CBCL000028EBM.v1.pdf

ORDER

IQO CONTRACT

FM: PL8211

TO: COMCAST BUSINESS COMMUNICATIONS, LLC - 6ER97

DATE (MM/DD/YYYY): 5/21/2020

SUBJECT: HC101320PA905

A. TYPE ACTION: START

1. PURPOSE: 1. IN ACCORDANCE WITH INQUIRY HC101320QA699, PROCEED TO PROVIDE,

INSTALL, AND MAINTAIN A PT TO PT ETHERNET L3VPN 1GB ACCESS BETWEEN BLDG DC-2

RM DEMARK, 1ST FLR, EQUINIX DATA CENTER 2, 21721 FILIGREE COURT; ASHBURN, VA,

20147 CCI AND BLDG 10803, TELCO ROOM, 10803 PARKRIDGE BLVD, RESTON, VA 20191

CCI.

A. SATELLITE OBJECTION: AVOIDANCE: THE USE OF SATELLITE CONNECTIVITY IS NOT

ACCEPTABLE. ECHOPLEXING CHARACTERISTICS OF DTE AND DCE EQUIPMENT ON THIS

CIRCUIT WILL RESULT IN UNDESIRABLE PERFORMANCE DUE TO THE PROPAGATION

DELAYS OF SATELLITE TRANSMISSION.

B. CUSTOMER DESIRES AND WILL ACCEPT SERVICE SOONER IF POSSIBLE.

2. THE SERVICE DATE TO BE MET IS: 14 AUG 2020 (SIP). THE GOVERNMENT WILL ASSESS

CONSIDERATION IAW STANDARD PROVISION 42 FOR DELAY ON DELIVERY OF CIRCUIT ON

CONTRACTED SERVICE DATE.

3. ESTABLISH TSP: TSP0K8LAL-02

4. SEE ATTACHMENTS AND UNIQUE INSTALLATION FACTORS FOR TECHNICAL

REQUIREMENTS SPECIFIC TO THIS ORDER.

5. CONTRACTOR MUST UPLOAD NOTICE OF COMPLETION IN IDEAS. If there are more than two locations, their information will be found in Attachment B to this Order.

B. ALLA NUMBER:

C. TSP AUTHORIZATION CODE: TSP0K8LAL-02

D. DEMANDER'S CODE:

E. SERVICE DATE (MM/DD/YYYY): 8/14/2020

F. TYPE OF CIRCUIT/BANDWIDTH/DATA RATE: 1 Gigabit

G. LOCATION OF TERMINATION A:

1. ADDRESS: (BLDG) DC-2;EQUINIX DATA CENTER 2,21721 FILIGREE COURT;ASHBURN, VA,

20147

HC101320PA905 / CBCL000028EBM

2. ROOM: DEMARK; 1ST FL

H. LOCAL PART A:

1. EXTENSION OF TELECOMMUNICATIONS SERVICE: All facilities between vendor's commercial communications interface point and termination location shall be provided by vendor. All cables shall be run in accordance with local site standards

2. INTERFACE: 1000BASELX, SM FIBER, LC CONNECTOR

3. DEMARK: (BLDG) DC-2;

EQUINIX DATA CENTER 2,

DEMARK; 1ST FL

21721 FILIGREE COURT;

ASHBURN, VA, 20147

(PMRY POC) MR. DONALD WIGGINS;

(UNCLASS USER)DWIGGINS@EQUINIX.COM;

(CMCL) 866-378-4649; (OFFHRS)571-233-8805

4. NPA/NXX: 703/840

5. UNIQUE INSTALLATION FACTORS: (1) FOR THE VENDOR: VENDOR WILL DELIVER

SERVICE TO THE COMMERCIAL DEMARC IDENTIFIED IN THE DOCUMENT.

(2) REQUEST THE COMMERCIAL VENDOR ASSIGNED EXTEND THIS CIRCUIT FROM THE

COMMERICAL DEMARK IN BLDG DC-2 ROOM DEMARK ON THE 1ST FLOOR, TO THE

CUSTOMER'S CISCO ASR 1006 ROUTER IN BLDG DC-11, ROOM 21333 ON THE 2ND FLOOR.

FOR CIRCUIT ACTIVATION ASSISTANCE CONTACT DCP COMMERICIAL ACTIVATION TEAM

(CAT) AT D312-850-0820, C614-692-0820.

(3) DHA WILL OPEN A WORK ORDER WITH LOCAL EQUINIX PERSONNEL FOR LOCAL SITE

PROVIDED CIRCUIT EXTENSION BETWEEN THE COMMERCIAL DEMARK IN BLDG DC-2 AND

THE CUSTOMER SERVICE DELIVERY POINT IN BLDG DC-11.

(4) THE VENDOR WILL PROVIDE ANY EQUIPMENT REQUIRED TO EXTEND THE CIRCUIT TO

THE SERVICE DELIVERY POINT (SDP).

(5) DISA REQUIRES THAT CIRCUIT VENDOR OBTAIN A SIGNATURE FROM A RESPONSIBLE

SITE POC CERTIFYING THAT THE VENDOR PROVIDED THE CONNECTIVITY AND THAT THE

CIRCUIT IS PROPERLY TAGGED WITH CIRCUIT ID, TSR NUMBER, AND CCSD.

