BPM055107 Bid Response Package.pdf

Bid Response Project#EC25-09010-126/BPM055107

This procurement has been designated for Certified Small Business Enterprises.

BID RESPONSE COVER SHEET

for Fence Replacement at Green Ridge State Forest at 28700 Headquarters Drive Flintstone, MD 21530 in Allegany County for the Maryland Department of Natural Resources – Engineering and Construction Unit

Solicitation Date: February 27,2026

Bid Due Date: March 31, 2026 Project Cost Classification “A”

BUSINESS NAME:

Business Address:

SBR Certification #:

The following documentation must be wholly completed and submitted at time of bid submission:

☐ Bid Response Packet (this document) ☐ Attachment A - Bid/Proposal Affidavit ☐ Attachment C - Bid Bond ☐ Attachment F - Bidder/Offeror Information Sheet ☐ Attachment I - Conflict of Interest Affidavit ☐ Attachment O - Payment of Employee Healthcare Expenses Certification ☐ Attachment P – List of Subcontractors ☐ Attachment U - Contract Affidavit ☐ Addendum

(when applicable, Addendum must be signed as acknowledgement and included)

All bid response documents listed above to be considered a fully responsive bid as ONE ATTACHMENT, using this page as your cover sheet.

Upon request by the DNR Procurement Officer, the following must be provided by way of email. Hard copies must be provided to DNR within 10 days of the initial request.

Performance Bond (Attachment W) Payment Bond (Attachment X)

Dept. Of Natural Resources DATE:

Engineering & Construction c/o FAS-Procurement Tawes State Office Bldg.; B-4 580 Taylor Ave.

Annapolis, MD 21401

To whom it may concern:

The following bid is for: Fence Replacement at Green Ridge State Forest 28700 Headquarters Drive Flintstone, MD 21530

Having carefully examined the "DGS Instructions to Bidders for Construction Projects" and “DGS General Conditions for Construction Projects”, and the Specifications and Plans outlined for the subject construction per the Project Manual dated 06/12/2025; and

Addenda Numbered and having received clarification on all items of conflict or upon which any doubt arose, the undersigned proposes to furnish all labor, materials and equipment called for by the said documents, for the stipulated sum of:

BASE BID: The total cost to complete all items, as described in the Bid Documents/ Detailed Specs excluding unit prices and alternates noted below.

UNIT PRICE #1: None.

TOTAL BID: The total cost to complete all items, as described in the Project Manual including the Base Bid, extended Unit Price Calculations, Allowances, and Alternates; as requested above and defined in the DGS Instructions to Bidders for Construction Projects dated July 1, 2022.

Basis of Award: To the responsible bidder that submits the lowest responsive and responsible Total Bid amount, Alternates will be added (or deducted) in accordance with Instructions to Bidders for Construction Contracts.

Failure to complete all attachments and eMMA digital line items wholly may result in the rejection of this bid.

SPECIAL QUALIFICATIONS:

1. The Contractor shall be licensed in the State of Maryland as a General Contractor and in accordance with COMAR regulations to perform work associated with this contract.

2. The Contractor shall have a minimum of 5 years of current and continuous experience installing fence and in performing similar work in the type of fence system that is being installed; and must be able to obtain and provide all warranties for this project.

3. Upon request, the Contractor shall supply to the DNR Procurement Officer a list of similar projects, which have been successfully completed by the Contractor.

It is understood that the bid price will be firm for a time period of one hundred twenty (120) calendar days from the bid opening date and that if the undersigned be notified of acceptance of this bid within this time period, the firm shall execute a contract for the above stated compensation and shall complete the work within 60 calendar days from the date of Notice to Proceed and agrees that if the work is not completed within the time period specified, the Contractor will be liable for Liquidated Damages of $350.00 per calendar day as specified in the "DGS General Conditions for Construction Contracts”, Section 8.

Failure to properly and completely fill in all blanks may be cause for rejection of this bid.

Construction Firm License No.

Date Issued

Place of Issuance

Federal Employer Identification No.

(or Social Security No. if no F.E.I.N.)

