DRAFT CPCS PWS 2024 (21May2024).docx

PERFORMANCE WORK STATEMENT FOR

CENTRAL PLANT COMPUTER SYSTEM (CPCS) MAINTENANCE

21 May 2024 Schriever SFB

CPCS Maintenance

1.18. Worksite Coordination & Site Access Badges

1.19 Safety

1.20 Service Summary

APPENDIXES

CPCS Maintenance

PERFORMANCE WORK STATEMENT FOR

CENTRAL PLANT COMPUTER SYSTEM MAINTENANCE

1.0. DESCRIPTION OF SERVICES. The contractor shall provide all management, tools, supplies, equipment, travel, and labor necessary to perform maintenance on the Central Plant Computer System (CPCS) located at Schriever Space Force Base (SSFB). Work shall comply with government and commercial standards. The CPCS, located inside Building 600, is the control system that automates/controls/monitors (3) 2. 65 - MW Caterpillar, (4) 2.79-MW Caterpillars generator, 12,470-volt commercial power and medium/low voltage switchgear, transformers, single phase Uninterruptable Power Systems and Motor Control Centers (MCC) in building 600.

1.1. CPCS EQUIPMENT. CPCS primarily includes (1) Set of ABB AC900 PLC Controls with its IO, Beijer iX Developer, Schweitzer Engineering Laboratories AcSELerator, Woodward Toolkit, Moxa MGate software/hardware and communication programs are needed to ensure reliable operation. In addition, CPCS includes, but is not limited to: ABB Freelance HMI software, (1) SEL (Schweitzer Engineering Laboratories) 3354 Embedded Automation Computing Platform with Microsoft Windows touch screen interface, (5) SEL-2030 Communications Processor, (42) SEL-351A Distribution Protection Systems, (7) SEL-700G Generator Protective Relay, Upgraded with (2) LS6XT & (7) Easygen 3400XT, (4) 2301E, (2) SATEC PM296 Power Analyzer, (5) Moxa Modbus gateways, (1) Beijer Box2 Modbus concentrator, (1) LCD Monitor, (1) Dell Desktop Computer with Windows 10 and all associated field wiring, current/potential transformers, meters, relays, modems, Ethernet switches, terminations, annunciations/alarm devices and desktop computer uninterruptable power supplies.

1.2. TECHNICAL SUPPORT. The contractor shall provide technical support 24 hours a day, 7 days a week by telephone and email. The technical support request shall be answered within 2 (two) hours of receipt. Technical support shall consist of verbal or written communications with the user by telephone and/or e-mail in attempt to assist the user in identifying the nature of the problem and lead the user through trouble-shooting repair procedures, as required (Estimated Total Call Hours is 120). Should the contractor fail to respond within the times specified or fail to contact the on-duty operator for a resolution, the Government shall have the right to repair, replace, or otherwise remedy such failure, defect, or damage as necessary.

1.3. CENTRAL PLANT COMPUTER SYSTEM REPAIRS. To perform repairs, replace or change components. Change or update systems programming and provide manufactures updates. All repairs will be performed IAW manufacturer’s current recommendations and specifications. If unable to correct issue with technical support, contractor will schedule a visit to perform hands on support within 24 hours. All work will be performed by qualified technicians (Qualified is defined as demonstrating experience with generator control systems in Section 1.0 and all components in Section 1.1). All CPCS electrical testing technicians that service SSFB Central Utility Plant (CUP) CPCS must be International Electrical Testing Association (NETA) certified with proof of up-to- date certificate. To ensure quality assurance and safety, all systems will be inspected for damage and deficiencies during repairs. Correct all electrical deficiencies as required IAW the most current National Electric Code and International Electrical Testing Association standards. Maintain service records for the duration of the contract and ensure all records are accurate, current, and provided to the Contracting Officer Representative (COR) within five (5) workdays of the completion of the Preventive Maintenance (PM) checks. Document all repairs and replaced parts in the service records. Any or all service records shall be provided to the COR upon request.

1.4. EMERGENCY SERVICE. Includes any critical repair action required by the contractor to return the CPCS to fully operability. The contractor shall begin the emergency service within 4 hours after notification by the Contracting Officer. Normally all work will be performed during normal operating hours (0630 – 1600, Monday through Friday) on SSFB. Unexpected services may be required in the event of natural disasters or other unscheduled repairs to CPCS. The contractor shall perform on-site emergency services to restore the equipment to automatic and manual modes of operation. The contractor will notify the On Duty Operator by phone at (719) 567-6530 and follow-up with an e-mail when the technician is dispatched to the site.

1.5. CONFIGURATION MANAGEMENT. The contractor shall provide a copy of the configuration of software/hardware and communication programs before any repairs or updates to the CPCS. Also, the contractor shall provide a copy of the configuration of software/hardware and communication programs after any repairs and updates.

