B.08.02 Solicitation Document 21Q0024.pdf

REQUEST FOR QUOTATIONS

(THIS IS NOT AN ORDER) 1

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED RATING

W912EF21Q0024 05-Mar-2021 5a. ISSUED BY

8. TO: NAME AND ADDRESS, INCLUDING ZIP CODE

SEE SCHEDULE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this

Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State, and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e) (f)

SEE SCHEDULE

AMOUNT

% No. %

NOTE: Additional provisions and representations [ ] are [ ] are not attached.

13. NAME AND ADDRESS OF QUOTER (Street, City, County, State, and ZIP Code)

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF

QUOTATION

16. NAME AND TITLE OF SIGNER (Type or print) (Include area code)

TELEPHONE NO.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 18 (REV. 6-95)

PREVIOUS EDITION NOT USABLE Prescribed by GSA FAR (48 CFR) 53.215-1(a)

THIS RFQ X[ ] IS [ ] IS NOT A SMALL BUSINESS SET-ASIDE

6. DELIVER BY (Date)

SEE SCHEDULE

AND/OR DMS REG. 1

UNDER BDSA REG. 2

4. CERT. FOR NAT. DEF.3. REQUISITION/PURCHASE

REQUEST NO.

USAED, WALLA WALLA - CONTRACTING DIV.

CHANDRA D. CROW

201 N. THIRD AVENUE

WALLA WALLA WA 99362-1876

9. DESTINATION (Consignee and address, including ZIP Code)

7. DELIVERY

[ ] FOB

DESTINATION

[ ] OTHER X

(See Schedule)

22-Mar-2021(Date)

PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS:10.

509-527-7202CHANDRA D. CROW

(Name and Telephone no.) (No collect calls)5b. FOR INFORMATION CALL:

d. CALENDAR DAYSc. 30 CALENDAR DAYSb. 20 CALENDAR DAYS12. DISCOUNT FOR PROMPT PAYMENT a. 10 CALENDAR DAYS

W912EF21Q0024

Section 00 01 10 - Table of Contents

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

Attachment 1 Statement of Work 122 09-JAN-2021 Attachment 2 Site Visit Maps 1 05-FEB-2021 Attachment 3 Site Visit Maps 1 05-FEB-2021 Attachment 4 Plans/Technical Data 8 11-JAN-2021 Attachment 5 DB Wage Determination 5 05-FEB-2021 Attachment 6 COVID SCREENING

QUESTIONNAIRE

2 02-FEB-2021

Section 00 10 00 - Solicitation

BID SCHEDULE

Walla Walla District Corps of Engineers Lucky Peak Dam South Robie Boundary Fence

The magnitude of construction is estimated to be between $25,000 and $100,000

ITEM

DESCRIPTION

QUANTITY

U/M*

U/P*

AMOUNT

Items

0001 Site Clearing 1 JOB

0002 Fence Run Survey and Staking 1 JOB

0003 Fence Run Installation Est* 2,180 LF

0004 20° Grade Change Panel Sections Est.* 4 EACH

0005 Fencing Sag Sections Est.* 6 EACH

0006 Other Fencing Panel Sections 1 JOB

SCHEDULE TOTAL $__________

IMPORTANT See Section 01 22 00.00 28; MEASUREMENT AND PAYMENT; Paragraph; Retainage of Payment, for withholding of payment for final deliverables.

U/M* = Unit of Measure U/P* = Unit Price NTE* = Not To Exceed

Est* = Estimated

Section 00 21 00 - Instructions

INSTRUCTIONS TO OFFERORS

BIDDER INQUIRY

All inquiries regarding this solicitation are to be submitted via Bidder Inquiry. Telephone and email inquiries will not be accepted. Bidder Inquiry is a web-site that allows bidders to post questions regarding the solicitation and view all questions by other bidders and responses by USACE. Bidder Inquiry can be accessed through ProjNet at (https://www.projnet.org).

To submit and review inquiry items, prospective vendors will need to use the Bidder Inquiry Key presented below and follow the instructions listed below the key for access. A prospective vendor who submits a comment /question will receive an acknowledgement of their comment/question via email. Another email to the same address will notify the prospective vendor once the reply is available for viewing.

TIMING OF BIDDER INQUIRIES: Bidders are encouraged to submit their bidder inquiries promptly. The Government will make every effort to answer all bidder inquiries; however, the closer to the bid or proposal due date an inquiry is received, the less likely it is that a timely response can be provided.

The Bidder Inquiry Key is: 4QY67X-4ZDDYJ

Specific Instructions for ProjNet Bid Inquiry Access:

1. From the ProjNet home page linked above, click on Quick Add on the upper right side of the screen.

2. Identify the Agency. This should be marked as USACE.

3. Key. Enter the Bidder Inquiry Key listed above.

4. Email. Enter the email address you would like to use for communication.

5. Click Continue. A page will then open saying that a user account was not found and will ask you to create one using the provided form.

6. Enter your First Name, Last Name, Company, City, State, Phone, Email, Secret Question, Secret Answer, and Time Zone. Make sure to remember your Secret Question and Answer as they will be used from this point on to access the ProjNet system.

7. Click Add User. Once this is completed you are now registered within ProjNet and are currently logged into the system.

Instructions for Entering Questions: After you are logged in click on the "post new inquiry", it is on the left side of the window under the Word "Submit" a.) This is the window where you will enter your questions b.) Comment Classification: Click on the down arrow to the right of the words “Please select from below”, select “Public” c.) Discipline: This is where you select who this question should be directed to. Example; if the question isabout an electrical drawing or specification select: “Electrical” from the pull down list.

d.) Sheet. Enter the sheet number of the drawing you are asking about.

e.) Detail. Enter the detail name of the detail shown on the drawing that you are asking about.

f.) Specification. Enter the Specification number and paragraph number.

g.) File. Use this if you are going to attach a pdf file.

h.) Question. Enter your question here.

Specific Instructions for Future ProjNet Bid Inquiry Access:

1. For future access to ProjNet, you will not be provided any type of password. You will utilize your Secret Question and Secret Answer to log in.

2. From the ProjNet home page linked above, click on Quick Add on the upper right side of the screen.

3. Identify the Agency. This should be marked as USACE.

4. Key. Enter the Bidder Inquiry Key listed above.

5. Email. Enter the email address you used to register previously in ProjNet.

6. Click Continue. A page will then open asking you to enter the answer to your Secret Question.

7. Enter your Secret Answer and click Login. Once this is completed you are now logged into the system.

For questions about the ProjNet Bidder Inquiry, please contact the Call Center help desk toll free at 1-800-428- HELP, which operates from 8AM to 5PM (Central US time zone). Bidder inquiry help questions can also be emailed to the helpdesk at staff@projnet.info

THE OFFEROR IS REQUIRED TO BID ON ALL LINE ITEMS OF THE BID SCHEDULE.

INFORMATION TO OFERORS: OFFERORS are required to complete and submit the Standard Form 33 Back (completed), Cost Proposal in the required format (see Page 6 hereof), and Section 00 45 00, Representations and Certifications.

PROPOSAL SUBMISSION: SUBMIT PROPOSAL IN ONE ELECTRONIC COPY. The electronic copy must accompany the original and be identical to the full proposal, including all cost or pricing data, the certificate, and any other attachments. The electronic copy must be submitted in a readable format such as PDF or XPS.

RESPONSIBILITY DETERMINATION: Responsibility Criteria IAW FAR Subpart 9.1: To ensure award is made to the responsible offeror, a determination of responsibility will be conducted. As part of this responsibility determination, the Contracting Officer will utilize the guidance contained in FAR Subpart 9.1, Responsible Prospective Contractors. In accordance with FAR 9.104-1, to be determined responsible, a prospective contractor must:

(a) Have adequate financial resources to perform the contract, or the ability to obtain them (see form below);

(b) Be able to comply with the required or proposed delivery or performance schedule, taking into consideration all existing commercial and governmental business commitments;

(c) Have a satisfactory performance record, similar in scope and magnitude of that stated in the contract requirements;

(d) Have a satisfactory record of integrity and business ethics;

(e) Have the necessary organization, experience, accounting and operational controls, and technical skills, or the ability to obtain them;

(f) Have the necessary production, construction, and technical equipment and facilities, or the ability to obtain them; and

(g) Be otherwise qualified and eligible to receive an award under applicable laws and regulations.

PRICE BASIS: Offerors are advised that only bids submitted on a firm price basis will be considered, and that bids submitted on any other than firm price basis will be rejected. (FAR 14.201-2 (a)) NOTE; Bid prices must include all Federal, state, and local taxes in accordance with Contract Clause: FEDERAL, STATE, AND LOCAL TAXES.

CONTRACTOR RESPONSIBILITY, PREAWARD SURVEY: In order to determine a contractor’s responsibility for purposes of contract award the contractor is required to provide a statement regarding previous experience and past performance in performing comparable work, information related to the business organization, financial resources, and/or plant to be used in performing the work.

(See the Attention to Bidders form included in this solicitation.) In accordance with FAR 9.104-1, to be determined responsible, a prospective contractor must –

(a) Have adequate financial resources to perform the contract, or the ability to obtain them;

(b) Be able to comply with the required or proposed delivery or performance schedule, taking into consideration all existing commercial and governmental business commitments;

(c) Have a satisfactory performance record. (A prospective contractor shall not be determined responsible or nonresponsible solely on the basis of a lack of relevant performance history except as provided in FAR 9.104-2);

(d) Have a satisfactory record of integrity and business ethics;

(e) Have the necessary organization, experience, accounting and operational controls, and technical skills, or the ability to obtain them;

(f) Have the necessary production, construction, and technical equipment and facilities, or the ability to obtain them; and

(g) Be otherwise qualified and eligible to receive an award under applicable laws and regulations.

ATTENTION: Evaluation Criteria: In addition to examining the criteria in FAR 9.104-1 as listed above, the Contracting Officer will also examine whether the low offeror can meet the requirements of the evaluation criteria mentioned in sections a) below. The apparent low offeror will be required to meet the following experience requirements:

a) Provide a minimum of (3) projects completed* within the last six (6) years**. Projects should include construction of fences similar to the scope of work with an emphasis on all-metal fences. For each of the projects please include the following information: Name of project, customer name and a brief narrative that describes the project.

*All Project examples must be at a minimum 75% complete to be considered.

**Define “6 years” as 6 years from the date the solicitation is posted.

The Contracting Officer will verify the submitted projects meet the evaluation criteria as part of the responsibility determination. Offerors are not required to submit additional documentation related to these criteria at the time of the bid. Instead, the Government will request the supporting documentation within a reasonable timeframe after bid opening and the apparent low bidder will be expected to provide the experience information within two (2) business days after the Government's request.

The Contracting Officer will verify the submitted projects meet the evaluation criteria as part of the responsibility determination.

Along with the Evaluation Criteria above, the apparent low offeror will be required to provide the following information for the Government’s use in the determination of Offeror(s) responsibility (See a) above).

a) Current Balance Sheet and latest Profit and Loss Statement prepared from the most recent fiscal/calendar year and certified by an officer of the company.

b) The name of your banking institution, telephone number and the name of the individual to contact for a line-of-credit reference. (If you are the apparent low offeror, please contact your bank reference to let him/her know our office will be calling for financial information.)

Bank Institution ________________________________ Telephone Number ______________________________ Contact ________________________________________ Email Address __________________________________ Tax Identification Number ________________________

c) List of present work to include agency or firm name, address, telephone number, and email address of primary point of contact responsible for inspection and acceptance of the work. (Attach list)

a. Will performance of the present work inhibit your ability to perform this contract? __________

b. Offeror’s email address: ____________________________________

Please return completed information listed above with all attachment’s copies of the experience credentials listed in the Evaluation Criteria information from above to:

Email: Chandra.d.crow@usace.army.mil

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.211-13 Time Extensions SEP 2000 52.211-18 Variation in Estimated Quantity APR 1984 52.225-10 Notice of Buy American Requirement--Construction

Materials

MAY 2014

52.232-13 Notice Of Progress Payments APR 1984 52.247-34 F.O.B. Destination NOV 1991 252.204-7019 Notice of NIST SP 800-171 DoD Assessment Requirements NOV 2020

CLAUSES INCORPORATED BY FULL TEXT

52.204-26 COVERED TELECOMMUNICATIONS EQUIPMENT OR SERVICES--REPRESENTATION (DEC

2019)

(a) Definitions. As used in this provision, “covered telecommunications equipment or services” has the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for “covered telecommunications equipment or services”.

(c) Representation. The Offeror represents that it [ ___ ] does, [ ___ ] does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

(End of provision)

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with CLAUSE: DEFAULT (FIXED-PRICE CONSTRUCTION) of the CONTRACT CLAUSES. In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

2. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

Monthly Anticipated Adverse Weather Delay Work Days Based on (7) Day Work Week

Location JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

LPA 6 1 4 2 2 1 0 1 1 2 4 7

3. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor shall record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled work day. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph 3.2, above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days and issue a modification in accordance with the CLAUSE: DEFAULT (FIXED PRICE CONSTRUCTION) of the CONTRACT CLAUSES.

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm-Fixed Price contract resulting from this solicitation.

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK (MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

52.232-16 PROGRESS PAYMENTS (JUN 2020)

The Government will make progress payments to the Contractor when requested as work progresses, but not more frequently than monthly, in amounts of $2,500 or more approved by the Contracting Officer, under the following conditions:

(a) Computation of amounts.

(1) Unless the Contractor requests a smaller amount, the Government will compute each progress payment as 80 percent of the Contractor's total costs incurred under this contract whether or not actually paid, plus financing payments to subcontractors (see paragraph (j) of this clause), less the sum of all previous progress payments made by the Government under this contract. The Contracting Officer will consider cost of money that would be allowable under Federal Acquisition Regulation (FAR) 31.205-10 as an incurred cost for progress payment purposes.

(2) The amount of financing and other payments for supplies and services purchased directly for the contract are limited to the amounts that have been paid by cash, check, or other forms of payment, or that are determined due and will be paid to subcontractors--

(i) In accordance with the terms and conditions of a subcontract or invoice; and

(ii) Ordinarily within 30 days of the submission of the Contractor's payment request to the Government.

(3) The Government will exclude accrued costs of Contractor contributions under employee pension plans until actually paid unless--

(i) The Contractor's practice is to make contributions to the retirement fund quarterly or more frequently; and

(ii) The contribution does not remain unpaid 30 days after the end of the applicable quarter or shorter payment period (any contribution remaining unpaid shall be excluded from the Contractor's total costs for progress payments until paid).

(4) The Contractor shall not include the following in total costs for progress payment purposes in paragraph (a)(1) of this clause:

(i) Costs that are not reasonable, allocable to this contract, and consistent with sound and generally accepted accounting principles and practices.

(ii) Costs incurred by subcontractors or suppliers.

(iii) Costs ordinarily capitalized and subject to depreciation or amortization except for the properly depreciated or amortized portion of such costs.

(iv) Payments made or amounts payable to subcontractors or suppliers, except for --

(A) Completed work, including partial deliveries, to which the Contractor has acquired title; and

(B) Work under cost-reimbursement or time-and-material subcontracts to which the Contractor has acquired title.

(5) The amount of unliquidated progress payments may exceed neither (i) the progress payments made against incomplete work (including allowable unliquidated progress payments to subcontractors) nor

(ii) the value, for progress payment purposes, of the incomplete work. Incomplete work shall be considered to be the supplies and services required by this contract, for which delivery and invoicing by the Contractor and acceptance by the Government are incomplete.

(6) The total amount of progress payments shall not exceed 80 percent of the total contract price.

(7) If a progress payment or the unliquidated progress payments exceed the amounts permitted by subparagraphs (a)(4) or (a)(5) of this clause, the Contractor shall repay the amount of such excess to the Government on demand.

(8) Notwithstanding any other terms of the contract, the Contractor agrees not to request progress payments in dollar amounts of less than $2,500. The Contracting Officer may make exceptions.

(9) The costs applicable to items delivered, invoiced, and accepted shall not include costs in excess of the contract price of the items.

(b) Liquidation. Except as provided in the Termination for Convenience of the Government clause, all progress payments shall be liquidated by deducting from any payment under this contract, other than advance or progress payments, the unliquidated progress payments, or 80 percent of the amount invoiced, whichever is less. The Contractor shall repay to the Government any amounts required by a retroactive price reduction, after computing liquidations and payments on past invoices at the reduced prices and adjusting the unliquidated progress payments accordingly. The Government reserves the right to unilaterally change from the ordinary liquidation rate to an alternate rate when deemed appropriate for proper contract financing.

(c) Reduction or suspension. The Contracting Officer may reduce or suspend progress payments, increase the rate of liquidation, or take a combination of these actions, after finding on substantial evidence any of the following conditions:

(1) The Contractor failed to comply with any material requirement of this contract (which includes paragraphs (f) and (g) of this clause).

(2) Performance of this contract is endangered by the Contractor's --

(i) Failure to make progress or

(ii) Unsatisfactory financial condition.

(3) Inventory allocated to this contract substantially exceeds reasonable requirements.

(4) The Contractor is delinquent in payment of the costs of performing this contract in the ordinary course of business.

(5) The fair value of the undelivered work is less than the amount of unliquidated progress payments for that work.

(6) The Contractor is realizing less profit than that reflected in the establishment of any alternate liquidation rate in paragraph (b) of this clause, and that rate is less than the progress payment rate stated in subparagraph (a)(1) of this clause.

(d) Title.

(1) Title to the property described in this paragraph (d) shall vest in the Government. Vestiture shall be immediately upon the date of this contract, for property acquired or produced before that date. Otherwise, vestiture shall occur when the property is or should have been allocable or properly chargeable to this contract.

(2) "Property," as used in this clause, includes all of the below-described items acquired or produced by the Contractor that are or should be allocable or properly chargeable to this contract under sound and generally accepted accounting principles and practices.

(i) Parts, materials, inventories, and work in process;

(ii) Special tooling and special test equipment to which the Government is to acquire title;

(iii) Nondurable (i.e., noncapital) tools, jigs, dies, fixtures, molds, patterns, taps, gauges, test equipment, and other similar manufacturing aids, title to which would not be obtained as special tooling under paragraph (d) (2)(ii) of this clause; and

(iv) Drawings and technical data, to the extent the Contractor or subcontractors are required to deliver them to the Government by other clauses of this contract.

(3) Although title to property is in the Government under this clause, other applicable clauses of this contract; e.g., the termination clauses, shall determine the handling and disposition of the property.

(4) The Contractor may sell any scrap resulting from production under this contract without requesting the Contracting Officer's approval, but the proceeds shall be credited against the costs of performance.

(5) To acquire for its own use or dispose of property to which title is vested in the Government under this clause, the Contractor must obtain the Contracting Officer's advance approval of the action and the terms. The Contractor shall

(i) exclude the allocable costs of the property from the costs of contract performance, and (ii) repay to the Government any amount of unliquidated progress payments allocable to the property. Repayment may be by cash or credit memorandum.

(6) When the Contractor completes all of the obligations under this contract, including liquidation of all progress payments, title shall vest in the Contractor for all property (or the proceeds thereof) not--

(i) Delivered to, and accepted by, the Government under this contract; or

(ii) Incorporated in supplies delivered to, and accepted by, the Government under this contract and to which title is vested in the Government under this clause.

(7) The terms of this contract concerning liability for Government-furnished property shall not apply to property to which the Government acquired title solely under this clause.

(e) Risk of loss. Before delivery to and acceptance by the Government, the Contractor shall bear the risk of loss for property, the title to which vests in the Government under this clause, except to the extent the Government expressly assumes the risk. The Contractor shall repay the Government an amount equal to the unliquidated progress payments that are based on costs allocable to property that is lost (see 45.101).

(f) Control of costs and property. The Contractor shall maintain an accounting system and controls adequate for the proper administration of this clause.

(g) Reports, forms, and access to records. (1) The Contractor shall promptly furnish reports, certificates, financial statements, and other pertinent information (including estimates to complete) reasonably requested by the Contracting Officer for the administration of this clause. Also, the Contractor shall give the Government reasonable opportunity to examine and verify the Contractor's books, records, and accounts.

(2) The Contractor shall furnish estimates to complete that have been developed or updated within six months of the date of the progress payment request. The estimates to complete shall represent the Contractor's best estimate of total costs to complete all remaining contract work required under the contract. The estimates shall include sufficient detail to permit Government verification.

(3) Each Contractor request for progress payment shall:

(i) Be submitted on Standard Form 1443, Contractor's Request for Progress Payment, or the electronic equivalent as required by agency regulations, in accordance with the form instructions and the contract terms; and

(ii) Include any additional supporting documentation requested by the Contracting Officer.

(h) Special terms regarding default. If this contract is terminated under the Default clause, (i) the Contractor shall, on demand, repay to the Government the amount of unliquidated progress payments and (ii) title shall vest in the Contractor, on full liquidation of progress payments, for all property for which the Government elects not to require delivery under the Default clause. The Government shall be liable for no payment except as provided by the Default clause.

(i) Reservations of rights.

(1) No payment or vesting of title under this clause shall --

(i) Excuse the Contractor from performance of obligations under this contract or

(ii) Constitute a waiver of any of the rights or remedies of the parties under the contract.

(2) The Government's rights and remedies under this clause

(i) Shall not be exclusive but rather shall be in addition to any other rights and remedies provided by law or this contract and

(ii) Shall not be affected by delayed, partial, or omitted exercise of any right, remedy, power, or privilege, nor shall such exercise or any single exercise preclude or impair any further exercise under this clause or the exercise of any other right, power, or privilege of the Government.

(j) Financing payments to subcontractors. The financing payments to subcontractors mentioned in paragraphs (a)(1) and (a)(2) of this clause shall be all financing payments to subcontractors or divisions, if the following conditions are met:

(1) The amounts included are limited to--

(i) The unliquidated remainder of financing payments made; plus

(ii) Any unpaid subcontractor requests for financing payments.

(2) The subcontract or interdivisional order is expected to involve a minimum of approximately 6 months between the beginning of work and the first delivery; or, if the subcontractor is a small business concern, 4 months.

(3) If the financing payments are in the form of progress payments, the terms of the subcontract or interdivisional order concerning progress payments--

(i) Are substantially similar to the terms of this clause for any subcontractor that is a large business concern, or this clause with its Alternate I for any subcontractor that is a small business concern;

(ii) Are at least as favorable to the Government as the terms of this clause;

(iii) Are not more favorable to the subcontractor or division than the terms of this clause are to the Contractor;

(iv) Are in conformance with the requirements of FAR 32.504(e); and

(v) Subordinate all subcontractor rights concerning property to which the Government has title under the subcontract to the Government's right to require delivery of the property to the Government if--

(A) The Contractor defaults; or

(B) The subcontractor becomes bankrupt or insolvent.

(4) If the financing payments are in the form of performance-based payments, the terms of the subcontract or interdivisional order concerning payments--

(i) Are substantially similar to the Performance-Based Payments clause at FAR 52.232-32 and meet the criteria for, and definition of, performance-based payments in FAR Part 32;

(ii) Are in conformance with the requirements of FAR 32.504(f); and

(iii) Subordinate all subcontractor rights concerning property to which the Government has title under the subcontract to the Government's right to require delivery of the property to the Government if--

(A) The Contractor defaults; or

(B) The subcontractor becomes bankrupt or insolvent.

(5) If the financing payments are in the form of commercial item financing payments, the terms of the subcontract or interdivisional order concerning payments--

(i) Are constructed in accordance with FAR 32.206(c) and included in a subcontract for a commercial item purchase that meets the definition and standards for acquisition of commercial items in FAR Parts 2 and 12;

(ii) Are in conformance with the requirements of FAR 32.504(g); and

(iii) Subordinate all subcontractor rights concerning property to which the Government has title under the subcontract to the Government's right to require delivery of the property to the Government if--

(A) The Contractor defaults; or

(B) The subcontractor becomes bankrupt or insolvent.

(6) If financing is in the form of progress payments, the progress payment rate in the subcontract is the customary rate used by the contracting agency, depending on whether the subcontractor is or is not a small business concern.

(7) Concerning any proceeds received by the Government for property to which title has vested in the Government under the subcontract terms, the parties agree that the proceeds shall be applied to reducing any unliquidated financing payments by the Government to the Contractor under this contract.

(8) If no unliquidated financing payments to the Contractor remain, but there are unliquidated financing payments that the Contractor has made to any subcontractor, the Contractor shall be subrogated to all the rights the Government obtained through the terms required by this clause to be in any subcontract, as if all such rights had been assigned and transferred to the Contractor.

(9) To facilitate small business participation in subcontracting under this contract, the Contractor shall provide financing payments to small business concerns, in conformity with the standards for customary contract financing payments stated in Subpart 32.113. The Contractor shall not consider the need for such financing payments as a handicap or adverse factor in the award of subcontracts.

(k) Limitations on undefinitized contract actions. Notwithstanding any other progress payment provisions in this contract, progress payments may not exceed 80 percent of costs incurred on work accomplished under undefinitized contract actions. A "contract action" is any action resulting in a contract, as defined in Subpart 2.1, including contract modifications for additional supplies or services, but not including contract modifications that are within the scope and under the terms of the contract, such as contract modifications issued pursuant to the Changes clause, or funding and other administrative changes. This limitation shall apply to the costs incurred, as computed in accordance with paragraph (a) of this clause, and shall remain in effect until the contract action is definitized. Costs incurred which are subject to this limitation shall be segregated on Contractor progress payment requests and invoices from those costs eligible for higher progress payment rates. For purposes of progress payment liquidation, as described in paragraph (b) of this clause, progress payments for undefinitized contract actions shall be liquidated at 80 percent of the amount invoiced for work performed under the undefinitized contract action as long as the contract action remains undefinitized. The amount of unliquidated progress payments for undefinitized contract actions shall not exceed 80 percent of the maximum liability of the Government under the undefinitized contract action or such lower limit specified elsewhere in the contract. Separate limits may be specified for separate actions.

(l) Due date. The designated payment office will make progress payments on the 30th day after the designated billing office receives a proper progress payment request. In the event that the Government requires an audit or other review of a specific progress payment request to ensure compliance with the terms and conditions of the contract, the designated payment office is not compelled to make payment by the specified due date. Progress payments are considered contract financing and are not subject to the interest penalty provisions of the Prompt Payment Act.

(m) Progress payments under indefinite--delivery contracts. The Contractor shall account for and submit progress payment requests under individual orders as if the order constituted a separate contract, unless otherwise specified in this contract.

(End of clause)

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting:

11 March 2021 starting at 9:00 a.m. MTN.

Meet at the Lake Office, then caravanning to the site 20 minutes down the road (see attached Maps). The Lake Office is accessed by turning into Sandy Point from Highway 21 downstream of the dam. Follow signs to “Lake Office” located on the left (there are three entities collocated in this area – people seeking USACE often make a wrong turn down the first driveway towards the Power Plant).

US Army Corps of Engineers 9723 E Hwy 21 Boise, ID 83716

(208) 343-0671

There are no cellular services at either the Lake Office or the work area so this is a best bet that affords restroom breaks as well.

There will be only one site visit offered. Offerors planning to attend must register for the site by sending an email to: chandra.d.crow@usace.army.mil.

Firms must register no later than the day before the site visit.

Site visit attendees must provide the following information: 1) Solicitation Number; 2) Project Title; 3) Names of individuals who will attend the site visit; 4) a statement as to whether the individual is a US citizen. If not a US citizen, please refer to ACCESS FOR FOREIGN NATIONALS in Section 00800 of this document; 5) Name of company being represented 6) Phone number of company being represented. All firms MUST register not later than 2:00 PM PST local time on 10 March 2021 by email to Mrs. Crow at chandra.d.crow@usace.army.mil.

Each individual attending the site visit must submit the Center for Disease Control (CDC) Active Screening questionnaire not later than 5:00 PM local time on 10 March 2021. Registered attendees that have not provided a completed questionnaire will not be permitted on-site due to ongoing COVID-19 concerns.

Each firm is allowed no more than two attendees for the site visit due to size of gathering restrictions. To ensure consistent information is shared among all potential offerors, all questions must be submitted through the ProjNet bidder inquiry process outlined in this solicitation. No questions will be answered at the site visit.

Each individual attending the site visit must have picture identification on his/her person while at the project site.

There can be no substitutions of one individual for another. If an individual arrives at the site visit without having registered and/or without having picture identification, that individual may not be allowed on the site.

Participants of site visits must abide by the U.S. Army Corps of Engineers Safety and Health Requirements Manual (EM 385-1-1, latest version) in accordance with Section 5, “Personal Protective and Safety Equipment. (PPE)” It is the responsibility of participants to wear personal protective and safety equipment as required by this regulation.

Failure to comply could result in denial of access to site visit location.

All attendees must follow federal, state, and local guidelines for the mitigation of COVID 19 when attending this site visit. Please ensure all attendees have PPE with them in order to comply with COVID 19 mitigation measures.

The ACCESS FOR FOREIGN NATIONALS requirement in Section 00 73 00 applies to site visits as well as to performance of the work.

Site Visit Guidelines:

The RSVP Cut-off date of 10 March 2021 at 2:00pm PST will be included via amendment to allow team to ensure enough Government staff is present to support. Appropriate masks will be required at all times while on site.

Start times will be assigned and are staggered starting at 9:00 am MTN.

- Government staff will read the description of the project.

- No questions will be answered during site visit.

- Completion and submission of the CDC Active Screening Questionnaire be each attendee prior to travel is required. (SEE CDC Active Screening Questionnaire attachment provided with the solicitation)

- The groups will then be escorted along a pre-determined path throughout the site locations.

The Government will not be answering any questions during the walkthrough. Potential offerors will be allowed to take equipment specific pictures and measurements of equipment that is along the pre-determined pathway only.

Once the site visit is complete, contractor attendees will be escorted back to their vehicles.

To ensure consistent information is shared among all potential offerors, all questions must be submitted through the ProjNet bidder inquiry process outlined in the solicitation.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov/

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov/

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Defense Federal Acquisition Regulation Supplement (DFARS) (48 CFR Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any Defense Federal Acquisition Regulation Supplement (DFARS) (48 CFR Chapter 2) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings: SECTION 00 01 15.00 28 LIST OF DRAWINGS

Bentley DGN format CAD, are the only CAD systems used by Walla Walla District. Contract drawings created on CAD in Bentley DGN format, will be available in electronic form for use by the Contractor. No For Information Only drawings are available on CAD. The Contractor assumes all risks associated in using electronic CAD drawings. The contract drawings shall govern if there are any discrepancies between the electronic copy and the contract drawing. The Contractor shall promptly notify the Contracting Officer of any discrepancies. The Government will not be responsible to correct the electronic CAD drawing. Electronic copies of CAD drawings are only available in Bentley DGN format.

The Government will provide the files via DoD safe file exchange.

Section 00 45 00 - Representations and Certifications

52.204-16 Commercial and Government Entity Code Reporting AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment.

AUG 2020

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

AUG 2020

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV 2011

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAR 2020)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238990.

(2) The small business size standard is $16,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services--Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiv) 52.222-22, Previous…