ESBD_359842_1715979241790_802-24-48343_40-45 ft Aluminum Boat Packages_LE.pdf

IFB No. 802-24-48343 Page 1 of 35

INVITATION FOR BID

SEND INVOICE TO: RETURN BIDS TO BIDDER MUST SIGN BELOW

Texas Parks and Wildlife Department ATTN: Accounts Payable 4200 Smith School Road Austin, Texas 78744

Purchasing.BidBox@tpwd.texas.gov FAX 512-389-4677, or return to:

TPWD - Purchasing and Contracting 4200 Smith School Road Austin, Texas 78744

BID DUE: 2:00 PM June 4, 2024

REQUISITION NO. 802-24-48343

Page 1 35

By signing this bid, bidder certifies that if a Texas address is shown as the address of the bidder, bidder qualifies as a Texas bidder as defined in Title 34 TAC Rule 20.32(68). FAILURE TO MANUALLY SIGN THE BID ABOVE WILL DISQUALIFY BID.

AWARD NOTICE: The State reserves the right to make an award on the basis of low line-item bid, low total of line items, or in any other combination that will serve the best interest of the State and to reject any and all bid items in the sole discretion of the State.

Item Description Class/Item 120-23, 120-63, 120-90 Quantity Unit of

Measure Unit Price Extension

Texas Parks and Wildlife Department (TPWD) is seeking to purchase two (2) each 40–45-foot Mono Step Hull custom-built aluminum boats, eight (8) Outboard Motors, two (2) Boat Trailers, and Accessories for the Law Enforcement Division as per the attached specifications dated May 2024.

TPWD will only award a contract for eight (8) outboard motors. Unless Dual Prop is bid by respondent, TPWD will require four (4) Each Counter Rotation and four (4) Each Standard rotation motors. Each vessel shall be powered by four (4) outboard motors.

TPWD will review bids and award based on best value. See best value factors in Section II General Terms and Conditions Subsection 3.3 Best Value.

NOTE: Two boat, motor, and trailer packages (with accessories) shall be delivered fully assembled as single units. However, for property reporting purposes, TPWD requires line-item cost for each item.

1.

40 – 45 ft. Mono Step Hull Aluminum Boat

Example: Metal Shark Fearless 42, Metal Craft Interceptor 12m, or TPWD approved equivalent

Specify Make/Model ____________________________________

Specify Warranty ______________________________________

Each

AUTHORIZED SIGNATURE DATE

SHOW BID OPENING

DATE AND REQUISITION

NUMBER ON SEALED BID

ENVELOPE AND SHOW

RETURN ADDRESS OF FIRM

BIDDER AGREES TO

COMPLY WITH ALL

CONDITIONS OF THIS BID.

BID F.O.B. AGENCY RECEIVING ROOM

UNLESS OTHERWISE SPECIFIED BELOW

DESTINATION IF DIFFERENT THAN ABOVE

Texas Parks and Wildlife Department TPWD LE Region 8 Office 5541 Bear Lane, Ste. 232 Corpus Christi, TX 78405

See instructions for Texas ID Number in General Terms & Conditions, Paragraph 1.10.

Bidder Must Fill in

TEXAS ID NUMBER

Name of Firm Street Address City–State-Zip Telephone No.

Email address

FAILURE TO

MANUALLY

SIGN WILL

DISQUALIFY BID

mailto:Purchasing.BidBox@tpwd.texas.gov

IFB No. 802-24-48343 Page 2 of 35

2a.

350hp Standard Rotation or Dual Prop Outboard Motor for Mono Step Hull Aluminum Boat described in Line 1

Example: Mercury 350 Verado Standard Rotation prop, Suzuki DF350 AMD Standard Rotation Prop or dual prop, or TPWD approved equivalent.

2b.

350hp Counter Rotation or Dual Prop Outboard Motor for Mono Step Hull Aluminum Boat described in Line 1

Example: Mercury 350 Verado Counter-Rotating Prop, Suzuki DF350 AMD Counter-Rotating Prop or dual prop, or TPWD approved equivalent.

Specify Make/Model____________________________________

2c. 350hp Duo Prop Outboard Motor for Mono Step Hull Aluminum Boat described in Line 1

Example: Mercury 350 Verado Dual Prop, Suzuki DF350 AMD Dual Prop, or TPWD approved equivalent.

Specify Make/Model____________________________________

3.

Boat Trailer for 40-45 ft. Mono Step Hull Aluminum Boat described in Line 1

Example: Evolution custom built trailer, Boat Master custom-built trailer, or TPWD approved equal

4.

Delivery fee for TWO (2) complete Boat Packages (boat, outboard motor, and trailer) to TPWD LE Region 8 Office –

Delivery in ________ calendar days after receipt of order.

Lot

IFB No. 802-24-48343 Page 3 of 35

OPTIONAL ACCESSORIES: Accessory items as described in Section 1, Subsection 3.5 Accessories may be awarded in part, in whole, or none, based on the availability of funds. Cost of each item shall include installation. Determination will be made at the time of award. Quantities listed below are total number required for both boats.

Item Description Class/Item 120-23, 120-63, 120-90 Quantity Unit of Measure Unit Price Extension

5.

5a.

5b.

5c.

5d.

5e.

5f.

5g.

5h.

5i.

5j.

5k.

5l.

5m.

5n.

5o.

OPTIONAL ACCESSORIES AS FOLLOWS:

Cup Holders (specify make) ______________________________

Dome Light (specify make) _______________________________

Flood Light (specify make) _______________________________

Spotlight (specify make) _________________________________

Controller (specify make) ________________________________

Siren (specify make) ____________________________________

Speaker (specify make) _________________________________

Signal (specify make) ___________________________________

Electronics Package (specify make)

FM/AM Satellite Radio (specify make)

Cutoff Switch (specify make) _____________________________

VHF Radio (specify make) _______________________________

Integrated Comms System (specify make)

Star Link Satellite Marine Internet__________________________

Emergency Position Indicating Radio Beacon (EPRIB)

IFB No. 802-24-48343 Page 4 of 35

6.

