B.01 W911WN24Q0006.pdf

SEE ADDENDUM

(No Collect Calls)

W911WN24Q0006 12-Apr-2024

b. TELEPHONE NUMBER

412-395-7551

8. OFFER DUE DATE/LOCAL TIME

05:00 PM 18 Apr 2024

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W911WN9. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

CONNIE L FERGUSON

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

0 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

W81ET440653408

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED ORX

SMALL BUSINESS

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

U.S. ARMY ENGINEER DISTRICT, PITTSBURGH

ATTN CELRP-CT

W S MOORHEAD FEDERAL BUILDING

1000 LIBERTY AVENUE ROOM 2203

PITTSBURGH PA 15222-4186

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE 965551 16. ADMINISTERED BY

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

HANNIBAL L/D, OHIO RVR

LOCKMASTER

40344 STATE ROUTE 7

HANNIBAL OH 43931-0008

TEL: 740-483-2305 FAX: 740-483-1325

412.395.7110FAX:

TEL: SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

NAICS:

327320

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF36

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job

CONCRETE MIX DESIGNS DEVELOPMENT

FFP

The Vendor shall be responsible for furnishing all supplies, materials, equipment and labor as necessary for the designs development in accordance with the Specifications for the Concrete Supply for Anchorage Repairs at Hannibal Locks and Dam.

FOB: Destination

PURCHASE REQUEST NUMBER: W81ET440653408

PSC CD: 5440

NET AMT

0002 100 Cubic

Yard

STRUCTURAL CONCRETE (WVDOH Class B Type)

FFP

The Vendor shall be responsible for furnishing all supplies, materials, equipment and labor as necessary for the delivery of concrete in accordance with the Specifications for the Concrete Supply for Anchorage Repairs at Hannibal Locks and Dam.

The concrete placements will occur between 1 July and 22 November 2024.

FOB: Destination

0003 60 Cubic

Yard

FILL CONCRETE (WVDOH Type C CLSM Type)

FFP

The Vendor shall be responsible for furnishing all supplies, materials, equipment and labor as necessary for the delivery of concrete in accordance with the Specifications for the Concrete Supply for Anchorage Repairs at Hannibal Locks and Dam.

The concrete placements will occur between 1 July and 22 November 2024.

FOB: Destination

0004 30 Hours

EXCESS UNLOADING TIME

FFP

The Vendor shall be responsible for furnishing all supplies, materials, equipment and labor as necessary for the delivery of concrete in accordance with the Specifications for the Concrete Supply for Anchorage Repairs at Hannibal Locks and Dam.

The concrete placements will occur between 1 July and 22 November 2024.

FOB: Destination

0005 20 Each

SMALL LOAD ADDITIONAL CHARGE PER DELIVER

FFP

The Vendor shall be responsible for furnishing all supplies, materials, equipment and labor as necessary for the delivery of concrete in accordance with the Specifications for the Concrete Supply for Anchorage Repairs at Hannibal Locks and Dam.

The concrete placements will occur between 1 July and 22 November 2024.

FOB: Destination

0006 35 Each

FUEL SURCHARGE PER TRUCK DELIVERY

FFP

Fuel Surcharge per truck delivery trip.

The concrete placements will occur between 1 July and 22 November 2024.

FOB: Destination

0007 5 Each

SATURDAY DELIVERY ADDITIONAL CHARGE

FFP

The Vendor shall include separate possible charges for the delivery of concrete on Saturdays. Saturday placements are not anticipated but may be required.

The concrete placements will occur between 1 July and 22 November 2024.

FOB: Destination

0008 5 Each

SUNDAY DELIVERY ADDITIONAL CHARGE

FFP

OPTIONAL QUOTE ITEM.

The Vendor shall include separate possible charges for the delivery of concrete on Sundays. Sunday placements are not anticipated but may be required.

The concrete placements will occur between 1 July and 22 November 2024.

FOB: Destination

0009 100 Each

CONCRETE TEST CYLINDER

FFP

CONCRETE TEST CYLINDER MAKING AND TESTING PER CYLINDER

(OPTIONAL QUOTE ITEM)

The Vendor shall include separate possible charges for the plant to make, cure and test break cylinders from each truck delivered. Per cylinder. Number of cylinders and cure time to be specified by governments project engineer, in accordance with the Specifications for the Concrete Supply for Anchorage Repairs at Hannibal Locks and Dam.