6. INSIDE WIRE INSTALLATION/MAINTENANCE REQUIRED: CPIWI-YES/CPIWM-YES

7. CONTACT: (PMRY POC) MR. DONALD WIGGINS;

(UNCLASS USER)DWIGGINS@EQUINIX.COM;

(CMCL) 866-378-4649; (OFFHRS)571-233-8805

I. TERMINATION EQUIPMENT A: COMMERCIAL DEMARK FDP; CISCO ASR 1006 ROUTER (DHA

PROVIDED)

J. LOCATION OF TERMINATION B:

1. ADDRESS: BLDG)10803DATA CENTER;10803 PARKRIDGE BLVD;RESTON, VA 20191

2. ROOM: TELCO

K. LOCAL PART B:

1. EXTENSION OF TELECOMMUNICATIONS SERVICE: All facilities between vendor's commercial communications interface point and termination location shall be provided by vendor. All cables shall be run in accordance with local site standards

2. INTERFACE: 1000BASELX, SM FIBER, LC CONNECTOR

3. DEMARK: BLDG)10803

DATA CENTER;

TELC0 ROOM

10803 PARKRIDGE BLVD;

RESTON, VA 20191

4. NPA/NXX: 703/995

5. UNIQUE INSTALLATION FACTORS: (1) FOR THE VENDOR: VENDOR WILL DELIVER

SERVICE TO THE COMMERCIAL DEMARC IDENTIFIED IN THE DOCUMENT.

(2) REQUEST THE COMMERCIAL VENDOR ASSIGNED EXTEND THIS CIRCUIT FROM THE

COMMERICAL DEMARK IN BLDG 10803, TELCO ROOM, TO THE DISN JUNIPER MX-240

ROUTER IN BLDG 10803, ROOM SUITE 1800. FOR CIRCUIT ACTIVATION ASSISTANCE

CONTACT DCP COMMERICIAL ACTIVATION TEAM (CAT) AT D312-850-0820, C614-692-0820.

(3) THE VENDOR WILL PROVIDE ANY EQUIPMENT REQUIRED TO EXTEND THE CIRCUIT TO

THE SERVICE DELIVERY POINT (SDP).

(4) DISA REQUIRES THAT CIRCUIT VENDOR OBTAIN A SIGNATURE FROM A RESPONSIBLE

SITE POC CERTIFYING THAT THE VENDOR PROVIDED THE CONNECTIVITY AND THAT THE

CIRCUIT IS PROPERLY TAGGED WITH CIRCUIT ID, TSR NUMBER, AND CCSD.

(5) FOR LOCAL COMMUNICATIONS UNIT: FOR CIRCUIT ACTIVATION ASSISTANCE OR

SERVICE IMPLEMENTATION INQUIRIES/SCHEDULING, CONTACT THE DISA CONUS

GLOBAL RF ACTIVATIONS TEAM VIA EMAIL, DISA.SCOTT.CONUS.MBX.RF-CIRCUIT-

ACTIVATIONS@MAIL.MIL, OR CALL DSN 418-8627, COML 618-418-8627.

6. INSIDE WIRE INSTALLATION/MAINTENANCE REQUIRED: CPIWI-YES/CPIWM-YES

7. CONTACT: PRI: GILBERT MAINVIELLE, D345-6876, C703-995-6876

EMAIL: GILBERT.MAINVIELLE.CTR@MAIL.MIL

ALT: MARK JESSOP, D345-7962, C703-995-7962

EMAIL: MARK.W.JESSOP.CTR@MAIL.MIL

ORG EMAIL: CIRCUIT_ACTIONS@ATAC.MIL

L. TERMINATION EQUIPMENT B: COMMERCIAL DEMARK FDP; JUNIPER MX-240 ROUTER

M. ADDITIONAL INFORMATION:

1. CSA NUMBER: CBCL000028EBM

2. BASIC AGREEMENT NUMBER: HC1013-15-H-0018

3. TSR NUMBER: DR04MAR205291

4. CCSD: SVI6H9M1

5. DIVERSITY REQUIREMENTS: NA

6. LOCATIONS TO BE AVOIDED: N/A

7. TRANSMISSION MEDIA TO BE AVOIDED: YES/AST ALL SATELLITE

8. NETWORKS TO BE AVOIDED: N/A

9. CIRCUIT PARAMETERS: SEE TESTING REQUIREMENTS

10. TESTING REQUIREMENTS: CONUS JUMBO FRAME ETHERNET ACCEPTANCE TESTING

SHALL BE PERFORMED BY VENDOR IN ACCORDANCE WITH ITU-T Y.1564. TEST PERIOD

24 HOURS. TESTS COVERED IN SECTIONS 9.1, 10, 11.1, 14, 20, 21, 26.1, 26.2, AND 26.3 OF

RFC 6815 MUST BE PERFORMED AND RESULTS REPORTED IN THE FORMAT SPECIFIED

BY THE RFC OR ITU-T Y. SPECIFICALLY FRAMES SIZE OF 4472 BYTES MUST BE USED.

THE TEST MUST VERIFY LENGTH OF RECEIVED FRAMES, INDICATE NUMBER OF FRAMES

DROPPED, NUMBER OF FRAMES RECEIVED OUT OF ORDER, AND DUPLICATE FRAMES.