Respondents are highly encouraged to submit a detailed price list for additional related accessories and attachments.

Cost of each item shall include installation. TPWD reserves the right to award one, none, or any combination of options depending on the availability of funds and as determined to be best value.

Determination will be made at the time of award. Optional items will not be included in the evaluation process.

ATTACH PRICE LIST

Offered by a Historically Underutilized Business certified by CPA.

PREFERENCES

See Appendix 22 of the State of Texas Procurement and Contract Management Guide regarding preferences.

Check below to claim a preference under Title 34 TAC Rule 20.38

□ Goods produced or offered by a Texas bidder that is owned by a Texas resident service-disabled veteran

□ Goods produced in Texas or offered by a Texas bidder that is not owned by a Texas resident service-disabled veteran

□ Agricultural products grown in Texas

□ Agricultural products offered by a Texas bidder

□ Services offered by a Texas bidder that is owned by a Texas resident service-disabled veteran

□ Services offered by a Texas bidder that is not owned by a Texas resident service-disabled veteran

□ Texas Vegetation Native to the Region

□ USA produced supplies, materials, or equipment

□ Products of persons with mental or physical disabilities

□ Products made of recycled, remanufactured, or environmentally sensitive materials including recycled steel

□ Energy Efficient Products

□ Rubberized asphalt paving material

□ Recycled motor oil and lubricants

□ Products produced at facilities located on formerly contaminated property

□ Products and services from economically depressed or blighted areas

□ Vendors that meet or exceed air quality standards

□ Recycled or Reused Computer Equipment of Other Manufacturers

□ Foods of Higher Nutritional Value

FOR FURTHER INFORMATION CONTACT PURCHASER:

Christina M. Brown, CTCD/CTCM – Telephone – 903-920-2185 Email: purchasing.bidbox@tpwd.texas.gov mailto:purchasing.bidbox@tpwd.texas.gov

IFB No. 802-24-48343 Page 5 of 35

Solicitation 802-24-48343 Specifications for 40-45 ft. Aluminum Boat Packages

1. INTRODUCTION: Texas Parks and Wildlife Department (TPWD) is seeking to purchase two (2) 40 – 45 ft.

Mono Step Hull Aluminum Boats, eight (8) Outboard Motors, two (2) Boat Trailers, and Accessories for the Law Enforcement Division as per the attached specifications dated May 2024.

2. TERM OF CONTRACT: Contract shall commence upon the issuance of a contract by TPWD and automatically expire upon the delivery date agreed upon and final acceptance by TPWD.

3. SPECIFICATIONS SHALL MEET OR EXCEED THE FOLLOWING:

3.1. Line 1 - 40 to 45’ Aluminum Boat

3.1.1. Examples: Metal Shark Fearless 42, Metal Craft Interceptor 12m, or TPWD approved equivalent.

3.1.2. Quantity: Two (2)

3.1.3. Requirement: Boat must conform to 33CFR, Code of Federal Regulations (Part #183)

3.1.4. Length: Approximately forty feet to forty-five feet (40-45’)

3.1.5. Beam: Approximately one hundred twenty inches to one hundred sixty-six inches (120” to 166”)

3.1.6. Weight: Maximum thirty thousand pounds (30,000 lbs.)

3.1.7. Draft: Twenty-eight to thirty-two inches (28”-32”)

3.1.8. Chine Length: To run full length of hull for stability and control.

3.1.9. Color: Grey color with black trim or TPWD approved equal, no decals

3.1.10. Fuel type, Tank and Storage:

A. Fuel Type: Gasoline

B. Tank Capacity: Approximately four hundred to six hundred gallons (400 to 600 gal.)

C. Fuel cell shall be American Boat and Yacht Council (ABYC) approved polyurethane with external fuel sending device with single drain line to bilge area of the boat.

3.1.11. Batteries: Eight (8) marine battery system with isolator. eight (8) battery boxes.

A. Four (4) cranking batteries.

B. Four (4) house batteries with 24v – 12v inverter.

3.1.12. Navigation Lights: United States Coast Guard (USCG) approved navigation lights shall be installed in accordance with USCG requirements.

A. Port and starboard navigation lights shall be mounted near or on T-Top or console.

B. All around white navigation lights shall be mounted to the top rear of the T-Top.

3.1.13. Bilge Pump: Minimum of two (2) each, five hundred gallons per hour (500 gph)

3.1.14. Boat Construction:

IFB No. 802-24-48343 Page 6 of 35

A. Boat hull shall be constructed of aluminum, step type hull.

B. Aluminum shall be 5086 Marine Aluminum Alloy.

C. Electric trim tabs with switches and components. Example: K-plane trim tabs or TPWD approved equivalent.

D. Steering system and components: See Section 4.2.14.

E. Wiring:

(i) Shall be marine grade tinned wire of appropriate size.

(ii) Shall be installed and color coded according to ABYC standards.

(iii) Wiring connections shall be soldered and shrink wrapped.

F. Deck hardware: Minimum of eight (8) cleats installed; four (4) starboard and four (4) port.

G. Transom Deck:

(i) Raised deck across transom with hatch, sealed storage compartments with aluminum hatch covers to mount battery.

H. Bow Deck:

(i) Raised bow deck to gunwale with hatched, sealed storage compartments with aluminum hatch covers and drains.

(ii) Bow deck shall have nonskid medium gray surface.

(iii) The bow deck must feature a six-foot (6’) platform that aligns with the gunnels, facilitating easy boarding with central steps. Storage boxes should extend along both the starboard and port sides from the platform, designed for storing weapons and a bandit reel. Storage boxes must be a minimum of four feet (4’) in length and match the height of gunnels.

(iv) Bow deck should be equipped with a removable pedestal to hold 240 weapons, along with removable handrails.

(v) Shall be equipped with a twenty-four-volt (24v) plug installed for powering Bandit reel.