INDIVIDUAL PRINCIPAL FIRM NAME

In Presence of SIGNED Witness: (Sign & Print Principal’s Name)

ADDRESS

TELEPHONE NUMBER

Firm Name

CO-PARTNERSHIP PRINCIPAL

(Name of Co-Partnership) In Presence of Witness: ADDRESS

TELEPHONE

as to By (Sign & Print Partner’s Name) as to By (Sign & Print Partner’s Name) as to By (Sign & Print Partner’s Name)

CORPORATE PRINCIPAL

(Name of Corporation)

Attest: ADDRESS

TELEPHONE

(Corporate Secretary) By (Sign Officer’s Name & Title) (Affix Corporate Seal)

Firm Name

Attachment A. Bid Proposal Affidavit effective date: July 2024

A. AUTHORITY

I hereby affirm that I, _________________________________________________ (name of affiant) am the ___________________________________ (title) and duly authorized representative of

____________________________________________________________ (name of business entity) and that I possess the legal authority to make this affidavit on behalf of the business for which I am acting.

B. CERTIFICATION REGARDING COMMERCIAL NONDISCRIMINATION

The undersigned Bidder/Offeror hereby certifies and agrees that the following information is correct:

In preparing its Bid/Proposal on this project, the Bidder/Offeror has considered all Bid/Proposals submitted from qualified, potential subcontractors and suppliers, and has not engaged in “discrimination” as defined in § 19-103 of the State Finance and Procurement Article of the Annotated Code of Maryland. “Discrimination” means any disadvantage, difference, distinction, or preference in the solicitation, selection, hiring, or commercial treatment of a vendor, subcontractor, or commercial customer on the basis of race, color, religion, ancestry, or national origin, sex, age, marital status, sexual orientation, sexual identity, genetic information or an individual’s refusal to submit to a genetic test or make available the results of a genetic test, disability, or any otherwise unlawful use of characteristics regarding the vendor’s, supplier’s, or commercial customer’s employees or owners.

“Discrimination” also includes retaliating against any person or other entity for reporting any incident of “discrimination”. Without limiting any other provision of the solicitation on this project, it is understood that, if the certification is false, such false certification constitutes grounds for the State to reject the Bid/Proposal submitted by the Bidder/Offeror on this project, and terminate any contract awarded based on the Bid/Proposal. As part of its Bid/Proposal, the Bidder/Offeror herewith submits a list of all instances within the past four (4) years where there has been a final adjudicated determination in a legal or administrative proceeding in the State of Maryland that the Bidder/Offeror discriminated against subcontractors, vendors, suppliers, or commercial customers, and a description of the status or resolution of that determination, including any remedial action taken. Bidder/Offeror agrees to comply in all respects with the State’s Commercial Nondiscrimination Policy as described under Title 19 of the State Finance and Procurement Article of the Annotated Code of Maryland.

B-1. CERTIFICATION REGARDING MINORITY BUSINESS ENTERPRISES.

The undersigned Bidder/Offeror hereby certifies and agrees that it has fully complied with the State Minority Business Enterprise Law, State Finance and Procurement Article, § 14-308(a)(2), Annotated Code of Maryland, which provides that, except as otherwise provided by law, a contractor may not identify a certified minority business enterprise in a Bid/Proposal and:

(1) Fail to request, receive, or otherwise obtain authorization from the certified minority business enterprise to identify the certified minority bid/proposal;

(2) Fail to notify the certified minority business enterprise before execution of the contract of its inclusion in the Bid/Proposal;

(3) Fail to use the certified minority business enterprise in the performance of the contract; or

(4) Pay the certified minority business enterprise solely for the use of its name in the

Attachment A. Bid/Proposal Affidavit

Attachment A. Bid Proposal Affidavit effective date: July 2024

Bid/Proposal.

Without limiting any other provision of the solicitation on this project, it is understood that if the certification is false, such false certification constitutes grounds for the State to reject the Bid/Proposal submitted by the Bidder/Offeror on this project, and terminate any contract awarded based on the Bid/Proposal.

B-2. CERTIFICATION REGARDING VETERAN-OWNED SMALL BUSINESS

ENTERPRISES.

The undersigned Bidder/Offeror hereby certifies and agrees that it has fully complied with the State veteran-owned small business enterprise law, State Finance and Procurement Article, § 14-605, Annotated Code of Maryland, which provides that a person may not:

(1) Knowingly and with intent to defraud, fraudulently obtain, attempt to obtain, or aid another person in fraudulently obtaining or attempting to obtain public money, procurement contracts, or funds expended under a procurement contract to which the person is not entitled under this title;

(2) Knowingly and with intent to defraud, fraudulently represent participation of a veteran-owned small business enterprise in order to obtain or retain a Bid/Proposal preference or a procurement contract;

(3) Willfully and knowingly make or subscribe to any statement, declaration, or other document that is fraudulent or false as to any material matter, whether or not that falsity or fraud is committed with the knowledge or consent of the person authorized or required to present the declaration, statement, or document;

(4) Willfully and knowingly aid, assist in, procure, counsel, or advise the preparation or presentation of a declaration, statement, or other document that is fraudulent or false as to any material matter, regardless of whether that falsity or fraud is committed with the knowledge or consent of the person authorized or required to present the declaration, statement, or document;

(5) Willfully and knowingly fail to file any declaration or notice with the unit that is required by COMAR 21.11.13; or

(6) Establish, knowingly aid in the establishment of, or exercise control over a business found to have violated a provision of § B-2(1) -(5) of this regulation.