TESTS MUST BE BI-DIRECTIONAL USING THE SAME DATA RATE IN EACH DIRECTION. BURST

TESTS MUST BE RUN TO DETERMINE MINIMUM INTERVAL BETWEEN FRAMES THAT CAN

BE PROCESSED WITHOUT FRAME LOSS. A THROUGHPUT TEST IS REQUIRED INDICATING

THE FASTEST RATE AT WHICH TEST FRAMES CAN BE TRANSMITTED WITHOUT FRAME

LOSS. A SEPARATE THROUGHPUT TEST MUST BE RUN WITH FRAMES ADDRESSED TO THE

HARDWARE BROADCAST ADDRESS CONSTITUTING AT LEAST 1% OF THE TEST STREAM

AND BE EVENLY DISTRIBUTED THROUGHOUT THE TEST. LATENCY TEST MUST BE RUN FOR

A PERIOD OF NO LESS THAN 120 SECONDS, AND REPEATED NO LESS THAT 20 TIMES. THE

TEST STREAM FOR THE LATENCY TEST SHOULD BE RUN AT THE THROUGHPUT RATE FOR

CORRESPONDING FRAME SIZES FROM THE THROUGHPUT TEST. END TO END LATENCY

WILL BE CALCULATED AS THE AVERAGE OVER THE 20 TEST RUNS. FRAME LOSS RATE

TESTS SHOULD BE RUN AT THE FRAME RATE CORRESPONDING TO THE MAXIMUM FRAME

RATE, AND REDUCED BY 10% INTERVALS UNTIL THERE ARE AT LEAST TWO CONSECUTIVE

RUNS IN WHICH NO FRAMES ARE LOST. THROUGHPUT TEST RESULTS: PASSING RATE

100% FOR ALL FRAME BYTE SIZES EXERCISED. FRAME LOSS RATE (%) RESULTS: FRAME

LOSS RATE LESS THAN 0.01% FOR ALL FRAME BYTE SIZES EXERCISED. LATENCY WILL BE

MEASURED WILL BE ACCORDING TO THE FOLLOWING ANY APS SWITCHOVER SHALL TAKE

LESS THAN 50 MILLISECONDS MONTHLY AVAILABILITY SHALL BE NO LESS THAN 99.5%.

11. GOVERNMENT ACCEPTANCE ACTIVITY: DHA MEDICAL CMO/D421-3442,C210-295-3442

12. SECURITY REQUIREMENTS: ESCORT REQUIRED; FOR VENDOR ACCESS FOR CIRCUIT

INSTALLATION, NOTIFY POC 48 HOURS IN ADVANCE AND PROVIDE VENDOR COMPANY

NAME, AND EMPLOYEE(S) NAME(S). VENDOR EMPLOYEE(S) PHOTO ID IS REQUIRED FOR

COMPOUND/FACILITY ACCESS.

13. SITE ACCESS REQUIREMENTS: ESCORT REQUIRED; FOR VENDOR ACCESS FOR

CIRCUIT INSTALLATION, NOTIFY POC 48 HOURS IN ADVANCE AND PROVIDE VENDOR

COMPANY NAME, AND EMPLOYEE(S) NAME(S). VENDOR EMPLOYEE(S) PHOTO ID IS

REQUIRED FOR COMPOUND/FACILITY ACCESS.

14. STANDARD PROVISIONS: Incorporated in full text below

15. CHARGES: See Attachment

16. DITCO FUND CITE: 97X4930.5F20 000 C1013 0 068142 2F 233003

17. EXPIRATION DATE: Telecommunications service provided under this contract will continue until 19 MAY 2025, unless sooner discontinued.

18. SIMULTANEOUS ACTION TSR NUMBER:

N. ADDRESS FOR SUBMISSION OF INVOICES: DFAS COLUMBUS (JAQEBB), P.O. BOX 182317,

COLUMBUS, OHIO, 43218-2317

Z. DITCO CONTACT:

JOHN WARNER

618-418-6466 john.d.warner28.civ@mail.mil

KEVIN L. KNOWLES

DITCO Contracting Officer

(618)418-6527 kevin.l.knowles4.civ@mail.mil

Attachment A - CLINs and Charges

Currency: USD

CLIN/SLIN Item # Description Qty Unit NRC MRC EXT Price PoP From PoP To Location

0001 MRC 8/14/2020 5/19/2025 ASHBUR

N; BCC;

0001AA MONTHLY

RECURRING

CHARGE

1 EA $753.00 $753.00 8/14/2020 5/19/2025 ASHBUR

N; BCC;

Total EXT MRC: $753.00 for POP from 8/14/2020 to 5/19/2025

Total EXT NRC: $0.00

Section G - Contract Administration Data

Included Clauses

G1 - Points of Contact - JUL 2018 Contracting Officer

Name: Kevin L. Knowles

Organization/Office Symbol: PL8211 Phone No.: 618-418-6527

E-Mail Address: kevin.l.knowles4.civ@mail.mil

Contract Specialist

Name: John D. Warner III

Organization/Office Symbol: PL8211 Phone No.: 618-418-6466

E-Mail Address: john.d.warner28.civ@mail.mil

COR/Mission Partner Point of Contact (Note: To be filled in upon contract award)

Name:

Organization/Office Symbol: Phone No.:

E-Mail Address:

Contractor Point of Contact

Contractor Legal Business Name: Comcast Business Communications, LLC

DUNS: 968185491

CAGE CODE: 6ER97

Contractor POC: Mike Brennan E-Mail Address: michael_brennan2@comcast.com Phone Number: 301-943-1724 Fax

Number:

(End of text)

Standard Provisions

252.204-7016 - Prohibition on the Acquisition of Covered Defense Telecommunications

Equipment or Services—Representation - DEC 2019

(a) Definitions. As used in this provision, covered defense telecommunications equipment or services has the meaning provided in the clause 252.204-7018, Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM)

(https://www.sam.gov) for entities excluded from receiving federal awards for "covered defense telecommunications equipment or services".