The concrete placements will occur between 1 July and 22 November 2024 FOB: Destination

0010 20 Each

CONCRETE DISPOSAL PER TRUCK RETURNED

FFP

The Vendor shall include possible charges for delivered but unused concrete that is sent back to the plant for disposal, in accordance with the Specifications for the Concrete Supply for Anchorage Repairs at Hannibal Locks and Dam.

The concrete placements will occur between 1 July and 22 November 2024.

FOB: Destination

0011 200 Each

CONCRETE MIX ADDITIVE

FFP

CONCRETE MIX ADDITIVE ICE OR COLD WATER PER DOSE/BAG

The Vendor shall include any add mixes that are requested in addition to the initial mix design. This can include but is not limited to, Ice, heated water, Super plasticizer, retarder and accelerators, in accordance with the Specifications for the Concrete Supply for Anchorage Repairs at Hannibal Locks and Dam.

The concrete placements will occur between 1 July and 22 November 2024.

FOB: Destination

0012 160 Each

CONCRETE MIX ADDITIVE

FFP

CONCRETE MIX ADDITIVE HEATED WATER PER CUBIC YARD DOSED

The Vendor shall include any add mixes that are requested in addition to the initial mix design. This can include but is not limited to, Ice, heated water, Super plasticizer, retarder and accelerators, in accordance with the Specifications for the Concrete Supply for Anchorage Repairs at Hannibal Locks and Dam.

The concrete placements will occur between 1 July and 22 November 2024.

FOB: Destination

0013 160 Each

CONCRETE MIX ADDITIVE PLASTICIZER

FFP

CONCRETE MIX ADDITIVE PLASTICIZER PER 1% DOSE PER CUBIC

YARD DOSED

The Vendor shall include any add mixes that are requested in addition to the initial mix design. This can include but is not limited to, Ice, heated water, Super plasticizer, retarder and accelerators, in accordance with the Specifications for the Concrete Supply for Anchorage Repairs at Hannibal Locks and Dam.

The concrete placements will occur between 1 July and 22 November 2024.

FOB: Destination

0014 160 Each

CONCRETE MIX ADDITIVE RETARDER

FFP

CONCRETE MIX ADDITIVE RETARDER PER 1% DOSE PER CUBIC YARD

DOSED

The Vendor shall include any add mixes that are requested in addition to the initial mix design. This can include but is not limited to, Ice, heated water, Super plasticizer, retarder and accelerators, in accordance with the Specifications for the Concrete Supply for Anchorage Repairs at Hannibal Locks and Dam.

The concrete placements will occur between 1 July and 22 November 2024.

FOB: Destination

10 of

0015 100 Each

CONCRETE MIX ADDITIVE ACCELERATOR

FFP

CONCRETE MIX ADDITIVE ACCELERATOR PER 1% DOSE PER CUBIC

YARD DOSED

The Vendor shall include any add mixes that are requested in addition to the initial mix design. This can include but is not limited to, Ice, heated water, Super plasticizer, retarder and accelerators, in accordance with the Specifications for the Concrete Supply for Anchorage Repairs at Hannibal Locks and Dam.

The concrete placements will occur between 1 July and 22 November 2024.

FOB: Destination

SPECIFICATIONS

Hannibal L/D, Ohio River 2024 Concrete Supply for Anchorage Repairs Specifications & General Requirements

1.0 CONCRETE SUPPLY

1.1 General Information.

The Contractor shall develop/design and test the mix design for the concrete mixes and supply the concrete per Specification Section 03 30 00 to the job site located at Hannibal Locks and Dam on the Ohio River. Note, the Contracting Officer shall be notified of any or all tests which are to be performed for verification of the mix design. The Contracting Officer reserves the right to observe all processes and tests used in mixture proportion verification.

1.2 Site Location: Hannibal L/D.

The Government will be placing the concrete, by government supplied crane and bucket, in formwork that is approximately 8 feet deep. It is anticipated that a concrete truck could be at the site approximately one (1) to two

(2) hours.