C. AFFIRMATION REGARDING BRIBERY CONVICTIONS

I FURTHER AFFIRM THAT:

Neither I, nor to the best of my knowledge, information, and belief, the above business (as is defined in Section 16-101(b) of the State Finance and Procurement Article of the Annotated Code of Maryland), or any of its officers, directors, partners, controlling stockholders, or any of its employees directly involved in the business’s contracting activities including obtaining or performing contracts with public bodies has been convicted of, or has had probation before judgment imposed pursuant to Criminal Procedure Article, § 6-220, Annotated Code of Maryland, or has pleaded nolo contendere to a charge of, bribery, attempted bribery, or conspiracy to bribe in violation of Maryland law, or of the law of any other state or federal law, except as follows (indicate the reasons why the affirmation cannot be given and list any conviction, plea, or imposition of probation before judgment with the date, court, official or administrative body, the sentence or disposition, the name(s) of person(s) involved, and their current positions and responsibilities with the business):

Attachment A. Bid Proposal Affidavit effective date: July 2024

D. AFFIRMATION REGARDING OTHER CONVICTIONS

I FURTHER AFFIRM THAT:

Neither I, nor to the best of my knowledge, information, and belief, the above business, or any of its officers, directors, partners, controlling stockholders, or any of its employees directly involved in the business’s contracting activities including obtaining or performing contracts with public bodies, has:

(1) Been convicted under state or federal statute of:

(a) A criminal offense incident to obtaining, attempting to obtain, or performing a public or private contract; or

(b) Fraud, embezzlement, theft, forgery, falsification or destruction of records or receiving stolen property;

(2) Been convicted of any criminal violation of a state or federal antitrust statute;

(3) Been convicted under the provisions of Title 18 of the United States Code for violation of the Racketeer Influenced and Corrupt Organization Act, 18 U.S.C. § 1961 et seq., or the Mail Fraud Act, 18 U.S.C. § 1341 et seq., for acts in connection with the submission of Bids/Proposals for a public or private contract;

(4) Been convicted of a violation of the State Minority Business Enterprise Law, § 14-308 of the State Finance and Procurement Article of the Annotated Code of Maryland;

(5) Been convicted of a violation of § 11-205.1 of the State Finance and Procurement Article of the Annotated Code of Maryland;

(6) Been convicted of conspiracy to commit any act or omission that would constitute grounds for conviction or liability under any law or statute described in subsections (1)— (5) above;

(7) Been found civilly liable under a state or federal antitrust statute for acts or omissions in connection with the submission of Bids/Proposals for a public or private contract;

(8) Been found in a final adjudicated decision to have violated the Commercial Nondiscrimination Policy under Title 19 of the State Finance and Procurement Article of the Annotated Code of Maryland with regard to a public or private contract;

(9) Been convicted of a violation of one or more of the following provisions of the Internal Revenue Code:

(a) §7201, Attempt to Evade or Defeat Tax;

(b) §7203, Willful Failure to File Return, Supply Information, or Pay Tax,

(c) §7205, Fraudulent Withholding Exemption Certificate or Failure to Supply Information;

(d) §7206, Fraud and False Statements, or

(e) §7207 Fraudulent Returns, Statements, or Other Documents;

(10) Been convicted of a violation of 18 U.S.C. §286 Conspiracy to Defraud the Government with Respect to Claims, 18 U.S.C. §287, False, Fictitious, or Fraudulent Claims, or 18 U.S.C. §371, Conspiracy to Defraud the United States;

(11) Been convicted of a violation of the Tax-General Article, Title 13, Subtitle 7 or Subtitle 10, Annotated Code of Maryland;

(12) Been found to have willfully or knowingly violated State Prevailing Wage Laws as provided in the State Finance and Procurement Article, Title 17, Subtitle 2, Annotated Code of Maryland, if:

Attachment A. Bid Proposal Affidavit effective date: July 2024

(a) A court:

(i) Made the finding; and

(ii) Decision became final; or

(b) The finding was:

(i) Made in a contested case under the Maryland Administrative Procedure act; and

(ii) Not overturned on judicial review;

(13) Been found to have willfully or knowingly violated State Living Wage Laws as provided in the State Finance and Procurement Article, Title 18, Annotated Code of Maryland, if:

(a) A court:

(i) Made the finding; and

(ii) Decision became final; or

(b) The finding was:

(i) Made in a contested case under the Maryland Administrative Procedure act; and

(ii) Not overturned on judicial review;

(14) Been found to have willfully or knowingly violated the Labor and Employment Article, Title 3, Subtitles 3, 4, or 5, or Title 5, Annotated Code of Maryland, if:

(a) A court:

(i) Made the finding; and

(ii) Decision became final; or

(b) The finding was:

(i) Made in a contested case under the Maryland Administrative Procedure act; and

(ii) Not overturned on judicial review; or

(15) Admitted in writing or under oath, during the course of an official investigation or other proceedings, acts or omissions that would constitute grounds for conviction or liability under any law or statute described in §§ B and C and subsections D(1)—(14) above, except as follows (indicate reasons why the affirmations cannot be given, and list any conviction, plea, or imposition of probation before judgment with the date, court, official or administrative body, the sentence or disposition, the name(s) of the person(s) involved and their current positions and responsibilities with the business, and the status of any debarment):

E. AFFIRMATION REGARDING DEBARMENT

I FURTHER AFFIRM THAT:

Neither I, nor to the best of my knowledge, information, and belief, the above business, or any of its officers, directors, partners, controlling stockholders, or any of its employees directly involved in the business’s contracting activities, including obtaining or performing contracts with public bodies, has ever been suspended or debarred (including being issued a limited denial of participation) by any public entity, except as follows (list each debarment or suspension providing the dates of the suspension or debarment, the name of the public entity and the status of the proceedings, the

Attachment A. Bid Proposal Affidavit effective date: July 2024 name(s) of the person(s) involved and their current positions and responsibilities with the business, the grounds of the debarment or suspension, and the details of each person’s involvement in any activity that formed the grounds of the debarment or suspension).

F. AFFIRMATION REGARDING DEBARMENT OF RELATED ENTITIES

(1) The business was not established and does not operate in a manner designed to evade the application of or defeat the purpose of debarment pursuant to Sections 16-101, et seq., of the State Finance and Procurement Article of the Annotated Code of Maryland; and

(2) The business is not a successor, assignee, subsidiary, or affiliate of a suspended or debarred business, except as follows (you must indicate the reasons why the affirmations cannot be given without qualification):

G. SUBCONTRACT AFFIRMATION

Neither I, nor to the best of my knowledge, information, and belief, the above business, has knowingly entered into a contract with a public body under which a person debarred or suspended under Title 16 of the State Finance and Procurement Article of the Annotated Code of Maryland will provide, directly or indirectly, supplies, services, architectural services, construction related services, leases of real property, or construction.

H. AFFIRMATION REGARDING COLLUSION

I FURTHER AFFIRM THAT:

Neither I, nor to the best of my knowledge, information, and belief, the above business has:

(1) Agreed, conspired, connived, or colluded to produce a deceptive show of competition in the compilation of the accompanying Bid/Proposal that is being submitted; or

(2) In any manner, directly or indirectly, entered into any agreement of any kind to fix the Bid/Proposal price of the Bidder/Offeror or of any competitor, or otherwise taken any action in restraint of free competitive bidding in connection with the contract for which the accompanying Bid/Proposal is submitted.

I. CERTIFICATION OF TAX PAYMENT

I FURTHER AFFIRM THAT:

Except as validly contested, the business has paid, or has arranged for payment of, all taxes due the State of Maryland and has filed all required returns and reports with the Comptroller of the Treasury, State Department of Assessments and Taxation, and Department of Labor, Licensing, and Regulation, as applicable, and will have paid all withholding taxes due the State of Maryland prior to final settlement.

J. CONTINGENT FEES

Attachment A. Bid Proposal Affidavit effective date: July 2024

The business has not employed or retained any person, partnership, corporation, or other entity, other than a bona fide employee, bona fide agent, bona fide salesperson, or commercial selling agency working for the business, to solicit or secure the Contract, and that the business has not paid or agreed to pay any person, partnership, corporation, or other entity, other than a bona fide employee, bona fide agent, bona fide salesperson, or commercial selling agency, any fee or any other consideration contingent on the making of the Contract.