1.6. WORK ORDERS. The contractor shall provide a Firm-Fixed-Priced (FFP) quote to the CO and 50 CES/CEOES upon request. Work orders may be used to support the Siemens-EMCS, upon request from 50 CES/CEOES and a contract modification. All quotes shall be itemized by labor rates including burdens, proposed hours, cost by line item of parts and the total firm fixed price. Work orders need to be submitted by the contractor within 72 hours of diagnosis. The contractor shall only commence work on a WO after the CO issues a proceed notice.

1.7. PARTS AND COST: Shall include documentation showing where the contractor has either competed the parts and rationale for the selection of the parts/cost or compared the parts with at least three (3) manufacturers of the parts when the cost is over $2,500, and rationale as to why one company's parts/cost was selected over another company's parts/cost. If only one company manufactures a part, the contractor shall state so in their quote. All electrical materials shall be approved by the Underwriter’s Laboratories (UL) for the use intended.

1.8. SAFETY AND HEALTH STANDARDS. The contractor shall initiate and maintain programs to comply with the provisions of the Occupational Safety and Health Standards Act (OSHA) concerning entry requirements in confined spaces and handling potential hazardous substances.

1.9. REPORTING. The Contractor shall submit a detailed trip report, to include travel time and costs, hours spent, and work accomplished and any recommendations to improve the system to 50 CES/CEOES NLT ten (10) calendar days from the date services were performed. Documents and reports shall be submitted in electronic format to the COR.

1.10. LABOR HOUR REPORTING. The contractor shall report ALL contractor labor hours (including subcontractor labor hours) required for performance of services provided under this contract. The contractor is required to completely fill in all required data fields using the following web address: http://www.ecmra.mil. Reporting inputs must be for the labor executed during the period of performance during each Governmental fiscal year (FY), which runs October 1 through September 30. While inputs may be reported any time during the FY, all data shall be reported back no later than October 31 of each calendar year for the previous governmental FY. Contractors may direct questions to the Electronic Contractor Manpower Reporting Application (ECMRA) help desk.

1.11. QUALITY ASSURANCE. The Government will periodically evaluate the Contractor's performance by appointing a representative(s) to monitor performance to ensure services are received. The Government representative will evaluate the Contractor's performance through intermittent on-site inspections of the Contractor's quality control program and receipt of complaints from base personnel. The Government may inspect each task as completed or increase the number of quality assurance inspections if deemed appropriate because of repeated failures discovered during quality assurance inspections or because of repeated customer complaints. Likewise, the Government may decrease the number of quality assurance inspections if performance dictates.

1.12. QUALITY CONTROL (QC). The Contractor shall develop and maintain a QC inspection system that encompasses all functions of the contract. The QC inspection system shall satisfy the requirements in the Inspection of Services clause in the RFP and resultant contract and shall be designed to keep the Contractor's management informed of all issues affecting quality. The QC records of inspections shall indicate the nature and number of observations made, the number and type of deficiencies found, and the nature of corrective action taken as appropriate.

1.13. GOVERNMENT REMEDIES. The contracting officer shall follow the requirements of FAR 52.212-4, Contract Terms and Conditions for Commercial Items (May 2015), for contractor’s failure to correct nonconforming services.

1.14. NORMAL OPERATING HOURS. 0630 Hours – 1600 Hours, Monday - Friday

1.14.1. RECOGNIZED HOLIDAYS: The contractor shall not provide service on Federal holidays, except in emergency situations. If the following holidays fall on Saturday, the preceding Friday will be observed. If these holidays fall on Sunday, the following Monday will be observed. If a holiday falls on a scheduled service day, the contractor will be responsible for rescheduling services for the first day past the holiday observance. The holidays are:

New Year’s Day - 1 January Martin Luther King Day - 3rd Monday in January Washington’s Birthday - 3rd Monday in February Memorial Day - Last Monday in May Juneteenth – 19 Jun Independence Day - 4 July Labor Day - 1st Monday in September Columbus Day - 2nd Monday in October Veteran’s Day - 11 November Thanksgiving Day - 4th Thursday in November Christmas Day - 25 December

1.15. SECURITY REQUIREMENTS.

1.15.1. Compliance: The contractor shall comply with all SSFB security requirements. SSFB is a controlled/restricted area and special security procedures are utilized to deter espionage, sabotage, and theft of Air Force resources. The Contractor shall be responsible for security of his work areas in cooperation with applicable base agencies. All contractor personnel must have legal United States residency and work authorization status. Contractors will be responsible to verify legal work status in accordance with US Code, Section 274a. 2., regarding I-9 (Employment Eligibility Verification Form). FC has differing Security Requirements, see paragraph 1.6.12 – 1.6.12.4

