RESPONDENT.

IT IS SPECIFICALLY UNDERSTOOD AND AGREED BY THE

RESPONDENT THAT SUCH INDEMNITY IS INDEMNITY BY THE

RESPONDENT TO INDEMNIFY AND PROTECT THE BRA FROM

LIABILITY, CLAIMS, SUITS, LOSSES, DAMAGES OR CAUSES OF

ACTION DUE TO THE RESPONDENT’S NEGLIGENCE, ERROR OR

OMISSION.

13. CRITERIA FOR AWARD: The BRA will select the most highly qualified Respondent on the basis of demonstrated competence and qualifications and then attempt to negotiate with that Respondent a contract at a fair and reasonable price. If a satisfactory contract cannot be negotiated with the most highly qualified Respondent, the BRA will select the next most highly qualified Respondent and attempt to negotiate a contract with that Respondent at a fair and reasonable price.

14. TERMINATION: The awarded contract may be terminated at any time by the BRA, in BRA’s sole discretion, for any cause or for convenience without penalty or liability. Upon receipt of such notice, the supplier shall immediately discontinue all services and actions.

The BRA shall pay the Respondent promptly the accrued and unpaid amounts due for services to the date of termination, to the extent the services are approved by the BRA.

15. CHANGE OF CONTRACT PRICE:

The agreed upon contract price shall not be exceeded without the prior written consent of the BRA and may only be modified by a written amendment to the contract executed by both BRA and Respondent.

16. PAYMENT: Unless otherwise specified, payment for services and/or product will be processed within thirty (30) days from invoice date and acceptance of Services and/or product. Invoices presented for payment must be submitted in accordance with instructions contained on the purchase order including reference to purchase order number and submittal to the correct address for processing. Unit price on invoice shall be in two (2) decimal places only, i.e., $ .XX.

The BRA has set a goal to have as much paperwork submitted electronically. Respondents are asked to submit invoices electronically to the following Accounts Payable email address:

accounts.payable@brazos.org. Respondents who use the electronic service should not mail the original invoice.

17. CONFIDENTIALITY OF DOCUMENTS: The BRA is subject to the Texas Public Information Act (PIA). Any information submitted to the BRA by a Respondent shall be considered non-confidential and available to the public, except as follows:

In the event a Respondent considers a specific portion of their Proposal to be confidential and subject to an exception to disclosure under the PIA, such portion must be clearly identified and marked "CONFIDENTIAL". Do not mark an entire Proposal confidential, as this is not in conformance with the PIA and is not acceptable. Only the specific portion or portions of the Proposal that the Respondent considers to be confidential pursuant to the PIA should be marked. IF

AN ENTIRE PROPOSAL IS MARKED CONFIDENTIAL, THE BRA

WILL NOT TREAT ANY PORTION OF THE PROPOSAL AS

CONFIDENTIAL AND THE PROPOSAL MAY BE REJECTED AS

NON-CONFORMING. The BRA will honor notations of confidentiality made in accordance with this paragraph and decline to release such information initially. However, final determination of whether a particular portion of a Proposal may in fact be withheld pursuant to the PIA will be made by the Texas Attorney General or a court of competent jurisdiction.

In the event a public information request is received for a portion of a Proposal that has been marked confidential, the BRA shall ask the affected Respondent if the information may be released. If the release is agreed to, the BRA shall release the information.

If the release is denied, the matter shall be referred to the Texas Attorney General's Office in accordance with the process set forth in the PIA. The Respondent shall be fully and solely responsible for submitting arguments and evidence within the statutory timeframes to the Texas Attorney General’s Office regarding its claim of confidentiality. The BRA will NOT submit arguments on behalf of the Respondent.

The Texas Attorney General's office shall rule on the matter. In the event that it is determined by opinion or order of the Texas Attorney General or a court of competent jurisdiction that such information may not be withheld, then such information will be made available to the requester. If it is determined that the information may be withheld, BRA will withhold the information from the requestor.

Pricing information contained in Proposals or contracts is not considered confidential under the PIA and will be disclosed without making a request to the Texas Attorney General.

18. NO PRICE: The selection of the Selected Respondent under this RFP shall be in accordance with Chapter 2254 of the Texas Local Government Code. Do not include any price information within the submittal. Any submittal containing any price information will be automatically disqualified.