K. CERTIFICATION REGARDING INVESTMENTS IN IRAN

(1) The undersigned certifies that, in accordance with State Finance and Procurement Article, §17- 705, Annotated Code of Maryland:

(a) It is not identified on the list created by the Board of Public Works as a person engaging in investment activities in Iran as described in State Finance and Procurement Article, §17-702, Annotated Code of Maryland; and

(b) It is not engaging in investment activities in Iran as described in State Finance and Procurement Article, §17-702, Annotated Code of Maryland.

(2) The undersigned is unable to make the above certification regarding its investment activities in Iran due to the following activities:

L. CONFLICT MINERALS ORIGINATED IN THE DEMOCRATIC REPUBLIC OF

CONGO (FOR SUPPLIES AND SERVICES CONTRACTS)

I FURTHER AFFIRM THAT:

The business has complied with the provisions of State Finance and Procurement Article, §14-413, Annotated Code of Maryland governing proper disclosure of certain information regarding conflict minerals originating in the Democratic Republic of Congo or its neighboring countries as required by federal law.

M. PROHIBITING DISCRIMINATORY BOYCOTTS OF ISRAEL

I FURTHER AFFIRM THAT:

In preparing its bid/proposal on this project, the Bidder/Offeror has considered all bid/proposals submitted from qualified, potential subcontractors and suppliers, and has not, in the solicitation, selection, or commercial treatment of any subcontractor, vendor, or supplier, refused to transact or terminated business activities, or taken other actions intended to limit commercial relations, with a person or entity on the basis of Israeli national origin, or residence or incorporation in Israel and its territories. The Bidder/Offeror also has not retaliated against any person or other entity for reporting such refusal, termination, or commercially limiting actions. Without limiting any other provision of the solicitation for bid/proposals for this project, it is understood and agreed that, if this certification is false, such false certification will constitute grounds for the State to reject the bid/proposal submitted by the Bidder/Offeror on this project, and terminate any contract awarded based on the bid/proposal.

N. I FURTHER AFFIRM THAT:

Any claims of environmental attributes made relating to a product or service included in the bid or bid/proposal are consistent with the Federal Trade Commission’s Guides for the Use of Environmental Marketing Claims as provided in 16 C.F.R. §260, that apply to claims about the environmental attributes of a product, package or service in connection with the marketing, offering for sale, or sale of such item or service.

Attachment A. Bid Proposal Affidavit effective date: July 2024

O. ACKNOWLEDGEMENT

I ACKNOWLEDGE THAT this Affidavit is to be furnished to the Procurement Officer and may be distributed to units of: (1) the State of Maryland; (2) counties or other subdivisions of the State of Maryland; (3) other states; and (4) the federal government. I further acknowledge that this Affidavit is subject to applicable laws of the United States and the State of Maryland, both criminal and civil, and that nothing in this Affidavit or any contract resulting from the submission of this Bid/proposal shall be construed to supersede, amend, modify or waive, on behalf of the State of Maryland, or any unit of the State of Maryland having jurisdiction, the exercise of any statutory right or remedy conferred by the Constitution and the laws of Maryland with respect to any misrepresentation made or any violation of the obligations, terms and covenants undertaken by the above business with respect to (1) this Affidavit, (2) the contract, and (3) other Affidavits comprising part of the contract.

I DO SOLEMNLY DECLARE AND AFFIRM UNDER THE PENALTIES OF PERJURY THAT

THE CONTENTS OF THIS AFFIDAVIT ARE TRUE AND CORRECT TO THE BEST OF MY

KNOWLEDGE, INFORMATION, AND BELIEF.

By:

Signature of Authorized Representative and Affiant

Printed Name:

Printed Name of Authorized Representative and Affiant

Title:

Title

Date:

Date

Attachment C. Bid Bond effective date: July 2024

Attachment C. Bid Bond

Bond No. __________________

We, _______________________________ as Principal, hereinafter called the Principal, and ____________________________, a corporation duly organized under the laws of the State of __________________, as Surety, hereinafter called the Surety, are held and firmly bound unto the State of Maryland, hereinafter called "State", for the sum of _______________________________________ for the payment of which sum, the Principal and the Surety bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents.