1.15.2. Vehicle Passes: All vehicles will be used in accordance with AFI 31-204, Air Force Motor Vehicle Traffic Supervision. All vehicles attempting to gain access to SSFB must be available for inspection. Large commercial vehicles will present themselves at the SSFB West Entry Gate for inspection prior to gaining access to SSFB

1.15.3. Restricted Area Unescorted Entry: Since this contract requires frequent access to the SSFB restricted area. Unescorted entry to the SSFB restricted area is required for completion of the contract; the Contractor will request National Agency Check w/Inquiries (NACI) through the 50 SCS Security Office. The Government shall conduct and cover the cost of the actual NACI, which will be submitted through 50 SW/IP (Information Protection Office). Upon favorable adjudication of the records check results, interim unescorted entry may be granted pending completion of NACI. Unescorted entry based on a favorable records check will be limited to Area 7. Individuals may be granted interim unescorted entry based on a favorable local agency check and submission of the NACI.

1.15.4. Denying entry to SSFB: The installation commander reserves the right to deny entry to SSFB to any person whose NACI is unfavorable or upon disclosure of information that indicates the individual’s continued entry to SSFB is not in the best interest of the USAF. Additionally, the violation of, or deviation from established security procedures by any Contractor employee may result in the confiscation of restricted/controlled area badges and denial of future entry to SSFB.

1.15.5. Verify/identity before entry: 50th SFS personnel will verify the identity and entry authorization of each Contractor employee and vehicle, and may conduct a search of any baggage, articles, or vehicles on SSFB.

1.15.6. Visitor badges: Contractor employees requiring entry, but not requiring unescorted entry, will be issued a visitor badge and will be under direct surveillance, at all times, of a contractor employee possessing a restricted/controlled area badge with escort authority. Contractor employees entering SSFB will obtain their visitor badge from the 50th SFS, Building 200, North Entry Control Facility (NECF). The visitor badge will be returned to the NECF each time the employee departs the SSFB controlled area. While within the SSFB controlled area, Contractor personnel will display the visitor badge on their outer garment above the waist and shall remain at all times within view of the escort official.

1.15.7. Reporting of lost badges: The Contractor shall immediately report the occurrence of lost badge(s) to the QAE, who will in turn report to SFS. If the QAE is not available, the loss shall be reported directly to 50th SFS within one duty day of loss. Replacement badge will not be issued until reporting procedures are satisfactorily completed.

1.16. WORK SITE MAINTENANCE. The Contractor shall maintain the work site to prevent the spread of contamination, provide for the safety of all individuals in the vicinity of the work site areas, and prevent the release of any contamination to the environment. The work site shall be well marked to prevent inadvertent entry into all work areas. Access to work areas shall be monitored and thoroughly controlled. Standard work zones and access points for controlled operations shall be established and maintained as the site conditions warrant. The Contractor shall ensure compliance with any federal, state, and local regulations and QA/QC protocols and procedures for decontaminating tools, equipment, or other materials, as required. The Contractor shall keep the work area free from accumulation of waste and non-essential hazardous materials. The Contractor shall remove non-essential equipment from the work site when not in use. The work site shall be maintained to present an orderly appearance and to maximize work efficiency. Before completing the work at each work location, the Contractor shall remove from the work premises any rubbish, tools, equipment, and materials that are not the property of the government.

1.17. MINIMIZE IMPACTS TO EXISTING OPERATIONS. The Contractor shall cooperate fully with other contractors and government employees. The Contractor shall not commit any act that will interfere with the performance of work by any other contractor or government employee. The COR will resolve work schedule conflicts between this contract and other contracts. The COR will provide written directions to the Contractor to reschedule work when required.

1.18. WORK SITE COORDINATION/SITE ACCESS BADGES. The Contractor shall coordinate work site activities to ensure the protection of human health and the environment; the prevention of damage to property, utilities, materials, supplies, and equipment; and the avoidance of work interruptions. The Contractor shall provide physical security to each work area with security equipment and personnel, as needed. SSFB is a secure facility, therefore, when extensive work onsite is required, the Contractor shall make the necessary arrangements with the 50 CES/CEOES to gain base entry. Access to the base can be time consuming; therefore, the Contractor should schedule for possible delays. There are access restrictions to SSFB, including the high security section regulated as a Restricted Area (RA). The Contractor shall submit a visit authorization request letter through 50 CES/CEOES a minimum of two weeks before site work begins. The letter must be on company stationery or letterhead and include justification for requiring entry, contract number, project title, number and name(s) of personnel requiring entry, areas to be visited at SSFB, and contact person(s) (primary and alternate). The Contractor shall monitor its employees to ensure all information remains current and to ensure all security badges or passes are returned to Building 200, North Entry Control Facility upon expiration of the badge, upon completion of the project, or when possession of the badge is no longer authorized (e.g., upon removal of contracted personnel from specific projects).