(c) Representation. The Offeror represents that it [ ] does, [ ] does not provide covered defense telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

(End of provision)

252.204-7017 - Prohibition on the Acquisiton of Covered Defense Telecommunications

Equipment or Services—Representation - DEC 2019 The Offeror is not required to complete the representation in this provision if the Offeror has represented in the provision at

252.204-7016, Covered Defense Telecommunications Equipment or Services--Representation, that it "does not provide covered defense telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument."

(a) Definitions. Covered defense telecommunications equipment or services, covered mission, critical technology, and substantial or essential component, as used in this provision, have the meanings given in the 252.204-7018 clause, Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services, of this solicitation.

(b) Prohibition. Section 1656 of the National Defense Authorization Act for Fiscal Year 2018 (Pub. L. 115-91) prohibits agencies from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service to carry out covered missions that uses covered defense telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) at https://www.sam.gov for entities that are excluded when providing any equipment, system, or service to carry out covered missions that uses covered defense telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless a waiver is granted.

(d) Representation. If in its annual representations and certifications in SAM the Offeror has represented in paragraph (c) of the provision at 252.204-7016, Covered Defense Telecommunications Equipment or Services--Representation, that it "does" provide covered defense telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument, then the Offeror shall complete the following additional representation:

The Offeror represents that it [ ] will [ ] will not provide covered defense telecommunications equipment or services as a part of its offered products or services to DoD in the performance of any award resulting from this solicitation.

(e) Disclosures. If the Offeror has represented in paragraph (d) of this provision that it "will provide covered defense telecommunications equipment or services," the Offeror shall provide the following information as part of the offer:

(1) A description of all covered defense telecommunications equipment and services offered (include brand or manufacturer;

product, such as model number, original equipment manufacturer (OEM) number, manufacturer part number, or wholesaler number; and item description, as applicable).

(2) An explanation of the proposed use of covered defense telecommunications equipment and services and any factors relevant to determining if such use would be permissible under the prohibition referenced in paragraph (b) of this provision.

(3) For services, the entity providing the covered defense telecommunications services (include entity name, unique entity identifier, and Commercial and Government Entity (CAGE) code, if known).

(4) For equipment, the entity that produced or provided the covered defense telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known).

252.204-7018 - Prohibition on the Acquisition of Covered Defense Telecommunications

Equipment or Services - DEC 2019

(a) Definitions. As used in this clause--

Covered defense telecommunications equipment or services means--

(1) Telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation, or any subsidiary or affiliate of such entities;

(2) Telecommunications services provided by such entities or using such equipment; or

(3) Telecommunications equipment or services produced or provided by an entity that the Secretary of Defense reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country.

Covered foreign country means--

(1) The People's Republic of China; or

(2) The Russian Federation.

Covered missions means--

(1) The nuclear deterrence mission of DoD, including with respect to nuclear command, control, and communications, integrated tactical warning and attack assessment, and continuity of Government; or

(2) The homeland defense mission of DoD, including with respect to ballistic missile defense.

"Critical technology" means--

(1) Defense articles or defense services included on the United States Munitions List set forth in the International Traffic in Arms

Regulations under subchapter M of chapter I of title 22, Code of Federal Regulations;

(2) Items included on the Commerce Control List set forth in Supplement No. 1 to part 774 of the Export Administration

Regulations under subchapter C of chapter VII of title 15, Code of Federal Regulations, and controlled--

(i) Pursuant to multilateral regimes, including for reasons relating to national security, chemical and biological weapons proliferation, nuclear nonproliferation, or missile technology; or

(ii) For reasons relating to regional stability or surreptitious listening;

(3) Specially designed and prepared nuclear equipment, parts and components, materials, software, and technology covered by part 810 of title 10, Code of Federal Regulations (relating to assistance to foreign atomic energy activities);

(4) Nuclear facilities, equipment, and material covered by part 110 of title 10, Code of Federal Regulations (relating to export and import of nuclear equipment and material);

(5) Select agents and toxins covered by part 331 of title 7, Code of Federal Regulations, part 121 of title 9 of such Code, or part

73 of title 42 of such Code; or

(6) Emerging and foundational technologies controlled pursuant to section 1758 of the Export Control Reform Act of 2018 (50

U.S.C. 4817).

Substantial or essential component means any component necessary for the proper function or performance of a piece of equipment, system, or service.

(b) Prohibition. In accordance with section 1656 of the National Defense Authorization Act for Fiscal Year 2018 (Pub. L. 115-91), the contractor shall not provide to the Government any equipment, system, or service to carry out covered missions that uses covered defense telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless the covered defense telecommunication equipment or services are covered by a waiver described in Defense Federal Acquisition Regulation Supplement 204.2104.

(c) Procedures. The Contractor shall review the list of excluded parties in the System for Award Management (SAM) at https://www.sam.gov for entities that are excluded when providing any equipment, system, or service, to carry out covered missions, that uses covered defense telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless a waiver is granted.

(d) Reporting.

(1) In the event the Contractor identifies covered defense telecommunications equipment or services used as a substantial or essential component of any system, or as critical technology as part of any system, during contract performance, the Contractor shall report at https://dibnet.dod.mil the information in paragraph (d)(2) of this clause.

