DRAFT SOW Construction_APHIS Dunseith Trailer_11.8.2020.pdf

1 | Page

CONSTRUCTION SCOPE OF WORK

U.S. GENERAL SERVICES ADMINISTRATION, ROCKY MOUNTAIN REGION 8

Date: 11/8/2020 Revision: (Date of any revisions to the initial scope) All revisions shown in RED

Section 1: Project Title APHIS Dunseith Trailer Relocation

Section 2: Project Location, Building Name, & Building Number APHIS Temporary Trailer

Dunseith Land Port of Entry (LPOE)

Old US 281 & Canadian Border

Dunseith, North Dakota

Building # ND

Section 3: Contact List

Contracting Officer (CO) Name: Dylan White Email:

Phone (C):

Contract Specialist (CS) Name: Miriam Babcock

Property Manager Name: Bryan Sayler Email:

Phone

Development Project Manager Name: Mike Writz

Delivery Project Manager Name:

Email:

Address:

Phone (O):

D

RA

T

2 | Page

Section 4: Project Background & Project Description APHIS (Animal Plant Health Inspection Service) for the Dunseith LPOE is currently housed in a temporary trailer on the east side of Highway 281. This location presents a safety hazard to the employees of APHIS who need to cross the highway to perform the on-load inspections which take place on the west side of Highway 281. Therefore, the goal of this project is to relocate the current trailer, from the east side of the highway to the west side of the highway, eliminating the pedestrian traffic and hence the safety concerns. In addition, APHIS would like to have an inspection platform provided constructed to the length of the semi-trailer, approximately 50 ft.

Section 5: Project Objectives The contractor shall provide labor, materials, equipment and supervision necessary to perform:

1) Refer to CDs dated 8/14/2020.

2) Any changes to the design drawings will need to be approved by GSA

Section 6: Proposal Pricing & Site Walk

1) Pre-proposal Site Visit Meeting: (Enter pre-proposal site walk date, time, and location)

a) The site visit shall consist of a meeting to review construction requirements followed by a walk-thru of the project site.

The meeting shall be attended by the contractor and GSA project personnel, and appropriate sub-contractors.

b) Review existing conditions of the project area including any field verification.

c) Review the solicitation/evaluation requirements.

2) Cost Proposal Requirements:

a) When submitting a proposal, provide a cost breakdown for each task into the following categories: Materials, equipment, labor hours, subcontractor's quotes, overhead, profit, and bond broken down into shell, tenant improvement (TI) (by tenant), Building- Specific Amortized Capital (BSAC), and environmental (as applicable). Pricing shall be broken down by Construction Specification Institute (CSI) divisions.

b) Base Bid- Relocation of Trailer

c) Option 1- N/A

Section 7: Period of Performance

Once award has been issued, the contractor has 120 calendar days to complete the project. The contractor must also promptly begin the badging process at the time of award. Please allow a minimum of 60 days to complete the badging process. Extensions will be granted for unforeseen conditions and other factors outside of the contractor’s control at the Contracting Officer’s discretion.

Section 8: Universal Scope Requirements

● ALL of the requirements in this section are MANDATORY for ALL GSA projects

● See the attached Universal Scope Requirements document for the full details outlining each item

● Failure to comply with any and all of the requirements will result in the project not being accepted as complete

REQUIREMENTS for ALL Projects (Construction, Design & Design/Build)

A. Safety and Health Program B. Asbestos (Pre-Alteration Assessments) C. Lead Containing Paint / Lead Based Paint D. Fire & Life Safety E. Accessibility (ABAAS) F. Green Purchasing G. Construction Indoor Air Quality (IAQ) Management Plan H. Construction Waste Diversion

REQUIREMENTS IF APPLICABLE (Remove any not needed)

I. Site Work (Stormwater/Erosion, Soil Disturbance, and Utility Locates) J. Historical Preservation K. Commissioning (for all new AHUs or all new building system equipment)

D

3 | Page

L. GSA IT Network M. Building Automation Systems (BAS) N. Advanced Metering System (AMS) O. Building Information Modelling (BIM) P. Sustainable Environmental Management System (SEMS) Q. Rebates

REQUIREMENTS IF APPLICABLE for DESIGN & DESIGN/BUILD Projects only

R. Energy Design S. Electrical Design T. Lighting Design U. Mechanical Design and Fuel Storage V. Seismic Safety Design W. Physical Security Performance Attributes X. Water-Efficient & Pollinator-friendly Landscaping

Section 9: Submittals

1) Contractor shall submit a Method of Procedures (MOP) to the GSA Delivery Project Manager (PM) for approval prior to commencement of work. At a minimum, the MOP shall include:

a) Brief narrative describing method of accomplishment, construction techniques, etc

b) Project schedule (to include critical path, major milestones, long lead time items, mob & de-mob, inspection dates, substantial completion, and occupancy dates)

c) Service/Utility Outages (if necessary)

d) Phasing schedule (if necessary)

e) Any building infrastructure/BAS equipment that may be impacted

2) As- Builts (CAD and/ or BIM) BIM is required for any project above the Simplified Acquisition Threshold, currently $250,000.

3) Pre-alteration assessment report

4) Manufacturer's specifications, instructions and material specification sheets in original form

5) Submittal register/ log for all products specified to establish a standard of quality to include. Submittal register response by the government shall be (14) calendar days or less.

a) For pricing purposed please assume X hard copies of submittals and X electronic copies to be sent to the project manager. Distribution list including final quantities will be finalized after receipt of the submittal log/ register by GSA project manager.

6) If product samples are not submitted in a timely fashion, any delays caused by the contractor will not warrant a time extension.

After completion of all work, the Contractor shall submit to the project manager the manufacturer's specifications, instructions and material specification sheets in original form. Additionally, the Contractor shall submit all inventory changes (removals, additions, upgrades, etc., and new condition codes) to the COR.

7) Submittal response by the government shall be (14) calendar days or less.

Section 10: General Requirements

1) Contractor Use of the Premises

a) During the period of the project, the contractor will have access to the site only during business hours of 6:00 am 6:00

pm. No on-site work shall be performed outside these hours or on holidays unless otherwise directed by the Contracting Officer. The contractor will need to coordinate with the Contracting Officer to arrange access to the parking lot. The contractor shall make every effort to cause a minimum of damage to parking lots, any other paved areas, any items that need to be moved during the course of the project, and any areas not included in this scope of work. Any damage caused will be repaired at the contractor’s expense.

2) Progress Meetings

a) The contractor shall schedule weekly meetings with the GSA and subcontractors. The contractor shall keep meeting minutes and distribute copies at the following meetings. The meeting agenda will include the following as a minimum:

Approval of previous meeting, review of work progress, field observations, problems and decisions, identification of problems which impede planned progress, review of submittals schedule and status of submittals, maintenance of progress schedules, planned progress during the succeeding work period.

D

4 | Page

3) Equipment The contractor shall provide all equipment associated with the entire project, operate in a safe manner and adhere to all OSHA and GSA standards.

4) Equipment and Material Storage The contractor shall provide and store all equipment, the materials specified above, and any other materials required completing the project. The materials are required to be kept clean and dry throughout the duration of the project.

Contractor to coordinate with building manager for location of storage sheds.

5) Sanitary Facilities Provide and maintain temporary toilet facilities in accordance with State Health Department and GSA requirements.

6) Electricity, Water, and Gas GSA will pay for electricity, water, and gas during the course of this project. The contractor is responsible for making connections to the existing systems. Temporary electrical work shall meet the requirements of NFPA 70-1996 (NEC), Article

305. When temporary connections are removed, restore existing utility services to their original condition.

7) Contractor’s Field Office The contractor may provide an office for their own use. Size, location, and construction shall be subject to approval.

8) Fire Watch Contractor shall be responsible for providing fire watch if required per attached GSA fire watch guidelines.

9) Fire Alarm Impairment and Hot Work When a fire suppression or alarm system impairment is required, contractor shall provide written outage request to GSA for approval in advance of impairing any systems. Contractor shall be responsible for having a GSA approved NICET certified fire alarm contractor perform all system impairments. During fire alarm/suppression impairments or hot work procedures, contractor shall provide a fire watch per the GSA Regional Fire Watch Guidelines.

10) Protection of Public The building site will continue to be used by tenants. The contractor shall fence, barricade, or otherwise block off the immediate work area to prevent unauthorized entry. The contractor shall illuminate barricades and obstructions at night and maintain safe building access and egress for tenants.

11) Housekeeping The project site shall be kept in a neat, orderly, and safe condition at all times. The contractor shall provide enough containers for collecting construction debris and construction materials to be recycled. The contractor shall wet down dry materials and rubbish to prevent blowing dust and keep volatile wastes in covered containers.

12) Transportation and Deliveries The contractor shall arrange deliveries of materials in accordance with construction schedules; coordinate with COR to avoid conflict with other tenants and other work conditions at the site. Contractor must make GSA PM & CO aware of any lead times that may affect the project schedule.

13) Cleaning Before scheduling the final inspection, the Contractor shall accomplish six items: (1) Remove all tools, equipment, surplus material, and rubbish; (2) Restore or refinish, to original condition, surfaces that are damaged due to the work of this contract; (3) Remove grease, dirt, stains, foreign materials, and labels from finished surfaces; (4) Thoroughly clean building interiors; (5) Pickup all construction debris from the site; and (6) At time of final inspection, project shall be thoroughly cleaned and ready for use.

14) Disruptive Work All painting, staining, or other activity which may cause noxious or undesirable fumes and/ or any noisy work that may be disruptive to the tenants/ public must be performed after normal working hours. The use of paint or stain that does not generate odors is preferred and may be required if the space will be occupied the following day with prior written approval from GSA.

Section 11: Badging & Security

1) Contractor is responsible to follow GSA’s security and badging requirements as detailed in the attached Badging & Security Requirements (Vendor Fitness Determination Training Manual).

2) US Access shared enrollment centers can be found at fedidcard.gov. Travel distances to the nearest center should be accounted for during the badging process.

Section 12: Payments

5 | Page

1) Information regarding payment requests and payment is in the solicitation/ contract. Please contact the CO if you have any questions regarding payments.

Section 13: Substantial Completion & Final Inspection

1) When project, or designated portion of project is complete, request a final inspection. Upon receipt of request that project is substantially complete, the Contracting Officer will proceed with the inspection within ten days of receipt of request or will advise the contractor of items that prevent the project from being designated substantially complete.

2) Red-lined drawings and CAD and/or BIM as-built drawings, and field training for Operations and Maintenance (O&M) personnel shall be provided at completion of project. Maintain one complete set of contract drawings. Clearly mark changes, deletions, and additions using GSA CAD Standards to show actual construction conditions. Show additions in red, deletions in green, and special instructions in blue print. Provide to GSA within timeframe negotiated at time of award.

3) The contractor shall provide O&M manuals. The O&M manuals shall contain the following:

o Executed Warranties (at project completion) o Maintenance and operation manuals

Section 14: Attachments

1) Universal Scope requirements

2) Badging & Security requirements (Vendor Fitness Determination & Training Manual)

3) 100% Design_APHIS Trailer Relocation_8.14.2020