1.19. SAFETY. In performing work under this contract on a Government installation, the contractor shall take all reasonable steps and precautions to prevent accidents and preserve the health and safety of contractor and Government personnel performing or in any way coming in contact with the performance of this contract. Take such additional immediate precautions as the contracting officer may reasonably require for health and safety purposes. The contracting officer may, by written order, direct Air Force Occupational Safety and Health (AFOSH) Standards and/or health/safety standards as may be required in the performance of this contract and any adjustments resulting from such direction will be in accordance with the Changes clause of this contract. Any violation of these health and safety rules and requirements, unless promptly corrected as directed by the contracting officer, shall be grounds for termination of this contract in accordance with the Default clause of this contract. Specifically, the contractor shall: maintain a safe and healthful working condition for all Contractor personnel and must ensure conformance with standards developed under US Public Law 91-596, the OSHA of 1970, and State Occupational Safety and Health (OSH) Standards, American National Standards Institute (ANSI), and National Fire Protection Association (NFPA) standards. If a conflict occurs, the Contractor shall apply the more stringent standard. Allow the Base Safety Office to monitor all operations to ensure the safety of Government property. Follow Air Force traffic regulations. Provide a Safety Plan for their employees not later than twenty (20) calendar days after contract award. The Contractor shall provide a preliminary draft. The contractor has ten (10) calendar days, after receipt of Government comments, to prepare and deliver final plan. The Contractor shall provide an updated copy as changes and updates occur. Report all lost time mishaps involving any person sustaining injury or illness resulting from Contractor operations and all mishaps involving Government property or equipment damaged by the Contractor to the Base Safety Office, the 50 SCS and CO no later than the end of the next duty day. If the mishap includes damage to Government property or equipment, the report and subsequent investigation is governed by the Base Safety Office. Be responsible for resolving all regulatory citations, request for delays, and variances and exemptions to OSHA. The Contractor is solely liable for fines, penalties, or other liabilities resulting from the Contractor’s failure to comply with these standards. Reimburse the Air Force for any damage to Air Force property determined by the CO to be in the Contractor’s fault. Inform the Base Safety Office of any identified safety hazards which expose personnel to possible injury, illness, or any possible damage to Government equipment or property. Mishaps Investigation: The Government has the authority to conduct investigations of mishaps in Government facilities managed by Contractors or to participate in the Contractor’s investigation of Contractor mishaps. The Contractor shall participate in, and cooperate with, Government mishap investigations as requested. The Government may conduct facility inspections in Government facilities that are occupied by the Contractor. Within the 50 states and US territories, Air Force Contractors operating Air Force facilities located on or off Air Force installations, are subject to enforcement authority by Federal and State safety and health organizations. Authorized safety and health officials from states without OSHA approved occupational safety and health plans may be subject to the exceptions contained here, also exercise jurisdiction over Contractors operations.

1.20. SERVICES SUMMARY: The contract service requirements are summarized in performance objectives that relate directly to mission essential items. The performance threshold briefly describes the minimally acceptable levels of service required for each requirement. The Services Summary (SS) and the contractor’s Quality Control Plan provide information on contract requirements and the expected level of contractor performance. These thresholds are critical to mission success.

Technical Support.

Ensure system is 100% operational in the automatic and manual modes after each scheduled maintenance and service.

Service calls are responded to within 4 hours if call and all work completed as specified.

APPENDIX A CYBER SECURITY REQUIREMENTS

1. In an effort to prevent hacking of the EMCS system and promote future Department of Defense monitoring capabilities, the following guidance shall be adhered to:

2. The Contractor shall provide support for Vulnerability Management and Malware Protection activities outlined in Evaluator Scoring Matrix (ESM) v9.2, as well as support the appropriate organization conducting Vulnerability Assessment and Analysis (VAA). The Contractor shall present and deliver relevant intrusion analysis and correlation information to enable EMCS operations and sustainment decisions. The Contractor shall provide technical assistance during repair until event is mitigated, isolated, or risk is removed to allow for restoration of full EMCS capability IAW Chairman of the Joint Chiefs of Staff Manual (CJCSM) 6510.01B.

