BGM OM Demo - Final Specification.pdf

Greater Binghamton Airport Outer Marker (BGM OM) Binghamton, NY

Demolish, Remove and Dispose of the BGM OM Facility

SPECIFICATIONS

For

Federal Aviation Administration New England Region

By

AJW-2E15A, OPS Engineering Center NE

FEDERAL AVIATION ADMINISTRATION JUNE 2022

OM FACILITY DISPOSITION BINGHAMTON, NY

Table of Contents

TABLE OF CONTENTS

00 00 00 GENERAL

00 80 00 Safety and Health Requirements

01 11 00 Summary of Work

01 33 00 Submittals Procedure

01 35 43.13 Hazardous Materials

02 00 00 Existing Conditions

02 41 00 Demolition

31 00 00 Earthwork

31 23 00 Excavation and Fill

APPENDICES

Appendix A: Supplemental Facility Info

Appendix B: Site Photographs

Appendix C: Hazmat Test Results

Safety and Health Requirements 00 73 19 - 1

SECTION 00 73 19 – SAFETY AND HEALTH REQUIREMENTS

PART 1 – GENERAL

1.1 Summary

A. Requirements for Employee Health and Safety

1.2 Applicable Publications - The publications listed below form a part of this specification to the extent referenced. The publications are referred to in the text by basic designation only:

A. Code of Federal Regulations (CFR)

1. OSHA General Industry Safety and Health Standards (29 CFR 1910), Publication V2206; OSHA Construction Industry Standards (29 CFR 1926). One source of these regulations is OSHA Publication 2207, which includes a combination of both parts 1910 and 1926 as they relate to construction safety and health.

2. National Emission Standards for Hazardous Air Pollutants (40 CFR, Part 61)

3. Federal Standard (Fed. Std.) 313A – Material Safety Data Sheets, Preparation and the

Submission of

4. FAA Order JO 3900.57A, Environmental and Occupational Safety and Health

(EOSH) Requirements in the Planning and Execution of Construction and Maintenance Activities at National Airspace System (NAS) Facilities. Specifically, FAA Form 3900-18, Pre-Construction EOSH Checklist. This checklist will be reviewed with the Contractor and FAA prior to construction.

1.3 Work Covered by This Section

A. This section is applicable to all work covered by this contract.

1.4 Definition of Hazardous Materials

A. Refer to hazardous and toxic materials/substances included in Subparts H and Z of 29 CFR 1910; and to others as additionally defined in Fed. Std. 313. Those most commonly encountered include asbestos, polychlorinated biphenyl’s (PCB’s), explosives, and radioactive material, but may include others.

1.5 Quality Assurance

A. Safety Meeting – Representatives of the Contractor shall meet with the CO and COR prior to the start of work, for the purpose of reviewing the contractor's safety and health programs and discussing implementation of all safety and health provisions pertinent to the work to be performed under this contract. The contractor shall be prepared to discuss, in detail, the measures he/she intends to take in order to control any unsafe or unhealthy conditions associated with the work to be performed under the contract. If directed by the COR, this meeting may be held in conjunction with other meetings, which are scheduled to take place prior to start of work under this contract. The contractor’s principal on-site representative(s), the general superintendent, and his/her safety representative(s) shall attend this meeting.

B. Compliance with Regulations – All work, including the handling of hazardous materials shall comply with applicable state and municipal safety and health requirements. Where there is a conflict between applicable regulations, the most stringent shall apply.

C. Contractor’s Responsibility – The contractor shall assume full responsibility and liability for compliance with all applicable regulations pertaining to the health and safety of personnel during the execution of the work.

Safety and Health Requirements 00 73 19 - 2

D. Inspections, Tests and Reports – The required inspections, tests, and reports made by the contractor, subcontractors, specially trained technicians, equipment manufacturers, and others as required, shall be at the contractor’s expense.

E. Site Specific Safety Plan (SSSP) – The Contractor will be required to submit his plan for maintaining a safe work environment for construction workers employed on this project. As a minimum, the plan shall show weekly “tail gate meetings”, scheduled inspections of equipment to check for potential hazards created by wear, etc. and a statement that the current OSHA regulations on safety in the construction industry will be followed. The plan will be used by the COR to insure that the work is accomplished in accordance with safety practices.

The COR may stop any operation, which is in violation of the OSHA standards and fails to comply with the safety plan or accepted safe work practices.

1.6 Submittals

A. Accident and Fire Reporting

1. The Contractor shall report to the Contracting Officer any accident or fire occurring at the site of the work which causes:

a. A fatality or as much as one lost workday on the part of any employee of the Contractor or subcontractor at any tier;

b. Damage of $1,000 or more to Government-owned or leased property, either real or personal;

c. Damage of $1,000 or more to Contractor or subcontractor owned or leased motor vehicles or mobile equipment; or

d. Damage for which a contract time extension may be requested.