RFP No. 24-1336 Electrical Vulnerability Assessment Page 4 of 11

REQUEST FOR PROPOSALS

ELECTRICAL VULNERABILITY ASSESSMENT

RFP NO. 24-1336

SUBMITTAL SCHEDULE

Proposals are posted on the BRA website and prospective Respondents should check www.brazos.org> Doing Business>, Purchasing & Professional Services>, Request for Proposals for potential updates to Proposal requirements.

Thursday, December 28, 2023

RFP is available to download from the BRA website at http://www.brazos.org/Doing- Business/Purchasing-Professional- Services/Request-for-Proposals, and click on “View this RFP”.

4:00 PM, Friday, January 12, 2024 Last date and time to ask questions or request additional information. Email questions to submissions@brazos.org.

4:00 PM, Friday, January 19, 2024

Post response to questions received as of the deadline or as soon thereafter, as an Addendum on the BRA website – www.brazos.org/ Doing Business/Purchasing and Professional Services/Request for Proposals.

10:00 AM, Thursday, January 25, Proposals are due.

11:00 AM Thursday, January 25, Proposals will be opened virtually at the link below……………………………..

https://youtube.com/live/Sp8cKuy6LGc?feature=share

RFP No. 24-1336 Electrical Vulnerability Assessment Page 5 of 11

ELECTRICAL VULNERABILITY ASSESSMENT

1. General DeCordova Bend Dam, owned and operated by the Brazos River Authority, was designed by Ambursen Engineering Corporation, and constructed in 1969 to form the Lake Granbury Reservoir. DeCordova Bend Dam is in Hood County, approximately 8 miles southeast of Granbury, Texas. DeCordova Bend Dam has a normal pool (El. 693 BRA datum) storage capacity of approximately 129,011 acre-feet and a spillway structure consisting of sixteen

(16) tainter gates.

The purpose of this project is to procure a quality firm to perform an assessment of the dam’s electrical and SCADA systems and their vulnerabilities. In addition, based upon the findings and recommendations from this assessment, to develop a design and oversee construction and possible remediation.

2.Scope of Services A scope of services will be developed in conjunction with the negotiation of a not to exceed, professional services contract between the BRA and the selected engineering Firm. The scope of services presented below for is a general description of the required work to develop this project and will be further developed during negotiations. The scope of services to be performed may include, but is not limited to, the following Assessment, Investigation, and Review Services

• Review all available and pertinent documents pertaining to the electrical and SCADA system. Review shall include discussion and interviews with BRA Operations and Engineering staff/departments identifying known issues, deficiencies, anticipated modifications, or improvements.

• Make a site reconnaissance visit(s) as necessary to assess the electrical and SCADA system

• Identify risks to the dam’s electrical system from power outages and lightning strikes

• Assess other issues that might affect the dam’s electrical source and backup sources including SCADA vulnerabilities

• Provide recommendations on mitigating/remediating any identified risks

• Identify and provide steps to protect the dam’s primary electrical source. Additionally, provide recommendations for reliable back-up sources of electrical power and means to protect them.

• Develop a one-line diagram of the facility.

• Ensure any modifications to electrical system will support future projects planned projects

• Provide Opinions of Probable Construction Cost for recommended mitigation strategies

• Provide a design for auxiliary power for construction projects.

Engineering Design Services (only if authorized by the BRA)

• Prepare 30%, 60%, 95%, and 100% final design plans

• Prepare conformed construction plans and specifications for bidding

• Prepare a detailed estimate of probable construction and life cycle cost

• Review permitting requirements and procure approvals as necessary

RFP No. 24-1336 Electrical Vulnerability Assessment Page 6 of 11

Bidding Services (only if authorized by the BRA)

• Provide engineering support services as required during bidding process

• Review bid respondent submittals and prepare a recommendation assessment to BRA

Construction Engineering, Administration, and Resident Project Representative Services (only if authorized by the BRA)

• Provide construction contract administrative services, including but not limited to, conducting a pre-construction meeting and participating in regular construction progress meetings as determined with BRA.

• Provide construction engineering services, including but not limited to, making visits to the site at a frequency sufficient to observe the progress and the quality of work as determined necessary by the engineer and to make sure the work is proceeding in accordance with the construction contract documents and reviewing submittals to ensure that products are furnished in accordance with the contract documents.

• Provide a full-time Resident Project Representative to monitor construction for compliance with the contract documents.

• Prepare record documents to capture any changes during construction.