(vi) Pusher knee shall be installed on the front of the boat for boardings.

3.1.15. Center Console:

A. Console shall be full width, full length T-Top designed for three-row seating with two (2) seats per row. The second row of seats must also include a console for additional navigation screen and communications. The third row shall have rear bulkhead dedicated to storing weapons and other equipment, or TPWD approved equivalent. Reference Item J.

for specifications for seating.

B. Console shall have six (6) sealed twelve-volt (12V) accessory plugs. Location of plugs shall be determined by TPWD upon award.

C. Electrical switches shall be waterproof, marine panel switch type.

IFB No. 802-24-48343 Page 7 of 35

D. Console shall have Marine boat rocker electrical switch panel, eight (8) gang waterproof toggle switches, digital voltage display, two (2) Universal Serial Bus (USB) poser charges adapters, and one (1) 12-volt accessory plug.

E. Console instrumentation shall include Tachometer, Speedometer, Water pounds per square inch (PSI) and temperature, fuel gauge, and hour meter.

G. Two (2) blue light-emitting diode (LED) lights shall be mounted on top of the console.

H. Main grounding lug/bar shall be located under the console for grounding of all installed accessories.

I. Main power lug/bar shall be located under the console for powering all installed necessary electronics.

J. Shall be equipped with windshield wipers for the front windshield of console.

K. Seating:

(i) Three (3) rows of shock mitigating seats with two (2) seats in each row. Examples:

Shockwave, SHOXS, or TPWD approved equivalent.

(ii) Leaning post mounted at the rear of the third row of seats with storage locker for patrol rifles and additional storage.

(iii) Seat material shall be waterproof. Color shall be black or TPWD approved color.

L. Radio Storage Compartment: Shall be installed on the top section of console, situated in front, just behind the windshield, and positioned above the seats for both the captain and co-pilot.

3.1.16. T-Top:

A. Shall be full width, full length, and accommodate three-row seating and heavy-duty aluminum compartment to house Motorola Apex radio head, VHF radio, and sirens.

B. Shall be welded to outside edge of top at each corner with three-eighths inch (3/8”) hole in center of tab to facilitate emergency light mounting. A folding radar arch shall be attached to the top of console, and T-Top shall be able to accommodate multiple antennas and additional places for mounting future equipment.

C. Cable pull wires shall be installed inside the T-Top uprights from the bottom to the top of the frame, suitable for pulling electronic wires through the T-Top for any future wiring of additional electronics.

3.1.17. Shall be equipped with a rub rail that is made of Gilman Corp Softlite Ionomer foam or TPWD

A. Foam fender shall be “Half D’ configuration based on sixteen-foot (16’) diameter fender 12” OD x 6” standoff x 72” LG, Type 450. Color shall be black with channel slots for attachment.

3.1.18. Stainless steel steering wheel with turning knob.

3.1.19. Shall be equipped with USCG approved fire extinguisher for vessel type.

3.2. Lines 2a, 2b, and 2c – 350 HP Outboard Motor for Fiberglass Boat described in Section 3.1.

3.2.1. Examples: Mercury Verado 350, Suzuki DF350 AMD, or TPWD approved equivalent.

IFB No. 802-24-48343 Page 8 of 35

3.2.2. Quantity: Eight (8) each, or number of outboard motors approved by TPWD for optimal performance.

A. If Respondent is bidding Dual Prop Outboard Motor, 8 Each will be required. If Respondent is not bidding Dual Prop, TPWD will require four (4) each Standard Rotation and four (4) Each Counter Rotation outboard motors.

3.2.3. Shall be compatible with the aluminum boat listed above in Section 4.1.

3.2.4. Horsepower (HP): 350 HP

3.2.5. Engine type: V6 or V8

3.2.6. Shaft Length: Twenty-five inches (25”) dependent upon manufacturer’s specification. Shaft length shall be appropriate for the boat model specified.

3.2.7. California Air Resource Board (CARB) Rating: Minimum 3-star rating

3.2.8. Gear Shift: Forward, neutral, reverse.

3.2.9. Rotation: Standard, Counter, or Duo Propeller

3.2.10. Full Throttle range, RPM: In an approximate range from 5,000 to 6,300 RPM.

3.2.11. Fuel induction system: Electronic Fuel Injection (EFI)

3.2.12. Starting: Electric Start

3.2.13. Steering: Integrated

A. Preferred fly by wire system.

B. If Respondent is bidding a power assisted hydraulic system, it must be constructed with commercial grade components for commercial use.

A. Must provide a steering system with all appropriate components for optimal performance of the vessel and outboard motor.

3.2.14. Color: Black, Gray, or TPWD approved equivalent

3.2.15. Propeller:

A. Shall have compatible propeller for aluminum boat listed above.

B. Pitch: Must provide a propeller with an appropriate pitch for optimal performance.

A. Material: Stainless steel

3.2.16. Motor shall be installed on boat by Respondent and fully operational with all required controls and gauges.

3.3. Line 3 – Boat Trailer for Aluminum Boat with mounted 350hp Outboard motors as described in Section 3.2.

3.3.1. Examples: Evolution custom built trailer, Boat Master custom-built trailer, or TPWD approved equivalent.

3.3.2. Quantity: Two (2)

IFB No. 802-24-48343 Page 9 of 35

3.3.3. Trailer material: Aluminum

3.3.4. Capacity: Suitable to fit and transport boat and outboard motors specified above.

3.3.5. Length: Shall be of appropriate and safe length to transport boat with installed outboard motors.

3.3.6. Axle: Galvanized triple axel with buddy bearing, lubricated hubs, or TPWD approved equivalent.

3.3.7. Tires and Wheels:

A. Shall be new radial trailer-rated tires specifically for the load.

B. Shall include one (1) mounted spare wheel and carrier.

A. Wheel material shall be galvanized.

3.3.8. Fenders: Aluminum

3.3.9. Mechanical Tongue-mounted Jack: Retractable / foldable with wheel for ground contact, and properly sized for boat, motors, and trailer.