2. Accident and fire reports required by paragraph (1) above shall be accomplished by the following means:

a. Accidents or fires resulting in a death, hospitalization of five or more persons, or destruction of Government-owned or leased property (either real or personal), the total value of which is estimated at $100,000 or more, shall be reported immediately by telephone to the Contracting Officer or his/her authorized representative and shall be confirmed by telegram or facsimile transmission within 24 hours to the Contracting Officer. Such telegram or facsimile transmission shall state all known facts as to extent of injury and damage and as to cause of the accident or fire.

b. Other accident and fire reports required by paragraph (a) above may be reported by the Contractor using a state, private insurance carrier, or Contractor accident report form which provides for the statement of:

i. The extent of injury; and

ii. The damage and cause of the accident or fire.

c. Such report shall be mailed or otherwise delivered to the Contracting Officer within 48 hours of the occurrence of the accident or fire.

3. The Contractor shall assure compliance by subcontractors at all tiers with the requirements of this clause.

B. Permits – If hazardous materials are disposed of off-site, submit copies of permits from applicable Federal, State, or municipal authorities.

1.7 Materials and Equipment

Safety and Health Requirements 00 73 19 - 3

A. Special facilities, devices, equipment, clothing, and similar items used by the Contractor in the execution of work shall comply with applicable regulations.

1.8 Hazardous Materials

A. The contractor shall bring to the attention of the COR any material suspected of being hazardous which he/she encounters during execution of the work. A determination will be made by the COR as to whether the contractor shall perform tests, and/or if the material is found hazardous and additional protective measures are needed, a contract change may be required, subject to applicable provisions of this contract.

1.9 Suspension of Work

A. The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government. The Contracting Officer may, in emergency or life threatening situations notify the contractor orally to suspend, delay or interrupt all or any part of the work and issue the notice in writing immediately after the oral notice.

B. If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted:

1. by an act of the Contracting Officer in the administration of this contract, or

2. by the Contracting Officer's failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly.

3. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

C. A claim under this clause shall not be allowed:

1. for any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order), and

2. unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

1.10 Protection

A. The Contractor shall take all necessary precautions to prevent injury to the public, building occupants, or damage to property of others. For the purposes of this contract, the public or building occupants shall include all persons not employed by the Contractor or related subcontractor.

B. Work shall not be performed in any area occupied by Federal employees unless adequate steps are taken for the protection of the public and Federal employees.

Safety and Health Requirements 00 73 19 - 4

C. Whenever practicable, the work area shall be fenced, barricaded, or otherwise blocked off to prevent unauthorized entry into the work area.

D. Alternate Precautions

1. When the nature of the work prevents isolation of the work area, alternate precautions such as the posting of signs, the use of signal persons, the erection of barricades or similar protection around particularly hazardous operations shall be used as appropriate.

END OF SECTION 00 73 19

Summary of Work 01 11 00 - 1

SECTION 01 11 00 - SUMMARY OF WORK

PART 1 - GENERAL

1.1 SCOPE

BGM OM Demolition Scope The Contractor shall furnish all labor, equipment and materials necessary for the demolition of the Binghamton Outer Marker (BGM OM) located in Binghamton, NY. The following items are a brief summary of the project and are provided solely for the purpose of describing the general nature of the work. The contractor is responsible for accomplishing all items of work identified in the applicable attachments, specifications, and provisions of the contract.

In general the work consists of the following:

1. Prior to the start of construction, the Contractor shall review the Hazmat report and take appropriate action for abatement of the OM Shelter. The OM Shelter has both Asbestos Containing Material (ACM) and Lead Based Paint (LBP). Provide the FAA documentation of the abatement process.

2. The Contractor shall remove and dispose of any equipment or materials inside the BGM OM shelter or fenced in area unless otherwise identified by the FAA. All Electronic Equipment removed from the shelter or OM plot shall be destroyed to the point of disrepair before disposal or brought to an electronic recycle facility.

3. The Contractor shall remove and dispose of six (6) 12V batteries in an environmentally compliant manner. Provide the FAA documentation of the disposal method.

4. The Contractor shall remove and dispose of the existing Thermostat and Fluorescent Light Tubes found within the shelter. Both are considered mercury-containing material and shall be disposed of in an environmentally compliant manner. Provide the FAA documentation of the disposal method.

5. The contractor shall remove the existing fire extinguisher from the shelter and dispose of properly.

6. The Contractor shall remove and dispose of the 8.5’ x 11’ x 10’ Wooden A-Frame with metal structure shelter, and the associated 5’ x 2’ 2 step concrete entrance.

7. Shelter foundation is comprised of four (4) 12” x 12” x 1’ visible concrete piers. The contractor shall remove the piers and spread the remaining crushed stone completely, and grade site accordingly.

8. The Contractor shall Demolish and remove the Single Yagi Antennae, 10’ Metal Antenna Mast, and associated 30” x 30” concrete pier foundation.

9. The Contractor shall remove the NDB Pole found on the site plot and any associated cabling that remains.

10. The Contractor shall remove and dispose of the NDB Pole metal foundation and tilt down pole support.

11. The Contractor shall remove and dispose of the power meter box, and associated conduit and cabling found on the side of the shelter.

Summary of Work 01 11 00 - 2

12. The Contractor shall remove and dispose of the site perimeter fencing. The fencing consists of approximately 160 linear feet of 7’ tall chain link fence fabric, 500 linear feet of barbed wire, two 6’ wide swing gates, one 3’ pedestrian gate and associated metal fence posts with concrete foundations.

