Combined Synopsis - Solicitation (70RFP324QE3000002).pdf

Combined Synopsis/ Solicitation IAW FAR 5.203 (a) (2), FAR 5.207 & FAR 12.603

“Whenever agencies are required to publicize notice of proposed contract actions under 5.201, they must proceed as follows:

(2) Use the combined synopsis and solicitation procedure (see 12.603)

FAR 12.603 Streamlined solicitations for commercial items & FAR 5.207 Preparation and transmittal of synopsis

The Department of Homeland Security (DHS), Federal Protective Service (FPS) is soliciting quotes for a various Personal Protective Equipment (PPE) to be delivered to Alexandria, VA 22312. Specific requirements are contained in the Federal Protective Service (FPS) Statement of Work (SOW). The commercial items shall be secured through a streamlined solicitation as outlined under FAR 12.603. As such, the following synopsis information as required under FAR 5.207 is being provided:

(1) Action Code: 70RFP324QE3000002

(2) Date: 2/6/24

(3) Year: 2024

(4) Contracting Office Zip Code: 19106

(5) NAICS Code: 315990

(6) Contracting Office Address: 701 Market Street, Philadelphia, PA

(7) Subject: Personal Protective Equipment for the Federal Protective Service (FPS)

(8) Proposed Solicitation Number: 70RFP324QE3000002

(9) Closing Response Date: 2/8/24

(10) Contact Point or Contract Specialist: Adam Dombrowski

(11) Description: Solicitation 70RFP324QE3000002 shall procure items herein, Personal Protective Equipment, in accordance with the attached SOW. DHS/FPS intends to award a Firm Fixed Price, Commercial Type Purchase Order in response to Request for Quote (RFQ) 70RFP324QE3000002. This requirement is being competed as a Small Business Set Aside.

(12) Place of Performance: Delivery to: Federal Protective Service (FPS) Mail Stop 0663 6315 Bren Mar Drive Suite 100 Alexandria, VA 22312

(13) Period of Performance: Delivery to be determined after days of receipt of award

(14) Set- Aside Statues: Small Business only

This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation: quotes are being requested and a written solicitation is hereby included.

A complete description of the requirements briefly described herein, to include Statement of Work, terms and conditions, provisions, clauses and associated attachments are all included in the formal Request for Quote (RFQ) 70RFP324QE3000002 attached to this synopsis/solicitation announcement.

All items required are denoted as Brand Name or Equal, with Salient features describing each piece of equipment. If proposing an item that is not the brand shown, the contractor shall ensure they provide extensive specifications detailing the alternatives to be considered. ALL QUOTE SUBMISSIONS SHALL

INCLUDE PRICING AS WELL AS ALL PRODUCT DESCRIPTIONS, CUT SHEETS AND/OR ANY

OTHER DOCUMENTATION TO DENOTE THE PROPOSED EQUIPMENT.

The Government will conduct a procurement evaluation in accordance with FAR 13.106-2(b)(3) and (4).

Schedule Of Item(s) - Responsible quoters shall provide a Firm Fixed Price (FFP) for the items described in the SOW. Further details are as follows:

• Contractor shall provide all equipment, materials, supplies to provide the Personal Protective Equipment (PPE), in accordance with the attached Statement of Work (SOW).

• Quoters shall include itemized pricing for each of the components.

• Quoters shall include specifications of all proposed equipment within their quotes.

• Further description of line items is detailed in the Statement of Work.

• A detailed description of item sizing will be provided upon award.

Line Item: Description: Expected Quantity: Unit: Unit Price: Total Amount:

0001 Helmet/Visor 240 EA

0002 Trust Jacket / Trousers 240 EA

0003 Gloves 240 EA

0004 Flight Jacket / Pant 240 EA

0005 Balaclava 240 EA

0006 Boots 240 EA

Quotations are due no later than 4:00 P.M. ET on 2/8/24 and shall be submitted electronically to the Contract Specialist, Adam Dombrowski, at Adam.E.Dombrowski@fps.dhs.gov . Facsimile quotes are not permitted and will be disregarded if received.

mailto:Adam.E.Dombrowski@fps.dhs.gov

DEPARTMENT OF HOMELAND SECURITY (DHS)

FEDERAL PROTECTIVE SERVICE (FPS)

STATEMENT OF WORK (SOW)

FOR

PERSONAL PROTECTIVE EQUIPMENT

1.0 GENERAL

1.1 ORGANIZATION

U.S. Department of Homeland Security (DHS), Federal Protective Service (FPS) Specialized and Advanced Training Division (SATD).