(2) The Contractor shall report the following information pursuant to paragraph (d)(1) of this clause:

(i) Within one business day from the date of such identification or notification: The contract number; the order number(s), if applicable; supplier name; brand; model number (original equipment manufacturer number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the information in paragraph (d)(2)(i) of this clause: Any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of a covered defense telecommunications equipment or services, and any additional efforts that will be incorporated to prevent future use or submission of covered telecommunications equipment or services.

(e) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (e), in all subcontracts and other contractual instruments, including subcontracts for the acquisition of commercial items.

(End of clause)

252.225-7974 - Representation Regarding Business Operations with the Maduro Regime

(Deviation 2020-O0005) - FEB 2020

(a) Definitions. As used in this provision--

"Agency or instrumentality of the government of Venezuela" means an agency or instrumentality of a foreign state as defined in section 28 U.S.C. 1603(b), with each reference in such section to "a foreign state" deemed to be a reference to "Venezuela."

"Business operations" means engaging in commerce in any form, including acquiring, developing, maintaining, owning, selling, possessing, leasing, or operating equipment, facilities, personnel, products, services, personal property, real property, or any other apparatus of business or commerce.

"Government of Venezuela" means the government of any political subdivision of Venezuela, and any agency or instrumentality of the government of Venezuela.

"Person" means--

(1) A natural person, corporation, company, business association, partnership, society, trust, or any other nongovernmental entity, organization, or group;

(2) Any governmental entity or instrumentality of a government, including a multilateral development institution (as defined in section 1701(c)(3) of the International Financial Institutions Act (22 U.S.C. 262r(c)(3)); and

(3) Any successor, subunit, parent entity, or subsidiary of, or any entity under common ownership or control with, any entity described in paragraphs (1) or (2) of this definition.

(b) Prohibition. In accordance with section 890 of the National Defense Authorization Act for Fiscal Year 2020 (Pub. L. 116-92), contracting officers are prohibited from entering into a contract for the procurement of products or services with any person that has business operations with an authority of the government of Venezuela that is not recognized as the legitimate government of

Venezuela by the United States Government, unless the person has a valid license to operate in Venezuela issued by the Office of Foreign Assets Control of the Department of the Treasury.

(c) Representation. By submission of its offer, the Offeror represents that the Offeror--

(1) Does not have any business operations with an authority of the Maduro regime or the government of Venezuela that is not recognized as the legitimate government of Venezuela by the United States Government; or

(2) Has a valid license to operate in Venezuela issued by the Office of Foreign Assets Control of the Department of the Treasury.

(End of provision)

52.204-24 - Representation Regarding Certain Telecommunications and Video

Surveillance Services or Equipment - DEC 2019 The Offeror shall not complete the representation in this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in the provision at 52.204-26, Covered Telecommunications

Equipment or Services-Representation, or in paragraph (v) of the provision at 52.212-3, Offeror Representations and

Certifications-Commercial Items.

(a) Definitions. As used in this provision--

"Covered telecommunications equipment or services", "critical technology", and "substantial or essential component" have the meanings provided in clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance

Services or Equipment.

(b) Prohibition. Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Contractors are not prohibited from providing--

(1) A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements;

or

(2) Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM)

(https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services".

(d) Representation. The Offeror represents that it [ ] will, [ ] will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation.

(e) Disclosures. If the Offeror has represented in paragraph (d) of this provision that it "will" provide covered telecommunications equipment or services", the Offeror shall provide the following information as part of the offer--

(1) A description of all covered telecommunications equipment and services offered (include brand; model number, such as original equipment manufacturer (OEM) number, manufacturer part number, or wholesaler number; and item description, as applicable);

(2) Explanation of the proposed use of covered telecommunications equipment and services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b) of this provision;

(3) For services, the entity providing the covered telecommunications services (include entity name, unique entity identifier, and Commercial and Government Entity (CAGE) code, if known); and

(4) For equipment, the entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known).

52.204-25 - Prohibition on Contracting for Certain Telecommunications and Video

Surveillance Services or Equipment - AUG 2019

(a) Definitions. As used in this clause--

Covered foreign country means The People's Republic of China.

Covered telecommunications equipment or services means--

(1) Telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities);

(2) For the purpose of public safety, security of Government facilities, physical security surveillance of critical infrastructure, and other national security purposes, video surveillance and telecommunications equipment produced by Hytera Communications

Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities);

(3) Telecommunications or video surveillance services provided by such entities or using such equipment; or

(4) Telecommunications or video surveillance equipment or services produced or provided by an entity that the Secretary of

Defense, in consultation with the Director of National Intelligence or the Director of the Federal Bureau of Investigation, reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country.

Critical technology means--

(1) Defense articles or defense services included on the United States Munitions List set forth in the International Traffic in Arms

Regulations under subchapter M of chapter I of title 22, Code of Federal Regulations;

(2) Items included on the Commerce Control List set forth in Supplement No. 1 to part 774 of the Export Administration

Regulations under subchapter C of chapter VII of title 15, Code of Federal Regulations, and controlled--

(i) Pursuant to multilateral regimes, including for reasons relating to national security, chemical and biological weapons proliferation, nuclear nonproliferation, or missile technology; or

(ii) For reasons relating to regional stability or surreptitious listening;

(3) Specially designed and prepared nuclear equipment, parts and components, materials, software, and technology covered by part 810 of title 10, Code of Federal Regulations (relating to assistance to foreign atomic energy activities);

(4) Nuclear facilities, equipment, and material covered by part 110 of title 10, Code of Federal Regulations (relating to export and import of nuclear equipment and material);

(5) Select agents and toxins covered by part 331 of title 7, Code of Federal Regulations, part 121 of title 9 of such Code, or part

73 of title 42 of such Code; or

(6) Emerging and foundational technologies controlled pursuant to section 1758 of the Export Control Reform Act of 2018 (50

U.S.C. 4817).