3.3.10. Lighting: Trailer shall be equipped with fully grounded, waterproof, submergible LED lighting that meets Texas Department of Transportation (TXDOT) regulation standards, with 4-prong connector.

3.3.11. All wiring shall meet TXDOT requirements.

3.3.12. Safety chains, transom saver, and guidepost.

3.3.13. Transom tie downs to secure boat to trailer.

3.3.14. Treated wood or composite bunking.

3.3.15. Aluminum I-beams and welded bunk under structure

3.3.16. Aluminum guidepost with polyvinyl chloride (PVC) cover / rollers with stainless pins

3.3.17. Heavy duty three-piece bow stop

3.3.18. All hardware and submersible parts shall be stainless steel.

3.3.19. Mechanical winch with strap and bow hook

3.3.20. Two and five eighths inch (2 5/8”) ball hitch

3.3.21. Rollers shall be minimum size twelve inches (12”).

3.3.22. Shall include two (2) boat buckles:

A. Examples: G2 retractable transom tie downs, Fulton Transom tie downs, or TPWD approved equivalent

B. Shall be installed by Respondent at rear of trailer for proper transom stabilization.

3.3.23. Trailer to be equipped in accordance with federal and State of Texas laws governing 24-hour highway operation.

3.4. Line 4 – Refer to delivery information in Section 7, Subsection 7.3. Delivery and Acceptance

IFB No. 802-24-48343 Page 10 of 35

3.5. Line 5 – Optional Accessory Items: Optional accessory items may be awarded in part, in whole, or none based on funds availability. Determination will be made at the time of wared. Cost of each item shall include installation. Accessories to be priced as separate line items shall include:

3.5.1. Cup Holders: Six (6) each per boat, location to be determined after award.

3.5.2. Dome Lights: Three (3) each per boat

A. Examples: i2Systems Tri-Color LED recessed light, ITC Tri-Color LED Light, or TPWD

B. Color: Marine grade Tri-Color LED light with red, white, and blue selection.

C. Location/ placement to be determined by TPWD after award.

3.5.3. Flood Lights: Three (3) each per boat.

A. Examples: Rigid Industries E-Series PRO ten-inch (10”) flood diffused white LED lights, Vision X Marine Grade Horizon Prime Xtreme LED fourteen-inch (14”) light bar, or TPWD

B. Color: White

C. Shall be installed by Respondent on T-Top as follows: One (1) center port side, one (1) center starboard side, and one (1) center stern side. Lights shall be wired to rocker switch panel.

3.5.4. Spotlight: Four (4) per boat

A. Examples: Vision X Marine Grade, Xmitter Low Pro Extreme LED bar 12.2”, Rigid Industries SR Series Pro 10” LED light, or TPWD approved equivalent.

B. Color: White

C. Shall be mounted and installed by Respondent on T-top, centered bow side, and wired to rocker switch panel.

3.5.5. Controller: One (1) per boat

A. Examples: Feniex 4200 Mini X Controller, Federal Signal Smart Controller Series B, or TPWD approved equivalent.

B. Shall be mounted and installed by Respondent on top starboard side of center console with necessary hardware and mounting plates.

3.5.6. Siren: One (1) per boat

A. Examples: Feniex Storm Pro 100-watt Siren, Federal Signal Smart Siren Platinum, or

TPWD approved equivalent.

B. Shall be mounted and installed by Respondent in T-Top electronics box. Accompanying microphone shall be mounted outside the T-Top electronics box on the starboard side with a properly weather sealed grommet to protect microphone cord.

3.5.7. Speaker: One (1) per boat

A. Examples: Feniex Triton 100-watt Siren Speaker, Federal Signal BP100 Series Siren

Speaker, or TPWD approved equivalent.

IFB No. 802-24-48343 Page 11 of 35

B. Shall be mounted and installed by Respondent in T-Top in the front of the electronics box facing the bow.

3.5.8. Signal: Two (2) per boat

A. Examples: Feniex Fusion Mini Lightbar, all blue LED, Federal Signal 18” Navigator Discrete all blue LED Light bar, or TPWD approved equivalent.

B. Shall be mounted / installed on the port and starboard side by Respondent on top of T-Top with adequate support plate and wired to controller.

3.5.9. Electronics Package: One (1) per boat

A. Examples: Raymarine Axiom Pro 16 RVX with Platinum + SD 365 Est Gulf of Mexico and

Mexico and RV-100 All-in-One Transom 8M with 170s Multifunction Color Display and AIS5000 Transponder Bundle and AR200 Augmented Reality with Quantum 2 Q24D Doppler 18” Radar, or TPWD approved equivalent.

B. To be installed and mounted by Respondent on top of center console with necessary hardware and mounting plates. Transducers to be mounted in appropriate place on vessel to avoid any interference with transmitting and receiving appropriate signals.

C. Shall be separately wired with main power line coming from battery and with main power disconnect switch wired into the six (6) panel rocker installed on the console.

3.5.10. Wireless Engine Cutoff Switch System: Six (6) Each per boat

A. Examples: Fell Marine MOB+, or TPWD approved equivalent.

B. Must meet ABYC A-33 standard for Engine cutoff devices.

C. Shall be installed in addition to the manufacturer’s installed manual switch and not replace it.

D. Must include a minimum of six (6) wireless devices for the vessel’s occupants.

E. Shall be installed and mounted by Respondent per manufacturer’s instructions and fully operational upon delivery.

3.5.11. VHF Radio: Two (2) Each per boat

A. Examples: Standard Horizon GX 1400B VHF with Antenna, G3 Ray 53 VHF Radio with

VHF Antenna, 8’, 6db, or TPWD approved equivalent.

B. Shall be mounted and installed by Respondent in T-Top Electronics box. Accompanying microphone shall be mounted outside the T-Top electronics box on the starboard side with a properly weather sealed grommet to protect the microphone cord.

