SF30amd_WindyCreek.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

N/A

PAGE

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE NO. 5. PROJECT NO. (If applicable)

A001 N/A MT GLAC 1430(1)

Windy and Apikuni Creek Bridge Repairs

6. ISSUED BY CODE N/A 7. ADMINISTERED BY (If other than Item 6) CODE N/A

Department of Transportation Federal Highway Administration 610 East Fifth Street Vancouver WA 98661-3801

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and Zip Code) 9A. AMENDMENT OF SOLICITATION NO.

X

DTFH70-14-B-00018

9B. DATED (SEE ITEM 11)

05/19/2015

10A. MODIFICATION OF CONTRACT/ORDER NO.

N/A

10B. DATED (SEE ITEM 13)

CODE: N/A FACILITY CODE: N/A N/A

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

| X | The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers (__ ) is extended, ( x ) is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

N/A

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A THIS CHANGE ORDER IS ISSUED PURSUANT TO (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN

ITEM 10A.

N/A

B THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (Such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

N/A

C THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

N/A

D OTHER (Specify type of modification and authority) N/A

E. IMPORTANT: Contractor n/a is not, n/a is required to sign this document and return n/a copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

MT GLAC 1430(1)

Windy and Apikuni Creek Bridge Repairs

Amendment A001 is issued to revise the following:

SPECIAL CONTRACT REQUIREMENTS

Page E-19, Subsection 108.04, Failure to Complete Work on Time. Revises Table 108-1 Enclosure: Page E-19

Notice to Bidders Page A-1 Revises question due date to June 3, 2015 Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15a. NAME AND TITLE OF SIGNER (Type or print) 15a. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

N/A

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

BY_________________________________________ BY N/A___________________________ N/A (Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

PREVIOUS EDITION NOT USABLE

30-105 STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

A-1

Notice to Bidder Project: MT GLAC 1430(1), Windy and Apikuni Creek Bridge Repairs

03USC03/19/14

NOTICE TO BIDDERS

I. Project Location.

The project work is located 5 miles west of Babb, MT in Glacier County.

Changed Project Number and Name: This project was formerly called MT NPS GLAC 1430(1) Windy Creek and Apikuni Road Bridges Repair. For administrative purposes, we have changed the project number and name to MT GLAC 1430(1), Windy and Apikuni Creek Bridge Repairs. The work remains the same.

Signs have not been erected to identify the project limits. No Government personnel will be available for show-me tours.

II. Pre-Bid Information.

Electronic Plans. This solicitation includes electronic plan sheets available at http://www.wfl.fhwa.dot.gov/contracting/construction/plans/windy/. A paper copy of the plan sheets is available by submitting the form posted with this solicitation.

Physical Data. Bridge data applicable to this project is listed in FAR Clause 52.236-4 Physical Data. A CD of the physical data is available by submitting the form posted with this solicitation.

TERO Requirements. This contract may require materials be obtained from within the boundaries of the Blackfeet Reservation.

The Bidder should be familiar with the Blackfeet Tribal Employment Rights Office (TERO) requirements, and take into consideration any TERO fees that may be assessed by the Blackfeet Tribe when preparing their bid. See Subsection(s) 105.02(b).

The Government is not subject to TERO requirements and is not a party to any agreements between the Tribe and Contractor pursuant to the TERO. The Tribe administers the TERO pursuant to its inherent sovereign powers of self-government. REPS & CERTS. Submit or update Representations and Certifications online at https://www.sam.gov/portal/public/SAM/ before bid submittal. For more details go to FAR Provision 52.204-8 Annual Representations and Certifications (see page B-2). If you have previously registered on-line and the NAICS code for this solicitation is different than the code listed in your online file, please note the amended changes on the lines provided in FAR 52.204-8.

Revised by Amendment A001

TECHNICAL QUESTIONS REGARDING PROPOSED WORK FOR THIS PROJECT

WILL BE ACCEPTED UNTIL CLOSE-OF-BUSINESS ON JUNE 3, 2015.

Questions can be submitted and answers viewed by going to project information at:

http://www.wfl.fhwa.dot.gov/contracting/construction/advertised.htm

Every attempt to respond to questions will be made. However, response to questions received after the above posted date is not guaranteed.

E-19

Special Contract Requirements Project: MT GLAC 1430(1), Windy and Apikuni Creek Bridge Repairs

(b) Days required to perform work added to the contract after substantial completion including items identified during the final inspection that were not required before that time;

(c) Delays by the Government after all work is complete and before a formal acceptance is executed;

(d) Periods of time when all work is complete but acceptance is delayed pending the plant establishment period or similar warranty period; and

(e) During winter shutdown periods ordered by the CO.

Table 108-1 Charge for Liquidated Damages for Each Day

Work Is Not Substantially Completed

Original Contract Price Daily

Charge From More Than —

To and Including —

$ 0 $ 1,000,000 $ 1,000

$ 1,000,000 $ 2,000,000 $ 1,800

$ 2,000,000 $ 5,000,000 $ 3,500

$ 5,000,000 $ 10,000,000 $ 4,400

$ 10,000,000 and more $ 5,200

108.06 Suspension. (Added Subsection).

Follow the requirements of FAR Clause 52.242-14 - Suspension of Work.

Suspend work, either in whole or in part, for such periods deemed necessary due to the presence of active eagle nest sites and other wildlife. See Subsection 107.10.

Revised by Amendment A001