1.1 BACKGROUND

The Federal Protective Service (FPS) is a federal law enforcement agency that provides integrated security and law enforcement services to over Nine Thousand (9,000 federally owned and leased buildings, facilities, properties, and other assets. The Federal Protective Service seeks to improve its ability to enforce the law while simultaneously balancing civil rights during events that require crowd/large group management. In 2019, the Federal Protective Service, Training and Professional Development Directorate (TPD) began developing a curriculum to prepare officers to ensure civil rights to gather and/or protest while simultaneously maintaining order using protective tactics and de-escalation techniques. Developing a practical curriculum guide is a multi-step, ongoing, and cyclical process. The process progresses from evaluating the existing program to designing a new, improved program. Implementing a new program requires new equipment and evaluation of the revised program. To assist TPD with this process, TPD seeks to procure essential and necessary equipment items to support the FPS Public Order Training Portfolio (FPSPOTP).

1.2 SCOPE

The objective of this effort is to procure Public Order Public Safety (POPS) Personal Protective Equipment (PPE) for FPS Law Enforcement Officers (LEOs).

The Contractor shall provide the following POPS PPE that meet the specific requirements for the level of protection as noted/required within the following:

o Reference: Department of Justice, National Institute of Justice (NIJ), Protective Equipment for Civil Disturbance Units (NCJ #251228) - NIJ has identified either British Standard 7971, Protective Clothing and Equipment for Use in Violent Situations and in Training or standards developed by the U.K. Home Office (HOSDB Blunt Trauma Protector Standards for UK Police, PSDB Protective Headwear Standard for UK Police, and HOSDB Flame Retardant Overalls Standard for UK Police).

Item 0001

PUBLIC ORDER PUBLIC SAFETY HELMET

The POPS helmet shall meet the following specifications equivalent to the Schuberth P100N A (Adjustable) POPS Helmet, with Salient features such as:

o Must have Expanded Polystyrene (EPS) foam impact protection and be able to sustain multiple hit blunt impact protection and still maintain interior helmet integrity.

o The exterior shell and neck guard must be constructed with multiple layers of Aramid and ballistic nylon to provide fire, chemical, impact and stab protection.

o The helmet must have VPAM: KDIW 2004 stab and impact resistance certification.

o The neck curtain must be padded and covered in Kevlar. It must also be replaceable and able to protect against liquid runoff.

o The outer shell must be coated in a fire extinguishing lacquer.

o Chinstrap face materials must be 100% Nomex Lycra and fasteners must be fire retardant.

o The interior liner must be 100% antibacterial and be 100% Nomex.

o The interior liner must be washable and able to be decontaminated.

o Must have removable head, crown, and cheek pads.

o Must have a high impact polycarbonate visor with rubber top seal to protect against liquid runoff.

o The visor must have anti-fog and anti-scratch coatings.

o Must have a three-point chinstrap with a quick adjusting ratchet style adjustment for effective fit and retention.

o Must have rapid circumferential fit adjustments which adjust to facilitate wearing a respirator, or other protective head gear, and then back to fitting without wearing them.

o Must be available in four helmet sizes (46-52, 53-56, 57-60, and 61-65 centimeters), as well as special helmet sizes upon request.

o Color: Navy blue

Item 0002

FIRE RETARDANT IMPACT PROTECTIVE ENSEMBLE (UNDERGARMENTS)

The impact protective ensemble shall meet the following specifications equivalent to the Trust Jacket and Trousers (MLA ltd.co.uk) ensemble complete with impact protective pads/guard, with Salient features such as:

o The garments must have met or exceeded standards for certifications for blunt trauma protection standards such as HOSDB 20/70 standards in the UK.

o Both garments must be easy to don and doff for most body types. Top must have a zipper for donning/doffing.

o The garments must be light weight.

o Must be designed to be worn comfortably under ballistic armor and police uniforms.

o Must be designed to be low profile ensuring officers remain agile to the environment and not to impede the user’s free range of motion.

o Must be made of breathable fire-retardant material and components.

o Protective pads/guards must be held within pockets designed to ensure they stay in place to maintain protective coverage.

o Impact Protective pads/guards must be removable.

o Impact Protective pads/guards must be made of D30.

o The garments must be machine washable and able to be decontaminated.

o There must be available groin protective pads/guards designed specifically for men and women.

o Protective pads/guards in the jacket must protect upper and lower arms, elbows, shoulders, collar bones.

o Pads/guards in the trousers must protect the groin, thighs, knees, and shins.

o Protective pads/guards must have impact absorbing and impact deflecting properties.

o Sizes must range from Extra Small (XS) to Extra Extra Large (XXL) with the option to order specific sizes upon request.