Substantial or essential component means any component necessary for the proper function or performance of a piece of equipment, system, or service.

(b) Prohibition. Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. The Contractor is prohibited from providing to the Government any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in Federal Acquisition Regulation 4.2104.

(c) Exceptions. This clause does not prohibit contractors from providing--

(1) A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(2) Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(d) Reporting requirement. (1) In the event the Contractor identifies covered telecommunications equipment or services used as a substantial or essential component of any system, or as critical technology as part of any system, during contract performance, or the Contractor is notified of such by a subcontractor at any tier or by any other source, the Contractor shall report the information in paragraph (d)(2) of this clause to the Contracting Officer, unless elsewhere in this contract are established procedures for reporting the information; in the case of the Department of Defense, the Contractor shall report to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (d)(1) of this clause:

(i) Within one business day from the date of such identification or notification: The contract number; the order number(s), if applicable; supplier name; supplier unique entity identifier (if known); supplier Commercial and Government Entity (CAGE) code

(if known); brand; model number (original equipment manufacturer number, manufacturer part number, or wholesaler number);

item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the information in paragraph (d)(2)(i) of this clause: Any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of covered telecommunications equipment or services, and any additional efforts that will be incorporated to prevent future use or submission of covered telecommunications equipment or services.

(e) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (e), in all subcontracts and other contractual instruments, including subcontracts for the acquisition of commercial items.

(End of clause)

STANDARD PROVISION - 02 - UNDERSTANDING OF DITCO IQO ACQUISITION

DESKBOOK - APR 2019

Contractor/Telecommunications Provider (TP) acknowledges it has read and understands the current published "DITCO

Inquiry/Quote/Order (IQO) Acquisition Deskbook" version 7.1 available from the Integrated Defense Enterprise Acquisition

System (IDEAS) Contractor web site https://depsland.csd.disa.mil/html/vendor/vendorreference.html. Contractor agrees that the most recent Standard Provisions as set forth in this order take precedent over any conflicting terms and conditions in the BA.

ACCEPTABLE CONTRACTOR/TELECOMMUNICATIONS PROVIDER (TP) RESPONSE: "UNDERSTAND."

STANDARD PROVISION - 27 - APPROVALS AND PERMITS - AUG 2017

Contractor/Telecommunications Provider (TP) receiving this contract shall be responsible for having or obtaining all approvals and permits necessary to provide this service. The requirement that the TP obtain all approvals and permits is a contract administration issue. Inability of Contractor/TP to obtain any such approval or permit shall not be a valid basis for not meeting service date or providing service. Failure of a Contractor/TP to obtain any approval or permit necessary to provide this service may result in termination of this contract by U.S. Government for default at no cost to U.S. Government and/or receipt of a negative past performance rating.

ACCEPTABLE CONTRACTOR/TELECOMMUNICATIONS PROVIDER (TP) RESPONSE: "UNDERSTAND/WILL COMPLY.

STANDARD PROVISION - 30 - CONTRACT PERIOD - AUG 2017

This telecommunications service contract shall continue on a month to month basis with a not to exceed date of 19 MAY 2025.

After this period the contract will be considered expired with no authority for service to continue unless mutually agreeable by both parties. Should service continue through the end of this contract period, no modification will be issued to authorize discontinuance of service. The minimum service period shall be one month. Accordingly the U.S. Government may discontinue service, at no additional cost to U.S. Government. U.S. Government will provide Contractor/Telecommunications Provider (TP)

30 days notice prior to discontinuing service before the not to exceed period. Contractors shall consider the ability of the

Government to discontinue service with 30 days notice when determining the reasonableness of incurring any costs. See

DFARS 252.239-7007, Cancellation Or Termination Of Orders.

Quotes that do not accept the minimum one month service period may be excluded from the competition and found unacceptable. In the event U.S. Government is unable to obtain quotes that meet this minimum service period, U.S.

Government may consider quotes with a minimum service period greater than one month.

The Government reserves the right to re-solicit these contracted services prior to the end of the not to exceed contract period when commercial market pricing demonstrates these services become available at lower prices.

ACCEPTABLE CONTRACTOR/TELECOMMUNICATIONS PROVIDER (TP) RESPONSE: "UNDERSTAND/WILL COMPLY."

STANDARD PROVISION - 33 - COMPLETION NOTICE - AUG 2017

Contractor/Telecommunications Provider (TP) shall provide a completion notice to DITCO within 72 hours of delivering service to

U.S. Government acceptance activity. The customer then has an additional 72 hours to notify DITCO if they disagree that the service is complete. A completion notice must include following information: (1) Contract PIID number; (2) DITCO CSA number,

(3) DITCO TSR number, (4) type of action, (5) contracted service date, (6) date service was delivered to and accepted by U.S.