13. The Contractor shall remove and dispose of the shelter and OM antenna counterpoise where possible or cut and remove any portions which are above 3’ below grade.

14. The existing PVC Shed and its contents found on the premises shall be removed by the SSC prior to the arrival of the contractor.

15. The Contractor shall remove and dispose of all conduits and conductors where it is practical to do so. Otherwise, the contractor shall cut and cap all conduits 3’ below grade or where vertical utilities transition to horizontal, whichever occurs first.

16. The Contractor shall demolish and remove all foundations or structures to a minimum of 3’ below grade and cover with existing ground cover material, if available, or import additional ground cover material to match existing, and cover to a depth of approximately 3’.

17. The Contractor shall grade all disturbed areas to match the surrounding site contours.

The facility contains a stoned access road from the public street to the facility. The access road shall be left in place.

18. The Contractor shall be responsible for obtaining any permits required for the demolition and restoration of the BGM OM facility. Contractor shall contact DigSafe prior to excavation.

19. The Contractor shall be solely responsible for any damage caused that is not directly related to the disposition of the BGM OM facility. This includes, but is not limited to, damage to underground or overhead cables still in use, sewer lines, neighboring fences, the surrounding landscape, and local roadways/curbs.

20. The Contractor shall be responsible for providing all temporary services needed for the disposition of the BGM OM facility. This includes, but is not limited to, sanitary facilities, covered dumpsters, and temporary power. The commercial power to the BGM OM facility will be shut off prior to the Contractor arriving on-site.

21. The Contractor shall coordinate the schedule of work with the COR, the SSC, the RE and any applicable local authorities.

1.2 APPLICABLE DOCUMENTS

A. Applicable Documents - All FAA, Military, Federal, and industrial codes or standards, specifications, and contract drawings referenced in this and the following divisions form a part of this specification are applicable only to the extent they were used as a basis of this design.

All references to codes, standards, specifications, and construction drawings refer to the latest editions (and any supplements) in effect on the date of the contract.

B. Applicable Publications - The publications listed below form a part of this specification to the extent referenced. The publications are referenced to in the text by basic designation only.

1. CODE OF FEDERAL REGULATIONS (CFR):

a. OSHA General Industry Safety and Health Standards (29 CFR 1910), OSHA

Construction Industry Standards (29 CFR 1926). OSHA 2202 is a condensed version of

Summary of Work 01 11 00 - 3

29 CFR 1926. Each is for sale by the Superintendent of Documents, U.S. Government Printing Office, Washington DC 20402.

b. National Emission Standards for Hazardous Air Pollutants (40 CFR, Part 61).

2. FEDERAL STANDARD:

a. Preparation and the Submission of 313A Material Safety Data Sheets.

1.3 DEFINITIONS

A. Federal Aviation Administration (FAA) - The terms "Federal Aviation Administration" (FAA) and "Government" as used herein denotes the "owner"

B. Contracting Officer (CO) - The term "Contracting Officer" (CO) as used herein denotes the person designated to act for the Government in the performance of this contract.

C. Contracting Officers Representative (COR) - The term "Contracting Officers Representative" (COR) as used herein denotes the representative of the Contracting Officer at the job site. The COR’s authority is limited. These limitations are defined in the Letter of Delegation provided to the COR and the Contractor at the preconstruction meeting.

D. Contractor and Subcontractor - The term "Contractor" as used herein denotes the firm retained by the FAA to perform and complete work required by the Contract. The term "subcontractor" as used herein denotes the person or firm retained by the Contractor to perform a particular unit of work required by the Contractor. Subcontractors shall be required to meet all specifications required of the Contractor.

E. Furnished Material - The term "furnished material" (GFM) as used herein denotes all

Government Furnished Equipment (GFE) and material furnished by the Federal Aviation Administration. Any and all material not listed as “Furnished” shall be supplied by the Contractor. Furnished material is listed in Section 01 11 00, Part 3.3.

1.4 GOVERNMENT FURNISHED EQUIPMENT AND MATERIAL (GFE & GFM)

Not Applicable

1.5 CONSTRUCTION CONDITIONS

A. Preconstruction Conference - The Contractor shall attend a preconstruction conference at the time and location specified by the CO. Local procedures related to ingress, egress and security will be discussed. Requirements for material disposal, security and safety will be discussed.

Compliance with these procedures while on site is mandatory.

B. Conflict Resolution - The Contractor shall meet standards, specifications, and drawings as specified herein. The specifications and drawings will rule in all cases. Specifications will govern over drawings. In the event of dimensional discrepancies or omissions, the Contractor shall field verify and correct the information, and the COR shall render an interpretation and decision.

C. Inspection

Summary of Work 01 11 00 - 4

1. Access for Inspection - The Contractor shall allow the COR complete access to all portions of the work. Portions of the work buried, enclosed, or disguised, will be inspected by the COR before being obscured by the next operation of the Contractor. In all cases, the COR shall be informed accordingly and given access to the work. Work obscured before inspection and acceptance by the COR, may, at the option of the COR be opened for inspection at no additional cost to FAA.

2. Joint Acceptance Inspection - The COR shall inspect all work after substantial completion including all materials, tools, and equipment. Such inspection may extend to all or a part of the work for the preparation, fabrication or manufacture of the materials to be used. The COR shall notify the Contractor of any non-compliance with the contract specifications and/or drawings, and may reject workmanship or materials accordingly. After the COR reviews the contract documents and verify the Contractor has completed all required work, a Joint Acceptance Inspection (JAI), which is a FAA internal approval process, will be held.

D. Existing Utilities - Subsurface utilities and cables, whose existence is known to FAA, are shown on the contract drawings in approximate locations. Other utilities may not be shown on the contract drawings. The Contractor shall ring out and mark the existing power and control cable runs prior to any construction activities so as to maintain clearances from underground cables during construction. The Contractor shall field verify the location of underground utilities before excavating cable trenches and concrete foundations. This will be accomplished, in part, by coordinating with the FAA and the COR.

1. Hand Excavation - Hand excavation methods will be used in locating all existing utilities.

Any damage caused by the Contractor will be repaired immediately by the Contractor at no additional cost to FAA. Repairs, if required, will be in accordance with the specifications and conditions stipulated by the COR.

E. Project Coordination - The Contractor shall be required to coordinate construction activities with the FAA through the COR. All work, which affects Facilities and Equipment, shall be coordinated and approved by FAA personnel through the COR twenty-one (21) days in advance of the scheduled work. Failure to notify and obtain the necessary approval may result in a rescheduling of the work. If weather conditions or operations preclude a scheduled shutdown of the FAA facility, the Contractor shall reschedule the work. The Contractor shall be required to coordinate all power shutdowns of existing facilities with the FAA, through the COR, twenty-one (21) days in advance. Each shutdown for testing or cut-overs will be limited to off-peak hours, with the facility placed back in service at the end of the workday or as stipulated by the FAA. The Contractor shall not be allowed any extension of time or compensation for lack of compliance with this requirement.

F. Layout of Work - The Contractor shall field verify measurements and work from the established base lines and bench marks indicated on the drawings and will be responsible for all measurements in connection therewith. The Contractor will furnish, at his/her own expense, all templates, equipment, tools, materials, and labor as may be required in laying out any part of the work.

G. Permits, Inspection, Licenses, Certificates - The Contractor shall obtain and pay fees for permits, licenses, or certificates required by Federal, State and City/Town officials as necessary to perform the work, prior to starting construction, and in a timely manner to avoid delays in

Summary of Work 01 11 00 - 5 starting the job. The Contractor will abide by all requirements dictated by the municipality for such permits without any additional cost.

H. Compliance with Local and Other Codes - The Contractor shall comply with codes and standards, such as the National Electric Code, latest edition or local code. Where the requirements of the specifications and drawings exceed those codes, the Contractor shall comply with the requirements of the specifications and drawings.

I. Temporary Facility - The Contractor shall provide and pay for all temporary services and facilities as specified below and as necessary for the proper and expeditious execution of the work. The Contractor shall make, or have made all connections to existing services and sources of supply as necessary and/or indicated and pay all charges for same. The Contractor shall remove all such temporary installations and connections when no longer necessary for the project work.

1. Temporary Water - The Contractor shall make arrangements to furnish a potable water supply for workers and project work, and pay for all temporary water and services, in accordance with OSHA requirements.

2. Temporary Toilets and Sanitation - The Contractor shall provide ample and suitable on-site sanitary conveniences with proper enclosures for the use of the workers and other personnel employed at the site, in accordance with OSHA requirements. Locations will be subject to approval from the COR. After completion of the work, such conveniences will be promptly removed from the site.

3. Temporary Light and Power - The Contractor shall arrange for, provide and maintain all temporary electric light and power as required throughout the work. The Contractor shall pay all costs for the installation and use of such temporary light and power.

a. The Contractor shall furnish, install, connect and maintain all the wiring, sockets, lamps, receptacles, switches, feeders, circuit work, etc. necessary to provide temporary artificial illumination and power as required for the performance of all work covered by these specifications or which may be required for safety and for inspection purposes.

Contractor shall provide all power unless coordinated and approved by the FAA and COR that the contractor may use onsite available receptacles.

K. Protection of Existing Vegetation, Improvements and Structures - The Contractor shall take all precautions necessary to protect the existing facilities, equipment, buildings, foundations, vegetation, etc., during construction. Any areas damaged by the Contractor or any subcontractors, will be repaired or replaced to their original conditions by the Contractor at no additional cost to FAA. Repairs will be approved by the COR and will match to original finish.

The Contractor shall provide all temporary covers, enclosures, barricades, etc., required to protect the existing facilities.

L. Schedules

1. Project Schedule - The Contractor shall, within ten (10) calendar days from date of award of contract, submit to the CO for approval a practical project schedule. The schedule will show the order in which the Contractor proposes to carry out the work, the date on which he/she

Summary of Work 01 11 00 - 6 shall start the several salient features (including procurement of materials, plant and equipment), night work required including cutovers, and the contemplated dates for completing the work. The schedule shall be in the form of a progress chart of suitable scale to indicate the approximate percentage of work scheduled for completion at any time. The Contractor shall enter on the chart the actual progress at such intervals as directed by the CO.

The project schedule shall include milestone schedule for payments. The milestones should be stated with requested reimbursement for each milestone (based upon actual costs, overhead and profit).

2. Progress Schedule - The Contractor, if requested by the CO, shall submit a progress schedule at such intervals as directed by the CO. If the Contractor fails to submit a progress schedule within three (3) business days, the CO may withhold approval of progress payment estimates until the Contractor submits the required progress schedule.

3. Hours of Work - Unless otherwise approved by the COR, all work shall be based on a standard 8 - hour workday unless longer hours have been approved and accomplished between the hours of 6:00 a.m. to 5:00 p.m. daily, except weekends and Federal holidays. No work is allowed on weekends and Federal holidays unless approved by the CO in writing.

M. Site Access – Access to the site will be via a pre-determined route identified and agreed upon at the preconstruction conference. The Site is not located in a restricted area, no badging is required.

N. Special Site Conditions – N/A

O. Equipment and Waste Disposal - The Contractor shall provide on-site covered containers for the collection of construction waste materials, debris and rubbish and periodically remove the aforementioned materials from the site. Any spillage on access and haul routes will be cleaned up immediately. Disposal location to be determined by the Contractor and approved by the COR. All equipment, materials, spoil, waste and debris removed from the work site and not specified for reuse or identified as salvageable items, or identified as contaminated contents will be disposed of off site in areas authorized by the applicable County, State and/or Local agencies and in accordance with current rules and regulations governing the disposal of such waste. The Contractor will pay disposal fees and miscellaneous charges. Copies of all documentations of the disposal of any hazardous wastes will be submitted in accordance with Section 01 35 43.13.

P. Cleanup - The work site shall be kept clean and orderly during the progress of work.

Q. Final Cleaning - After final inspection, but before final acceptance of the work, all exterior surfaces of the equipment will be cleaned. All debris will be removed from the general site area.

1.6 Sequence of Work

The Contractor shall be required to submit detailed sequence of work for demolition of the facility. The plans shall limit any impact to the Airport and personnel. The plans will describe, in detail, all preparatory work, and estimated time required for each event listed in the plans. A list of equipment and quantity and type of personnel will be attached.

Summary of Work 01 11 00 - 7

1.7 SAFETY

OSHA and FAA safety standards will be enforced. In keeping with such standards, the Contractor shall, at a minimum, provide:

A. Safety Plan - The Contractor shall have a Safety Plan with the purpose of maintaining a safe working environment for construction workers employed on site. Two (2) copies of the plan shall be submitted to the CO for review and approval. As a minimum, the safety plan shall require weekly "tailgate" meetings, scheduled inspections of equipment which check for potential hazards created by wear, damages, etc. and a statement that the current Occupation Safety and Health Act (OSHA) regulations on safety in the construction industry, OSHA Title 29, Part 1910 and Part 1926, as well as FAA safety regulations, are followed. The plan will be used by the COR, who is OSHA trained, to insure that the work is accomplished in accordance with accepted safety practices.

B. First Aid and CPR - At least one (1) employee shall have a current certification in First Aid and

Cardio-Pulmonary Resuscitation (CPR) and be on the site at all times. Such employee shall be designated to provide first response medical treatment to site personnel in the event of an accident or other medical emergency. The employee shall not be permitted to work on live electrical circuits or be placed in any other situation, which may endanger or interfere in their ability to provide medical treatment.

C. Trained Personnel - Personnel shall be properly trained in the usage of all equipment for which they will be required to use during the Contract. Documentation or other evidence of training may be requested by the COR at any time. Personnel without adequate training will be prohibited from using such equipment.

D. Material Safety Data Sheets - The Contractor shall have Material Safety Data Sheets (MSDS) conforming to Federal Standard 313A, written by the manufacturer, for all materials containing chemicals or other substances which may pose a hazard. One (1) copy of each MSDS will be submitted to the CO and one (1) copy of each MSDS will be kept on file at the job site at all times. The Contractor and subcontractors shall be prohibited from handling any material, which does not have an applicable MSDS on file at the site until such MSDS arrives on site.

E. Safety Equipment - The Contractor shall provide safety equipment including, but not limited to, a Red Cross approved First-Aid kit and the appropriate number of annually inspected, charged, fire extinguishers with the proper NFPA rating.

F. HAZCOM Program - The Contractor shall have a hazard communications (HAZCOM) program.

The Contractor and each subcontractor shall submit a copy of their HAZCOM program as well as a copy of their current OSHA 200 form, if requested.

G. Designated Foreman - When any construction activity is conducted at the site, the presence of a designated, competent, badged contractor’s foreman is required at the job site. The foreman must be qualified and capable of organizing and coordinating all activities of the Contractor and his subcontractors, and keeping a safe job site.

H. Work Force - The Contractor shall at all times, when construction activities are conducted, have a substantial number of workers for each task to proceed expeditiously and without generating delay, for lack of man-power.

Summary of Work 01 11 00 - 8

PART 2 - MATERIALS AND EQUIPMENT

2.1 FAA/GOVERNMENT-FURNISHED EQUIPMENT/MATERIAL

Not Applicable

2.2 CONTRACTOR-FURNISHED MATERIAL AND EQUIPMENT

A. Material Deliveries - All material deliveries made under this contract shall be arranged for delivery to the Contractor's material staging area. This area shall be located as determined at the preconstruction conference. Delivery vehicles shall be directed to the material staging area.

B. Storage and Protection - The Contractor, through the COR, shall secure from FAA all necessary clearances for storage areas on site, including any time limitations upon the use of such areas.

The storage and protection of Contractor material will be the sole responsibility of the Contractor. The Contractor shall provide at his/her own expense all fencing, shelters and security personnel as may be necessary for the protection of the material and equipment.

PART 3 - EXECUTION

3.1 WORK SEQUENCE

A. Work shall be performed in the following sequence:

1. FAA shall provide the Contractor with all necessary shop drawings, product data, and samples for all Government furnished equipment.

2. The Contractor shall submit all required product information, shop drawings, and samples as required in the specifications. Protective device time current characteristic curves will be those for the equipment being furnished. Alternate protective devices will be submitted for approval.

3. The Contractor is responsible for handling, storing, and installing all furnished and non-furnished equipment.

4. Upon completion of demolition the contractor shall clean the affected area and repair any damage caused due to construction. A final walk through will be performed with the COR to insure a satisfactory end result.

3.2 CONTRACTOR USE OF PREMISES

A. General - During the construction period the Contractor shall have full use of the premises for construction operations, including use of the site. The Contractor's use of the premises is limited only by the Government’s right to perform work or to retain other contractors on portions of the Project.

B. Use of the Site - Limit use of the premises to work in areas indicated. Confine operations to areas within contract limits indicated. Do not disturb portions of the site beyond the areas in which the Work is indicated.

Summary of Work 01 11 00 - 9

1. Driveways and Entrances: Keep driveways and entrances serving the premises clear and available to the Government, the Government's employees, and emergency vehicles at all times. Do not use these areas for parking or storage of materials. Schedule deliveries to minimize space and time requirements for storage of materials and equipment on-site.

3.3 GOVERNMENT-FURNISHED EQUIPMENT / MATERIAL- Not Applicable

Summary of Work 01 11 00 - 10

Excess Property:

Upon completion of all work under these specifications, the Contractor, together with the COR, shall list the excess Government material in the space provided below. Both the Contractor and the COR shall certify the quantity of excess material listed. In addition, the Contractor shall perform the following with respect to residual furnished material:

Item # Item Description Quantity Received Remarks

CERTIFICATION OF EXCESS MATERIAL

The undersigned hereby acknowledge transfer of excess materials in the quantities and condition noted:

COR/CO_________________________________ _________________________

SIGNATURE DATE TRANSFERRED

CONTRACTOR__________________________ ________________________

SIGNATURE DATE RECEIVED

END OF SECTION 01 11 00

SUBMITTAL PROCEDURES 01 33 00 - 1

SECTION 01 33 00 - SUBMITTAL PROCEDURES

PART 1 - GENERAL

1.1 GENERAL

A. Samples, certificates, reports, catalog cuts, letters, shop drawings, etc. required under this specification shall be submitted to the CO and/or Project Engineer. All products specified herein to meet certain published specifications shall have clarifications submitted which state compliance with such specifications. The Contractor shall provide a minimum of ten (10) business days for FAA to review the submittals, unless otherwise noted in the specifications.

Rejection of submittals shall not be grounds for claims by the Contractor.

1.2 SUBMITTAL PROCEDURE

A. Three (3) complete sets (to include one reproducible) of all shop drawings and/or product data shall be submitted by the Contractor to the CO. Two sets will be marked and returned to the Contractor by the Project Engineer, with the approval status noted.

B. All submittals shall be accompanied by transmittal letters identifying the contents of the submittal. Transmittal letters shall consist of one original and one copy.

C. Work requiring an approved submittal shall not be initiated prior to approval of that submittal.

D. Submittals from subcontractors shall be reviewed and approved by the Contractor and coordinated with any other work involved before they are transmitted for review. Submittals shall be complete and detailed, and assembled in sets. Incomplete or inadequate descriptions will not be approved.

1.3 SUBMITTAL APPROVAL

A. Approved As Submitted - If “Approved As Submitted” is marked by the Project Engineer, each copy of the submittal will be identified as having received such approval by being stamped (or annotated) and dated. After submittals have been approved, no changes or substitutions will be permitted without written approval by the Project Engineer.

B. Approved As Noted - If “Approved As Noted” is marked by the Project Engineer, the submittal is satisfactory contingent upon the Contractor’s acceptance of comments and notations. If accepted, resubmittal is not required.

C. Not Approved - If “Not Approved” is marked by the Project Engineer, the submittal does not meet job requirements and the Contractor must resubmit. If submittal is disapproved, the Contractor shall resubmit the corrected material in the same quantity as specified for the original submittal.

1.4 SUBSTITUTE MATERIAL

The Contractor may submit for approval material other than that specified if it meets the following:

A. Meets or exceeds the specifications as determined by the FAA.

B. Material is available on a timely basis.

C. Substitution of a material shall not obligate the FAA for additional costs which may be associated with furnishing and installing the substitute material. Substitution submissions shall be clearly marked as such and shall meet the requirements of paragraph 2.1, Submittals. The

SUBMITTAL PROCEDURES 01 33 00 - 2

Contractor shall allow ten (10) business days from date of receipt by the Project Engineer for substitute submission approval.

END OF SECTION 01 33 00

Hazardous Materials 01 35 43.13 - 1

SECTION 01 35 43.13 - ENVIRONMENTAL PROCEDURES FOR HAZARDOUS MATERIALS

PART 1 - GENERAL

1.1 DESCRIPTION OF WORK

A. General: This section details what is known about specific hazardous materials that might be affected by the work as described in the attached plans and drawings. It includes warnings to the General Contractor and his subcontractors, and general rules on how to perform the work and protect workers and the environment.

B. This section covers work with Lead based paint (LBP) and other hazard-containing materials. Any other hazardous material suspected of being present at the site should be brought to the attention of the COR.

C. It is the responsibility of the Contractor to remove the material with Care: Cutting and sawing on painted surfaces shall be done under lead abatement conditions. All materials containing LBP shall be disposed of in accordance with all applicable Federal, State and Local regulations. If materials are to be recycled, a receipt from the recycling facility shall be submitted to the COR. The Contractor shall be responsible for securing and paying for:

1. Labor, materials and equipment;

2. Other facilities and services necessary for proper execution and completion of the work;

3. All permits, government fees and/or notifications, as required by Federal, State, and local regulations.

4. Any required employee training (e.g. - supervisor and worker, lead awareness, respiratory protection program, etc.) and/or monitoring (e.g. - medical, employee exposure, etc.);

5. Clearance testing;

6. Waste disposal permits and testing, and associated disposal costs; and

7. Providing submittals to the COR prior to the commencement of work.

1.2 DEFINITIONS

A. Abatement: Procedures to control fiber or dust release from asbestos or lead-containing materials, or other hazardous materials. Includes removal, encapsulation, enclosure, repair, demolition, disposal and renovation activities.

B. Clearance Air Monitoring: The processes of measuring the concentrations of airborne contaminants to determine if an abated area is sufficiently clean to allow reoccupancy.

C. Competent Person: A person who is capable of identifying existing ACM or LBP hazards in the workplace. The duties of the Competent Person include the performance or supervision of the following:

establishing the negative-pressure enclosure, ensuring its integrity, and controlling entry and exit from the enclosures; supervising any employee exposure monitoring required by the OSHA standards; ensuring that all employees in the work area wear the appropriate personal protective equipment and are trained in the use of appropriate methods of exposure control and the use the hygiene facilities. The Competent Person shall also be trained in the contents of OSHA regulations 29 CFR 1926.1101 and 29 CFR 1926.62; and other practices for reducing the hazards.

D. Eight-Hour Time Weighted Average (TWA): Airborne concentration of a contaminant averaged over an 8-hour workday to which an employee is exposed.

E. Hazardous Materials Abatement Subcontractor: The individual and/or business performing the Hazardous Materials Abatement. The Subcontractor is responsible for the proper completion of project activities in accordance with all Federal, State and local regulations, and FAA guidelines.

Hazardous Materials 01 35 43.13 - 2

F. Permissible Exposure Limit (PEL): An airborne concentration of asbestos fibers (longer than

5 micrometers) of 0.1 fibers per cubic centimeter (f/cc) calculated as an eight (8) hour time-weighted average (TWA). For lead, the PEL is 50 micrograms per cubic meter (g/m3 ).

G. TSDF: An EPA and/or State approved Treatment, Storage, and Disposal Facility for hazardous materials.

H. Visible Debris: Any particulate material or residue that is visually detectable on a surface without the aid of instruments.

I. Asbestos: The minerals amosite, chrysolite, crocidolite, actinolite, anthophyllite and tremolite.

J. Asbestos-Containing Material (ACM): Material composed of asbestos of any type in an amount greater than 1 percent by weight.

K. Friable Asbestos: ACM that, when dry, may be easily crumbled, pulverized, or reduced to powder by hand pressure; includes previously non-friable material after it has become damaged to the extent that when dry, it may be crumbled, pulverized, or reduced to powder by hand pressure.

1.3 APPLICABLE PUBLICATIONS

A. The publications listed below form a part of this specification to the extent referenced. The publications are referred to in the text by basic designation only.

1. CODE OF FEDERAL REGULATIONS (CFR):

a. OSHA General Industry Safety and Health Standards (29 CFR 1910), and OSHA 1910.120, Hazardous Waste Operations

b. OSHA Construction Industry Standards (29 CFR 1926), including but not limited to, the following:

(1) CFR 1926.62: Lead

(2) CFR 1926.1101: Asbestos

(3) OSHA: Flooring Industry Settlement Agreement (asbestos, 6/15/95)

(4) OSHA: Roofing Industry Settlement Agreement (asbestos, 3/15/95)

c. National Emission Standards for Hazardous Air Pollutants (40 CFR, Part 61)

d. EPA Resource Conservation and Recovery Act (40 CFR Parts 260 through 271)

e. Department of Transportation (DOT) 49 CFR Part 173 and Part 178

2. FEDERAL STANDARD

a. 313: Material Safety Data Sheets, Preparation and Submission

1.4 RELATED DOCUMENTS

A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and Division 1 Specification Sections apply to this Section.

1.5 SUBMITTALS

A. General: Submittals shall be in conformance with Section 01 33 00. Submit the following:

1. Product data and MSDS where applicable, for the following:

a. Materials to be used for LBP abatement, including LBP removal chemicals, encapsulants, washing solutions, neutralizers, etc.

2. Transportation and disposal facilities to be used for hazardous materials.

Hazardous Materials 01 35 43.13 - 3

3. Permits and Notifications: When hazardous materials are disposed, the Contractor shall submit copies of permits and manifests from applicable Federal, State, and local authorities, and necessary certificates to document that the material(s) has (have) been disposed of as per regulations and Contract Specifications.

4. Plan of Action: A detailed site-specific plan of action for handling hazardous materials including, but not limited to, LBP must be submitted. The hazardous materials plan of action shall contain the following:

a. Identification of possible hazards, problems, and proposed control mechanisms.

b. Description of how applicable safety and health regulations and standards are to be met.

c. Protection of public or others not related to the operation.

d. List of names of employees to be used for the work, including specialized training, licenses and experience.

e. Type of protective equipment and work procedures to be used.

f. Material Safety Data Sheets (MSDS) for and procedures for using, disposing of, or storing toxic/hazardous materials (See also 29 CFR 1910.1200 and 1926.59).

g. Emergency procedures for accidental spills or exposures.

h. Interfacing and control of subcontractors, if applicable.

i. Identifications of any required analyses, test demonstrations, and validation requirements.

j. Methods of certification for compliance.

5. Results of monitoring, clearance tests, and laboratory tests.

PART 2 - PRODUCTS

2.1 MATERIALS AND EQUIPMENT

A. Special facilities, devices, equipment, clothing, and similar items used by the Contractor in the execution of the work shall comply with all applicable Federal, State, and local regulations.

2.2 MATERIAL SAFETY DATA SHEETS (MSDS)

A. MSDS shall be available for all products used under this contract. The Contractor shall be responsible for meeting the hazard communication requirements, in accordance with 29 CFR 1910.1200 and

29 CFR 1926.59.

PART 3 - EXECUTION

3.1 OTHER ASBESTOS-CONTAINING AND HAZARDOUS MATERIALS

A. If any other suspected hazardous material is encountered during the work, the information shall be immediately transmitted to the COR. The work in the impacted area shall be stopped and contained immediately pending appropriate consultation with the Owner. After consultation with the Owner, the CO will direct the Contractor through the COR as to what further actions are to be taken.

END OF SECTION 01 35 43.13

Demolition 02 41 00 - 1

SECTION 02 41 00 - DEMOLITION

PART 1 - GENERAL

1.1 SUMMARY: This section specifies removal, disposal, storage and salvage of existing materials, equipment and fixtures.

1.2 APPLICABLE DOCUMENTS: N/A

1.3 CONSTRUCTION CONDITIONS: It is the contractor’s responsibility to bring the site back to its original condition as stated in the scope of work found in section 01 11 00 of this specification.

Contractor must coordinate all efforts and submit demolition plans to the COR for approval.

PART 2 - MATERIALS AND EQUIPMENT

2.1 MATERIALS

A. Removal of any government property from the facility shall be at the expressed direction of the FAA

B. Title to removed property: Materials and equipment to be removed and salvaged shall remain the property of the FAA. Materials and equipment to be removed and disposed of shall become the property of the contractor.

C. Contractor shall relocate/dispose of equipment from the facility per governing regulations.

2.2 EQUIPMENT TO BE REMOVED

A. The following list of existing material and equipment shall be removed. Equipment and material includes, but is not limited to:

1. NDB antennae found onsite, and Metal foundation.

2. OM shelter and concrete entrance pad.

3. Power meter enclosure and associated conduit and cabling.

4. OM Antennae and associated foundation

5. Chain link Fence fabric, barbed wire, gate, and fence posts.

6. Any associated equipment or materials inside the OM plot unless otherwise identified by the FAA.

PART 3 - EXECUTION

3.1 PERSONNEL PROTECTION: Erect and maintain, as required by conditions and progress of the work, all necessary safeguards for safety and protection of employees, and FAA personnel working within the facility. Safeguards shall include railings, partitions, polyethylene dust enclosures, lighting, posting of danger signs and other warnings against hazards. Take such steps as necessary to minimize dust pollution during the demolition operations. Critical equipment is located in the working vicinity; polyethylene dust enclosures must be established before and during the working period.

3.2 GENERAL

Demolition 02 41 00 - 2

A. All materials, equipment and fixtures to be removed and salvaged shall be removed with care, stored and protected.

B. Each item of equipment indicated to be removed and salvaged shall be removed as a unit;

listed, indexed, and tagged for storage.

C. Each unit shall be removed with the auxiliary equipment required for normal operation of the unit, except when multiple units have common auxiliary equipment that is required for continuous operation of the units left in place.

D. Do not commence demolition until all equipment is de-energized and clearance given by

COR.

E. The sequence of area demolitions shall be scheduled, with respect to performance of new finishing. Schedule the demolition work in such a way as to ensure against disruption of systems and services essential to the operation of the facility, prolonged inconvenience to personnel, and in relation to preceding and succeeding construction activities. Follow the sequence of work in specification 01 11 00 Summary of Work.

F. Construction materials i.e.