Item 0003

TACTICAL GLOVE REQUIREMENT

The tactical gloves shall meet the following specifications equivalent to the First Tactical, Slash & Flash Protective Knuckle Glove, with Salient features such as:

o Must have Kevlar lined palm that is ANSI Level II certified for abrasion resistance.

o Must be constructed with a Nomex jersey fire-retardant material with fire-retardant silicon overprint.

o Must have high impact-resistant foam padding to back of hand.

o Must have TPR hard knuckle protection.

o Must be colored black.

o Must be adjustable at the wrist with hook and loop closure.

o Gloves must allow for maximum dexterity for the safe use of a multitude of weapon triggers— able to fit within trigger guards and have finger sensitivity to allow for the correct manipulation of firearm and less lethal weapon triggers.

o Gloves must be machine washable with the ability to be decontaminated from substance exposer.

o Sizes must range from Small to Extra Large (XL) with the option to order specific sizes upon request.

Item 0004

LAW ENFORCEMENT TWO-PIECE UNIFORM (JACKET AND PANTS)

The uniform characteristics shall meet the following specifications as a fire-retardant protective uniform made from Nomex equivalent to the Massif Flight Suit Jacket and Pants, with Salient features such as:

o All fabrics pass the ASTM D6413-F2302 performance specifications for fire-retardant.

o Fabrics must be composed of 45% Nomex Meta-Aramid and 6% Kevlar Para-Aramid o Must be machine washable and able to be decontaminated.

o Fabrics must meet the Nomex industrial launderers estimates for durability—being able to last five years and worn and laundered at least 125 times without compromising its protection and professional appearance.

o Must not lose its fire-retardant properties from extended wear or machine washing.

o Must have an Athletic Fit which is professional in appearance and not impinge any range of motion.

o Both garments must have zipper closures for donning and doffing.

o The garments must have a means to attach the jacket to the pants that maximizes range of motion and does not permit separation of garments.

o There must be a fire-retardant loop patch on chest, shoulders and chest for Velcro identification patches.

o Jackets must have two chest pockets and two upper arm pockets.

o Pockets must be mesh-lined for enhanced heat-stress mitigation.

o Sleeve cuffs must have fire-retardant hook/loop adjustment.

o Pants must have dual-entry secure cargo pockets and secure calf pockets.

o There must be a three-point attachment system to connect the jacket with the pants.

o Knees must be articulated—having been constructed to aid knees by not limiting range of motion in climbing, kneeling, running, etc.

o For ease of donning/doffing and wearing over boots, pants must have side leg openings with hook/loop closures and adjustment tabs at the pant cuff.

o Every component must be fire-retardant (hook/loop patches, elastics, zippers, etc.)

o Sizes must range from XS to XXL with the option to order specific sizes upon request.

Item 0005

BALACLAVA

The balaclava characteristics shall meet the following specifications equivalent to the Massif Hot Johns Balaclava, with Salient features such as:

o All fabrics pass the ASTM D6413-F2302 performance specifications for fire-retardant.

o Fire-retardant fabric that is 91% Nomex Meta-Aramid that can stretch to conform and protect the neck, face, ears, nose and long hair from heat and flames.

o Machine washable and able to be decontaminated.

o Breathable, lightweight, and durable with excellent moisture management o Constructed with flat seam stitching that mitigates rubbing or impinging on the face or head while wearing it under a helmet.

o Must be soft to the touch and non-irritating to skin.

o Can be worn in several configurations as a neck gaiter, half-face, full-face and head cover.

o Ear seams to help keep the garment in place and add strength.

o Compressible to be stored easily in a pocket until needed.

o Sizes must range from Small to Extra Large o Color: black

Item 0006

FIRE-RETARDANT TACTICAL BOOTS

The fire-retardant tactical boots shall meet the following specifications equivalent to the Pro Warrington 3003, 8" Wildland/Station Boot, with Salient features such as:

o Must have NFPA 1977 certification.

o Any component of the tactical boots which stands to encounter fire must be made of fire-retardant material to include, the laces, uppers, tongue, stitching.

o Boots must be water-resistant that can still allow for moisture to escape to keep feet dry.

o Have an abrasion resistant and bacteria resistant Cambrelle lining.

o Must have a non-chafing collar o The outsole must be a Vibram Technical Lug fire retardant NFPA compound and provide improved traction.

o Must have a puncture resistant steel bottom plate.

o Composite or steel toe protection o The footbed must provide for cushioning that will maximize support and comfort.

o The boots must provide for athletic mobility.

o Minimum of an 8-inch-tall shaft/quarter o Color: black

2.0 CONTRACTOR PERSONNEL

2.1 EMPLOYEE IDENTIFICATION

N/A.

2.2 EMPLOYEE CONDUCT

N/A.

2.3 REMOVING EMPLOYEES FOR MISCONDUCT OR SECURITY REASONS

N/A.

3.0 OTHER APPLICABLE CONDITIONS

N/A.

3.1 PERIOD OF PERFORMANCE

All products shall be delivered immediately after upon receipt of award. Delivery timeframe to be established upon award.

3.2 PLACE OF PERFORMANCE

Delivery to:

Federal Protective Service (FPS) Mail Stop 0663 6315 Bren Mar Drive Suite 100 Alexandria, VA 22312

3.3 HOURS OF OPERATION

N/A.