3.5.12. AM/FM Satellite Radio: One (1) per boat

A. Examples: JL Audio, FUSION, JBL, or TPWD approved equivalent.

B. Shall have four (4) marine grade speakers: Two (2) in the front on the console facing towards the stern and two (2) in rear of the bulkhead facing towards the bow.

C. Wiring and connections shall be waterproof.

3.5.13. Integrated COMMS System: One (1) Each per boat

IFB No. 802-24-48343 Page 12 of 35

A. Examples: SetComm, Sampson Racing, or TPWD approved equivalent.

3.5.14. Starlink Marine Satellite Internet: Quantity of one (1) per boat.

A. Mobile Priority, 50GB

B. Download: 40-220+MBPS

C. Upload: 8-25+MPTS

D. Latency: Less than 99MS

3.5.15. Emergency Position-Indicating Radiobeacon (EPRIB) capable of transmitting a digital 406 MHz distress signal that contains a unique 15-digit identifier to the Cospas-Sarsat Satellite System shall be installed.

A. Quantity of one (1) each per boat.

4. REFERENCED BRAND EXAMPLE: Catalogs, brand names or manufacturer's references are descriptive only, and indicate type and quality desired. Proposals on brands of like nature and quality will be considered. If proposing other than the referenced brands/model number, Respondent must show manufacturer, brand or trade name, product number and provide complete descriptive information of product offered and include with response. Failure to take exception to specifications or reference data will require Respondent to furnish specified brand names, numbers, etc.

5. REQUIREMENTS:

5.1. Condition of Product: New Equipment ONLY; NO re-manufactured or “gray market” items. All items must be covered by the manufacturer’s warranty. The unit shall be made ready for continuous operation upon delivery. Responded is cautioned that any unit delivered to the FOB point that does not meet specifications in every aspect will not be accepted.

5.2. All Parts: All parts not specifically mentioned which are necessary for the unit to be complete and ready for operation or which are normally furnished as standard equipment shall be furnished by the vendor. All parts shall conform in strength, quality, and workmanship to the accepted standards of the industry.

5.3. Quantities: Quantities listed are projected order quantities. TPWD reserves the right to increase or decrease quantities prior to award depending on bid results and budget constraints.

5.4. Manuals: Manuals containing illustrated parts list, operating and service instructions for the unit shall be delivered with unit. Manual shall outline all necessary service and operating instructions for the unit delivered and provide necessary warning and safety precautions.

5.5. Warranty Requirements: The unit shall be warranted against defects in material and workmanship for the Manufacturer’s Standard Warranty for government use. The warranty begins on the date the unit is determined to meet specifications and accepted by TPWD.

6. DELIVERY AND ACCEPTANCE:

6.1. Freight Charges: Shipping shall be F.O.B. destination; therefore, unit prices must include all shipping, handling, fuel surcharges and delivery fees.

6.2. Delivery Schedule and Requirements:

6.2.1. Vendor must contact TPWD point of contact as shown on any resulting contract award or purchase order to schedule delivery date and time. Vendor shall provide one (1) week notice prior to delivery to contact designated on purchase order.

IFB No. 802-24-48343 Page 13 of 35

6.2.2. Respondent shall provide delivery terms with bid response. Delivery may be a factor in determining best value award.

6.2.3. TPWD does not have a loading dock to unload fully assembled boat/motors/trailer packages upon delivery. Delivery shall be made by means and method that does not require TPWD to unload at no additional cost to TPWD.

6.3. Delivery Address:

Line 4: TPWD LE Region 8 Office 5541 Bear Lane, Suite 232

6.4. Registration and Titling: Respondents shall title and register as EXEMPT registration, all equipment requiring titling and registration to the address listed below once received by TPWD. The original Manufacturer’s Statement of Origin (MSO) as well as the most current version of TxDMV form 130U or Application for Texas Title, with signature shall be submitted to:

Texas Parks and Wildlife Department Attn: John Wyatt, Fleet Manager 4200 Smith School Road Austin, TX 78744

6.5. Delivery Delays: If delay is foreseen, Contractor shall give written notice to TPWD and must keep TPWD advised at all times of status of order. Default in promised Delivery Days After Receipt of Order (ARO) without accepted reasons or failure to meet specifications authorizes TPWD to purchase goods and services of this contract elsewhere and charge any increased costs for the goods and services, including the cost of re-soliciting, to the Contractor.

6.6. Compliant Products: Delivery does not occur until the Contractor delivers products, materials, or services in full compliance with the specifications to Customer’s F.O.B. destination, unless delivery is specifically accepted, in whole or in part, by the Customer. Providing products, materials or services which do not meet all specification requirements does not constitute delivery. Customer reserves the right to require new delivery or a refund in the event that materials or products not meeting specifications are discovered after payment has been made.

6.7. Acceptance: All equipment ordered will be subject to acceptance inspection and performance testing upon receipt. Acceptance inspection and performance testing will not take more than five (5) working days, weather permitting. Vendor will be notified within this time frame of any units not delivered in full compliance with the purchase order specifications.

7. INQUIRIES:

7.1. CONTACT: All requests, questions, or other communications about this Solicitation shall be made in writing to TPWD’s Purchasing Department, addressed to the following person:

Christina M. Brown, Purchaser Phone 903-920-2185 Texas Parks & Wildlife Department Fax 512-389-4677 4200 Smith School Road, Austin, Texas 78744 christina.brown@tpwd.texas.gov

7.2. CLARIFICATIONS: TPWD will allow written requests for clarification of this Solicitation. Questions may be faxed or e-mailed to the point-of-contact listed above. Questions should be submitted in the following format: a) Reference the Solicitation number; b) Reference the Section number, Page number, Paragraph number, and Text of passage being questioned; and c) Question.