Provide operation and maintenance manuals and applicable training as necessary

2. Information Required in the RFP Submittal

The BRA specifically requests succinct submittals tailored to the general and discipline-specific scopes of services summarized above. Each response should describe in sufficient detail the relevance of the individual team member’s expertise and experience to the specific requirements of the project. All submittals become the property of the BRA. Each submittal shall include the information requested below. Please limit each submittal to no more than 20 pages (not including resumes and required forms)

Tab A: Include the following:

(1) Date your company was established and a brief history; number of employees; provide number and location of offices.

(2) Provide name, title and office location of person who will be the principal contact for the BRA and the billing location if different.

(3) Describe the types of organizations that your company typically serves and general nature of the work.

(4) A list and description of similar services completed within the last five years under your current company name or any other company name similar in nature to this solicitation.

This should include the name, the location, a brief description of Scope of Services, and a contact name and telephone number of a reference for each client. List litigation that your company has been a party to in the last five (5) years, under your current company name or any other company name. Include only litigation that involves business units in your company that are proposed for performing services under this

RFP.

(5) List all such litigation involving owners and/or general contractors. To be fully responsive, provide the level of detail in the attached example, as well as a name and phone number to contact an authorized representative of your company in the event that the BRA needs to clarify your response. Failure to be fully responsive will be sufficient grounds for the BRA to disqualify your company.

(6) Have you ever defaulted, failed to complete a contract or had a contract terminated by the other party? If so, where and why? Provide name and telephone number of the other party.

RFP No. 24-1336 Electrical Vulnerability Assessment Page 7 of 11

Tab B: Include the following:

(1) Provide an overview of your understanding and approach to the project requirements with a detailed technical proposal for how you will approach the scope of services necessary to complete the project. At a minimum, include the following:

a. Understanding of project specific objectives and approach to address those challenges.

b. Approach to interaction with the BRA on technical items and decision making.

c. Additional scope items you recommend to improve the outcome of the services.

d. A conceptual project schedule for completion of the services.

e. Approach to quality assurance and quality control for the project.

2. Provide a summary of the project team and the functional structure of the project team as it relates to delivery of this work. At a minimum, include the following information:

a. Identification of the person proposed to serve as the project manager for delivery of the services and any task leads, if planned, for each project phase.

b. Organizational chart showing the names of the personnel, their Texas P.E.

license number and their associated engineering discipline that will serve as technical experts for the Respondent. Note: All engineering site inspectors and designers must have a minimum of 5 years’ experience inspecting and conducting design improvements to large high hazard dams (as defined by TCEQ) as it relates to their associated engineering discipline/expertise. In addition, prior to executing the associated Professional Services Contract(s), each engineering site inspector and designer must obtain licensure in the state of Texas in their assigned project engineering discipline.

c. A two-page (maximum) resume for each team member proposed (include at the end of Tab B).

d. If you plan to utilize sub-consultants, provide their name, address, resume, and their role on the team.

3. Provide the anticipated availability of key staff for providing services on this project.

Briefly describe your approach to project staffing and succession plan for the project team should a vacancy arise.

4. Describe your approach to employee health and safety and incorporating health and safety principles into designed work.

Tab C: Include the following:

1.Complete and submit the attached Request for Proposal – Proposal Form

2. Complete and submit the attached W-9 form, or if foreign entity submit the appropriate tax document information.

3.Complete and submit the attached Conflicts of Interest Questionnaire [CIQ] form.

4.Complete and submit the Non-Collusion Affidavit form.

5.HUB Subcontracting Plan

RFP Inquiries All inquiries, including clarifying questions, related to this RFP shall only be directed to the Purchasing Agent via e-mail to submissions@brazos.org . The Purchasing Agent will direct any inquiries to the appropriate BRA staff, a response will be issued and if warranted, an Addendum will be posted on the BRA’s website at www.brazos.org. Failure to adhere to this restriction during the http://www.brazos.org/

RFP No. 24-1336 Electrical Vulnerability Assessment Page 8 of 11 advertising, evaluation, and selection phases will result in the rejection of a Respondent’s Proposal.

3. Hub Subcontracting Plan This solicitation requires a HUB Subcontracting Plan to be completed and submitted. The HUB Subcontracting Plan is attached to this solicitation. If you have any questions regarding the HUB Subcontracting Plan please contact David Thompson, HUB Coordinator at David.Thompson@Brazos.org.

4. Hub Subcontracting Plan Instructions (If Self Performing HUB and no Subcontractors) If you will not be subcontracting any portion of the contract and will be fulfilling the entire contract with your own resources (i.e., employees, supplies, materials and/or equipment), follow the instructions on the HUB Subcontracting Plan Checklist, first page of the HUB Plan included in this solicitation.

