ESBD_360574_1716568449335_010 IFB - LQB_Vertical_Alternates_10.1.23.pdf

CITY OF SAN ANTONIO

Issued By: Building & Equipment Services Department Date Issued: May 24, 2024

ID NO.: 35-00301

(010) LOW QUALIFIED FORMAL INVITATION FOR BIDS (IFB) to CONTRACT

Underground Fuel Tank - PTA

Form 010 Invitation for Bids (IFB) Revised 10/2023

Online bidding is utilized via CivCast at https://www.civcastusa.com/bids. Online bid services will open for bidding on Friday, May 24, 2024 and close on Tuesday, June 25, 2024 at 2:00 P.M. CT. Follow submittal instructions on https://www.civcastusa.com/. Hard Copies will not be accepted for this solicitation. Bids will be opened and the Bid Results will be posted on CivCast on the day of the bid deadline.

Bid Results will be read aloud utilizing WebEx. Access WebEx by phone at 1-415-655-0001 and/or https://www.webex.com/ with Access

Code: 1770 23 1452, Password: 3HrMPWvWr58.

A Non-Mandatory Pre-bid meeting will be held through WebEx on Tuesday, June 4, 2024 at 10:00 A.M. CT and a Site Visit will be held at 2:00 P.M. CT at the San Antonio Police Training Academy, located at 12200 South East Loop 410, San Antonio, Texas, 78224. Access the WebEx by phone at 1-415-655-0001 and/or https://www.webex.com/ with Access Code: 2633 040 0344, Password: 6VjJMA9msJ8.

The Deadline for questions is scheduled for June 11, 2024 at 4:00PM (CT).

The estimated construction budget for this contract is $600,000.00.

There will be seven Alternates for this project.

Bidder acknowledges that this is a unit price contract; that unit prices established will remain in effect and valid throughout the duration of the contract; the quantities shown are estimated quantities for budgetary purposes only; the award of this contract does not guarantee contractor the entire work shown in this FORMAL INVITATION FOR BID (IFB); the City of San Antonio (City) may order all, some, or none of the work shown in this IFB; and projects will be assigned as they become available. City may elect to award this Project based solely on the base bid, based on a combination of the base bid plus any combination of selected alternates or based on a combination of the base bid plus all alternates that serve the best interest of City. All bids must include a price for all units or line items, including any alternates. Entering a price of “$0.00” shall mean the units or line items will be provided at no cost to City. A unit price left blank shall result in the bid being deemed nonresponsive and disqualified from consideration. City reserves the right to delete line items prior to award.

This invitation includes the following Contract Documents which are required downloads in CivCast:

010 Invitation for Bids 076 Payment Bond

020 Contract Signature Page 081 General Conditions for Construction Contracts

030 Experience & Qualifications Form w/Project Sheets ◘ Local Preference Program Identification Form

040 Standard Instructions to Respondent ◘ VOSB Program Tracking Form

041 Certificate of Interested Parties (TEC Form 1295) ◘ Wage Decision

060 Supplemental Conditions ◘ Insurance Requirements

075 Performance Bond ◘ Heat Illness Prevention Acknowledgment Form

The City of San Antonio point of contact for this solicitation is Procurement Specialist II, Peter Duro, Peter.DuroJR@sanantonio.gov.

Questions are to be submitted in writing in the Questions and Answers section on CivCast. Bidder understands and agrees to the responsibility for obtaining any and all addenda and adhering to all requirements in addenda. City is not responsible for incorrect information obtained through other sources.

Bid Documents must contain “Legal Name of Company” as listed by the Texas Secretary of State Registry (http://www.sos.state.tx.us/).

The documents required in CivCast (fully completed and with digital signatures) constitute the required information to be submitted as a part of the bid proposal.

The following documents constitute the required information to be submitted as a part of the bid proposal and are required uploads in CivCast:

020 Contract Signature Page ◘ Local Preference Program Identification Form

030 Experience & Qualifications Form w/Project Sheets ◘ VOSB Program Tracking Form

◘ Bid Bond ◘ Heat Illness Prevention Acknowledgment Form

◘ TEC Form 1295 Certification Number & Date

It is understood and agreed that the work is to be substantially completed on or before 100 calendar days. This project does not include hazardous environmental work. This project requires 0 project sign(s).

Local Preference Program Ordinance – For more detailed information on the Local Preference Program Ordinance, see solicitation document “040 Standard Instructions to Respondent”, section 5.

Veteran-Owned Small Business Preference Program – For more detailed information on the Veteran-Owned Small Business Preference

Program, see Ordinance No. 2013-12-05-0864 and solicitation document “040 Standard Instructions to Respondent”, section 6.

https://www.civcastusa.com/bids https://www.civcastusa.com/ https://www.webex.com/ https://www.webex.com/ mailto:Peter.DuroJR@sanantonio.gov http://www.sos.state.tx.us/

Form 010 Invitation for Bids (IFB)

Responsible Bidder Ordinance – For more detailed information on the Responsible Bidder Ordinance, see Ordinance No. 2023-01-26-

0041 and solicitation document “040 Standard Instructions to Respondent”, section 7.

Heat Illness Ordinance – For more detailed information on the Heat Illness Ordinance, see Ordinance No. 2023-08-31-0585 and General

Conditions for Construction Contract, Article X.1.5 and Art.X.2.3(a).

Bid Protest Procedures – See solicitation document “040 Standard Instructions to Respondent”, section 11.

Wage Decision – Bidder shall meet the prevailing wage rate requirements established for this contract and shall reference the wage decision posted with this solicitation on the City’s website.