Bids - Gulf County_ FL Salinas Park Dune Restoration.pdf
PDF 62 KB Posted
- Attached to
- Salinas Park Dune Restoration
- Solicitation number
- 2526-40
- Issued by
- Glades County, Florida
About this file
This is a Notice to Receive Sealed Bids issued by the Gulf County Board of County Commissioners for the Salinas Park Dune Restoration project in Gulf County, Florida (Bid #2526-40). The project involves restoration, replanting, and irrigation of an existing sand dune located in Salinas Park. The completion deadline is 120 days from the Notice to Proceed issuance. Sealed bids must be submitted in triplicate (original plus two copies) with the company name, sealed bid amount, and bid number clearly marked on the envelope. Bids are due by 10:00 a.m. Eastern Time on October 15, 2026, at the Gulf County Clerk's Office, 1000 Cecil G. Costin Sr. Blvd, Room 149, Port St. Joe, Florida 32456. Bids will be publicly opened and read aloud at 1:00 p.m. Eastern Time on the same date at the Donald H. Butler Commission Chamber in the Robert M. Moore Administration Building. Bid specifications are available on the County's website or through the Gulf County Clerk's Office. All bids remain firm for sixty days following opening.
Liquidated damages are assessed at $1,685.00 per day for failure to meet the project completion date. All bidders must comply with applicable Florida state and local licensing, registration, and contractor regulation requirements, as well as Section 287.133(3) Florida Statutes regarding public entity crimes. The project is subject to the Buy America, Buy American Act domestic preference requirements, necessitating that all iron, steel, manufactured products, and construction materials be produced in the United States with supporting documentation. Minority and women's business enterprises are actively solicited as prime contractors and for subcontracting opportunities. The Gulf County Board of County Commissioners reserves the right to waive bid informalities and accept or reject any bids at its discretion. Questions should be directed to Clay Kennedy at ckennedy@gulfcounty-fl.gov.
View the file
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
NOTICE TO RECEIVE SEALED BIDS
BID #2526-40
The Gulf County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing the:
SALINAS PARK DUNE RESTORATION
This project includes restoration, replanting and irrigation of an existing sand dune in Salinas Park in Gulf County, FL.
The completion date for this project will be 120 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $1,685.00 per day.
Please place YOUR COMPANY NAME, SEALED BID, and the BID NUMBER on the outside of your envelope and include the original bid plus 2 copies.
Bids will be received until 10:00 a.m. Eastern Time on October 15, 2026 at the Gulf County Clerk’s Office, 1000 Cecil G. Costin Sr. Blvd, Room 149, Port St. Joe, Florida 32456, and will be opened and read aloud at a meeting of the Board of County Commissioners held in the Donald H. Butler Commission Chamber in the Robert M. Moore Administration Building, Gulf County Courthouse Complex, Port St. Joe, Florida on October 15, 2026 at 1:00 p.m.
Eastern Time.
Bid specifications can be obtained on the County’s website or through the Gulf County Clerk’s Office. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. All questions must be submitted to Clay Kennedy at ckennedy@gulfcounty-fl.gov.
The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Gulf County.
The Project is subject to the domestic preference requirement of the Build America, Buy America Act, which requires that all iron, steel, manufactured products, and construction materials used in the project be produced in the United States. Documentation will be required to support compliance with the Buy American provisions.
Minority and women’s business enterprises are hereby solicited to bid on this contract as prime contractors and are encouraged to make inquiries regarding potential subcontracting opportunities and equipment, material and/or supply needs. All bidders must make positive efforts to use small and minority owned business and women business enterprises.
The Gulf County Board of County Commissioners is an Equal Opportunity Employer.
BOARD OF COUNTY COMMISSIONERS
GULF COUNTY, FLORIDA
/s/ Sandy Quinn, Chairman
9/25/26, 12:06 PM Bids - Gulf County, FL https://www.gulfcounty-fl.gov/meeting/bids 1/1 mailto:ckennedy@gulfcounty-fl.gov?subject=BID%20#2526-40:%20SALINAS%20PARK%20DUNE%20RESTORATION
File details come from the government source that posted it. Updated .