WHEREAS, the Principal has submitted a bid for (Identify project by number and brief description):

NOW, THEREFORE, if the Principal, upon acceptance by the State of its bid identified above, within the period specified therein for acceptance (ninety (90) days, if no period is specified), shall execute such further contractual documents, if any, and give such bond(s) as may be required by the terms of the bid as accepted within the time specified (ten (10) days if no period is specified) after receipt of the forms, or in the event of failure so to execute such further contractual documents and give such bonds, if the Principal shall pay the State the difference not to exceed the penalty hereof between the amount specified in Principal's bid and such larger amount for which the State may in good faith contract with another party to perform the work covered by said bid, then the above obligation shall be void and of no effect.

The Surety executing this instrument hereby agrees that its obligation shall not be impaired by any extension(s) of the time for acceptance of the bid that the Principal may grant to the State, notice of which extension(s) to the Surety being hereby waived; provided that such waiver of notice shall apply only with respect to extensions aggregating not more than ninety (90) calendar days in addition to the period originally allowed for acceptance of the bid.

Individual Principal

In Presence of:

Witness

(Name) as to (SEAL)

Partnership Principal

In Presence of:

Witness

(Name) as to (SEAL) Partner as to (SEAL) Partner as to (SEAL) Partner

Corporate Principal

Attachment C. Bid Bond effective date: July 2024

Attest: (Name of Corporation) AFFIX

SEAL

Secretary President

Attest: (Surety)

Attorney-in-fact AFFIX

SEAL

Bonding Agent’s Name

Agent’s Address:

Approved as to form and legal sufficiency this ____ day of _____ 20___

Assistant Attorney General

Attachment F. Bidder/Offeror Information Sheet effective date: July 2024

Bidder/Offeror

Company Name

Street Address

City, State, Zip Code

Contractor Federal Employer Identification Number

(FEIN)

Contractor eMM ID Number As of the Bid/Proposal submission date, are you registered to do business with the State of Maryland?

SBE / MBE/ VSBE Certification

SBE Number:

Expiration Date:

VSBE Number:

Expiration Date:

MBE Number:

Expiration Date:

Categories to be applied to this solicitation (dual certified firms must choose only one category).

Bidder/Offeror Primary Contact

Name

Title

Office Telephone Number (with area code)

Cell Telephone Number (with area code)

E-mail Address

Authorized Bid/Proposal Signatory

Name

Title

Office Telephone Number (with area code)

Cell Telephone Number (with area code)

E-mail Address

Signature to authorized commit of the Bidder/Offeror to its Bid/Proposal

Attachment F. Bidder/Offeror Information Sheet

Attachment F. Bidder/Offeror Information Sheet effective date: July 2024

Attachment I. Conflict of Interest Affidavit effective date: July 2024

Attachment I. Conflict of Interest Affidavit and Disclosure

Reference COMAR 21.05.08.08

A. “Conflict of interest” means that because of other activities or relationships with other persons, a person is unable or potentially unable to render impartial assistance or advice to the State, or the person’s objectivity in performing the contract work is or might be otherwise impaired, or a person has an unfair competitive advantage.

B. “Person” has the meaning stated in COMAR 21.01.02.01B(64) and includes a Offeror, Contractor, consultant, or subcontractor or sub-consultant at any tier, and also includes an employee or agent of any of them if the employee or agent has or will have the authority to control or supervise all or a portion of the work for which a Proposal is made.

C. The Offeror warrants that, except as disclosed in §D, below, there are no relevant facts or circumstances now giving rise or which could, in the future, give rise to a conflict of interest.

D. The following facts or circumstances give rise or could in the future give rise to a conflict of interest (explain in detail — attach additional sheets if necessary):

E. The Offeror agrees that if an actual or potential conflict of interest arises after the date of this affidavit, the Offeror shall immediately make a full disclosure in writing to the procurement officer of all relevant facts and circumstances. This disclosure shall include a description of actions which the Offeror has taken and proposes to take to avoid, mitigate, or neutralize the actual or potential conflict of interest. If the contract has been awarded and performance of the contract has begun, the Contractor shall continue performance until notified by the procurement officer of any contrary action to be taken.

I DO SOLEMNLY DECLARE AND AFFIRM UNDER THE PENALTIES OF PERJURY THAT THE

CONTENTS OF THIS AFFIDAVIT ARE TRUE AND CORRECT TO THE BEST OF MY

KNOWLEDGE, INFORMATION, AND BELIEF.

