Contract package - 19GG8026Q0006.pdf

ELEVATOR MAINTENANCE

OVERSEAS MODEL

COMMERCIAL ITEMS FORMAT

TABLE OF CONTENTS

SECTION 1 - THE SCHEDULE

• SF 1449 cover sheet

• Continuation To SF-1449, RFQ Number 19GG8026Q0006,Prices, Block 23

• Continuation To SF-1449, RFQ Number 19GG8026Q0006, Schedule Of

Supplies/Services, Block 20 Description/Specifications/Work Statement

• Attachment 1 -List of Elevators to be Maintained

• Attachment 2 - List of Tasks to be Performed

SECTION 2 - CONTRACT CLAUSES

• Contract Clauses

• Addendum to Contract Clauses - FAR and DOSAR Clauses not Prescribed in Part 12

SECTION 3 - SOLICITATION PROVISIONS

• Solicitation Provisions

• Addendum to Solicitation Provisions - FAR and DOSAR Provisions not Prescribed in

Part 12

SECTION 4 - EVALUATION FACTORS

• Evaluation Factors

• Addendum to Evaluation Factors - FAR and DOSAR Provisions not Prescribed in

Part 12

SECTION 5 - REPRESENTATIONS AND CERTIFICATIONS

• Offeror Representations and Certifications

• Addendum to Offeror Representations and Certifications - FAR and DOSAR

Provisions not Prescribed in Part 12

SECTION 1 - THE SCHEDULE

Continuation/Addendum to SF-1449 RFQ Number 19GG8026Q0006

PRICES, BLOCK 23

1.0 DESCRIPTION

The U.S. Embassy Tbilisi requires services to maintain building elevators in safe, reliable and efficient operating condition. The contract type is a firm fixed price contract for routine maintenance services paid at the monthly rate below. These rates include all costs associated with providing elevator maintenance services in accordance with manufacturer’s warranty including materials, labor, insurance (see FAR 52.228-4 and 52.228-5), overhead, profit. The contract will be for a one-year period, with four one-year optional periods of performance.

2.0 PRICING

2.1 VALUE ADDED TAX

VALUE ADDED TAX. Value Added Tax (VAT) is not applicable to this contract and shall not be included in the CLIN rates or Invoices because the U.S. Embassy has a tax exemption certificate from the host government.

2.2 Base Year - The Contractor shall provide the services shown below for the base period of the contract, starting on the date stated in the Notice to Proceed and continuing for a period of 12 months. The fixed unit prices, estimated quantities, and ceiling for each category are:

Line Item Description

Price in USD Dollars x 12 Months

Annual Total is US Dollars

Routine monthly maintenance for Chancery Passenger Elevator 1

“PE 1”* 12

Routine monthly maintenance for Chancery Passenger Elevator 2

“PE 2”* 12

Routine monthly maintenance for US Embassy Annex Passenger Elevator 3 “PE 3”* 12

Routine monthly maintenance for Chief of Mission Residence (CMR) Passenger Elevator 4 “PE 4”* 12

*described in attachment 1

2.3 Option Year 1 - The Contractor shall provide the services shown below for Option Year 1, starting one year after the date stated in the Notice to Proceed and continuing for a period of 12 months.

Item Description Monthly Price x 12 Months Annual Total

Routine monthly maintenance for Chancery Passenger Elevator

1 “PE 1”* 12

Routine monthly maintenance for Chancery Passenger Elevator

2 “PE 2”* 12

Routine monthly maintenance for US Embassy Annex Passenger Elevator 3 “PE 3”* 12

Routine monthly maintenance for Chief of Mission Residence (CMR) Passenger Elevator 4

“PE 4”* 12

2.4 Option Year 2 - The Contractor shall provide the services shown below for Option Year 2, starting two years after the date stated in the Notice to Proceed and continuing for a period of 12 months.

x 12 Months Annual Total

Routine monthly maintenance for Chancery Passenger Elevator

1 “PE 1”* 12

Routine monthly maintenance for Chancery Passenger Elevator

2 “PE 2”* 12

Routine monthly maintenance for US Embassy Annex Passenger Elevator 3 “PE 3”* 12

Routine monthly maintenance for Chief of Mission Residence (CMR) Passenger Elevator 4

2.5 Option Year 3 - The Contractor shall provide the services shown below for Option Year 3, starting three years after the date stated in the Notice to Proceed and continuing for a period of 12 months.

x 12 Months Annual Total

Routine monthly maintenance for Chancery Passenger Elevator

1 “PE 1”* 12

Routine monthly maintenance for Chancery Passenger Elevator

2 “PE 2”* 12

Routine monthly maintenance for US Embassy Annex Passenger Elevator 3 “PE 3”* 12

Routine monthly maintenance for Chief of Mission Residence (CMR) Passenger Elevator 4

2.6 Option Year 4 - The Contractor shall provide the services shown below for Option Year 4, starting four years after the date stated in the Notice to Proceed and continuing for a period of 12 months.

x 12 Months Annual Total

Routine monthly maintenance for Chancery Passenger Elevator

1 “PE 1”* 12

Routine monthly maintenance for Chancery Passenger Elevator

2 “PE 2”* 12

Routine monthly maintenance for US Embassy Annex Passenger Elevator 3 “PE 3”* 12

Routine monthly maintenance for Chief of Mission Residence (CMR) Passenger Elevator 4

Base Year Total

Option Year 1 Total

Option Year 2 Total

Option Year 3 Total

Option Year 4 Total

GRAND TOTAL OF BASE YEAR PLUS ALL OPTION YEARS

3.0 NOTICE TO PROCEED

After contract award and submission of acceptable insurance certificates and copies of all applicable licenses and permits, the Contracting Officer will issue a Notice to Proceed. The Notice to Proceed will establish a date (a minimum of ten (10) days from date of contract award unless the Contractor agrees to an earlier date) on which performance shall start.

CONTINUATION/ADDENDUM TO SF-1449

RFQ Number 19GG8026Q0006

SCHEDULE OF SUPPLIES/SERVICES, BLOCK 20

DESCRIPTION/SPECIFICATION/WORK STATEMENT

1.0 SCOPE OF WORK

The U.S. Embassy Tbilisi requires the Contractor to maintain the elevators identified in Attachment 1 in safe, reliable and efficient operating condition. The Contractor shall provide all necessary managerial, administrative and direct labor personnel, and as well as all necessary transportation, equipment, tools, repair parts, supplies and materials required to perform inspection, maintenance, repair, and component replacement as required to maintain the elevators in accordance with the manufacturer's specifications. Under this contract the Contractor shall provide:

• The services of a trained elevator mechanic on a monthly basis to check and repair equipment operation and perform scheduled and preventive maintenance; on monthly basis for Chancery, Annex and CMR Residence

• 24 hours/day, 7 days/week emergency response service;

• appropriate, same day, service in response to an elevator malfunction trouble call; and

• after-hours emergency minor adjustment callback service

2.0 HOURS OF PERFORMANCE

The Contractor shall schedule all routine maintenance and repair work during normal building hours which are defined as 9:00 to 18:00 Monday to Friday, excluding local and bank holidays, unless approved in advance by the Contracting Officer's Representative (COR).

3.0 ACCESS TO GOVERNMENT BUILDINGS AND STANDARDS OF CONDUCT

3.1 General. The Contractor shall designate a representative who shall supervise the Contractor's elevator mechanics and be the Contractor's liaison with the U.S.

Embassy/Consulate. The Contractor's employees shall be on-site only for contractual duties and not for any other business or purposes. Contractor employees shall have access to the elevators' hoistways, lobbies and machine rooms, either with or without security escorts, only with specific permission by either the Contracting Officer or the COR.

3.2 Personnel Security. The Government reserves the right to deny access to U.S owned and U.S.-operated facilities to any individual. The Contractor shall provide the names, biographic data and police clearance on all Contractor personnel who shall be used on this contract prior to their utilization. The Government shall issue identity cards to approved Contractor personnel, each of whom shall display his/her card(s) on the uniform at all times while on Government property or while on duty at private residences serviced under this contract. These identity cards are the property of the Government. The Contractor shall return all identity cards when the contract is completed, when a Contractor’s employee leaves this contract, or at the request of the Government.

3.3 Standards of Conduct

3.3.1 General. The Contractor shall maintain satisfactory standards of employee competency, conduct, cleanliness, appearance and integrity and shall be responsible for taking such disciplinary action with respect to employees as may be necessary. Each Contractor employee shall adhere to standards of conduct that reflect credit on themselves, their employer, and the United States Government. The Government reserves the right to direct the Contractor to remove an employee from the worksite for failure to comply with the standards of conduct. The Contractor shall immediately replace such an employee to maintain continuity of services at no additional cost to the Government.

3.3.2 Uniforms and Personal Equipment. The Contractor's employees shall wear clean, neat and complete uniforms when on duty. All employees shall wear uniforms approved by the Contracting Officer's Representative (COR). The Contractor shall provide, to each employee and supervisor, uniforms and personal equipment. The Contractor shall be responsible for the cost of purchasing, cleaning, pressing, and repair of the uniforms.

3.3.3 Neglect of duties shall not be condoned. This includes sleeping while on duty, unreasonable delays or failures to carry out assigned tasks, conducting personal affairs during duty hours and refusing to render assistance or cooperate in upholding the integrity of the worksite security.

3.3.4 The Contractor shall not condone disorderly conduct, use of abusive or offensive language, quarreling, and intimidation by words, actions, or fighting. Also included is participation in disruptive activities that interfere with normal and efficient Government operations.

3.3.5 Intoxicants and Narcotics. The Contractor shall not allow its employees while on duty to possess, sell, consume, or be under the influence of intoxicants, drugs or substances which produce similar effects.

3.3.6 Criminal Actions. Contractor employees may be subject to criminal actions as allowed by law in certain circumstances. These circumstances include but are not limited to the following actions: falsification or unlawful concealment, removal, mutilation, or destruction of any official documents or records or concealment of material facts by willful omission from official documents or records; unauthorized use of Government property, theft, vandalism, or immoral conduct; unethical or improper use of official authority or credentials; security violations; organizing or participating in gambling in any form; and misuse of weapons.

3.3.7 Key Control. The Contractor shall receive, secure, issue and account for any keys issued for access to buildings, offices, equipment, gates, or other areas, for the purposes of this contract.

Keys shall not be duplicated without the COR's approval. Where the Government determines that the Contractor or its agents have duplicated a key without permission of the COR, the Contractor shall remove the individual(s) responsible from performing work under the contract.

If the Contractor has lost any such keys, the Contractor shall immediately notify the COR. In either event, the Contractor shall reimburse the Government for the cost of rekeying that portion of the system so compromised.

4.0 WORK REQUIREMENTS

4.1 General. The Contractor shall provide full service to meet routine maintenance requirements. The Contractor shall maintain elevators so that the elevators are in a safe and efficient operating condition at all times. In the event of a break down, the Contractor shall make every effort to immediately return the elevator to an operating condition.

WINDING DRUM ELEVATORS:

CANCERY “PASSENGER ELEVATOR 1” AND PASSENGER ELEVATOR 2”

US EMBASSY ANNEX: “PASSENGER ELEVATOR 3”

4.2.1 Summary of Services - Traction and Winding Drum Elevators

To maintain the designated "Traction" type elevators, (including geared, gearless, DC drive and AC drive machines), and "Winding Drum" type elevators in accordance with the manufacturer's specifications, the Contractor shall perform all of the following services:

Examine, clean, lubricate, adjust, repair, and replace:

• elevator machines,

• motor generators,

• solid state drives,

• controllers,

• selectors,

• dispatcher & relay panels and parts thereof, including:

• hoisting motors,

• selector motors,

• worms & gears,

• bearings,

• rotating elements,

• brake magnet coils,

• brushes and commutators,

• brake shoes,

• brake linings & pins,

• windings & coils,

• contacts & relays,

• resistors & transformers,

• and solid state devices;

• keep guide rails properly lubricated except where roller guides are used;

• repair or replace guide shoe gibs or rollers;

• replace inoperative position indicator and car/hall call lamps;

• repair or replace control cables;

• examine clean, lubricate, adjust, repair or replace the safety devices including interlocks, door closers, buffers, overspend governors, car & counterweight safeties, limit switches, landing & slowdown switches, door protective devices and alarm bells;

• replace wire ropes and equalize the tension of the hoisting ropes;

• examine, evaluate, and when needed, regroove or replace all sheaves and sheave assemblies, including drive sheaves, governor tension sheaves and compensating sheaves;

• examine, lubricate, adjust, repair and replace car & corridor operating stations, car & corridor hangers & tracks, door operating devices, door gibs and car fans;

• clean elevator machine rooms, hatch equipment, rails, inductors, relaying devices, switches, buffers, and car tops;

• dismantle, clean, examine, replace worn parts, lubricate, reassemble, and adjust brake plunger assemblies;

• refasten/resocket the hoisting ropes, using the babbitt socketing method procedure, on an annual basis for winding drum machines located over the hoistway or on a 2-year basis for machines located below or at the side of a hoistway.

• provide "emergency service" assistance defined in 6.2 to correct major elevator problems occurring after normal working hours.

HYDRALIC ELEVATOR: CHIEF OF MISSION RESIDENCE (CMR)

4.2.2 Summary of Services – Hydraulic Elevato

In order to maintain the designated hydraulic type elevators in accordance with the manufacturer's specifications, the Contractor shall perform all of the following services:

Examine, clean, lubricate, adjust, repair, and replace:

• pumps,

• valves,

• motors,

• controllers and parts thereof, including:

• bearings,

• windings & coils,

• rotating elements,

• contacts & relays,

• resistors & contactors,

• packing gaskets,

• drive belts,

• strainers,

• mufflers

• and above ground piping;

• keep guide rails properly lubricated except where roller guides are used;

• repair or replace guide shoe gibs or rollers;

• replace inoperative position indicator and car/hall call lamps;

• repair or replace control cables;

• top off hydraulic oil holding tank;

• examine clean, lubricate, adjust, repair or replace the safety devices including interlocks, door closers, buffers, limit switches, landing & slowdown switches, door protective devices and alarm bells;

• examine, lubricate, adjust, repair and replace car & corridor operating stations, car & corridor hangers & tracks, door operating devices, door gibs and car fans;

• clean elevator machine rooms, hatch equipment, rails, inductors, relaying devices, switches, buffers, and car tops;

5.0 SCHEDULED ROUTINE MAINTENANCE

5.1 General

5.1.1 The objective of scheduled routine maintenance is to eliminate or minimize elevator malfunction, breakdown and deterioration. Contract maintenance of the elevator must assure continuous, safe, and satisfactory operation of all elevators, their parts and components. The Contractor shall schedule routine maintenance to include all tasks herein described, in addition to routine lubrication and adjustments.

5.1.2. Elevator equipment shall include, but is not limited to: controllers, selectors, worm gears, thrust bearings, brake magnet coils, brake shoes, brushes, windings, commutators, rotating elements, contacts, coils, resistors for operating and motor circuits, magnet frames, cams, car door and hoistway door hangers, tracks and guides, door operating devices, interlocks and contacts, pushbuttons, pumps, pump motors, operating valves, electronic tubes, electronic programmable controllers, hall lanterns and indicators, hatch lighting, pit bulbs, bulb replacement and all other elevator signal accessories.

5.1.3 The Contractor shall inventory, supply, repair and replace all parts that have become unsafe due to wear and tear. The Contractor shall use genuine manufacturer’s parts or approved or equal (to be approved by COR) for all replacements. The Contractor shall maintain an easily accessible supply of spare parts sufficient for normal maintenance and expedient emergency repairs.

5.2 Checklist Approval - The Contractor shall submit to the COR a schedule and description of the scheduled routine maintenance tasks which the Contractor plans to provide. The Contractor shall prepare this schedule and task description in a checklist format similar to the one provided in Attachment 2. The Contracting Officer or COR must approve the proposed "Scheduled Routine Maintenance Task Checklist" prior to contract work commencement.

5.3 Minimum Requirements - The Contractor shall provide a trained mechanic to inspect and service every elevator a minimum of every month of the year for Chancery and Annex elevators.

The elevator mechanic shall sign off on every item of the checklist. The elevator mechanic shall leave a copy of this signed checklist with the COR or the COR's designate following that week's routine maintenance visit. This weekly inspection and servicing shall include, but not be limited to, the following tasks:

• Ride all cars to detect and repair any improper operation of the car doors, hoistway doors, acceleration, leveling accuracy on the floor stops, and the action of the machine brake;

• Check and make necessary repairs to assure proper operation of retractable doors;

• Review elevator’s performance with the COR, or the designated representative, to determine if any malfunctions have occurred in connection with the operation of the cars since the most recent previous scheduled routine maintenance visit;

• Investigate any malfunctions which have occurred, devoting special attention to any problem involving unsafe operations, and make repairs as necessary;

• Examine car stations and call buttons and replace any damaged switches, burned out lamps, bulbs and broken buttons, defective fixtures, switches, covers, and related hardware;

• Trouble shoot any failure to equipment, lighting and receptacle electrical circuits;

• Report findings to the COR or the COR's designee including identification of failed equipment and reason for failure;

• Leave signed and dated copy of the Maintenance Checklist and also leave signed and dated copies of any other monthly, quarterly or annual checklists if those were completed during the subject visit;

• Maintain emergency light units in operable condition.

6.0 TROUBLE CALL RESPONSE SERVICE

6.1 General. The Contractor shall provide "around-the-clock" service coverage for elevator trouble calls as described below and which are not excluded by paragraph 8.0 below.

6.2 Emergency Response Service - The Contractor shall provide, at no extra cost, a 24 hours/day, 7 days/week, 52 weeks/year coverage for emergency trouble calls. A trained mechanic shall be "on call" and shall be on site within a one-hour time period of the placement of an emergency trouble call by the Contracting Officer or COR. Emergency situations include people trapped in an elevator car, the suspicion/confirmation of a fire in or around elevator equipment, or an inoperative elevator with no suitable backup.

6.3 Non-Emergency Response Service - The Contractor shall provide, at no extra cost, a non-emergency response service. A trained elevator mechanic will be on site, within one working day, to trouble shoot and repair an elevator malfunction.

6.4 Callback Service - When an elevator which was previously worked on by the Contractor's mechanic, has a repeat malfunction within a 24-hour period, the Contractor shall be obligated to provide, at no extra cost, a return visit by a trained elevator mechanic to correct the problem, even if the problem is minor in nature. The elevator mechanic shall respond to this callback within a three-hour time period regardless of what time the Contracting Officer or COR made the callback complaint, including the "after hours" time periods.

7.0 PERSONNEL, TOOLS, REPAIR PARTS, MATERIALS AND SUPPLIES

The Contractor shall provide trained elevator mechanics with the appropriate tools and testing equipment for scheduled maintenance, unscheduled repairs, emergency repairs/assistance, safety inspection, and safety testing as required by this contract. The Contractor shall provide all of the necessary repair parts, materials and supplies to maintain, service, inspect and test the elevators as required by this contract.

8.0 EXCLUSIONS

The Contractor shall not assume responsibility for the following items of elevator equipment, which are not included in this contract:

• Car enclosures and related items including, but not limited to, fixed or removable panels, door panels, car gates, plenum chambers, hung ceilings, light diffusers, fluorescent tubes, dry cell batteries, handrails, mirrors, floor coverings, carpets and other architectural features and accessories;

• Buried caissons, cylinders and piping, and power supply feeder circuits to the machine room circuit breakers;

• Computer and microprocessor devices not exclusively dedicated to the elevator equipment such as terminal keyboards and display units;

• Communications equipment, such as telephones, intercoms, heat detectors, and smoke sensors, which were not installed by the Contractor or the original elevator installer;

• Major Repairs: Any individual unit or incident of repair with a total estimated cost (labor and direct material costs) exceeding $3,500.00 which is not covered under routine maintenance, is not covered by this contract. The Government reserves the right to determine how these repairs are to be handled. Such repairs will normally be accomplished by separate purchase order or contract. This exclusion does not apply if the repair is to correct damage caused by Contractor negligence.

9 Health and Safety

Department of State Acquisition Regulations (DOSAR) 652.236-70 Accident Prevention.

ACCIDENT PREVENTION (APR 2004)

(a) General. The contractor shall provide and maintain work environments and procedures which will safeguard the public and Government personnel, property, materials, supplies, and equipment exposed to contractor operations and activities; avoid interruptions of Government operations and delays in project completion dates; and, control costs in the performance of this contract. For these purposes, the contractor shall:

(1) Provide appropriate safety barricades, signs and signal lights;

(2) Comply with the standards issued by any local government authority having jurisdiction over occupational health and safety issues; and,

(3) Ensure that any additional measures the contracting officer determines to be reasonably necessary for this purpose are taken.

(4) For overseas construction projects, the contracting officer shall specify in writing additional requirements regarding safety if the work involves:

(i) Scaffolding;

(ii) Work at heights above two (2) meters;

(iii) Trenching or other excavation greater than one (1) meter in depth;

(iv) Earth moving equipment;

(v) Temporary wiring, use of portable electric tools, or other recognized electrical hazards. Temporary wiring and portable electric tools require the use of a ground fault circuit interrupter (GFCI) in the affected circuits; other electrical hazards may also require the use of a GFCI;

(vi) Work in confined spaces (limited exits, potential for oxygen less that 19.5 percent or combustible atmosphere, potential for solid or liquid engulfment, or other hazards considered to be immediately dangerous to life or health such as water tanks, transformer vaults, sewers, cisterns, etc.);

(vii) Hazardous materials – a material with a physical or health hazard including but not limited to, flammable, explosive, corrosive, toxic, reactive or unstable, or any operations which creates any kind of contamination inside an occupied building such as dust from demolition activities, paints, solvents, etc.; or

(viii) Hazardous noise levels.

(b) Records. The contractor shall maintain an accurate record of exposure data on all accidents incident to work performed under this contract resulting in death, traumatic injury, occupational disease, or damage to or theft of property, materials, supplies, or equipment. The contractor shall report this data in the manner prescribed by the contracting officer.

(c) Subcontracts. The contractor shall be responsible for its subcontractors’ compliance with this clause.

(d) Written program. Before commencing work, the contractor shall:

(1) Submit a written plan to the contracting officer for implementing this clause. The plan shall include specific management or technical procedures for effectively controlling hazards associated with the project; and,

(2) Meet with the contracting officer to discuss and develop a mutual understanding relative to administration of the overall safety program.

(e) Notification. The contracting officer shall notify the contractor of any non-compliance with these requirements and the corrective actions required. This notice, when delivered to the contractor or the contractor’s representative on site, shall be deemed sufficient notice of the non-compliance and corrective action required. After receiving the notice, the contractor shall immediately take corrective action. If the contractor fails or refuses to promptly take corrective action, the contracting officer may issue an order suspending all or part of the work until satisfactory corrective action has been taken. The contractor shall not be entitled to any equitable adjustment of the contract price or extension of the performance schedule on any suspension of work order issued under this clause.

A contractor carrying out a post managed project must submit a project safety and health plan that addresses the issues identified in the safety, health, and environmental management specification. In the plan, the contractor shall identify risks, propose practices to reduce risks, and supply protective measures to protect employees from project hazards and nuisance. Activity Hazard Analyses (AHA) must be developed as necessary to address hazards during the pre-award phase. They shall designate a competent person or a project safety manager to implement and oversee the safety and health plan that must also address waste disposal, emergency response, rescue operations, prevention of hazardous discharge to the environment, and protection of occupied spaces.

Safety control measures outlined in the plan must be verified by post personal and the work stopped if the hazards are not controlled.

Contractor’s General Responsibilities:

-Contractor must demonstrate understanding of their responsibilities under Post Managed Project safety program by addressing hazards in pre-planning processes and meetings.

-Contractors must provide their employees with a safe and healthful condition of employment.

-The contractor shall ensure individuals working at the site are trained and are aware of potential hazards. Contractors shall ensure these individuals are provided with proper safety equipment to prevent accident injury in accordance with the requirement of the contract.

Personal Protective Equipment:

Contractors are required to comply with the following provisions: Protective equipment for eyes, face , head, and extremities, protective clothing, respiratory devices and protective shields and barriers, shall be used wherever necessary by reason of hazards of process or environment.

Hand and Power Tool safety Contractors are required to:

-Ensure the safety of tools and equipment used by its employees anytime their employees utilize hand and power tools and other hand-held equipment.

-Ensure that all employees receive instruction on regulations and the safe use of each power tool.

Fall Protection Use anytime a contractor is suspected to work at unguarded location above 1.8m.

Contractors are required to:

-Reduce the hazards associated with falls.

-Control fall hazards through engineering controls and personal fall arrest systems, administrative controls and training.

-Have the necessary fall protection equipment to safely perform the job and have workers properly trained in the use of fall protection equipment.

Electrical Safety -Contractors are required to Identify any potential sources of electrical energy likely to cause death, injury, or serious physical harm.

-They are required to follow Lock-Out/Tag-Out procedures for Control of hazardous Energy as specified in OSHA 29 CFR 1910.147 Standard.

Load Handing Equipment (Cranes and Hoisting Equipment) -Contractors are required for proper selection and safe use of lifting equipment, cranes and other industrial trucks for material and equipment relocation during project stages.

-Contractors are required to have the procedures for safe operational controls during load handing operations developed by a qualified person.

Barricading and Fencing Contractors are responsible for maintaining a safe and accessible path-of-travel for all pedestrians. Contractor is required to:

-Erect and maintain for the duration of the Contract proper barricades including fencing material, traffic cones, caution tape complying with all access codes and regulations.

-maintain the project barriers in a sound, neat and clean condition.

-Ensure that no project material be stored and/or placed on the path-of travel.

Any other project safety requirement identified during the process shall be analyzed and a solution of elimination of the hazard to be coordinated with Post Safety representatives.

INSURANCE REQUIREMENTS

9.1 Personal Injury, Property Loss or Damage (Liability). The Contractor assumes absolute responsibility and liability for any and all personal injuries or death and property damage or losses suffered due to negligence of the Contractor's personnel in the performance of this contract

The Contractor's assumption of absolute liability is independent of any insurance policies.

Insurance. The Contractor, at its own expense, shall provide and maintain during the entire period of performance of this contract, whatever insurance is legally necessary. The Contractor shall carry the following minimum insurance:

Comprehensive General Liability

Bodily Injury 20,000.00 GEL per occurrence Property Damage 100,000.00 GEL per occurrence

Workers’ Compensation and Employer’s Liability

Workers’ Compensation and Occupational Disease Statutory, as required by Georgia country law

Employer’s Liability: as required by Georgia country law

9.3 Worker's Compensation Insurance. The Contractor agrees to provide all employees with worker's compensation benefits as required by the laws of either the country in which the employees are working or the employee's native country, whichever offers greater benefits, following FAR 52.228-4 “Worker’s Compensation and War-Hazard Insurance Overseas”.

10.0 PERMITS

The Contractor shall maintain in full force and affect all permits, licenses, and appointments required for the prosecution of work under this contract at no additional cost to the Government.

The Contractor shall obtain these permits, licenses, and appointments in compliance with host country laws.

11.0 LOCAL LAW REGISTRATION

If the local law or decree requires that one or both parties to the contract register the contract with the designated authorities to insure compliance with this law or decree, the entire burden of this registration shall rest upon the Contractor. Any local or other taxes which may be assessed against the contract shall be payable by the Contractor without Government reimbursement.

12.0 GOVERNMENT FURNISHED PROPERTY/EQUIPMENT

Reserved

13.0 QUALITY ASSURANCE AND SURVEILLANCE PLAN (QASP)

13.1 This plan provides an effective method to promote satisfactory contractor performance.

The QASP provides a method for the Contracting Officer's Representative (COR) to monitor Contractor performance, advise the Contractor of unsatisfactory performance, and notify the Contracting Officer of continued unsatisfactory performance. The Contractor, not the Government, is responsible for management and quality control to meet the terms of the contract.

The role of the Government is to monitor quality to ensure that contract standards are achieved.

Performance Objective Scope of Work Para Performance Threshold Services.

1. thru 11.

All required services are performed and no more than one

Performs all elevators maintenance services set forth in the scope of work.

(1) customer complaint is received per month.

13.2 Surveillance. The COR will receive and document all complaints from Government personnel regarding the services provided. If appropriate, the COR will send the complaints to the Contractor for corrective action.

13.3 Standard. The performance standard is that the Government receives no more than one (1) customer complaint per month. The COR shall notify the Contracting Officer of the complaints so that the Contracting Officer may take appropriate action to enforce the inspection clause (FAR 52.212-4, Contract Terms and Conditions-Commercial Items), if any of the services exceed the standard.

13.4. Procedures.

13.4.1 If any Government personnel observe unacceptable services, either incomplete work or required services not being performed they should immediately contact the COR.

13.4.2 The COR will complete appropriate documentation to record the complaint.

13.4.3 If the COR determines the complaint is invalid, the COR will advise the complainant.

The COR will retain the annotated copy of the written complaint for his/her files.

13.4.4 If the COR determines the complaint is valid, the COR will inform the Contractor and give the Contractor additional time to correct the defect, if additional time is available. The COR shall determine how much time is reasonable.

13.4.5 The COR shall, as a minimum, orally notify the Contractor of any valid complaints.

13.4.6 If the Contractor disagrees with the complaint after investigation of the site and challenges the validity of the complaint, the Contractor will notify the COR. The COR will review the matter to determine the validity of the complaint.

13.4.7 The COR will consider complaints as resolved unless notified otherwise by the complainant.

13.4.8 Repeat customer complaints are not permitted for any services. If a repeat customer complaint is received for the same deficiency during the service period, the COR will contact the Contracting Officer for appropriate action under the Inspection clause.

ATTACHMENT 1

LIST OF ELEVATORS TO BE SERVICE

A. Chancery

US Embassy Tbilisi #29 Georgian American Friendship Ave.

0131Tbilisi, Georgia

Passenger Elevator 1 Name: “PE 1” Date of Install: 2005

Manufacturer: KONE Capacity: 1600 KG

Speed: “1 m/s” Drive Type: Electric Traction Date of Last

Inspection: 10/23/2024 Known Issues: None

Passenger Elevator 2

Name: “PE 2” Date of Install: 2005

Manufacturer: KONE Capacity: 2000 KG Speed: “1 m/s” Drive Type: Electric Traction Date of Last

B. US Embassy Annex

US Embassy Tbilisi #29 Georgian American Friendship Ave.

0131 Tbilisi, Georgia

Passenger Elevator 3 Name: “PE 3” Date of Install: 2008 Manufacturer: KONE Capacity: 1800 KG Speed: “1 m/s” Drive Type: Electric Traction Date of Last Inspection: 10/23/2024 Known Issues: “None”

C. Chief of Mission Residence (CMR) Digomi #9 Nikoloz Beradze #26

0131 Tbilisi, Georgia

Passenger Elevator4 Name: “PE 4” Date of Install: 2006 Manufacturer: Kleeman Hellas S.A. Hydraulic Lift and Elevators Capacity: 400KG Speed: 1m/s Drive Type: Hydraulic Date of last

ATTACHMENT 2 - LIST OF TASKS TO BE PERFORMED

YEAR_________________ OBSERVE, CLEAN, ADJUST & TEST

MAINTENANCE OPERATION

Week# 1 2 3 4 5 6 7 8 9 1

Car Operation Starter, Control & Relay Panels M.G. Set & Regulator Selector Machine & Brake Relay Panel Supervisory System Rectified Voltage Test Volts Volts Governor Small Motors Car Top, Type E Landing Switch & Door Operator

Hoist Cables & Fastenings - Traveling Cables

Traffic Sentinel Pit-Compensator & Governor Sheave Guide Shoes or Roller Guides Hatch Doors & Interlocks Safety Edge Car Station Slow Down & Hatch Limit Switches

ATTACHMENT 2 (continued) – LIST OF TASKS TO BE PERFORMED: CLEAN & LUBRICA Week# 1 2 3 4 5 6 7 8 9 1

MG Set & Machine Bearings - Babbitt MG Set & Machine Bearings - Roller Governor Shaft Bearing SD Selector Guide & SD-DM Gear Box Car Door Hanger Rails Secondary Sheave Bearings - Babbitt SN Selector Lead Screw & Cams-Grease Sparingly

SD & DM Selector Chains, Carriage Guides & Cams

Governor Pins, Bevel Gears & Tripping Lever

Stepping Switch Brake Pins Hatch Doors - Terminal Floors Regulator & Small Motors Car Door Operator & Retiring Cam Guide Rail Lubricators Safety, Buffer, Comp.Guides & Gov.Tension Sheave

Deflector, Secondary, 2:1, Compensating Sheave Bearings-Roller

Hatch Doors -Intermediate Floors Door Operator Contact Cams Flexible Guide Shoes Hatch Limits & Slow Down Switch Brake Overhaul - Fill Out & Submit Report

Blow Out Panels & Rotating Equipment

YEAR_________________ OBSERVE, CLEAN, ADJUST & TEST

MAINTENANCE OPERATION

Week # 2

Car Operation Starter, Control & Relay Panels M.G. Set & Regulator Selector Machine & Brake Relay Panel Supervisory System Rectified Voltage Test Volts Volts Governor Small Motors

Car Top, Type E Landing Switch & Door Operator

Hoist Cables & Fastenings - Traveling Cables

Traffic Sentinel Pit-Compensator & Governor Sheave Guide Shoes or Roller Guides Hatch Doors & Interlocks Safety Edge Starter, Control & Relay Panel Connections & Wiring

Syncro Dials & Corr. Push Buttons Governor & Safety Test - Fill Out & Submit Report

Evaluation - Fill Out abd Submit Report

CLEAN & LUBRICATE

Week # 2

MG Set & Machine Bearings - Babbitt MG Set & Machine Bearings - Roller Governor Shaft Bearing SD Selector Guide & SD-DM Gear Box Car Door Hanger Rails Secondary Sheave Bearings - Babbitt SN Selector Lead Screw & Cams-Grease Sparingly

SD & DM Selector Chains, Carriage Guides & Cams

Governor Pins, Bevel Gears & Tripping Lever

Stepping Switch Brake Pins Hatch Doors - Terminal Floors Regulator & Small Motors Car Door Operator & Retiring Cam Guide Rail Lubricators Safety, Buffer, Comp.Guides & Gov.Tension Sheave

Deflector, Secondary, 2:1, Compensating Sheave Bearings-Roller

Hatch Doors -Intermediate Floors Door Operator Contact Cams Flexible Guide Shoes

SECTION 2 - CONTRACT CLAUSES

52.212-4 CONTRACT TERMS AND CONDITIONS – COMMERCIAL ITEMS

(NOV 2023) IS INCORPORATED BY REFERENCE. (SEE SF-1449,

BLOCK 27A)

FAR 52.212-5 Contract Terms and Conditions Required to Implement Statutes or Executive Orders—Commercial Products and Commercial Services (JAN 2025)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (Dec 2023) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Nov 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(5) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) ( 31 U.S.C. 3903 and 10 U.S.C. 3801).

(6) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(7) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Public Laws 108-77 and 108-78 ( 19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

__(1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Jun 2020), with Alternate I (Nov 2021) (41 U.S.C. 4704 and 10 U.S.C. 4655).

__(2) 52.203-13, Contractor Code of Business Ethics and Conduct (Nov 2021) (41 U.S.C. 3509)).

__(3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

__(4) 52.203-17, Contractor Employee Whistleblower Rights (Nov 2023) ( 41 U.S.C. 4712); this clause does not apply to contracts of DoD, NASA, the Coast Guard, or applicable elements of the intelligence community—see FAR 3.900(a).

X (5) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Jun 2020) (Pub. L. 109-282) ( 31 U.S.C. 6101 note).

__(6) [Reserved].

__(7) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

https://www.acquisition.gov/far/part-52#FAR_52_203_19 https://www.acquisition.gov/far/part-52#FAR_52_204_23 https://www.acquisition.gov/far/part-52#FAR_52_204_25 https://www.acquisition.gov/far/part-52#FAR_52_209_10 https://www.acquisition.gov/far/part-52#FAR_52_232_40 https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section3903&num=0&edition=prelim https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title10-section3801&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_233_3 https://www.acquisition.gov/far/part-52#FAR_52_233_4 https://www.acquisition.gov/far/part-52#FAR_52_203_6 https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title10-section4655&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_203_13 https://www.acquisition.gov/far/part-52#FAR_52_203_15 https://www.acquisition.gov/far/part-52#FAR_52_203_17 https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-section4712&num=0&edition=prelim https://www.acquisition.gov/far/part-3#FAR_3_900 https://www.acquisition.gov/far/part-52#FAR_52_204_10 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section6101&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_204_14

__(8) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

X (9) 52.204-27, Prohibition on a ByteDance Covered Application (Jun 2023) (Section 102 of Division R of Pub. L. 117-328).

__(10) 52.204-28, Federal Acquisition Supply Chain Security Act Orders—Federal Supply Schedules, Governmentwide Acquisition Contracts, and Multi-Agency Contracts. (Dec 2023) ( Pub. L. 115–390, title II).

X (11) (i) 52.204-30, Federal Acquisition Supply Chain Security Act Orders—Prohibition. (Dec 2023) ( Pub. L. 115–390, title II).

__(ii) Alternate I (Dec 2023) of 52.204-30.

X (12) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Nov 2021) ( 31 U.S.C. 6101 note).

__(13) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018) ( 41 U.S.C. 2313).

__(14) [Reserved].

__(15) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Oct 2022) ( 15 U.S.C. 657a).

__(16) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2022) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

__(17) [Reserved] __(18)

(i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2020) (15 U.S.C. 644).

__(ii) Alternate I (Mar 2020) of 52.219-6.

__(19)

(i) 52.219-7, Notice of Partial Small Business Set-Aside (Nov 2020) (15 U.S.C. 644).

__(ii) Alternate I (Mar 2020) of 52.219-7.

__(20) 52.219-8, Utilization of Small Business Concerns (Feb 2024) (15 U.S.C. 637(d)(2) and (3)).

__(21)

(i) 52.219-9, Small Business Subcontracting Plan (Sep 2023) (15 U.S.C. 637(d)(4)).

__(ii) Alternate I (Nov 2016) of 52.219-9.

__(iii) Alternate II (Nov 2016) of 52.219-9.

__(iv) Alternate III (Jun 2020) of 52.219-9.

__(v) Alternate IV (Sep 2023) of 52.219-9.

__(22)

(i) 52.219-13, Notice of Set-Aside of Orders (Mar 2020) (15 U.S.C. 644(r)).

__(ii) Alternate I (Mar 2020) of 52.219-13.

__(23) 52.219-14, Limitations on Subcontracting (Oct 2022) (15 U.S.C. 657s).

__(24) 52.219-16, Liquidated Damages—Subcontracting Plan (Sep 2021) (15 U.S.C. 637(d)(4)(F)(i)).

__(25) 52.219-27, Notice of Set-Aside for, or Sole-Source Award to, Service-Disabled Veteran- Owned Small Business (SDVOSB) Concerns Eligible Under the SDVOSB Program (Feb 2024) (15 U.S.C. 657f).

__(26)

(i) 52.219-28, Post Award Small Business Program Rerepresentation (Feb 2024) X (15 U.S.C. 632(a)(2)).

https://www.acquisition.gov/far/part-52#FAR_52_204_15 https://www.acquisition.gov/far/part-52#FAR_52_204_27 https://www.acquisition.gov/far/part-52#FAR_52_204_28 https://www.govinfo.gov/link/plaw/115/public/390 https://www.acquisition.gov/far/part-52#FAR_52_204_30 https://www.govinfo.gov/link/plaw/115/public/390 https://www.acquisition.gov/far/part-52#FAR_52_204_30 https://www.acquisition.gov/far/part-52#FAR_52_209_6 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section6101&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_209_9 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-section2313&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_219_3 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title15-section637a&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_219_4 https://www.acquisition.gov/far/part-52#FAR_52_219_6 https://www.acquisition.gov/far/part-52#FAR_52_219_6 https://www.acquisition.gov/far/part-52#FAR_52_219_7 https://www.acquisition.gov/far/part-52#FAR_52_219_7 https://www.acquisition.gov/far/part-52#FAR_52_219_8 https://www.acquisition.gov/far/part-52#FAR_52_219_9 https://www.acquisition.gov/far/part-52#FAR_52_219_9 https://www.acquisition.gov/far/part-52#FAR_52_219_9 https://www.acquisition.gov/far/part-52#FAR_52_219_9 https://www.acquisition.gov/far/part-52#FAR_52_219_9 https://www.acquisition.gov/far/part-52#FAR_52_219_13 https://www.acquisition.gov/far/part-52#FAR_52_219_13 https://www.acquisition.gov/far/part-52#FAR_52_219_14 https://www.acquisition.gov/far/part-52#FAR_52_219_16 https://www.acquisition.gov/far/part-52#FAR_52_219_27 https://www.acquisition.gov/far/part-52#FAR_52_219_28

__(ii) Alternate I (Mar 2020) of 52.219-28.

__(27) 52.219-29, Notice of Set-Aside for, or Sole-Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Oct 2022) (15 U.S.C. 637(m)).

__(28) 52.219-30, Notice of Set-Aside for, or Sole-Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Oct 2022) (15 U.S.C. 637(m)).

__(29) 52.219-32, Orders Issued Directly Under Small Business Reserves (Mar 2020) ( 15 U.S.C. 644(r)).

__(30) 52.219-33, Nonmanufacturer Rule (Sep 2021) ( 15 U.S.C. 637(a)(17)).

__(31) 52.222-3, Convict Labor (Jun 2003) (E.O.11755).

X (32) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Feb 2024).

__(33) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

__(34)

(i) 52.222-26, Equal Opportunity (Sep 2016) (E.O.11246).

__(ii) Alternate I (Feb 1999) of 52.222-26.

__(35)

(i) 52.222-35, Equal Opportunity for Veterans (Jun 2020) ( 38 U.S.C. 4212).

__(ii) Alternate I (Jul 2014) of 52.222-35.

__(36)

(i) 52.222-36, Equal Opportunity for Workers with Disabilities (Jun 2020) ( 29 U.S.C. 793).

__(ii) Alternate I (Jul 2014) of 52.222-36.

__(37) 52.222-37, Employment Reports on Veterans (Jun 2020) ( 38 U.S.C. 4212).

__(38) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

__(39) X (i) 52.222-50, Combating Trafficking in Persons (Nov 2021) (22 U.S.C. chapter 78 and E.O.

13627).

__(ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

__(40) 52.222-54, Employment Eligibility Verification (May 2022) (Executive Order 12989).

(Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in FAR 22.1803.)

__(41)

(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) ( 42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__(ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__(42) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (May 2024) ( 42 U.S.C. 7671, et seq.).

__(43) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (May 2024) ( 42 U.S.C. 7671, et seq.).

__(44) 52.223-20, Aerosols (May 2024) ( 42 U.S.C. 7671, et seq.).

__(45) 52.223-21, Foams (May 2024) ( 42 U.S.C. 7671, et seq.).

__(46) 52.223-23, Sustainable Products and Services (May 2024) ( E.O. 14057, 7 U.S.C.

8102, 42 U.S.C. 6962, 42 U.S.C. 8259b, and 42 U.S.C. 7671l).

X (47)

(i) 52.224-3 Privacy Training (Jan 2017) ( 5 U.S.C. 552 a).

https://www.acquisition.gov/far/part-52#FAR_52_219_28 https://www.acquisition.gov/far/part-52#FAR_52_219_29 https://www.