7.3. PROHIBITED COMMUNICATIONS: Upon issuance of this solicitation, TPWD, its representative(s), or partners will not answer questions or otherwise discuss the contents of this Solicitation with any potential Respondent or their representative(s), except for the written inquires described in Section

7.2 above. Attempts to ask questions by phone or in person will not be allowed or recognized as mailto:christina.brown@tpwd.texas.gov

IFB No. 802-24-48343 Page 14 of 35 valid. Failure to observe this restriction may disqualify respondent. Respondent shall rely only on written statements issued through or by TPWD’s purchasing staff. This restriction does not preclude discussions between affected parties for the purposes of conducting business unrelated to this solicitation.

8. BID RESPONSE INSTRUCTIONS:

8.1. Bid Submission:

8.1.1. Submission Deadline: All bids shall be received, and time stamped at TPWD prior to 2:00 PM

Central Time on the “Bid Opening” date specified on the IFB Cover Page (page 1). Late bids will not be considered under any circumstance and will be returned.

8.1.2. General Format: Respondent shall submit bid response, signed dated and completed.

8.1.3. Bid Delivery: Bids may be returned via email to Purchasing.BidBox@tpwd.texas.gov, mail, hand-delivery or fax to 512-389-4677.

8.1.4. Bids returned by mail or hand delivery should be placed in a sealed envelope and correctly identified with IFB number, submittal deadline/opening date and time. Bids returned by fax should include a fax cover sheet correctly identified with IFB number, submittal deadline/opening date and time. It is the Bidder’s responsibility to appropriately mark and deliver the bids to TPWD by the specified date.

8.1.5. Respondents are responsible for all costs of bid preparation.

8.2. Bid Content: Below is a summary of required and requested information. Bids submitted without this information will be evaluated accordingly. TPWD reserves the right, in its sole judgment and discretion, to waive minor technicalities and errors in the best interest of the state.

8.2.1. Bid Form: Respondent must submit the IFB form, signed, dated, and completed. Failure to submit this information will result in disqualification of bid.

8.2.2. Brand Name/Model: Respondents to specify Brand/Model of quoted product. Failure to take exception to specifications or referenced data will require Respondent to furnish specified brand name and model, etc. (Respondent may be required to submit product spec sheets and/ or other documentation prior to award.)

8.2.3. Descriptive Literature: Respondent should provide descriptive literature (product specification sheets) with response submission. Literature to address all salient characteristics, and clearly document that the offered product meets salient characteristics stated in the specifications.

(Note: Respondent may be required to submit product specification sheets and/ or other documentation prior to award.)

8.2.4. Delivery Time: Respondent to specify delivery time from receipt of TPWD order.

8.3. Response Period: Responses shall be binding for a period of sixty (60) business days from bid due date. No other costs, rates, or fees shall be payable to the Successful Respondent unless expressly agreed upon in writing by TPWD.

9. EVALUATION AND AWARD:

9.1. Only responses submitted by the bid opening, with required submittal documents and meeting qualifications will be considered. Failure to submit the required information may be cause for rejection of the bid response. TPWD reserves the right to waive informalities and minor irregularities in bids received.

9.2. TPWD reserves the right to consider respondent qualifications, equipment, facility, references; conduct studies and other investigations as necessary to evaluate any response; request additional relevant information; disqualify bid based on unsatisfactory reference checks, reports, and records of service.

mailto:Purchasing.BidBox@tpwd.texas.gov

IFB No. 802-24-48343 Page 15 of 35

9.3. Award: TPWD will award a Contract(s) to the Respondent(s) whose quote is considered to be the Best

Value to TPWD, price and other factors considered. The following factors may be used to evaluate bids:

9.3.1. Lowest Price

9.3.2. Ability, Qualifications and Experience - Meeting or Exceeding the Requirement

9.3.3. Delivery / Service Schedule

9.3.4. Past Performance

10. INVOICING AND PAYMENT:

The following procedures apply to invoicing and payment in addition to those listed in the General Terms and Conditions, Para. 9:

10.1. Contractor to submit invoice(s) to: Texas Parks & Wildlife, Accounts Payable, 4200 Smith School

Road, Austin, Texas 78744.

10.2. Invoices must show:

10.2.1. Name of contractor exactly as shown on the contract, Texas Payee Identification Number

(PIN), and correct “Remit to” address.

10.2.2. Name of receiving entity

10.2.3. Contract/purchase order number

10.2.4. Description, quantity, unit of measure, unit price, extended price of each item

10.2.5. Total Price

10.2.6. Discount, if applicable, extended and deducted to arrive at a NET TOTAL for invoice

10.2.7. Attach supporting documentation, if required.

10.3. Payment:

10.3.1. Contractor will be paid for the services as invoiced. If another payment mechanism is agreed to by the parties, then Contractor will be paid in accordance with the agreement approved by the parties.

10.3.2. Payment normally will be made to the Contractor within 30 days after receipt of a properly prepared invoice or the receipt of and the acceptance of goods/services ordered, whichever is later. State agencies are required by state law to pay properly submitted invoices within 30 days or the Contractor may charge a late payment fee established by law.

10.3.3. Payments for goods/services purchased with state appropriated funds will be made through state warrants issued by the Comptroller of Public Accounts. Payments by qualified ordering entities will be made through the entities’ local payment system.

Electronic payment may be available through some ordering entities. Contact Accounts Payable at 512-389-4833 for additional information.

11. BIDDER AFFIRMATION:

11.1. Bidder has not given, offered to give, nor intends to give at any time hereafter any economic opportunity, future employment, gift, loan, gratuity, special discount, trip, favor, or service to a public servant connected with the submitted bid.

11.2. Pursuant to Texas Government Code, Title 10, Subtitle D, Section 2155.004(a), the bidder has not received compensation for participation.

IFB No. 802-24-48343 Page 16 of 35

GENERAL TERMS AND CONDITIONS – FEDERALLY FUNDED PROJECTS

MARCH 2023

(ITEMS BELOW APPLY TO AND BECOME A PART OF THE CONTRACT)

Any Contract awarded as a result of this solicitation will contain the General Terms and Conditions listed below in this Section. Subcontractors are also obliged to comply with these provisions.