Section 1 - Respondent and Requisition Information

Section 2 a. - No, I will not be subcontracting any portion of the contract, and I will be fulfilling the entire contract with my own resources.

Section 3 - Self Performing Justification Section 4 – Affirmation (Remember to sign Section 4)

If you are subcontracting any work please follow the instructions on the HUB Subcontracting Plan Checklist, first page of the HUB Plan included in this solicitation.

5. Respondent’s Past Performance BRA will consider Respondent’s past performance and may conduct reference checks with other entities regarding past performance. BRA may examine Respondent’s performance including, but not limited to:

the Comptroller of Public Accounts Statewide Procurement Division Vendor Performance Tracking System, notices of termination, cure notices, assessments of liquidated damages, litigation, audit reports, repeated negative performance, records of repeated non-responsiveness to performance issues, and non-renewals of contracts. Such sources of Respondent performance may include any governmental entity, whether an agency or political subdivision of the State of Texas, another state, or the Federal government. Further, BRA may initiate such examinations of Respondent performance based upon media reports. Any such investigations shall be at the sole discretion of BRA, and any negative findings, as determined by BRA, may result in non-award to Respondent.

6. Conflict of Interest Pursuant to Chapter 176 of the Local Government Code, any person or agent of a person who contracts or seeks to contract for the sale or purchase of property, goods, or services with a local government entity (i.e., Brazos River Authority) must disclose in the Conflicts of Interest Questionnaire Form ("CIQ") the person's affiliation or business relationship that might cause a conflict of interest with the local government entity. By law, the CIQ must be filed with the BRA Records Management Officer no later than seven (7) days after the date the person begins contract discussions or negotiations with the BRA, or submits an application or response to a Request for Proposals, correspondence, or another writing related to a potential agreement with the BRA. Updated Questionnaires must be filed in conformance with Chapter 176.

A copy of the CIQ is attached. If you have any questions about compliance, please consult your own legal counsel. Compliance is the individual responsibility of each person or agent of a person who is subject to the filing requirement. An offense under Chapter 176 carries a penalty up to a Class A misdemeanor.

7. Disclosure of Interested Parties Pursuant to Section 2252.908 of the Government Code, the selected Firm in contracts for the sale or purchase of property, goods, or services with a local government entity (i.e., BRA) anticipated to have a value of at least $250,000/$500,000 must submit a Disclosure of Interested Parties Form to the local mailto:David.Thompson@Brazos.org

RFP No. 24-1336 Electrical Vulnerability Assessment Page 9 of 11 government entity that discloses all persons at the Selected Firm who have a controlling interest in the selected Firm or who actively participated in facilitating the contract or negotiating the terms of the contract.

The requirements of Section 2252.908 of the Government Code are subject to change, and if you have any questions about compliance, please consult your own legal counsel.

https://www.ethics.state.tx.us/whatsnew/elf_info_form1295.htm

8. Term of Agreement The services of the PROVIDER shall commence on the Effective Date of this Contract and shall continue until the Work is completed

9. Selection Process Proposals will be evaluated and scored based on the factors listed below.

• Firm's Background Information

• Similar Work Performed

• Proposed Project Team Experience and Qualifications

• Proposed Project Approach

• Resource Availability

10. Contract The executed contract between BRA and the selected Respondent shall be a BRA standard form contract for Professional Services. Contract terms are not subject to modification and Respondent will be expected to execute the contract in substantially the form provided. Respondent should not base a proposal on an expectation that BRA will modify its contract terms.

Compensation for services provided under the professional services contract to be entered into with the selected Firm will be based on time and materials up to a total mutually agreeable not-to-exceed amount. Individual tasks under the contract will also be billed on a time and material basis up to a not-to-exceed amount for such task.

The BRA reserves the right to award contract(s) without any negotiations and reserves the right to not make awards. The BRA reserves the right to conduct studies and other investigations as necessary to evaluate any submittal. Submission of a proposal confers no legal right upon any Respondent.

The decision of BRA, or its designee with regard to the above, shall be administratively final. BRA, in its sole discretion, may waive administrative deficiencies and/or minor technicalities in submittals received.

