B01_Synopsis_of_Proposed_Contract_Action_2.docx
DOCX document 18 KB Posted
- Attached to
- BADL REHAB PROPANE DISTRIBUTION LINES Federal contract opportunity
- Solicitation number
- 140P6326B0003
About this file
This is a Pre-Solicitation Notice for construction services to rehabilitate propane distribution lines at Badlands National Park in Interior, South Dakota. The National Park Service Contracting Operations Central, Nekota Major Acquisition Buying Office, will conduct this acquisition using an Invitation for Bids (IFB) sealed bid process under solicitation number 140P6326B0003. The scope of work includes removal of existing propane piping and installation of approximately 3,080 linear feet of new propane distribution piping, 1,980 linear feet of propane service piping (330 linear feet via horizontal directional drilling), shutoff valves, cleanout of two culverts, 560 cubic yards of channel excavation hauled to a government-provided disposal site, and 285 cubic yards of fill material for an earthen berm. The contract will be firm-fixed price with a 90-calendar-day period of performance from the Notice to Proceed, inclusive of supply lead times, material deliveries, installation, weather contingencies, and final commissioning.
This acquisition is classified under NAICS code 237120 (Oil and gas pipeline and related structures construction) with a $45 million small business size standard and is set aside for 100% Total Small Business participation. Construction Wage Rate Requirements for Jackson County apply. The formal solicitation is expected to be issued on or about February 25, 2026, with responses due approximately 30 days thereafter, anticipated close on March 25, 2026. Award is expected in Spring 2026. Prospective offerors must possess an UEI number, maintain active registration and completed Online Representations and Certifications in the System for Award Management (SAM.GOV) by the solicitation close date. All specifications and drawings will be provided with the formal solicitation. The Contracting Officer is Joseph Kirk at joseph_kirk@nps.gov or 605.574.0510.
View the file
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
PRE-SOLICITATION NOTICE:
The National Park Service Contracting Operations (ConOps) Central, Nekota Major Acquisition Buying Office, is issuing an Invitation for Bid for construction services to Rehab Propane Lines located at Badlands National Park, Interior, South Dakota. The acquisition will be conducted using Invitation for Bids (IFB)/Sealed Bid process.
SOLICITATION NUMBER: 140P6326B0003
Project Description:.
Work consists of removal of existing propane piping and construction of approximately 3,080 LF of new propane distribution piping, 1,980 LF of propane service piping, 330 LF of which shall be installed by horizontal directional drilling, shutoff valves, cleanout of two culverts, 560 CY of channel excavation to be hauled to a park-provided soil waste disposal site, and 285 CY of haul-on material for construction of an earthen berm.
All specifications documents/drawings will be provided if/when the government proceeds with a formal solicitation.
Period of Performance:
Work shall be completed within 90 calendar days of the start date provided on the Notice to Proceed.
The Notice to Proceed will be issued with a period of performance that is all inclusive of supply lead times, material deliveries, decommissioning, installation, anticipated average weather days for location, final commissioning, and acceptance of completed work. The contractor will be expected to provide a project schedule with adequate critical path details to ensure all work is completed within the stated calendar days from issuance of the Notice to Proceed. If there are weather related environmental factors affecting the construction period where unexpected adverse weather conditions may delay progress, the Contracting Officer will work the Contractor to adjust the Period of Performance at no additional cost to the Government.
TYPE OF CONTRACT: This will be a firm-fixed price contract expected to be awarded to a prime contractor in Spring 2026. Construction Wage Rate Requirements for Jackson County will apply.
NAICS CODE CLASSIFICATION: 237120 Oil and gas pipeline and related structures construction. The small business size standard is $45 million.
SMALL BUSINESS ECONOMIC SET ASIDE: This project is set aside for 100% Total Small Business
SITE VISIT: Information will be available on the solicitation when it is posted on SAM.GOV.
The contracting office will not provide hardcopies or email copies of the solicitation.
REGISTRATIONS: In order to be awarded a contract, an offeror must have an UEI number. Also, the offeror must be registered and active in the System for Award Management (SAM), website at http://www.sam.gov, and have completed their Online Representations and Certifications at the time of the solicitation close date once the solicitation is posted.
The government intends to issue a formal Solicitation with construction specifications on or about February 25, 2026. If this date is delayed, the solicitation will follow as soon as possible. This is the preliminary notice of a solicitation that will follow. The responses will be due approximately 30 days after the IFB issue date and it is anticipated close on March 25, 2026. The specific date and time will be announced in the solicitation that will follow this notice.
POINT OF CONTACT: Joseph Kirk, Contracting Officer, joseph_kirk@nps.gov, 605.574.0510.
File details come from the government source that posted it. Updated .