3.4 TRAVEL

N/A

3.5 GOVERNMENT FURNISHED RESOURCES

N/A.

3.6 CONTRACTOR FURNISHED PROPERTY

The Contractor shall furnish all materials and supplies necessary.

4.0 INVOICING

4.1 Payments shall not be made for any unauthorized supplies or for any unauthorized changes to the work specified herein. This includes any supplies or services performed by the Contractor of their own volition or at the request of an individual other than a duly appointed CO. Only a duly appointed CO is authorized to change the specifications, terms, and conditions under this effort.

4.2 The Contractor shall submit invoices within 15 business days after acceptance of shipment.

4.3 The invoice shall have the following information:

• Name of Contractor

• Contract Number

• Date of Order

• Quantity, Unit Price, and Extension of each item

5.0. AUTHORITY:

Only the DHS Contracting Officer has authority to modify the terms and conditions of this task order.

6.0. INVOICING:

After award of any potential purchase order, but prior to performance, the contractor shall meet with the Contracting Officer and Contracting Officer’s Representative upon request to discuss proper invoice preparation and submission. The contractor and government shall agree on a standardized invoice format to be used for submission of all invoices under this contract that meets the requirements of FAR 52.212-4 Contract Terms and Conditions – Commercial Items, Paragraph (g) “Invoice.” Use of a standardized invoice format will facilitate timely invoice reviews and approvals. Failure to use the agreed standardized invoice format shall result in rejection of invoices.

Invoices shall not contain any employee Personally Identifiable Information (PII). Invoices shall be submitted via one of the following three methods:

1. by mail: NPPD-FPS-Region 11

DHS, NPPD

Financial Operations-Burlington

P.O. Box 1279

Williston, VT 05495-1279

Attn: FPS Region11 Invoice

2. by facsimile (fax): # 802-288-7658. The invoice submission shall include a cover sheet with the contractor’s point of contact information and # of pages.

3. by e-mail: NPPDInvoice.Consolidation@ice.dhs.gov

The invoice number and FPS Region 11 shall be annotated in the subject line of the e-mail. Only (1) invoice shall be submitted per e-mail message. The invoice attached to the e-mail shall be in Portable Document Format (PDF)

Invoices submitted by other than these three methods will not be processed and will be returned.

Contractors shall provide an informational copy of any invoice to the Contracting Officer, the Contract Specialist and the Contracting Officer’s Representative concurrent with submission to the designated billing office referenced above.

In addition to the information required for a proper invoice as identified in FAR 52.212-4 (g)(1), Contract Terms and Conditions – Commercial Items, (FEB 2012), the contractor shall include the following information:

1. Annotate “FPS Region 11” on the face of each invoice.

2. Clearly identify the period of performance for which the supply was delivered.

3. Cite the identical CLIN description on the invoice as what is cited within the CLIN description listed in any subsequent purchase order.

Failure to comply with these submission requirements will result in rejection of the invoice.

Final invoices shall be marked “FINAL” and be accompanied by an executed “Contractor’s Release” (DHS Form 700-3 (12/07)) available at http://dhsconnect.dhs.gov/forms/documents/DHS_Form_700-3.pdf or by request to the Contracting Officer. A release discharging the Government, its officers, agents and employees of and from all liabilities, obligations, and claims arising out of or under this contract subject only to the exceptions listed at FAR 52.212-4 (ALT1), paragraph (i)(7)(i)-(iii) is a condition precedent to final payment.

mailto:NPPDInvoice.Consolidation@ice.dhs.gov http://dhsconnect.dhs.gov/forms/documents/DHS_Form_700-3.pdf

CLAUSES

FAR 52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders – Commercial Products and Commercial Services (Jan 2022)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (NOV 2021) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (NOV 2015).

(5) 52.233-3, Protest After Award (AUG 1996) ( 31 U.S.C. 3553).

(6) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77 and 108-78 ( 19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

[Contracting Officer check as appropriate.]

__ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (JUN 2020), with Alternate I (NOV 2021) ( 41 U.S.C. 4704 and 10 U.S.C. 2402).

_X_ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (NOV 2021) ( 41 U.S.C. 3509)).

__ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (JUN 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

https://www.acquisition.gov/far/52.203-19#FAR_52_203_19 https://www.acquisition.gov/far/52.204-23#FAR_52_204_23 https://www.acquisition.gov/far/52.204-25#FAR_52_204_25 https://www.acquisition.gov/far/52.209-10#FAR_52_209_10 https://www.acquisition.gov/far/52.233-3#FAR_52_233_3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.233-4#FAR_52_233_4 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.203-6#FAR_52_203_6 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.203-13#FAR_52_203_13 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.203-15#FAR_52_203_15

__ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (JUN 2020) (Pub. L. 109-282) ( 31 U.S.C. 6101 note).

__ (5) [Reserved].

__ (6) 52.204-14, Service Contract Reporting Requirements (OCT 2016) (Pub. L.

111-117, section 743 of Div. C).

__ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (OCT 2016) (Pub. L. 111-117, section 743 of Div. C).

__ (8) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (NOV 2021) ( 31 U.S.C. 6101 note).

__ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (OCT 2018) ( 41 U.S.C. 2313).

__ (10) [Reserved].

__ (11) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (SEP 2021) ( 15 U.S.C. 657a).

__ (12) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (SEP 2021) (if the offeror elects to waive the preference, it shall so indicate in its offer) ( 15 U.S.C. 657a).

__ (13) [Reserved]

_X_ (14)

(i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2020) ( 15 U.S.C. 644).

__ (ii) Alternate I (MAR 2020) of 52.219-6.

__ (15)

(i) 52.219-7, Notice of Partial Small Business Set-Aside (NOV 2020) ( 15 U.S.C. 644).

__ (ii) Alternate I (MAR 2020) of 52.219-7.

__ (16) 52.219-8, Utilization of Small Business Concerns (OCT 2018) ( 15 U.S.C. 637(d)(2) and (3)).

__ (17) https://www.acquisition.gov/far/52.204-10#FAR_52_204_10 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section6101&num=0&edition=prelim https://www.acquisition.gov/far/52.204-14#FAR_52_204_14 https://www.acquisition.gov/far/52.204-15#FAR_52_204_15 https://www.acquisition.gov/far/52.209-6#FAR_52_209_6 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section6101&num=0&edition=prelim https://www.acquisition.gov/far/52.209-9#FAR_52_209_9 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-section2313&num=0&edition=prelim https://www.acquisition.gov/far/52.219-3#FAR_52_219_3 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title15-section637a&num=0&edition=prelim https://www.acquisition.gov/far/52.219-4#FAR_52_219_4 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-6#FAR_52_219_6 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-6#FAR_52_219_6 https://www.acquisition.gov/far/52.219-7#FAR_52_219_7 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-7#FAR_52_219_7 https://www.acquisition.gov/far/52.219-8#FAR_52_219_8

(i) 52.219-9, Small Business Subcontracting Plan (NOV 2021) ( 15 U.S.C. 637(d)(4)).

__ (ii) Alternate I (NOV 2016) of 52.219-9.

__ (iii) Alternate II (NOV 2016) of 52.219-9.

__ (iv) Alternate III (JUN 2020) of 52.219-9.

__ (v) Alternate IV (SEP 2021) of 52.219-9.

__ (18)

(i) 52.219-13, Notice of Set-Aside of Orders (MAR 2020) ( 15 U.S.C. 644(r)).

__ (ii) Alternate I (MAR 2020) of 52.219-13.

__ (19) 52.219-14, Limitations on Subcontracting (SEP 2021) ( 15 U.S.C. 637s).

__ (20) 52.219-16, Liquidated Damages—Subcontracting Plan (SEP 2021) ( 15 U.S.C. 637(d)(4)(F)(i)).

__ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set- Aside (SEP 2021) ( 15 U.S.C. 657f).

__ (22)

(i) 52.219-28, Post Award Small Business Program Rerepresentation (SEP 2021) ( 15 U.S.C. 632(a)(2)).

__ (ii) Alternate I (MAR 2020) of 52.219-28.

__ (23) 52.219-29, Notice of Set-Aside for, or Sole-Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (SEP 2021) ( 15 U.S.C. 637(m)).

__ (24) 52.219-30, Notice of Set-Aside for, or Sole-Source Award to, Women- Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (SEP 2021) ( 15 U.S.C. 637(m)).

__ (25) 52.219-32, Orders Issued Directly Under Small Business Reserves (MAR 2020) ( 15 U.S.C. 644(r)).

__ (26) 52.219-33, Nonmanufacturer Rule (SEP 2021) ( 15U.S.C. 637(a)(17)).

X_ (27) 52.222-3, Convict Labor (JUN 2003) (E.O.11755).

https://www.acquisition.gov/far/52.219-9#FAR_52_219_9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-9#FAR_52_219_9 https://www.acquisition.gov/far/52.219-9#FAR_52_219_9 https://www.acquisition.gov/far/52.219-9#FAR_52_219_9 https://www.acquisition.gov/far/52.219-9#FAR_52_219_9 https://www.acquisition.gov/far/52.219-13#FAR_52_219_13 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-13#FAR_52_219_13 https://www.acquisition.gov/far/52.219-14#FAR_52_219_14 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-16#FAR_52_219_16 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-27#FAR_52_219_27 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-28#FAR_52_219_28 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-28#FAR_52_219_28 https://www.acquisition.gov/far/52.219-29#FAR_52_219_29 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-30#FAR_52_219_30 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-32#FAR_52_219_32 https://www.govinfo.gov/content/pkg/USCODE-2018-title15/html/USCODE-2018-title15-chap14A-sec644.htm https://www.acquisition.gov/far/52.219-33#FAR_52_219_33 https://www.govinfo.gov/content/pkg/USCODE-2018-title15/html/USCODE-2018-title15-chap14A-sec637.htm https://www.acquisition.gov/far/52.222-3#FAR_52_222_3

__ (28) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (JAN 2022) (E.O.13126).

X_ (29) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

X_ (30)

(i) 52.222-26, Equal Opportunity (SEP 2016) (E.O.11246).

