CONTRACT FORMAT.pdf

Contract Format

Section C: Description/Specifications/Statement of Work

The contractor shall comply with the Statement of Work/Specifications attached

Section D: Packaging and Marking

No clauses

Section E: Inspection and Acceptance

No clauses

Section F: Deliveries or Performance

The period of performance for this requirement is ___3__ Calendar Days from the start date noted on the notice to proceed. .

Clauses incorporated by reference:

FAR 52.211-10 Commencement, Prosecution, and Completion of Work. Alt I. (Apr1984)

The Contractor shall be required to (a) commence work under this contract within __10_______ [Contracting Officer insert number] calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than ___3______.* The time stated for completion shall include final cleanup of the premises.

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

FAR 52.211-13 Time Extensions. (Sep 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

FAR 52.242-14 Suspension of Work. (Apr 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1)by an act of the Contracting Officer in the administration of this contract, or (2)by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed-

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

Section G: Contract Administration Data

The invoicing instructions are included as an attachment to this contract.

Section H: Special Contract Requirements

52.236-1 Performance of Work by the Contractor.

Performance of Work by the Contractor (Apr 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least _Twenty-Five Percent 25%_ of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

The Contractor shall submit, simultaneously with the schedule of costs required by the Payments under Fixed-Price Construction Contracts clause of the contract, a statement designating the portions of contract work to be performed with the Contractor's own forces. The approved schedule of costs will be used in determining the value of a work activity/event, or portions thereof, of the work for the purpose of this article.

In establishing the percent of work to be performed by the Contractor. Cost of material and equipment installed by such labor may be included. The work by the Contractor's executive, administrative and clerical forces shall be excluded in establishing compliance with the requirements of this clause.

Section I: Contract Clauses

See attached “FREEPORT CLAUSES AND INVOICING INSTRUCTIONS”

Section J: List of Attachments

Attachment List

Attachment Name Attachment Date Number of Pages

STATEMENT OF WORK 8

Wage Determination Number TX20250062 01/03/2025 1-3-2025 25

DOCK REMOVAL CLAUSES – INVOICE

INSTRUCTIONS 20