11. Insurance Requirements The Respondent shall, at Respondent’s sole expense, maintain insurance coverage as determined acceptable to the BRA. The Respondent must obtain the following minimum insurance requirements and provide proof to the BRA prior to entering into a contract:

General Liability Insurance:

Bodily Injury $ 500,000 per person Bodily Injury $ 1,000,000 per occurrence Property Damage $ 1,000,000 per occurrence https://www.ethics.state.tx.us/whatsnew/elf_info_form1295.htm

RFP No. 24-1336 Electrical Vulnerability Assessment Page 10 of 11

Aggregate $ 2,000,000

Professional Liability:

$ 1,000,000 per occurrence

Workers’ Compensation:

Statutory

Automobile Liability: $ 1,000,000 per claim / aggregate

Employers’ Liability

$ 1,000,000 policy limit

Prior to commencement of work under this agreement, Respondent shall register with myCOItracking.com and subsequently provide documentation that satisfies the insurance requirements of this agreement. Respondent shall add registration@myCOItracking.com and certificaterequest@myCOIsolution.com to it’s safe sender’s list for necessary communication from myCOI. For any registration difficulties, call myCOItracking team at (317) 759-9426.

12. Recycled and Recyclable Products The BRA encourages the use of recycled products and products that may be recycled or reused.

13. Delivery of Proposal Submittals Proposals may be submitted in one of the following manners:

Electronic Transmission. Email transmission to submissions@brazos.org. Emailed proposal submissions shall be an attachment, in a Portable Document Format (PDF). Proposals shall be clearly identified in the Subject Line as follows: RFP Title, RFP Number and RFP Due Date. The BRA shall not be responsible for submissions that are not properly identified. Proper identification of Respondent’s proposal is the sole responsibility of the Respondent and failure to do so may result in the submission not being included in the proposal opening.

Drop Box Submission Prior to Proposal Submission Deadline: Hand delivery of one sealed, clearly identified original signed paper copy submission may be received up to the proposal submission deadline contained in the solicitation at the Brazos River Authority, 4600 Cobbs Drive, Waco, TX. 76710, utilizing the secure drop box located near of the office building. The BRA shall not be responsible for submissions that are not properly identified. Proper identification of Respondent’s proposal is the sole responsibility of the Respondent and failure to do so may result in the submission not being included in the proposal opening.

Mail-In Delivery: Mailed by commercial carrier, overnight or express mail, one sealed clearly identified original signed paper copy submission may be accepted by the Purchasing Agent or other designee up to the proposal submission deadline contained in the solicitation at the Brazos River Authority 4600 Cobbs Drive, Waco, TX. 76710. The BRA shall not be responsible for submissions that are not properly identified. Proper identification of Respondent’s proposal is the sole responsibility of the Respondent and failure to do so may result in the submission not being included in the proposal opening.

mailto:registration@myCOItracking.com mailto:certificaterequest@myCOIsolution.com

RFP No. 24-1336 Electrical Vulnerability Assessment Page 11 of 11

ELECRICAL VULNERABILITY ASSESSMENT

ACKNOWLEDGMENT OF REQUEST FOR PROPOSALS AND

RECEIPT OF ADDENDA

RESPONDENT MUST ACKNOWLEDGE RECEIPT OF THIS REQUEST FOR PROPOSALS

AND ADDENDA BY SIGNING BELOW AND SUBMITTING THIS ACKNOWLEDGEMENT

WITH YOUR PROPOSAL. FAILURE TO SIGN THIS ACKNOWLEDGEMENT WILL

DISQUALIFY THE PROPOSAL AS NON-RESPONSIVE. SIGNATURE MAY BE DIGITAL,

ELECTRONIC OR HAND WRITTEN.

This acknowledgement shall become part of your response and the subsequent contract documents if applicable.

ACKNOWLEDGMENT OF REQUEST FOR PROPOSALS:

Respondent hereby acknowledges that it has received and read the Request for Proposals and all Addenda, and that this Proposal is made in accordance with the provisions thereof.

Respondent acknowledges that this Proposal meets or exceeds all terms, requirements, conditions, and/or specifications set forth in the Request for Proposals and Addenda, and exceptions or deviations from such terms, requirements, conditions, and/or specifications, if any, have been clearly and conspicuously identified as such in the Proposal.

Does your company have ten (10) or more full time employees? Check one box only.

YES NO

Name of Firm (Respondent)

Signature – Authorized Representative

Printed Name

Date

E-mail Address

Telephone Number

EXAMPLE RESPONSE TO LITIGATION HISTORY QUESTION

Date Parties Nature/Description of Litigation Outcome 2010 XYZ, Inc. v. Owner Owner brought suit against XYZ, Inc.

claiming flawed design of a concrete pad.

XYZ, Inc.

Nonsuited

2011 XYZ, Inc. v. Owner XYZ, Inc. retained to design bike path, the path collapsed in construction and owner sued XYZ, Inc. and contractor

Settled

2012 XYZ, Inc. v. Contractor Contractor claimed XYZ, Inc. negligent on a project where Contractor was constructing a tower and the tower allegedly incorporated incorrect materials. XYZ, Inc. disputes the allegations.

Ongoing

Rev. 2/17

HUB Subcontracting Plan (HSP)

QUICK CHECKLIST

While this HSP Quick Checklist is being provided to merely assist you in readily identifying the sections of the HSP form that you will need to complete, it is very important that you adhere to the instructions in the HSP form and instructions provided by the contracting agency.

If you will be awarding all of the subcontracting work you have to offer under the contract to only Texas certified HUB vendors, complete:

Section 1 - Respondent and Requisition Information Section 2 a. - Yes, I will be subcontracting portions of the contract.

Section 2 b. - List all the portions of work you will subcontract, and indicate the percentage of the contract you expect to award to Texas certified HUB vendors.

Section 2 c. - Yes Section 4 - Affirmation GFE Method A (Attachment A) - Complete an Attachment A for each of the subcontracting opportunities you listed in Section 2 b.

If you will be subcontracting any portion of the contract to Texas certified HUB vendors and Non-HUB vendors, and the aggregate percentage of all the subcontracting work you will be awarding to the Texas certified HUB vendors with which you do not have a continuous contract* in place for more than five (5) years meets or exceeds the HUB Goal the contracting agency identified in the “Agency Special Instructions/Additional Requirements”, complete:

Section 1 - Respondent and Requisition Information Section 2 a. - Yes, I will be subcontracting portions of the contract.

Section 2 b. - List all the portions of work you will subcontract, and indicate the percentage of the contract you expect to award to Texas certified HUB vendors and Non-HUB vendors.

Section 2 c. - No Section 2 d. - Yes Section 4 - Affirmation GFE Method A (Attachment A) - Complete an Attachment A for each of the subcontracting opportunities you listed in Section 2 b.

If you will be subcontracting any portion of the contract to Texas certified HUB vendors and Non-HUB vendors or only to Non-HUB vendors, and the aggregate percentage of all the subcontracting work you will be awarding to the Texas certified HUB vendors with which you do not have a continuous contract* in place for more than five (5) years does not meet or exceed the HUB Goal the contracting agency identified in the “Agency Special Instructions/Additional Requirements”, complete:

Section 2 a. - Yes, I will be subcontracting portions of the contract.

Section 2 b. - List all the portions of work you will subcontract, and indicate the percentage of the contract you expect to award to Texas certified HUB vendors and Non-HUB vendors.

Section 2 c. - No Section 2 d. - No Section 4 - Affirmation GFE Method B (Attachment B) - Complete an Attachment B for each of the subcontracting opportunities you listed in Section 2 b.

If you will not be subcontracting any portion of the contract and will be fulfilling the entire contract with your own resources (i.e., employees, supplies, materials and/or equipment), complete:

Section 2 a. - No, I will not be subcontracting any portion of the contract, and I will be fulfilling the entire contract with my own resources.

Section 3 - Self Performing Justification Section 4 - Affirmation

*Continuous Contract: Any existing written agreement (including any renewals that are exercised) between a prime contractor and a HUB vendor, where the HUB vendor provides the prime contractor with goods or service, to include under the same contract for a specified period of time. The frequency the HUB vendor is utilized or paid during the term of the contract is not relevant to whether the contract is considered continuous. Two or more contracts that run concurrently or overlap one another for different periods of time are considered by CPA to be individual contracts rather than renewals or extensions to the original contract. In such situations the prime contractor and HUB vendor are entering (have entered) into “new” contracts.

HUB Subcontracting Plan (HSP)

In accordance with Texas Gov’t Code §2161.252, the contracting agency has determined that subcontracting opportunities are probable under this contract. Therefore, all respondents, including State of Texas certified Historically Underutilized Businesses (HUBs) must complete and submit this State of Texas HUB Subcontracting Plan (HSP) with their response to the bid requisition (solicitation).

NOTE: Responses that do not include a completed HSP shall be rejected pursuant to Texas Gov’t Code §2161.252(b).