Date: ____________________ By: ______________________________________

(Authorized Representative and Affiant)

SUBMIT THIS AFFIDAVIT WITH BID/PROPOSAL

Attachment O. Payment of Employee Healthcare Expenses Certification effective date: July 2024

Attachment O. Payment of Employee Healthcare Expenses Certification Under State Finance & Procurement Article Title 17, Subtitle 8

In connection with Solicitation Number _________I, ___________________[Name] hereby certify that ___________________ [Firm Name] is ☐ the bidder/☐ a subcontractor on this project (indicate whether the firm is the bidder or a subcontractor). I further certify that, with respect to employees who will work on or at the site of the project:

[CHOOSE ONLY ONE OPTION BELOW. Note that for purposes of this Certification, “Credible Health Insurance Plan” means any group policy, contract, or program that is written or administered by a disability insurer, health care service plan, fraternal benefits society, self-insured employer plan, or any other entity, in the state of Maryland or elsewhere, that arranges or provides medical, hospital, and surgical coverage not designated to supplement other private or governmental plans.]

1. ☐ The firm pays aggregate employee healthcare expenses of at least 5% of the aggregate social security wages paid.

OR

2. ☐ The firm pays 50% or more of the required premium necessary to obtain employee coverage by a credible health care insurance plan (as defined above).

OR

3. ☐ The firm has 30 or fewer employees and is therefore exempt.

Further, I acknowledge that under §17-804 of the State Finance and Procurement Article, Maryland Annotated Code, a person or entity providing false information regarding this requirement may be subject to a civil penalty of not less than $2,500 and not exceeding $25,000 for each violation.

Signature of Authorized Representative Date

Title of Authorized Representative

Company Street Address

City, State, ZIP Code

Attachment U. Contract Affidavit effective date: July 2024

Attachment U. Contract Affidavit

A. AUTHORITY

I hereby affirm that I, ________________________________ (name of affiant) am the __________________________________ (title) and duly authorized representative of __________________________________ (name of business entity) and that I possess the legal authority to make this affidavit on behalf of the business for which I am acting.

B. CERTIFICATION OF REGISTRATION OR QUALIFICATION WITH THE STATE

DEPARTMENT OF ASSESSMENTS AND TAXATION

I FURTHER AFFIRM THAT:

The business named above is a (check applicable box):

(1) Corporation - domestic or foreign;

(2) Limited Liability Company - domestic or foreign;

(3) Partnership - domestic or foreign;

(4) Statutory Trust - domestic or foreign;

(5) Sole Proprietorship.

and is registered or qualified as required under Maryland Law. I further affirm that the above business is in good standing both in Maryland and (IF APPLICABLE) in the jurisdiction where it is presently organized, and has filed all of its annual reports, together with filing fees, with the Maryland State Department of Assessments and Taxation. The name and address of its resident agent (IF APPLICABLE) filed with the State Department of Assessments and Taxation is:

Name and Department ID Number: __________________

Address: _______________________________ and that if it does business under a trade name, it has filed a certificate with the State Department of Assessments and Taxation that correctly identifies that true name and address of the principal or owner as:

Name and Department ID Number: _____________________________

Address: _______________________________

C. FINANCIAL DISCLOSURE AFFIRMATION

I FURTHER AFFIRM THAT:

I am aware of, and the above business will comply with, the provisions of State Finance and Procurement Article, §13-221, Annotated Code of Maryland, which require that every business that enters into contracts, leases, or other agreements with the State of Maryland or its agencies during a calendar year under which the business is to receive in the aggregate $200,000 or more shall, within 30 days of the time when the aggregate value of the contracts, leases, or other agreements reaches $200,000, file with the Secretary of State of Maryland certain specified information to include disclosure of beneficial ownership of the business.

D. POLITICAL CONTRIBUTION DISCLOSURE AFFIRMATION

I FURTHER AFFIRM THAT:

I am aware of, and the above business will comply with, Election Law Article, Title 14, Annotated Code of Maryland, which requires that every person that enters into a procurement contract with the

Attachment U. Contract Affidavit effective date: July 2024

State, a county, or a municipal corporation, or other political subdivision of the State, during a calendar year in which the person receives a contract with a governmental entity in the amount of $200,000 or more, shall file with the State Board of Elections statements disclosing: (a) any contributions made during the reporting period to a candidate for elective office in any primary or general election; and (b) the name of each candidate to whom one or more contributions in a cumulative amount of $500 or more were made during the reporting period. The statement shall be filed with the State Board of Elections: (a) before execution of a contract by the State, a county, a municipal corporation, or other political subdivision of the State, and shall cover the 24 months prior to when a contract was awarded; and (b) if the contribution is made after the execution of a contract, then twice a year, throughout the contract term, on or before: (i) May 31, to cover the six (6) month period ending April 30; and (ii) November 30, to cover the six (6) month period ending October 31.