APPENDIX B APPLICABLE PUBLICATIONS AND FORMS

1. Regulations, Manuals, and other Documents: Publications and forms applicable to this Performance Work Statement (PWS) are listed below. The contractor is obligated to follow those publications and use those forms coded as mandatory to the extent specified in other sections of this PWS. The contractor shall be guided by those publications or use those forms coded advisory to the extent necessary to accomplish requirements in this PWS. Where Government specifications are not directed, the contractor shall perform work to meet commercial standards and manufacturers recommendations. All publications annotated are mandatory. All of the following publications, directives and forms can be obtained from the World Wide Web (WWW) at the following internet address: http://afpubs.hq.af.mil, or as specified, with exception of those identified with asterisks “*” shall be provided by the Government upon request. At the start of the contract, the Government will provide all publications, directives, and forms unavailable on the WWW upon request. The Government may issue supplements or amendments to listed publications from any organizational level during the life of the contract. The contractor shall keep all issued publications up to date. The contractor shall immediately implement those changes in publications that result in a decrease or no change in the contract price. Before implementing any such revision, supplement, or amendment that will result in an increase in contract price, the contractor shall submit to the administrative CO a price proposal negotiation. Price proposals shall be submitted within 30 calendar days from the date the contractor receives notice of the revision, supplement, or amendment giving rise to the increase in cost of performance. The Government will consider changes in the contract price due to supplements and amendments under the Changes clause of this contract. The Government will continue to supply the Government forms needed for daily operations. Upon completion of the contract, the contractor shall return to the Government all issued publications and unused forms.

2. Publication and Regulations:

AFOSHS 91-25

3. AF Forms:

APPENDIX C ENVIRONMENTAL PROTECTIONS

1. GENERAL REQUIREMENTS

Activities implemented, in whole or in part, with federal funds must comply with applicable legislation and regulations established to protect the human environment and the physical environment. The Contractor shall remain in compliance with federal statutes during the performance of the contract, including but not limited to the Clean Air Act (CAA), Endangered Species Act, Resource Conservation and Recovery Act (RCRA), and other applicable laws, regulations, and requirements.

2. NOTIFICATION

The Contracting Officer will notify the Contractor in writing of any observed noncompliance with Federal, State, or local environmental laws, regulations, and/or permits. There may be unforeseen circumstances regarding environmental aspects on the contract. If unforeseen circumstances occur, the contracting officer or contracting officer representative must be contacted prior to work beginning or continuing.

3. EXECUTION

Protection of Fish and Wildlife The Contractor shall follow all Federal, State, County, and SSFB Integrated Natural Resources Management Plan policies as briefed by the Environmental Office regarding the protection of fish and wildlife. The Contractor shall at all times perform all work and take such steps required to prevent any interference of disturbance to fish and wildlife.

4. AIR RESOURCES

The Contractor shall comprehend and comply with the current Air Permit and all applicable Federal, State, County and Municipal laws concerning air pollution, particularly the CAA and all subsequent amendments. All work under this contract shall be performed in such a manner that objectionable or nuisance conditions will not be created in the air, nor will objectionable particulates be released into the air.

5. OZONE DEPLETING SUBSTANCES (ODSs) Class I ODSs are prohibited. Class II ODSs are prohibited for use in any weapon or facility or other system that will remain in the Air Force inventory beyond January 1, 2020. The following table lists these chemicals. Contractor shall provide a statement to the Contracting Officer confirming that no Class I ODSs will be used and disclosing if Class II ODSs will be used in execution of the contract.

CLASS I OZONE DEPLETING SUBSTANCES

METHYL BROMIDE

CLASS II OZONE DEPLETING SUBSTANCES

When the project calls for work on existing HVAC and refrigerant systems containing substances listed in paragraph 2.2.4(A), the Contractor shall have available refrigerant recovery and/or reclamation equipment to remove these substances without venting to the atmosphere. All R22 refrigerant recovered by the Contractor shall be turned in to the Contracting Officer. Prior to commencing work on a system containing the substances listed in paragraph 2.2.4(A), the Contractor shall submit all current licenses for personnel and equipment authorized to perform this work.

6. AIR EMMISIONS

Material usage which produces Volatile Organic Compounds (VOCs) or Hazardous Air Pollutants (HAPs) emissions shall be reported through the Contracting Officer to the Environmental Office. Materials such as welding rods, welding gases, paints, thinners, solvents, blast media, generators and asphalt will require reporting immediately through the Contracting Officer to the Environmental Office. Usage of any items previously listed shall be reported on a monthly basis using form 3952.

7. WASTEWATER MANAGEMENT AND DISCHARGE NOTIFICATION

The Installation’s sanitary sewer system discharges into the Cherokee Metro District (CMD) operated by Colorado Springs, CO. CMD has established testing requirements for certain constituents as well as discharge limits of those same constituents. Accordingly, any Contractor performing work at the Installation and contemplating a release of non-hazardous water into the sanitary sewer system shall comply with the testing/release requirements established by the Permit CMD-00777 and the CWA. Contractor is also responsible for any and all testing, monitoring, measuring, documenting, etc. to prove compliance with the permit. If discharge to sanitary sewer system is required, the Contractor must contact the Environmental Office through the Contracting Officer at least 7 days in advance for permission. The Environmental Office shall review this request and provide appropriate authorization prior to discharge. If there is an accidental discharge the Environmental Office must be notified immediately (within 15 minutes of knowledge of the accidental discharge).