The HUB Program promotes equal business opportunities for economically disadvantaged persons to contract with the State of Texas in accordance with the goals specified in the 2009 State of Texas Disparity Study. The statewide HUB goals defined in 34 Texas Administrative Code (TAC) §20.284 are:

• 11.2 percent for heavy construction other than building contracts,

• 21.1 percent for all building construction, including general contractors and operative builders’ contracts,

• 32.9 percent for all special trade construction contracts,

• 23.7 percent for professional services contracts,

• 26.0 percent for all other services contracts, and

• 21.1 percent for commodities contracts.

- - Agency Special Instructions/Additional Requirements - -

Respondent (Company) Name:

Point of Contact:

State of Texas VID #:

Bid Open Date:

SECTION 1: RESPONDENT AND REQUISITION INFORMATION

(mm/dd/yyyy)

- Yes - No a.

b.

c.

In accordance with 34 TAC §20.285(d)(1)(D)(iii), a respondent (prime contractor) may demonstrate good faith effort to utilize Texas certified HUBs for its subcontracting opportunities if the total value of the respondent’s subcontracts with Texas certified HUBs meets or exceeds the statewide HUB goal or the agency specific HUB goal, whichever is higher. When a respondent uses this method to demonstrate good faith effort, the respondent must identify the HUBs with which it will subcontract. If using existing contracts with Texas certified HUBs to satisfy this requirement, only the aggregate percentage of the contracts expected to be subcontracted to HUBs with which the respondent does not have a continuous contract* in place for more than five (5) years shall qualify for meeting the HUB goal. This limitation is designed to encourage vendor rotation as recommended by the 2009 Texas Disparity Study.

E-mail Address:

Is your company a State of Texas certified HUB?

Requisition #:

Phone #:

Fax #:

- Yes, I will be subcontracting portions of the contract. (If Yes, complete Item b of this SECTION and continue to Item c of this SECTION.)

- Yes (If Yes, continue to SECTION 4 and complete an “HSP Good Faith Effort - Method A (Attachment A)” for each of the subcontracting opportunities you listed.)

- No (If No, continue to Item d, of this SECTION.)

- Yes (If Yes, continue to SECTION 4 and complete an “HSP Good Faith Effort - Method A (Attachment A)” for each of the subcontracting opportunities you listed.)

- No (If No, continue to SECTION 4 and complete an “HSP Good Faith Effort - Method B (Attachment B)” for each of the subcontracting opportunities you listed.)

Non-HUBs

HUBs

Enter your company’s name here: Requisition #:

SECTION 2: RESPONDENT's SUBCONTRACTING INTENTIONS

After dividing the contract work into reasonable lots or portions to the extent consistent with prudent industry practices, and taking into consideration the scope of work to be performed under the proposed contract, including all potential subcontracting opportunities, the respondent must determine what portions of work, including contracted staffing, goods and services will be subcontracted. Note: In accordance with 34 TAC §20.282, a “Subcontractor” means a person who contracts with a prime contractor to work, to supply commodities, or to contribute toward completing work for a governmental entity.

a. Check the appropriate box (Yes or No) that identifies your subcontracting intentions:

b. List all the portions of work (subcontracting opportunities) you will subcontract. Also, based on the total value of the contract, identify the percentages of the contract you expect to award to Texas certified HUBs, and the percentage of the contract you expect to award to vendors that are not a Texas certified HUB (i.e., Non-HUB).

Item # Subcontracting Opportunity Description Percentage of the contract expected to be subcontracted to

HUBs with which you do not have a continuous contract* in place for more than five (5) years.

Percentage of the contract expected to be subcontracted to

HUBs with which you have a continuous contract* in place for more than five (5) years.

Percentage of the contract expected to be subcontracted to non-HUBs.

1 %

6 %

11 %

Aggregate percentages of the contract expected to be subcontracted:

(Note: If you have more than fifteen subcontracting opportunities, a continuation sheet is available online at https://www.comptroller.texas.gov/purchasing/vendor/hub/forms.php).

c. Check the appropriate box (Yes or No) that indicates whether you will be using only Texas certified HUBs to perform all of the subcontracting opportunities you listed in SECTION 2, Item b.

d. Check the appropriate box (Yes or No) that indicates whether the aggregate expected percentage of the contract you will subcontract with Texas certified HUBs with which you do not have a continuous contract* in place with for more than five (5) years, meets or exceeds the HUB goal the contracting agency identified on page 1 in the “Agency Special Instructions/Additional Requirements.”

*Continuous Contract: Any existing written agreement (including any renewals that are exercised) between a prime contractor and a HUB vendor, where the HUB vendor provides the prime contractor with goods or service under the same contract for a specified period of time. The frequency the HUB vendor is utilized or paid during the term of the contract is not relevant to whether the contract is considered continuous. Two or more contracts that run concurrently or overlap one another for different periods of time are considered by CPA to be individual contracts rather than renewals or extensions to the original contract. In such situations the prime contractor and HUB vendor are entering (have entered) into “new” contracts.

- No, I will not be subcontracting any portion of the contract, and I will be fulfilling the entire contract with my own resources, including employees, goods and services. (If No, continue to SECTION 3 and SECTION 4.)

SECTION 2: RESPONDENT's SUBCONTRACTING INTENTIONS (CONTINUATION SHEET)

This page can be used as a continuation sheet to the HSP Form’s page 2, Section 2, Item b. Continue listing the portions of work (subcontracting opportunities) you will subcontract. Also, based on the total value of the contract, identify the percentages of the contract you expect to award to Texas certified HUBs, and the percentage of the contract you expect to award to vendors that are not a Texas certified HUB (i.e., Non-HUB).

Item # Subcontracting Opportunity Description

HUBs Non-HUBs

16 % % %

Aggregate percentages of the contract expected to be subcontracted:

HSP – SECTION 2

(Continuation Sheet)

*Continuous Contract: Any existing written agreement (including any renewals that are exercised) between a prime contractor and a HUB vendor, where the HUB vendor provides the prime contractor with goods or service under the same contract for a specified period of time. The frequency the HUB vendor is utilized or paid during the term of the contract is not relevant to whether the contract is considered continuous. Two or more contracts that run concurrently or overlap one another for different periods of time are considered by CPA to be individual contracts rather than renewals or extensions to the original contract. In such situations the prime contractor and HUB vendor are entering (have entered) into “new” contracts.

Percentage of the contract expected to be subcontracted to

HUBs with which you do not have a continuous contract* in place for more than five (5) years.

Percentage of the contract expected to be subcontracted to

HUBs with which you have a continuous contract* in place for more than five (5) years.

Percentage of the contract expected to be subcontracted to non-HUBs.

SECTION 3: SELF PERFORMING JUSTIFICATION (If you responded “No” to SECTION 2, Item a, you must complete this SECTION and continue to SECTION 4.) If you responded “No” to SECTION 2, Item a, in the space provided below explain how your company will perform the entire contract with its own employees, supplies, materials and/or equipment.

SECTION 4: AFFIRMATION

As evidenced by my signature below, I affirm that I am an authorized representative of the respondent listed in SECTION 1, and that the information and supporting documentation submitted with the HSP is true and correct. Respondent understands and agrees that, if awarded any portion of the requisition:

• The respondent will provide notice as soon as practical to all the subcontractors (HUBs and Non-HUBs) of their selection as a subcontractor for the awarded contract. The notice must specify at a minimum the contracting agency’s name and its point of contact for the contract, the contract award number, the subcontracting opportunity they (the subcontractor) will perform, the approximate dollar value of the subcontracting opportunity and the expected percentage of the total contract that the subcontracting opportunity represents. A copy of the notice required by this section must also be provided to the contracting agency’s point of contact for the contract no later than ten (10) working days after the contract is awarded.

• The respondent must submit monthly compliance reports (Prime Contractor Progress Assessment Report – PAR) to the contracting agency, verifying its compliance with the HSP, including the use of and expenditures made to its subcontractors (HUBs and Non-HUBs). (The PAR is available at https://www.comptroller.texas.gov/purchasing/docs/hub-forms/ProgressAssessmentReportForm.xls).

• The respondent must seek approval from the contracting agency prior to making any modifications to its HSP, including the hiring of additional or different subcontractors and the termination of a subcontractor the respondent identified in its HSP. If the HSP is modified without the contracting agency’s prior approval, respondent may be subject to any and all enforcement remedies available under the contract or otherwise available by law, up to and including debarment from all state contracting.

• The respondent must, upon request, allow the contracting agency to perform on-site reviews of the company’s headquarters and/or work-site where services are being performed and must provide documentation regarding staffing and other resources.

Printed Name Title Date (mm/dd/yyyy)

Signature

Reminder:

If you responded “Yes” to SECTION 2, Items c or d, you must complete an “HSP Good Faith Effort - Method A (Attachment A)” for each of the subcontracting opportunities you listed in SECTION 2, Item b.

If you responded “No” SECTION 2, Items c and d, you must complete an “HSP Good Faith Effort - Method B (Attachment B)” for each of the subcontracting opportunities you listed in SECTION 2, Item b.

HSP…