Government acceptance activity; (7) commercial circuit identifier or phone number; (8) Contractor's/TP's trouble reporting number; (9) Contractor bill cycle end date; (10) a listing of any equipment installed on government premises by location and any deviations from service ordered; (11) name, phone number, and e-mail address U.S. Government representative (non-DITCO) that accepted service; and (12) Contractor/TP POC name, phone number, and e-mail address; (13) Local Exchange Company

(LEC) circuit identification (ID) number(s). Unless deviations are identified, completion notice will serve as Contractor/TP's confirmation that service was provided in accordance with contract. A follow-up completion notice will be required when deviations are cleared. Failure of Contractor/TP to provide completion notice may result in delay in invoice payment. DITCO's preferred method of receiving a completion notice is via Integrated Defense Enterprise Acquisition System (IDEAS). However, Contractors/TPs not authorized to obtain a PKI certificate may submit their completion notice via email to the applicable following address that issued the inquiry:

DITCO-Scott (IQO Section) disa.scott.ditco.mbx.pl8211@mail.mil

DITCO-Scott (PL8212 Section) disa.scott.ditco.mbx.pl8212@mail.mil

DITCO-Pacific (Ford Is Office) disa.jbphh.ditco.mbx.iqo@mail.mil

DITCO-Pacific (Alaska Office) disa.jber.ditco.other.ditcoako@mail.mil

DITCO-Europe (Stuttgart Office) disa.stuttgart.ditco.mbx.pl511@mail.mil

DITCO-Europe (SWA Bahrain Office) disa.stuttgart.ditco.mbx.pl52@mail.mil

ACCEPTABLE CONTRACTOR/TELECOMMUNICATION PROVIDER (TP) RESPONSE: "UNDERSTAND/WILL COMPLY."

STANDARD PROVISION - 37 - JEOPARDY NOTICE - AUG 2017

Contractor/Telecommunications Provider (TP) shall immediately provide a Jeopardy Notice via Integrated Defense Enterprise

Acquisition System (IDEAS) prior to the contracted service date as soon as Contractor/TP becomes aware contract service date may not be or cannot be met. A Jeopardy Notice must include following information: (1) Contract PIID number; (2) DITCO CSA number; (3) TSR number; (4) contracted service date; (5) explanation of why contracted service date may not be or cannot be met; (6) revised service date requested; and (7) name, phone number, and email address of Contractor/TP representative that can be contacted for any questions concerning the Jeopardy Notice. DITCO's preferred method of receiving a jeopardy notice is via Integrated Defense Enterprise Acquisition System (IDEAS). However, Contractors/TPs not authorized to obtain a PKI certificate may submit their jeopardy notice via email to the applicable following address that issued the inquiry:

DITCO-Scott (IQO Section) disa.scott.ditco.mbx.pl8211@mail.mil

DITCO-Scott (PL8212 Section) disa.scott.ditco.mbx.pl8212@mail.mil

DITCO-Pacific (Ford Is Office) disa.jbphh.ditco.mbx.iqo@mail.mil

DITCO-Pacific (Alaska Office) disa.jber.ditco.other.ditcoako@mail.mil

DITCO-Europe (Stuttgart Office) disa.stuttgart.ditco.mbx.pl511@mail.mil

DITCO-Europe (SWA Bahrain Office) disa.stuttgart.ditco.mbx.pl52@mail.mil

DISA's acknowledgement of the Contractor/TP's representation of delayed performance is not an explicit or implicit acceptance of the performance delay nor is it a waiver of any rights or remedies allowed under the contract, the FAR, or applicable case law.

Moreover, it is not an acknowledgment that DISA is responsible for any part of the Contractor/TP's delayed performance.

ACCEPTABLE CONTRACTOR/TELECOMMUNICATION PROVIDER (TP) RESPONSE: "UNDERSTAND/WILL COMPLY."

STANDARD PROVISION - 38 - STATUS REPORT (monthly) - AUG 2017 Due to the criticality of this telecommunications service, Contractor/Telecommunications Provider (TP) shall provide an updated status report to DITCO contracting officer monthly. Status report shall include (1) Contract PIID number; (2) DITCO CSA number, (3) TSR number, (4) contracted service date, (5) explanation of current status of telecommunications service installation and how current status provides assurance that contracted service date will be met, and (6) name, phone number, and e-mail address of Contractor/TP representative to contact for any questions concerning the status report.

STANDARD PROVISION - 41 - SCHEDULED OUTAGES - AUG 2017

To ensure this service is available to support U.S. Government requirements, Contractor/Telecommunications Provider (TP) shall utilize alternate or spare facilities whenever possible to eliminate or minimize service interruptions. However, when a scheduled service interruption cannot be avoided, Contractor/TP shall obtain the approval of appropriate approval authority before initiating any scheduled outage. To obtain such approval, a written "circuit release request" must be submitted to appropriate approval authority at least 21 calendar days prior to requested circuit release date.

When an interruption of service is required to correct hazardous or degraded conditions, a 48-hour prior notification is required, if practicable. Contractor/TP shall notify the U.S. Government service acceptance activity as soon as it is known that a service interruption will occur. The request from Contractor/TP must include the same information as identified below, and additionally, identify the hazardous or degraded conditions that exist which preclude providing the U.S. Government with 21-day advance notice.

In emergency situations, when loss of life or property might occur through lack of immediate action, Contractor/TP must make every reasonable attempt to notify the U.S. Government service acceptance activity identified on the CSA immediately, and coordinate arrangements for the service interruption to the maximum extent possible. Within five business days of the interruption, Contractor/TP must submit the same information as identified below, and additionally, identify the emergency conditions that existed which precluded providing the U.S. Government with 21-day advance notice.