1. DEFINITIONS: As used throughout this solicitation, the following terms have the meaning set forth below.

All other terms have the meaning set forth in Webster’s II New College Dictionary.

1.1. Bidder: An individual or entity that submits a bid. The term includes anyone acting on behalf of the individual or entity that submits a bid, such as an agent, employee and representative. See Respondent.

1.2. Contractor: The individual, corporation, company, partnership, firm, or organization that has to furnish the materials and has to perform the work as stated in the solicitation.

1.3. ESBD: The Electronic State Business Daily, which is available online at http://www.txsmartbuy.com/esbd .

1.4. Gov’t Code: The Texas Government Code.

1.5. Owner: Texas Parks and Wildlife Department, an agency of the State of Texas.

1.6. Party/Parties: Either the TPWD and Respondent separately or collectively.

1.7. Respondent: Any person or Vendor who submits a Bid/Proposal/Offer in response to this solicitation.

1.8. Services: Includes the use of labor, materials, facilities, equipment, and any other need that is necessary or incidental to the successful completion of the Contract.

1.9. Subcontractor: Any supplier, distributor, Contractor, person, or firm furnishing to the Contractor, materials or services necessary or incidental to the performance of the Contract between TPWD and Contractor.

1.10. TAC: The Texas Administrative Code, which is the publication for administrative rules.

1.11. Texas Identification Number: A unique 11-digit number assigned by the Texas Comptroller of Public Accounts. When a Payee first contracts with a state agency, that Payee must provide either a federal Employer Identification Number (EIN) or a Social Security number (SSN). The Texas Identification Number (TIN) is based on this number. (Note: If Respondent does not have a TIN, or does not know their TIN, they may list their EIN or SSN on the “Texas Identification Number” line of the Vendor Information Block of their RFP, RFO, IFB or RFQ response.)

1.12. TPWD: Texas Parks and Wildlife Department acting on behalf of the State of Texas.

2. SPECIFICATIONS:

2.1. The goods/services provided shall be in accordance with the purchase specifications herein. TPWD will decide the answers to all questions that may arise as to the interpretation of the specifications and the quality, or acceptability of goods/services provided. TPWD will decide the rate of progress of the work and the acceptable fulfillment of the goods/service on the part of the Contractor.

2.2. Catalogs, brand names or manufacturer's references are descriptive only, and indicate type and quality desired. Bids/Proposals on brands of like nature and quality will be considered unless advertised under Texas Gov't Code §2155.067. If the Respondent is offering brands other than the references, response should show manufacturer, brand or trade name, and other description of product offered. If Respondent is offering brand(s) other than brand(s) specified, illustrations and complete description of product offered are requested to be made part of the bid. Failure to take exception to specifications or reference data will require Respondent to furnish specified brand names, numbers, etc.

2.3. Unless otherwise specified, items shall be new and unused and of current production.

2.4. Samples, when requested, must be furnished free of expense to the State. If not destroyed in examination, they will be returned to the Respondent, on request, at Respondent's expense. Each http://www.txsmartbuy.com/esbd

IFB No. 802-24-48343 Page 17 of 35 sample should be marked with Respondent's name and address, and requisition number. Do not enclose in or attach response submission to sample.

2.5. The State will not be bound by any oral statement or representation contrary to the written specifications of this Solicitation.

2.6. Manufacturer's standard warranty shall apply unless otherwise stated in the solicitation.

3. AWARD OF A PURCHASE ORDER: Standard Purchase Order Terms and Conditions apply. If a conflict exists between the standard Purchase Order Terms and Conditions and specific language in this solicitation, the language in the solicitation shall prevail.

3.1. A response to a solicitation is an offer to Contract with TPWD based on the terms, conditions and specifications contained in the solicitation. Responses do not become Contracts unless and until they are accepted through an authorized TPWD designee by issuance of a Purchase Order.

3.2. This procurement will be conducted in accordance with the State Purchasing Act, Title 10, Subtitle D, Chapters 2151 through 2177 of the Texas Gov’t Code (TGC) and TPWD rules. Any Contract resulting from this procurement shall consist of one (1) document. This document will contain all of the rights and duties of the parties extracted from the relevant terms and conditions of this solicitation (including its attachments, exhibits, supplements, and addenda); the successful Contractor’s response; any TPWD request for a Best and Final Offer; and any successful Contractor’s Best and Final Offer, if applicable.

3.3. Best Value – TPWD will be the sole judge of best value. Award will be based on Best Value criteria and may include, but is not limited to:

3.3.1. Best meets the goals and objectives of the solicitation as stated above.

3.3.2. Best meets the quality and reliability of the proposed services.

3.3.3. Effect of the proposed solution on agency productivity.

3.3.4. Provides the most customer focused solution that will best meet the needs of the public.

3.3.5. Experience in successfully providing services in this solicitation.

3.3.6. Past Performance: A Respondent’s past performance will be measured based upon pass/fail criteria in compliance with applicable provisions of Gov't Code §§2155.074, 2155.075, 2156.007, 2157.003, and 2157.125. Respondents may fail this selection criterion for any of the following conditions:

• The Vendor has a score less than C or Legacy Unsatisfactory in the Vendor

Performance System,

• Currently under a Corrective Action Plan through the Texas Comptroller of Public

Accounts (CPA),

• Having repeated negative Vendor Performance Reports for the same reason,

• Having Purchase Orders that have been cancelled in the previous 12 months for non-performance (i.e., late delivery, etc.).

3.3.7. Contractor performance information is located on the CPA web site at:

www.txsmartbuy.com/vpts. CPA may conduct reference checks with other entities regarding past performance. In addition to evaluating performance through the Vendor Performance Tracking System (as authorized by 34 Texas Administrative Code §20.115), CPA may examine other sources of vendor performance including, but not limited to, notices of termination, cure notices, assessments of liquidated damages, litigation, audit reports, and non-renewals of Contracts. Any such investigations shall be at the sole discretion of CPA, and any negative findings, as determined by CPA, may result in non-award to the Respondent.