8. HAZARDOUS MATERIALS/WASTE DISCARGES

No hazardous materials or hazardous wastes as defined by 49 CFR 172 and 40 CRF 261 shall be discharged into the sanitary sewer. If an accidental discharge occurs, the contractor shall immediately inform the Contracting Officer and the Environmental Office.

9. MULCHING AND COMPOSTING

As applicable, any trees removed under the contract shall be mulched and reapplied as landscaping ground cover as part of this contract. All other living matter (shrubs, bushes, plants etc...) shall be composted and compost reapplied during the landscaping phase of the contract, to the greatest extent practicable.

10. HAZARDOUS MATERIALS MANAGEMENT

Contractor shall abide by the following for any Hazardous Material (HAZMAT) that they intend to utilize for the project. Approval: Contractors using any type of hazardous material, to include POL products, on the Installation must comply with the review and approval process and shall provide the Contracting Officer with a list of proposed materials that it plans to use on the installation during the performance of the contract NLT 10 days from NTP, the Contractor shall provide to the Contracting Officer a copy of the 3952 Form, Hazardous Material Tracking Form - Material and Approval Submittal, listing all materials that will be utilized during the contract period as well as the current Safety Data Sheet (SDS) for each of the materials. This 3952 is local to the Installation and shall be provided by the Contracting Officer to the Contractor. The Environmental Office will determine if any of the proposed materials are classified as hazardous and are covered under Emergency Planning and Community Right-to-Know Act (EPCRA) (42 U.S.C. 11001-11050). If they fall into this category, the Environmental Office will issue an authorized use list to the Contracting Officer for this Contractor. For contracts lasting longer than one year, the Contractor shall report through the Contracting Officer to the 50 Logistics Readiness Flight (LRF) hazardous material pharmacy located at building 613 and the Environmental Office to get approved barcode tracking labels for all hazardous materials. The Contractor must maintain a file of all SDSs during the performance of this contract. Any hazardous material not utilized by the Contractor must be taken off the Installation as soon as the project ends. For contracts lasting less than one year, the authorized use list will serve as tracking for all hazardous materials. The contractor must maintain a file of all SDSs during the performance of this contract. Any hazardous material not utilized by the Contractor must be taken off the Installation as soon as the project ends.

If additional hazardous material is required during the course of the contract or if there is a change to existing hazardous material, the Contractor shall update the 3952 Form and provide a SDS for each hazardous material through the Contracting Officer to the Environmental Office. The Contractor shall submit the new authorization request no later than (NLT) 15 days prior to delivery of the hazardous material onto the Installation. For each Contractor-identified chemical that the Environmental Office determines does not meet the definition of a hazardous material, EPCRA requirements do not apply. The Environmental Office will notify the CO that the Contractor has authorization to bring and use that material on the installation without requiring the reporting of usage unless required under Green Procurement Program or specifications requiring data submittals. The Contractor shall be responsible for reporting all sub-contractors hazardous material usage from the date of hire throughout the duration of their contract through the Contracting Officer to the Environmental Office. The Contractor shall not use products that are, or contain Diisocyanates, Dioxins and Dioxin-like Compounds, Extremely Hazardous Substances, Ozone Depleting Substances (ODS), CFCs or Persistent Bio-accumulative and Toxic chemicals. Any hazmat containing any of these banned substances will not be allowed on the installation.

11. MANUFACTURES SAFETY SHEETS (SDS)

Contractor shall maintain, at all times, an up-to-date SDS for all hazardous materials used. This information shall be maintained at the site and be readily available for review by Contractor’s employees and/or Contracting Officer or designee.

12. STORAGE AND HANDLING PROCEEDURES

All hazardous materials shall be stored in accordance with the requirements of 49 CFR 172. At a minimum all containers shall be closed when not in active use, labels clean and clearly discernible, materials stored at a central location when not in use, storage area monitored periodically for leaks and spills, materials stored in appropriate cabinets in compliance with 49 CFR 172, and all warning labels in area clearly visible. Any hazardous material that is not completely used under this contract can be either taken back to the Contractor’s facility for reuse or disposed of as a hazardous waste in accordance with the Hazardous Waste requirements of this specification. No hazardous material, lubricants, oils, liquids or related materials shall be deposited in the refuse containers on the installation.

13. HAZARDOUS MATERIALS USEAGE REPORTS

Submit report to Contracting Officer as indicated: For performance period of less than or equal to 90 days, the Contractor shall report total hazardous materials usage at end of service. The report shall identify the items by type and quantity. Additionally, the report shall list the end disposition of said material (i.e., fully consumed as part of contract, saved for future use and taken back to Contractor’s facilities, etc.) For performance periods greater than 90 days, submit a report within 10 working days after end of each calendar quarter of project execution. Note: No hazardous or potentially hazardous material may be brought onto the installation without full compliance with all authorization, approval, and reporting requirements specified in the Federal, DOD and Air Force regulations or local supplements.

14. HAZARDOUS WASTE MANAGEMENT

The Installation is designated as a Very Small Quantity Generator for hazardous waste. All work conducted within the boundaries of the base must meet the regulatory requirements of this generator designation. The Contractor is responsible for the proper handling and management of all hazardous waste generated from work performed on Air Force property. Handling, storage, and disposal costs of hazardous waste generated from the project shall be the responsibility of the Contractor. If all hazardous materials brought on site will be consumed in executing this contract or are still useable by the Contractor and will be taken off site as useable materials, this section does not apply for that material. For hazardous waste generated by the Contractor, accumulation and storage must be specifically approved in writing by the Contracting Officer and the Environmental Office. Such approval must be given prior to the generation of any hazardous waste. Approval for accumulation or storage of hazardous waste will require a minimum lead time of forty-five (45) calendar days from the date of the receipt of the request and may not be approved at that time. The contractor shall pay all fines/penalties assessed by federal, state, or local agencies for the improper management or illegal disposal of regulated substances; or laws/regulations violated by the contractor. No hazardous waste or universal waste may be stored, accumulated or left on the property after finalization of project. Under no circumstances shall disposal or treatment of hazardous waste be allowed on the Installation by the Contractor.

15. HAZARDOUS WASTE ITENTIFICATION

Identify all activities which will generate hazardous waste/debris. The Contractor shall provide a documented determination for all resultant waste streams. Hazardous waste/debris shall be identified, labeled, handled, stored, and disposed of in accordance with all Federal, State, and local regulations including 40 CFR 261, 40 CFR 262, 40 CFR 266 and 40 CFR 268. Hazardous waste generated within the confines of Government facilities shall be identified as being generated by the Government. Provide the Contracting Officer a copy of waste determination documentation for all hazardous waste streams generated in executing this contract.

16. STORAGE AND HANDLING

All containers used to store hazardous waste must be non-leaking, in good condition, and free from severe rusting, bulging, or structural defects. Drums that are rusty, dented, or leaking should be over-packed. Containers, drums and/or over-packs must be purchased by the Contractor. Drums filled with hazardous waste shall be inspected weekly. Completed inspections shall be maintained on-site by the contractor and be readily available for inspection by the Contracting Officer or designee. Hazardous waste must be stored in an authorized area. In general, the area must provide security, spill response equipment, communication, fire equipment, and applicable signage.

Drums/Containers must be kept closed except when adding or removing waste. In the event the Contractor encounters unknown material/waste, all work around the area shall cease immediately and the Contracting Officer notified immediately. If work requires the temporary storage/collection of hazardous waste, the Contractor will submit a request in writing to the Contracting Officer for establishment of a satellite accumulation point.

17. DISPOSAL

All hazardous waste generated by a project must be disposed of under the contract. The Installation is not responsible for any disposal fees associated with the Contractor’s hazardous waste generation/disposal. Hazardous Waste manifests must be signed by an authorized representative from the Environmental Office, the Contractor shall coordinate with the Contracting Officer at least 5 business days prior to any planned shipment of hazardous waste to ensure the proper representative can be present to sign the manifest. Disposal of any materials, wastes, effluents, trash, garbage, oil, grease, chemicals, and similar hazardous substances shall be transported to a suitable disposal site by the Contractor subject to the approval of the Contracting Officer and the Environmental Office. The contractor shall ensure the waste is disposed at a properly permitted treatment storage or disposal facility and that copies of all manifests and other required documents are provided through the Contracting Officer to the Environmental Office.

18. ELECTRIC LIGHT FIXTURES, BALLASTS AND TRANSFORMERS

Contractor shall segregate light fixtures and ballasts by type. Fixtures containing mercury shall be recycled or processed as hazardous/universal waste; fixtures, ballasts or transformers containing PCB shall be disposed of by the Contractor in accordance with applicable regulations and laws; and ballasts containing neither shall be recycled as scrap metal. Any light fixtures sent to recycling facilities shall be captured on the disposal and recycling reports required in this specification. No new light fixtures to be installed under this contract shall have any mercury containing components.

19. POLYCHLORINATED BIPHENYLS (PCB)

Contractor is required to assure that all electrical equipment including, but not limited to transformers, capacitors, circuit breakers, reclosers, voltage regulators, switches, electromagnets, and cable, shall be PCB free or not be contaminated with PCBs in detectable concentrations. The Contractor shall submit SDS and/or PCB Free certification prepared by the manufacturer for the equipment installed under the project. The Contractor is also responsible for ensuring any equipment to be removed as part of the contract is PCB free. Whether or not equipment is PCB free, the Contractor is responsible for proper disposal and costs associated with the disposal.

20. ASBESTOS

No asbestos containing material (ACM) shall be used on the Installation. Asbestos surveys must be accomplished by the Contractor prior to any renovation or demolition which may disturb material in a quantity greater than 260 linear feet on piping, 160 square feet on other surfaces, or a volume equivalent of a 55-gallon drum. Types of materials that must be surveyed includes, but are not limited to: floor and/or ceiling tile; tile mastic; roofing materials and flashing mastics; pipe and boiler insulation; wall coverings; sheetrock joint compound; and transit materials. The Environmental Office maintains records of all ACM on base and will provide the results of any asbestos testing previously accomplished. If no asbestos is identified in the contract drawings or specifications, yet the Contractor suspects asbestos containing material exists in the work area, notify the Contracting Officer immediately for resolution.

When asbestos abatement is required to execute a contract, the Contractor shall provide a detailed abatement plan. The Contractor’s designated EPA certified asbestos abatement project designer and/or supervisor, or Certified Industrial Hygienist (CIH) or Industrial Hygienist (IH) designated by corporations shall develop an asbestos abatement plan that meets the contractual specifications. At a minimum, the plan shall incorporate the following:

A) Name and certificates of asbestos plan designer and asbestos abatement qualified site superintendent B) Level of training received by asbestos abatement employees C) Detail design of containment systems D) Air monitoring procedures and analysis to include clearance air sampling E) Certification of laboratory to be used for sampling analysis F) Disposal plan In addition, the Contractor shall be responsible for all Colorado Department of Public Health and Environment asbestos notifications and coordination with the Environmental Office.

21. LEAD BASED PAINT (LBP)

No LBP is authorized for use on the Installation. The Contractor will cease operations if lead contamination is suspected and contact the Contracting Officer. The Environmental Office maintains records of all LBP and lead containing material on base and will provide the results of any lead testing previously accomplished. When LBP abatement is required to execute a contract, the Contractor shall provide a detailed abatement plan. The Contractor’s designated EPA certified LBP project designer and/or supervisor, or Certified Industrial Hygienist (CIH) or Industrial Hygienist (IH) designated by corporations shall develop an abatement plan that meets with the contractual specifications.

A) Name and certificates of asbestos plan designer and LBP abatement qualified site superintendent B) Level of training received by LBP abatement employees C) Detail design of containment systems D) Air monitoring procedures and analysis to include clearance air sampling E) Certification of laboratory to be used for sampling analysis F) Disposal plan

22. SPILL RESPONSE

No hazardous materials are to be sprayed or spilled to the environment, ground, asphalt, or concrete covered surfaces. The Contractor shall be charged for any cleanups and disposal costs. Only trained personnel shall handle all spill cleanups. All spills shall be reported immediately to the Environmental Office and a spill plan may be required for a regulated substance. Petroleum spills exceeding 25 gallons must be reported to the Colorado Department of Labor and Employment, Division of Oil and Public Safety. The reporting will be coordinated through the Contracting Officer and the Environmental Office. Within 24 hours of the incident, Contractor shall submit a written report detailing the accident and steps taken to prevent such incidents in the future. Contractor will be liable to pay, in full, any fines and violations incurred by the Installation resulting from the spill.

Spill Response Procedure A) Notify the installation Fire Department immediately of any spills that are 25 gallons or more or beyond the Contractor’s response capabilities. Smaller spills should be handled by the Contractor but shall be coordinated with the Contracting Officer and the Environmental Office. Maintain spill response equipment on-site.

B) Stop source of spill without undue risk of personal injury. Use on-site containment, safety equipment, and materials.

C) Make spill scene off limits to all non-cleanup personnel.

D) Restrict all sources of ignition if flammable material in spill.

E) Report to the Contracting Officer and the Environmental Office within 15 minutes.

23. HISTORICAL, ARCHAEOLOGICAL, AND CULTURAL RESOURCES

Resources covered by this paragraph include but are not limited to: any human skeletal remains or burial; artifacts; shell, midden, bone, charcoal, or other deposits; rock or coral alignments, pavings, wall, or other constructed features; and any indication of agricultural or other human activities. Existing historical, archaeological, and cultural resources within the Contractor’s work area are shown on the drawings and are represented as geospatial data sets in the Installation Development Plan. Additionally, special care and handling procedures for work in the historic district will be identified in the specifications. If they are not, Contractor shall verify with the Contracting Officer that there will be no special conditions required.

Contractor shall preserve these resources and be responsible for their preservation during the life of the Contract. Contractor shall be familiar with the requirements of the Standard Operating Procedure for Inadvertent Discovery, Section 7.4 of the current SSFB Integrated Cultural Resources Management Plan and shall be responsible for implementation of contractor responsibilities described therein in the event of an inadvertent discovery of potential or suspected historical, archaeological, or cultural resources. In summary, if during excavation or other construction activities any previously unidentified or unanticipated historical, archaeological, and cultural resources are discovered or found, immediately cease all activities that may result in impact to or the destruction of such resources.