E. DRUG AND ALCOHOL FREE WORKPLACE

(Applicable to all contracts unless the contract is for a law enforcement agency and the agency head or the agency head’s designee has determined that application of COMAR 21.11.08 and this certification would be inappropriate in connection with the law enforcement agency's undercover operations.)

I CERTIFY THAT:

(1) Terms defined in COMAR 21.11.08 shall have the same meanings when used in this certification.

(2) By submission of its Proposal, the business, if other than an individual, certifies and agrees that, with respect to its employees to be employed under a contract resulting from this solicitation, the business shall:

(a) Maintain a workplace free of drug and alcohol abuse during the term of the contract;

(b) Publish a statement notifying its employees that the unlawful manufacture, distribution, dispensing, possession, or use of drugs, and the abuse of drugs or alcohol is prohibited in the business' workplace and specifying the actions that will be taken against employees for violation of these prohibitions;

(c) Prohibit its employees from working under the influence of drugs or alcohol;

(d) Not hire or assign to work on the contract anyone who the business knows, or in the exercise of due diligence should know, currently abuses drugs or alcohol and is not actively engaged in a bona fide drug or alcohol abuse assistance or rehabilitation program;

(e) Promptly inform the appropriate law enforcement agency of every drug-related crime that occurs in its workplace if the business has observed the violation or otherwise has reliable information that a violation has occurred;

(f) Establish drug and alcohol abuse awareness programs to inform its employees about:

(i) The dangers of drug and alcohol abuse in the workplace;

(ii) The business's policy of maintaining a drug and alcohol free workplace;

(iii) Any available drug and alcohol counseling, rehabilitation, and employee assistance programs; and

(iv) The penalties that may be imposed upon employees who abuse drugs and alcohol in the workplace;

(g) Provide all employees engaged in the performance of the contract with a copy of the statement required by §E(2)(b), above;

(h) Notify its employees in the statement required by §E(2)(b), above, that as a condition of continued employment on the contract, the employee shall:

Attachment U. Contract Affidavit effective date: July 2024

(i) Abide by the terms of the statement; and

(ii) Notify the employer of any criminal drug or alcohol abuse conviction for an offense occurring in the workplace not later than 5 days after a conviction;

(i) Notify the procurement officer within 10 days after receiving notice under §E(2)(h)(ii), above, or otherwise receiving actual notice of a conviction;

(j) Within 30 days after receiving notice under §E(2)(h)(ii), above, or otherwise receiving actual notice of a conviction, impose either of the following sanctions or remedial measures on any employee who is convicted of a drug or alcohol abuse offense occurring in the workplace:

(i) Take appropriate personnel action against an employee, up to and including termination; or

(ii) Require an employee to satisfactorily participate in a bona fide drug or alcohol abuse assistance or rehabilitation program; and

(k) Make a good faith effort to maintain a drug and alcohol free workplace through implementation of §E(2)(a)—(j), above.

(3) If the business is an individual, the individual shall certify and agree as set forth in §E(4), below, that the individual shall not engage in the unlawful manufacture, distribution, dispensing, possession, or use of drugs or the abuse of drugs or alcohol in the performance of the contract.

(4) I acknowledge and agree that:

(a) The award of the contract is conditional upon compliance with COMAR 21.11.08 and this certification;

(b) The violation of the provisions of COMAR 21.11.08 or this certification shall be cause to suspend payments under, or terminate the contract for default under COMAR 21.07.01.11 or 21.07.03.15, as applicable; and

(c) The violation of the provisions of COMAR 21.11.08 or this certification in connection with the contract may, in the exercise of the discretion of the Board of Public Works, result in suspension and debarment of the business under COMAR 21.08.03.

F. CERTAIN AFFIRMATIONS VALID

I FURTHER AFFIRM THAT:

To the best of my knowledge, information, and belief, each of the affirmations, certifications, or acknowledgements contained in that certain Bid/Proposal Affidavit dated _____________________, and executed by me for the purpose of obtaining the contract to which this Exhibit is attached remains true and correct in all respects as if made as of the date of this Contract Affidavit and as if fully set forth herein.

I DO SOLEMNLY DECLARE AND AFFIRM UNDER THE PENALTIES OF PERJURY THAT

THE CONTENTS OF THIS AFFIDAVIT ARE TRUE AND CORRECT TO THE BEST OF MY

KNOWLEDGE, INFORMATION, AND BELIEF.

Date: _______________________

By: ________________________ (print name of Authorized Representative and Affiant)

_________________________________ (signature of Authorized Representative and Affiant)