4. UNIT PRICES: Respondents must price per unit shown. Unit prices shall govern in the event of extension errors.

5. FREIGHT: Quote FOB destination, freight prepaid and allowed unless otherwise stated within the specifications.

6. DELIVERY:

http://www.txsmartbuy.com/vpts

IFB No. 802-24-48343 Page 18 of 35

6.1. Show number of days required to place material in receiving agency's designated location under normal conditions. Delivery days mean calendar days, unless otherwise specified. Failure to state delivery time obligates Respondent to deliver in 14 calendar days. Unrealistic delivery promises may cause solicitation to be disregarded.

6.2. If delay is foreseen, Contractor shall give written notice to the TPWD. Contractor must keep the TPWD advised at all times of status of order.

6.3. Default in promised delivery (without accepted reasons) or failure to meet specifications authorizes the TPWD to purchase supplies elsewhere and charge full increase, if any, in cost and handling to defaulting Contractor.

6.4. Substitutions: No substitutions permitted without written approval of TPWD.

6.5. Delivery shall be made during normal working hours only unless prior approval has been obtained from ordering agency. Normal working hours are 8:00 AM until 5:00 PM Monday through Friday except State and National holidays.

7. TESTING AND INSPECTION:

7.1. TPWD may test and inspect goods and services purchased under the Contract to ensure compliance with the specifications of this solicitation and the Contract. TPWD may also test and inspect goods and services before they are purchased under the Contract. Authorized TPWD personnel shall have access to the Respondent's place of business for the purpose of inspecting the goods. To the extent practical, TPWD inspections will not disrupt the Respondent's daily operations. Tests shall be performed on samples submitted with the Bid/Proposal or on samples taken from regular shipments. All costs of testing and inspection shall be borne by the Respondent.

In the event the goods tested fail to meet or exceed all conditions and requirements of the solicitation and Contract, the goods will be rejected in whole or in part, at the State's option, and returned to the Respondent or held for disposition at the Respondent's expense. Latent defects may result in cancellation of the Contract at no expense to the state.

7.2. If material fails to meet specifications, the Respondent will be notified by fax, mail, or e-mail. The Respondent will have ten (10) working days after receipt of the notification to remove the rejected material from state property. Material will be removed at the Respondent’s expense. Material not removed in the allotted time period will be disposed by TPWD. The Respondent will be charged for all disposable expenses conducted by TPWD.

8. CHANGES: TPWD may at any time, by a written order, make changes within the general scope of this Contract, in the definition of services to be performed, and the time (i.e., hours of the day, days of the week, etc.) and place of performance thereof. If any such change causes an increase or decrease in the cost of, or the time required for the performance of any part of the services under this Contract, whether changed or not changed by any such order, an equitable adjustment shall be made in the Contract price or time of performance or both and the Contract shall be modified in writing accordingly. Any claim by the Contractor for adjustment under this clause must be asserted within 30 days from the date of receipt by the Contractor of the notification of change, provided, however, that TPWD, if it decides that the facts justify such action, may receive and act upon such claims asserted at any time prior to final payment under this Contract.

Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this Contract entitled "Dispute Resolution."

9. INVOICING AND PAYMENT:

9.1 Invoices: In order to receive payment under the Contract, the Contractor must submit an original invoice to TPWD, which will be designated in the Purchase Order as the "Bill To" address. To be a proper invoice that may be accepted and paid, the invoice must include the following information and/or attachments: (1) Name and address of the Contractor. (2) The Contractor's Texas Identification Number (TIN). (3) The Contractor's invoice remittance address. (4) The Purchase Order number authorizing the delivery of products or services. (5) A description of what the Contractor delivered, including, as applicable, the time period, serial number, unit price, quantity, and total price of the products and services. If the invoice is for a lease, the Contractor must also include the payment number (e.g., 1 of 36).

IFB No. 802-24-48343 Page 19 of 35

9.2 Disputed Invoices: As stated above, the Contractor will receive notice of an error in an invoice submitted for payment by not later than the 21st day after the date the invoice was received by the TPWD. If an invoice dispute is resolved in favor of the Contractor, the Contractor is entitled to receive interest on the unpaid balance of the invoice, beginning on the date the invoice became overdue, pursuant to Gov't Code §2251. 021. If a dispute is resolved in favor of the TPWD, the Contractor shall submit a corrected invoice that must be paid in accordance with Section 2251.021.

The unpaid balance accrues interest if the corrected invoice is not paid by the appropriate date.

9.3 Time and Manner of Payment: Pursuant to Texas Gov’t Code Chapter 2251, payment by TPWD is overdue on the 31st day after the later of: (1) the date the TPWD receives the goods under the Contract; (2) the date the performance of the service under the Contract is completed; or (3) the date the TPWD receives the invoice for the goods or service. Payment by a political subdivision Customer whose governing body meets only once a month or less frequently is overdue on the 46th day after the later event of: (1) the date TPWD receives the goods under the Contract; (2) the date the performance of the service under the Contract is completed; or (3) the date TPWD receives the invoice for the goods or service.

10. PATENTS, TRADEMARKS, OR COPYRIGHTS: Respondent agrees to defend and indemnify the TPWD and State from claims involving infringement or violation of patents, trademarks, copyrights, trade secrets, or other proprietary rights, arising out of the TPWD's or the State's use of any good or service provided by the Respondent as a result of this solicitation.

11. PROHIBITION ON LOBBYING: The Respondent shall comply with the provisions of a federal law known generally as the Lobbying Disclosure Act, 2 U.S.C. §1601 et seq. By submitting a Bid/Proposal, the Respondent certifies that it shall not and has not used federally appropriated funds to pay any person or organization for influencing or attempting to influence any officer or employee of any federal agency, a member of Congress, officer or employee of Congress, or an employee of a member of Congress in connection with obtaining any federal Contract, grant, or any other award covered by 31 U.S.C. §1352.