__ (ii) Alternate I (FEB 1999) of 52.222-26.

_X_ (31)

(i) 52.222-35, Equal Opportunity for Veterans (JUN 2020) ( 38 U.S.C. 4212).

__ (ii) Alternate I (JUL 2014) of 52.222-35.

X_ (32)

(i) 52.222-36, Equal Opportunity for Workers with Disabilities (JUN 2020) ( 29 U.S.C. 793).

__ (ii) Alternate I (JUL 2014) of 52.222-36.

__ (33) 52.222-37, Employment Reports on Veterans (JUN 2020) ( 38 U.S.C. 4212).

__ (34) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496).

X_ (35)

(i) 52.222-50, Combating Trafficking in Persons (NOV 2021) ( 22 U.S.C. chapter 78 and E.O.

13627).

__ (ii) Alternate I (MAR 2015) of 52.222-50 ( 22 U.S.C. chapter 78 and E.O.

13627).

__ (36) 52.222-54, Employment Eligibility Verification (NOV 2021) . (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in

FAR 22.1803.)

__ (37)

(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) ( 42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

https://www.acquisition.gov/far/52.222-19#FAR_52_222_19 https://www.acquisition.gov/far/52.222-21#FAR_52_222_21 https://www.acquisition.gov/far/52.222-26#FAR_52_222_26 https://www.acquisition.gov/far/52.222-26#FAR_52_222_26 https://www.acquisition.gov/far/52.222-35#FAR_52_222_35 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title38-section4212&num=0&edition=prelim https://www.acquisition.gov/far/52.222-35#FAR_52_222_35 https://www.acquisition.gov/far/52.222-36#FAR_52_222_36 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title29-section793&num=0&edition=prelim https://www.acquisition.gov/far/52.222-36#FAR_52_222_36 https://www.acquisition.gov/far/52.222-37#FAR_52_222_37 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title38-section4212&num=0&edition=prelim https://www.acquisition.gov/far/52.222-40#FAR_52_222_40 https://www.acquisition.gov/far/52.222-50#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-50#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-54#FAR_52_222_54 https://www.acquisition.gov/far/22.1803#FAR_22_1803 https://www.acquisition.gov/far/52.223-9#FAR_52_223_9

__ (ii) Alternate I (MAY 2008) of 52.223-9 ( 42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (38) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693).

__ (39) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (JUN 2016) (E.O. 13693).

__ (40)

(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (JUN 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (OCT 2015) of 52.223-13.

__ (41)

(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (JUN 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Jun2014) of 52.223-14.

__ (42) 52.223-15, Energy Efficiency in Energy-Consuming Products (MAY 2020) ( 42 U.S.C. 8259b).

__ (43)

(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (OCT 2015) (E.O.s 13423 and 13514).

__ (ii) Alternate I (JUN 2014) of 52.223-16.

X_ (44) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (JUN 2020) (E.O. 13513).

__ (45) 52.223-20, Aerosols (JUN 2016) (E.O. 13693).

__ (46) 52.223-21, Foams (Jun2016) (E.O. 13693).

__ (47)

(i) 52.224-3 Privacy Training (JAN 2017) (5 U.S.C. 552 a).

__ (ii) Alternate I (JAN 2017) of 52.224-3.

https://www.acquisition.gov/far/52.223-9#FAR_52_223_9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.223-11#FAR_52_223_11 https://www.acquisition.gov/far/52.223-12#FAR_52_223_12 https://www.acquisition.gov/far/52.223-13#FAR_52_223_13 https://www.acquisition.gov/far/52.223-13#FAR_52_223_13 https://www.acquisition.gov/far/52.223-14#FAR_52_223_14 https://www.acquisition.gov/far/52.223-14#FAR_52_223_14 https://www.acquisition.gov/far/52.223-15#FAR_52_223_15 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.223-16#FAR_52_223_16 https://www.acquisition.gov/far/52.223-16#FAR_52_223_16 https://www.acquisition.gov/far/52.223-18#FAR_52_223_18 https://www.acquisition.gov/far/52.223-20#FAR_52_223_20 https://www.acquisition.gov/far/52.223-21#FAR_52_223_21 https://www.acquisition.gov/far/52.224-3#FAR_52_224_3 https://www.acquisition.gov/far/52.224-3#FAR_52_224_3

__ (48) 52.225-1, Buy American-Supplies (NOV 2021) ( 41 U.S.C. chapter 83).

_X_ (49)

(i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (NOV 2021) ( 41 U.S.C.chapter83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109- 283, 110-138, 112-41, 112-42, and 112-43.