"Circuit Release Request" must include following information: (1) Contractor/TP requesting circuit release, and name and phone number of Contractor/TP representative responsible for managing circuit release; (2) Contract PIID number; (3) DITCO CSA number of circuit for which release is being requested; (4) date and inclusive times of scheduled circuit release, along with an alternate circuit release date and time; (5) purpose of scheduled circuit release; (6) statement indicating all equipment, parts, and/or supplies required to complete action are on-hand, or their expected delivery date; (7) statement indicating that all avenues of bypass capability (e.g., alternate facilities, spare facilities, etc.) Have been considered; and (8) estimated maximum recovery time to restore circuit. The authority for approving circuit releases for this service is U.S. Government CCO/CMO.

Failure of Contractor/TP to obtain an approved circuit release prior to initiating a scheduled outage may result in U.S.

Government termination of this contract for default at no cost to U.S. Government and/or receipt of a negative past performance rating.

STANDARD PROVISION - 42 - CONSIDERATION - AUG 2015

Upon Contractor/telecommunications Provider (TP) caused failure to provide telecommunications service by the specified date in the contract, failure to make progress as to endanger performance by that date, or failure to comply with any contract terms or conditions; U.S. Government may cancel or terminate this contract pursuant to contract clause DFARS 252.239-7007 at no cost to the Government. However, U.S. Government may elect to waive its right to cancel or terminate and request Contractor/TP to provide consideration to U.S. Government in lieu thereof. Consideration will be negotiated on a case-by-case basis. If

Contractor/TP fails to meet the service date or comply with any contract terms or conditions and U.S. Government elects to request consideration, Contractor/TP hereby agrees to negotiate in good faith and provide such consideration. Quotes, which fail to accept this standard provision, may be excluded from consideration for award.

ACCEPTABLE CONTRACTOR/TELECOMMUNICATIONS PROVIDER (TP) RESPONSE: “UNDERSTAND/WILL COMPLY.”

STANDARD PROVISION - 44 - SYSTEM FOR AWARD MANAGEMENT REGISTRATION -

MAR 2014

(a) Definitions. As used in this clause-

"Central Contractor Registration (CCR) database" means the retired primary Government repository for Contractor information required for the conduct of business with the Government.

"Commercial and Government Entity (CAGE) code" means-

(1) A code assigned by the Defense Logistics Agency (DLA) Logistics Information Service to identify a commercial or

Government entity; or

(2) A code assigned by a member of the North Atlantic Treaty Organization that DLA records and maintains in the CAGE master file. This type of code is known as an "NCAGE code."

"Data Universal Numbering System (DUNS) number" means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities.

"Data Universal Numbering System+4 (DUNS+4) number" means the DUNS number means the number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.) This 4-character suffix may be assigned at the discretion of the business concern to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts (see the FAR at Subpart 32.11) for the same concern.

"Registered in the SAM database" means that-

(1) The Contractor has entered all mandatory information, including the DUNS number or the DUNS+4 number, into the SAM database;

(2) The Contractor's CAGE code is in the SAM database; and

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS), and has marked the record "Active". The Contractor will be required to provide consent for TIN Attachment, Page 1 of 4 validation to the Government as a part of the SAM registration process.

"System for Award Management (SAM)" means the primary Government repository for prospective federal awardee information and the centralized Government system for certain contracting, grants, and other assistance related processes. It includes-

(1) Data collected from prospective federal awardees required for the conduct of business with the Government;

(2) Prospective Contractor submitted annual representations and certifications in accordance with FAR Subpart 4.12; and

(3) The list of all parties suspended, proposed for debarment, debarred, declared ineligible, or excluded or disqualified under the nonprocurement common rule by agencies, Government corporations , or by the Government Accountability Office.

(b)

(1) The Contractor shall be registered in the SAM database prior to submitting an invoice and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The SAM registration shall be for the same name and address identified on the contract, with its associated CAGE code and DUNS or DUNS+4.

(3) If indicated by the Government during performance, registration in an alternate system may be required in lieu of SAM.

(c) If the Contractor does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) A Contractor may obtain a DUNS number-

(i) Via the internet at http://fedgov.dnb.com/webform or if the Contractor does not have internet access, it may call Dun and

Bradstreet at 1-866-705-5711 if located within the United States; or

(ii) If located outside the United States, by contacting the local Dun and Bradstreet office. The Contractor should indicate that it is a Contractor for a U.S. Government contract when contacting the local Dun and Bradstreet office.

(2) The Contractor should be prepared to provide the following information:

(i) Company legal business name.

(ii) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(iii) Company physical street address, city, state and Zip Code.

(iv) Company mailing address, city, state and Zip Code (if separate from physical).

(v) Company telephone number.

(vi) Date the company was started.

(vii) Number of employees at your location.

(viii) Chief executive officer/key manager.

(ix) Line of business (industry).

(x) Company Headquarters name and address (reporting relationship within your entity).

(d) Reserved.

(e) Processing time for registration in SAM, which normally takes five business days, should be taken into consideration when registering. Contractors who are not already registered should consider applying for registration at least two weeks prior to invoicing.

(f) The Contractor is responsible for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document.

(g)

(1)

(i) If a Contractor has legally changed its business name, "doing business as" name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in Subpart 42.12, the Contractor shall provide the responsible Contracting Officer sufficient documentation to support the legally changed name with a minimum of one business day's written notification of its intention to-

(A) Change the name in the SAM database;

(B) Comply with the requirements of subpart 42.12 of the FAR; and

(C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer.

(ii) If the Contractor fails to comply with the requirements of paragraph (g) (1) (i) of this clause, or fails to perform the agreement at paragraph (g) (1) (i) (C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor…