B.08.02 Solicitation.pdf

SEE ADDENDUM

(No Collect Calls)

W912EF20Q0067 01-May-2020

b. TELEPHONE NUMBER

509-527-7222

8. OFFER DUE DATE/LOCAL TIME

04:00 PM 15 May 2020

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W912EF9. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

RUTH A JOHNSON

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

0 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

USAED, WALLA WALLA - CONTRACTING DIV.

RUTH A. JOHNSON

201 N. THIRD AVENUE

WALLA WALLA WA 99362-1976

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE 16. ADMINISTERED BY

SEE SCHEDULE

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

509-527-7802FAX:

TEL: 509-527-7222 SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

NAICS:

212319

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF43

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

Section SF 1449 - CONTINUATION SHEET

INSTRUCTIONS TO OFFERORS

BIDDER INQUIRY:

Bidder/Offeror Solicitation Questions:

All inquiries regarding this solicitation are to be submitted via Bidder Inquiry. Telephone and email inquiries will not be accepted. Bidder Inquiry is a web-site that allows bidders to post questions regarding the solicitation and view all questions by other bidders and responses by USACE. Bidder Inquiry can be accessed through ProjNet at (https://www.projnet.org)

To submit and review inquiry items, prospective vendors will need to use the Bidder Inquiry Key presented below and follow the instructions listed below the key for access. A prospective vendor who submits a comment /question will receive an acknowledgement of the comment/question via email. Another email to the same address will notify the prospective vendor once the reply is available for viewing.

TIMING OF BIDDER INQUIRIES: Bidders are encouraged to submit their bidder inquiries promptly. The Government will make every effort to answer all bidder inquiries; however, the closer to the solicitation due date an inquiry is received, the less likely it is that a timely response can be provided.

The Bidder Inquiry Key is: EUUK3H-TQG9Z3

Specific Instructions for ProjNet Bid Inquiry Access:

1. From the ProjNet home page linked above, click on Quick Add on the upper right side of the screen.

2. Identify the Agency. This should be marked as USACE.

3. Key. Enter the Bidder Inquiry Key listed above.

4. Email. Enter the email address you would like to use for communication.

5. Click Continue. A page will then open saying that a user account was not found and will ask you to create one using the provided form.

6. Enter your First Name, Last Name, Company, City, State, Phone, Email, Secret Question, Secret Answer, and Time Zone. Make sure to remember your Secret Question and Answer as they will be use from this point on to access the ProjNet system.

7. Click Add User. Once this is completed you are now registered within ProjNet and are currently logged into the system.

Instructions for Entering Questions:

1. After you are logged in click on the "post new inquiry", it is on the left side of the window under the Word "Submit" a.) This is the window where you will enter your questions b.) Comment Classification: Click on the down arrow to the right of the words “Please select from below”, select “Public” c.) Discipline: This is where you select who this question should be directed to. Example; if the question is about an electrical drawing or specification select: “Electrical” from the pull down list.

d.) Sheet. Enter the sheet number of the drawing you are asking about.

e.) Detail. Enter the detail name of the detail shown on the drawing that you are asking about.

f.) Specification. Enter the Specification number and paragraph number.

g.) File. Use this if you are going to attacha pdf file.

h.) Question. Enter your question here.

Specific Instructions for Future ProjNet Bid Inquiry Access:

1. For future access to ProjNet, you will not be provided any type of password. You will utilize your Secret Question and Secret Answer to log in.

2. From the ProjNet home page linked above, click on Quick Add on the upper right side of the screen.

3. Identify the Agency. This should be marked as USACE.

4. Key. Enter the Bidder Inquiry Key listed above.

5. Email. Enter the email address you used to register previously in ProjNet.

6. Click Continue. A page will then open asking you to enter the answer to your Secret Question.

7. Enter your Secret Answer and click Login. Once this is completed you are now logged into the system.

For questions about the ProjNet Bidder Inquiry, please contact the Call Center help desk toll free at 1-800-428- HELP, which operates from 8AM to 5PM (Central US time zone). Bidder inquiry help questions can also be emailed to the helpdesk at staff@projnet.info

Offerors are cautioned to clearly print prices for all line items. Be especially careful placing decimal points, as a mistake in your offer may render it unresponsive. Your quote must be valid for 30 calendar days after the due date specified for receipt of quotations. Please include shipping costs in the quoted price of each item.

Registration at www.sam.gov is required. If not registered, please do so. Step-by-step help information on how to register is detailed on the website, along with frequently asked questions (FAQs). Lack of registration in the SAM database may make an offeror ineligible for award.

Effective 29 April 2018, the notarized letter process is now mandatory on all CURRENT registrants at SAM who have a requirement to update data on their SAM record. The notarized letter is mandatory and is required in order for the GSA Federal Service Desk (FSD) to activate the entity's registration. Both Federal Assistance entities and all non-Federal entities must mail the original, signed copy of the notarized letter to the Federal Service Desk. Failure to do so within 30 days of activation may result in the registration no longer being active. Mail the completed, signed, notarized letter to:

FEDERAL SERVICE DESK

ATTN: SAM.GOV REGISTRATION PROCESSING

460 INDUSTRIAL BLVD

LONDON, KY 40741-7285

UNITED STATES OF AMERICA

Completion of the required FAR 52.212-3 Alt. I, Offeror Representations and Certifications – Commercial Items is required. When you complete your SAM registration, the link to complete your Reps and Certs is also available.

Please do not hesitate to contact me or the SAM web site if you need assistance or have questions.

In accordance with FAR 52.229.3, State and Local Taxes, and per Title 4 of the US Code 104-107, the Government is exempt from paying local and state taxes. Exempt Tax Identification Number 91-0828090.

General Contract Information:

Delivery Date________________________________________________

Offeror’s Name (Printed) _________________________________________

Offeror’s Contact Telephone Number_______________________________

Offeror’s Email Address___________________________________________

Federal Tax Identification No. ____________________________________________

CAGE Code __________________ DUNS No. ______________________________

Is your company registered on-line in SAM (www.sam.gov)? YES NO

To ensure receipt of your quote, please send to the attention of Ruth Johnson at:

Email: ruth.a.johnson@usace.army.mil

ADDENDUM TO FAR 52.212-1 INSTRUCTIONS TO OFFERORS – COMMERCIAL ITEMS

Submission of Price Quote – Contractor shall submit the following in 1 copy:

1. Signed and dated Standard Form 1449 (Solicitation / Contract / Order for Commercial Items).

2. Signed and dated Standard Form 30, if applicable, for any Amendments to the Solicitation

3. Completed schedule (pricing information) for all line items listed in the solicitation / amendments.

4. Completed Clause 52.212-3 and Alt I, “Offeror Representations and Certifications – Commercial Item’s” As noted above.

5. Verification of Equipment: a minimum of three tractor/trailer or truck/pup combinations capable of transporting 25 tons of riprap.

BASIS FOR AWARD

The Government will award one contract resulting from this solicitation in accordance with FAR 13.106 to the responsible offeror meeting or exceeding all solicitation requirements and representing the best value based on price.

Requirements Contract:

This contract is an indefinite delivery “Requirements” contract to supply riprap to the Jackson Hole Project, Jackson, Wyoming.

A requirements contract provides for filling all actual purchase requirements of a designated Government activity for supplies during a specified contract period (from one contractor) with deliveries or performance to be scheduled by placing task orders with the contractor. The quantities of services specified in the Price Schedules are estimates only and are not purchased by this contract; purchases are only made when the Government places task orders for specific requirements.

The Contractor shall perform no work under this contract unless a written task order, signed by the Contracting Officer, has been issued. The Contractor shall complete all items described in the technical specification for each task order within the performance period stated in the task order.

Task order quantities identified as “estimated” are subject to the Variation in Estimated Quantity clause of the contract. Payment for task orders will be based on the firm fixed unit price and actual quantities provided.

The contract performance period is one base year, which begins on the date of contract award. The Government may exercise up to four options to extend the contract period for up to four additional years of contract performance.

ORDERING PROCEDURES

Task Orders will be sent electronically to the Single Award Task Order Contract (SATOC) contractor when the Government has a requirement. Prices will be in accordance with the Price Schedule. The Task Order will detail delivery amount, delivery location, and delivery timeline.

PRICING SCHEDULE

Walla Walla District Corps of Engineers Jackson Hole Riprap

SCHEDULE A – BASE YEAR 2020 – 2021

Period of performance for Schedule A is 365 calendar days after date of contract award.

(Specific dates will be filled in upon contract award.)

ITEM

DESCRIPTION

QUANTITY

U/M

U/P

AMOUNT

0001 Gradation Testing 2 EA $________ $________

Furnish, deliver, and Stockpile Riprap to the following Sites.

0002 Main Stockpile Riprap Est.* 10,500 Ton $________ $________

0003 WYDOT Riprap Est.* 2000 Ton $________ $________

0004 Taylor Riprap Est. * 2000 Ton $________ $________

0005 Solitude Levee Riprap Est. * 1000 Ton $________ $________

0006 Imeson Levee Riprap Est. * 1500 Ton $________ $

0007 Surcharge Est.* 10,000 Ton $________ $________

SCHEDULE A TOTAL $________________

Est* = Estimated

Quantities identified as Estimated (“Est”) in the price schedule are subject to FAR Clause

52.211-18, VARIATION IN ESTIMATED QUANTITY.

OPTIONAL SCHEDULE B – 1st OPTION YEAR 2021 – 2022

1001 Gradation Testing 2 EA $________ $________

1002 Main Stockpile Riprap Est.* 10,500 Ton $________ $________

1003 WYDOT Riprap Est.* 2000 Ton $________ $________

1004 Taylor Riprap Est. * 2000 Ton $________ $________

1005 Solitude Levee Riprap Est. * 1000 Ton $________ $________

1006 Imeson Levee Riprap Est. * 1500 Ton $________ $

1007 Surcharge Est.* 10,000 Ton $________ $________

SCHEDULE B TOTAL $________________

Quantities identified as Estimated (“Est”) in the price schedule are subject to FAR Clause 52.211-18, VARIATION

IN ESTIMATED QUANTITY.

OPTIONAL SCHEDULE C – 2nd OPTION YEAR 2022 – 2023

2001 Gradation Testing 2 EA $________ $________

2002 Main Stockpile Riprap Est.* 10,500 Ton $________ $________

2003 WYDOT Riprap Est.* 2000 Ton $________ $________

2004 Taylor Riprap Est. * 2000 Ton $________ $________

2005 Solitude Levee Riprap Est. * 1000 Ton $________ $________

2006 Imeson Levee Riprap Est. * 1500 Ton $________ $

2007 Surcharge Est.* 10,000 Ton $________ $________

SCHEDULE C TOTAL $________________

Quantities identified as Estimated (“Est”) in the price schedule are subject to FAR Clause 52.211-18, VARIATION

OPTIONAL SCHEDULE D – 3rd OPTION YEAR 2023 – 2024

3001 Gradation Testing 2 EA $________ $________

3002 Main Stockpile Riprap Est.* 10,500 Ton $________ $________

3003 WYDOT Riprap Est.* 2000 Ton $________ $________

3004 Taylor Riprap Est. * 2000 Ton $________ $________

3005 Solitude Levee Riprap Est. * 1000 Ton $________ $________

3006 Imeson Levee Riprap Est. * 1500 Ton $________ $

3007 Surcharge Est.* 10,000 Ton $________ $________

SCHEDULE D TOTAL $________________

Quantities identified as Estimated (“Est”) in the price schedule are subject to FAR Clause 52.211-18, VARIATION

W912EF20Q0067

OPTIONAL SCHEDULE E – 4th OPTION YEAR 2024 – 2025

4001 Gradation Testing 2 EA $________ $________

4002 Main Stockpile Riprap Est.* 10,500 Ton $________ $________

4003 WYDOT Riprap Est.* 2000 Ton $________ $________

4004 Taylor Riprap Est. * 2000 Ton $________ $________

4005 Solitude Levee Riprap Est. * 1000 Ton $________ $________

4006 Imeson Levee Riprap Est. * 1500 Ton $________ $

4007 Surcharge Est.* 10,000 Ton $________ $________

SCHEDULE E TOTAL $________________

Quantities identified as Estimated (“Est”) in the price schedule are subject to FAR Clause

52.211-18, VARIATION IN ESTIMATED QUANTITY.

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

CLAUSES INCORPORATED BY REFERENCE

52.203-3 Gratuities APR 1984 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-16 Preventing Personal Conflicts of Interest DEC 2011 52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

APR 2014

52.203-18 Prohibition on Contracting With Entities That Require Certain Internal Confidentiality Agreements or Statements-- Representation

JAN 2017

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-7 System for Award Management OCT 2018 52.204-13 System for Award Management Maintenance OCT 2018 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.204-21 Basic Safeguarding of Covered Contractor Information

Systems

JUN 2016

52.204-22 Alternative Line Item Proposal JAN 2017 52.204-24 Representation Regarding Certain Telecommunications and

Video Surveillance Services or Equipment.

DEC 2019

52.204-26 Covered Telecommunications Equipment or Services-- Representation.

DEC 2019

52.209-7 Information Regarding Responsibility Matters OCT 2018 52.212-1 (Dev) Instructions to Offerors - Commercial Items. (DEVIATION

2018-O0018)

MAR 2020

52.212-4 Contract Terms and Conditions--Commercial Items OCT 2018 52.212-5 (Dev) Contract Terms and Conditions Required to Implement

Statutes or Executive Orders--Commercial Items (Deviation 2018-O0021)

MAR 2020

52.217-5 Evaluation Of Options JUL 1990 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.232-18 Availability Of Funds APR 1984 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.242-13 Bankruptcy JUL 1995 52.247-34 F.O.B. Destination NOV 1991 52.253-1 Computer Generated Forms JAN 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

DEC 2019

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.204-7017 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services -- Representation

DEC 2019

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services

DEC 2019

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By The Government of a Country that is a State Sponsor of Terrorism

MAY 2019

252.213-7000 Notice to Prospective Suppliers on Use of Supplier Performance Risk System in Past Performance Evaluations

SEP 2019

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7001 Buy American And Balance Of Payments Program-- Basic DEC 2017 252.225-7002 Qualifying Country Sources As Subcontractors DEC 2017 252.225-7012 Preference For Certain Domestic Commodities DEC 2017 252.225-7013 Duty-Free Entry--Basic MAY 2016 252.225-7048 Export-Controlled Items JUN 2013 252.226-7001 Utilization of Indian Organizations and Indian-Owned

Economic Enterprises, and Native Hawaiian Small Business Concerns

APR 2019

252.232-7010 Levies on Contract Payments DEC 2006 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.244-7000 Subcontracts for Commercial Items JUN 2013 252.247-7023 Transportation of Supplies by Sea FEB 2019

CLAUSES INCORPORATED BY FULL TEXT

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with CLAUSE: DEFAULT (FIXED-PRICE CONSTRUCTION) of the CONTRACT CLAUSES. In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. A weather delay day is any day when the maximum temperature does not exceed 32 degrees Fahrenheit or when 0.10 inch or more of precipitation occurs.

The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

Monthly Anticipated Adverse Weather Delay Work Days Based on (7) Day Work Week

Location Jan Feb Mar Apr May Jun Jul Aug Sep Oct Nov Dec Jackson Hole Wyoming

21 15 7 3 3 3 3 3 3 4 9 24

Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the

Contractor shall record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled workday. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number “Anticipated Adverse Weather Delay Work Days”, above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days and issue a modification in accordance with the CLAUSE: DEFAULT (FIXED PRICE CONSTRUCTION) of the CONTRACT CLAUSES.

(End of Clause)

52.209-2 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS--

REPRESENTATION (NOV 2015)

(a) Definitions. Inverted domestic corporation and subsidiary have the meaning given in the clause of this contract entitled Prohibition on Contracting with Inverted Domestic Corporations (52.209-10).

(b) Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation, unless the exception at 9.108-2(b) applies or the requirement is waived in accordance with the procedures at 9.108-4.

(c) Representation. The Offeror represents that--

(1) It [ ___ ] is, [ ___ ] is not an inverted domestic corporation; and

(2) It [ ___ ] is, [ ___ ] is not a subsidiary of an inverted domestic corporation.

(End of provision)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

52.209-11 REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A

FELONY CONVICTION UNDER ANY FEDERAL LAW (FEB 2016)

(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that--

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that--

(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (MAR 2020)

ALTERNATE I (OCT 2014)

The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically in the System for Award Management (SAM) accessed through https://www.sam.gov. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (v) of this provision.

(a) Definitions. As used in this provision--

“Covered telecommunications equipment or services” has the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Forced or indentured child labor” means all work or service—

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation,” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

“Sensitive technology”—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern, consistent with 13 CFR 124.1002,” means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans(as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern --

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127),” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

(b)

(1) Annual Representations and Certifications. Any changes provided by the Offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications in SAM.

(2) The offeror has completed the annual representations and certifications electronically in SAM accessed through http://www.sam.gov. After reviewing SAM information, the Offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications--Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard(s) applicable to the NAICS code(s) referenced for this solicitation), at the time this offer is submitted and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs __.

[Offeror to identify the applicable paragraphs at (c) through (v) of this provision that the offeror has completed for the purposes of this solicitation only, if any.

These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.]

(c) Offerors must complete the following representations when the resulting contract is to be performed in the United States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a small business concern.

(2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a veteran-owned small business concern.

(3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a service-disabled veteran-owned small business concern.

(4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.]The offeror represents that it [ ___ ] is, [ ___ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.]The offeror represents that it [ ___ ] is, [ ___ ] is not a women-owned small business concern.

Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold.

(6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that—

(i) It [ ___ ] is, [ ___ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: ___ .] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that—

(i) It [ ___ ] is, [ ___ ] is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: ___ .] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(8) Women-owned business concern (other than small business concern). [Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [ ___ ] is, a women-owned business concern.

(9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:

(10) HUBZone small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that--

(i) It [ ___ ] is, [ ___ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and

(ii) It [ ___ ] is, [ ___ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: ___ .] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(11) (Complete if the offeror has represented itself as disadvantaged in paragraph (c)(4) of this provision.)

[The offeror shall check the category in which its ownership falls]:

___ Black American.

___ Hispanic American.

___ Native American (American Indians, Eskimos, Aleuts, or Native Hawaiians).

___ Asian-Pacific American (persons with origins from Burma, Thailand, Malaysia, Indonesia, Singapore, Brunei, Japan, China, Taiwan, Laos, Cambodia (Kampuchea), Vietnam, Korea, The Philippines, Republic of Palau, Republic of the Marshall Islands, Federated States of Micronesia, the Commonwealth of the Northern Mariana Islands, Guam, Samoa, Macao, Hong Kong, Fiji, Tonga, Kiribati, Tuvalu, or Nauru).

___ Subcontinent Asian (Asian-Indian) American (persons with origins from India, Pakistan, Bangladesh, Sri Lanka, Bhutan, the Maldives Islands, or Nepal).

___ Individual/concern, other than one of the preceding.

(d) Representations required to implement provisions of Executive Order 11246 --

(1) Previous contracts and compliance. The offeror represents that --

(i) It [ ___ ] has, [ ___ ] has not, participated in a previous contract or subcontract subject to the Equal Opportunity clause of this solicitation; and

(ii) It [ ___ ] has, [ ___ ] has not, filed all required compliance reports.

(2) Affirmative Action Compliance. The offeror represents that --

(i) It [ ___ ] has developed and has on file, [ ___ ] has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 CFR parts 60-1 and 60-2), or

(ii) It [ ___ ] has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor.

(e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made.

(f) Buy American Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy American – Supplies, is included in this solicitation.)

(1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.” The terms “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American—Supplies.”

(2) Foreign End Products:

LINE ITEM NO. COUNTRY OF ORIGIN

[List as necessary]

(3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(g)

(1) Buy American -- Free Trade Agreements -- Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American -- Free Trade Agreements -- Israeli Trade Act, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms “Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product,” “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” “Free Trade Agreement country,” “Free Trade Agreement country end product,” “Israeli end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American--Free Trade Agreements--Israeli Trade Act.”

(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”:

Free Trade Agreement Country End Products (Other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:

LINE ITEM NO. COUNTRY OF ORIGIN

[List as necessary]

(iii) The…