__ (ii) Alternate I (JAN 2021) of 52.225-3.

__ (iii) Alternate II (JAN 2021) of 52.225-3.

__ (iv) Alternate III (JAN 2021) of 52.225-3.

__ (50) 52.225-5, Trade Agreements (OCT 2019) ( 19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

X_ (51) 52.225-13, Restrictions on Certain Foreign Purchases (FEB 2021) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

__ (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302Note).

__ (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov2007) ( 42 U.S.C. 5150).

__ (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov2007) ( 42 U.S.C. 5150).

__ (55) 52.229-12, Tax on Certain Foreign Procurements (FEB 2021).

__ (56) 52.232-29, Terms for Financing of Purchases of Commercial Products and Commercial Services (NOV 2021) ( 41 U.S.C. 4505, 10 U.S.C. 2307(f)).

__ (57) 52.232-30, Installment Payments for Commercial Products and Commercial Services (NOV 2021) ( 41 U.S.C. 4505, 10 U.S.C. 2307(f)).

X_ (58) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (OCT2018) ( 31 U.S.C. 3332).

__ (59) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) ( 31 U.S.C. 3332).

https://www.acquisition.gov/far/52.225-1#FAR_52_225_1 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.225-3#FAR_52_225_3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.225-3#FAR_52_225_3 https://www.acquisition.gov/far/52.225-3#FAR_52_225_3 https://www.acquisition.gov/far/52.225-3#FAR_52_225_3 https://www.acquisition.gov/far/52.225-5#FAR_52_225_5 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title19-section2501&num=0&edition=prelim http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title19-section3301&num=0&edition=prelim https://www.acquisition.gov/far/52.225-13#FAR_52_225_13 https://www.acquisition.gov/far/52.225-26#FAR_52_225_26 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.226-4#FAR_52_226_4 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.226-5#FAR_52_226_5 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.229-12#FAR_52_229_12 https://www.acquisition.gov/far/52.232-29#FAR_52_232_29 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.232-30#FAR_52_232_30 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.232-33#FAR_52_232_33 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section3332&num=0&edition=prelim https://www.acquisition.gov/far/52.232-34#FAR_52_232_34

__ (60) 52.232-36, Payment by Third Party (MAY 2014) ( 31 U.S.C. 3332).

__ (61) 52.239-1, Privacy or Security Safeguards (AUG 1996) ( 5 U.S.C. 552a).

__ (62) 52.242-5, Payments to Small Business Subcontractors (JAN 2017) ( 15 U.S.C. 637(d)(13)).

__ (63)

(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (NOV 2021) ( 46 U.S.C. 55305 and 10 U.S.C. 2631).

__ (ii) Alternate I (APR 2003) of 52.247-64.

__ (iii) Alternate II (NOV 2021) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

[Contracting Officer check as appropriate.]

__ (1) 52.222-41, Service Contract Labor Standards (AUG 2018) ( 41 U.S.C. chapter67).

__ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (MAY 2014) ( 29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards- Price Adjustment (Multiple Year and Option Contracts) (AUG 2018) ( 29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (4) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards- Price Adjustment (May 2014) ( 29U.S.C.206 and 41 U.S.C. chapter 67).

__ (5) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment- Requirements (May 2014) ( 41 U.S.C. chapter 67).

__ (6) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (MAY 2014) ( 41 U.S.C. chapter 67).

__ (7) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order

14026 (JAN 2022).

https://www.acquisition.gov/far/52.232-36#FAR_52_232_36 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.239-1#FAR_52_239_1 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title5-section552a&num=0&edition=prelim https://www.acquisition.gov/far/52.242-5#FAR_52_242_5 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.247-64#FAR_52_247_64 https://www.govinfo.gov/content/pkg/USCODE-2019-title46/html/USCODE-2019-title46-subtitleV-partD-chap553-subchapI-sec55305.htm https://www.govinfo.gov/content/pkg/USCODE-2019-title46/html/USCODE-2019-title46-subtitleV-partD-chap553-subchapI-sec55305.htm http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.247-64#FAR_52_247_64 https://www.acquisition.gov/far/52.247-64#FAR_52_247_64 https://www.acquisition.gov/far/52.222-41#FAR_52_222_41 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-42#FAR_52_222_42 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-43#FAR_52_222_43 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-44#FAR_52_222_44 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-51#FAR_52_222_51 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-53#FAR_52_222_53 https://www.acquisition.gov/far/52.222-55#FAR_52_222_55

__ (8) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2022) (E.O.

13706).

__ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (Jun 2020) ( 42 U.S.C. 1792).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, as defined in FAR 2.101, on the date of award of this contract, and does not contain the clause at 52.215-2, Audit and Records-Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e)

(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial products or commercial services. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause-

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (NOV 2021) ( 41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

https://www.acquisition.gov/far/52.222-62#FAR_52_222_62 https://www.acquisition.gov/far/52.226-6#FAR_52_226_6 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/2.101#FAR_2_101 https://www.acquisition.gov/far/52.215-2#FAR_52_215_2 https://www.acquisition.gov/far/subpart-4.7#FAR_Subpart_4_7 https://www.acquisition.gov/far/52.203-13#FAR_52_203_13 https://www.acquisition.gov/far/52.203-19#FAR_52_203_19

(iii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (NOV 2021) (Section 1634 of Pub. L. 115-91).

(iv) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115- 232).

(v) 52.219-8, Utilization of Small Business Concerns (OCT 2018) ( 15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds the applicable threshold specified in FAR 19.702(a) on the date of subcontract award, the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(vi) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(vii) 52.222-26, Equal Opportunity (SEP 2015) (E.O.11246).

(viii) 52.222-35, Equal Opportunity for Veterans (JUN 2020) ( 38 U.S.C. 4212).

(ix) 52.222-36, Equal Opportunity for Workers with Disabilities (JUN 2020) ( 29 U.S.C. 793).

(x) 52.222-37, Employment Reports on Veterans (JUN 2020) ( 38 U.S.C. 4212).

(xi) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xii) 52.222-41, Service Contract Labor Standards (AUG 2018) ( 41 U.S.C. chapter 67).

(xiii)

(A) 52.222-50, Combating Trafficking in Persons (NOV 2021) ( 22 U.S.C. chapter 78 and E.O 13627).

(B) Alternate I (MAR 2015) of 52.222-50 ( 22 U.S.C. chapter 78 and E.O. 13627).

(xiv) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment- Requirements (May2014) ( 41 U.S.C. chapter 67).

(xv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (MAY 2014) ( 41 U.S.C. chapter 67).

https://www.acquisition.gov/far/52.204-23#FAR_52_204_23 https://www.acquisition.gov/far/52.204-25#FAR_52_204_25 https://www.acquisition.gov/far/52.219-8#FAR_52_219_8 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title15-section637&num=0&edition=prelim https://www.acquisition.gov/far/19.702#FAR_19_702 https://www.acquisition.gov/far/52.219-8#FAR_52_219_8 https://www.acquisition.gov/far/52.222-21#FAR_52_222_21 https://www.acquisition.gov/far/52.222-26#FAR_52_222_26 https://www.acquisition.gov/far/52.222-35#FAR_52_222_35 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-36#FAR_52_222_36 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-37#FAR_52_222_37 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-40#FAR_52_222_40 https://www.acquisition.gov/far/52.222-40#FAR_52_222_40 https://www.acquisition.gov/far/52.222-41#FAR_52_222_41 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-chapter67-front&num=0&edition=prelim https://www.acquisition.gov/far/52.222-50#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-50#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-51#FAR_52_222_51 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-53#FAR_52_222_53

(xvi) 52.222-54, Employment Eligibility Verification (NOV 2021) (E.O. 12989).

(xvii) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order

14026 (JAN 2022).

(xviii) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2022) (E.O.

13706).

(xix)

(A) 52.224-3, Privacy Training (Jan 2017) ( 5 U.S.C. 552a).

(B) Alternate I (JAN 2017) of 52.224-3.

(xx) 52.225-26, Contractors Performing Private Security Functions Outside the United States (OCT 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xxi) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (JUN 2020) ( 42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxii) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (NOV 2021) ( 46 U.S.C. 55305 and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial products and commercial services a minimal number of additional clauses necessary to satisfy its contractual obligations.

(End of clause)

FAR 52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS

SUBCONTRACTORS (APR 2020) (DEVIATION)

(a)(l) In accordance with 31 U.S.C. 3903 and 10 U.S.C. 2307, upon receipt of accelerated payments from the Government, the Contractor shall make accelerated payments to its small business subcontractors under this contract in accordance with the accelerated payment date established, to the maximum extent practicable and prior to when such payment is otherwise required under the applicable contract or subcontract, with a goal of 15 days after receipt of a proper invoice and all other required documentation from the small business subcontractor if a specific payment date is not established by contract.

(2) The Contractor agrees to make such payments to its small business subcontractors without any further consideration from or fees charged to the subcontractor.

https://www.acquisition.gov/far/52.222-54#FAR_52_222_54 https://www.acquisition.gov/far/52.222-55#FAR_52_222_55 https://www.acquisition.gov/far/52.222-62#FAR_52_222_62 https://www.acquisition.gov/far/52.224-3#FAR_52_224_3…