1.2.1 Quantities and Delivery Requirements - Concrete.

11 of

a. The batch plant shall be within 45 minutes travel time from the delivery site.

b. The estimated total amount of concrete ordered may be up to 160 cubic yards. Each individual delivery load will be a Minimum of 2 cubic yards and Maximum of 10 cubic yards. For each placement date estimate 1 - 3 individual concrete truck deliveries.

c. The concrete placements will occur between 1 July and 22 November 2024. The Government’s Project Engineer will keep the concrete supply company’s POC informed to the actual delivery dates as they approach. Weekend placements are not anticipated, but may be required. Refer to section 2.0 below for additional Quote item details.

d. The contractor will be notified at least 48 hours prior to the required delivery, including weekends and holidays.

1.2.2 Delivery site address:

Hannibal L/D, Ohio River

40344 OH-7,

Hannibal, OH 43931 740-483-2305

2.0 ADDITIONAL QUOTE ITEMS

2.1 Excess Unloading Time.

The Quote is to include separate possible charges for truck waiting time in excess of normal unloading time.

2.2 Small Load Additional Costs.

The Quote is to include separate possible charges for truck small load charges below the typical 6 cubic yard per truck minimum; per delivery.

2.3 Fuel Surcharge

Fuel Surcharge per truck delivery trip.

2.4 Saturday Delivery Additional Costs

The Quote is to include separate possible charges for the delivery of concrete on Saturdays. Typically, there is an extra cost/yard of concrete delivered. Saturday placements are not anticipated but may be required.

2.5 Sunday Delivery Additional Costs (OPTIONAL QUOTE ITEM)

This Quote is to include separate possible charges for the delivery of concrete on Sundays. Typically, there is a plant start-up charge for Sunday deliveries in addition to regular cost/ yard of concrete delivered. Sunday placements are not anticipated but may be required.

2.6 Concrete Test Cylinder Making and Breaking

This Quote is to include separate possible charges for the plant to make, cure and test break cylinders from each truck delivered. Per cylinder. Number of cylinders and cure time to be specified by governments project engineer.

(OPTIONAL QUOTE ITEM)

12 of

2.7 Concrete disposal.

This Quote item is to include possible charges for delivered but unused concrete that is sent back to the plant for disposal.

2.8 Concrete mix additives.

This Quote item is to include any add mixes that are requested in addition to the initial mix design. This can include but is not limited to, Ice, heated water, Super plasticizer, retarder and accelerators. Per add mix, per cubic.

- - End of Section - -

SECTION TABLE OF CONTENTS

DIVISION 03 – CONCRETE

SECTION 03 30 00

CAST-IN-PLACE CONCRETE SUPPLY

PART 1 GENERAL

1.1 SCOPE

The work covered by this Section consists of furnishing all equipment, labor, materials, and performing all operations in connection with furnishing cast-in-place concrete as indicated. The Government will be responsible for placing the concrete and performing quality assurance testing on site.

1.2 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

ASTM INTERNATIONAL (ASTM)

ASTM C33/C33M (2023) Standard Specification for Concrete Aggregates

ASTM C39/C39M (2023) Standard Test Method for Compressive

Strength of Cylindrical Concrete Specimens

ASTM C94/C94M (2023) Standard Specification for Ready-Mixed Concrete

ASTM C143/C143M (2020) Standard Test Method for Slump of Hydraulic-

Cement Concrete

ASTM C150/C150M (2022) Standard Specification for Portland Cement

ASTM C231/C231M (2022) Standard Test Method for Air Content of Freshly Mixed Concrete by the Pressure Method

ASTM C403/C403M (2023 ) Standard Test Method for Time of Setting of

Concrete Mixtures by Penetration Resistance

ASTM C494/C494M (2019; E 2022) Standard Specification for Chemical Admixtures for Concrete

ASTM C595/C595M (2023) Standard Specification for Blended Hydraulic

Cements

ASTM C618 (2023; E 2023) Standard Specification for Coal Fly Ash and Raw or Calcined Natural Pozzolan for Use in Concrete

ASTM C989/C989M (2022) Standard Specification for Slag Cement for Use in Concrete and Mortars

ASTM C1240 (2020) Standard Specification for Silica Fume Used in

Cementitious Mixtures

ASTM C1260 (2023) Standard Test Method for Potential Alkali Reactivity of Aggregates (Mortar-Bar Method)

ASTM C1293 (2008; R 2015) Standard Test Method for Determination of

Length Change of Concrete Due to Alkali-Silica Reaction

ASTM C1567 (2023) Standard Test Method for Potential Alkali-Silica Reactivity of Combinations of Cementitious Materials and Aggregate (Accelerated Mortar-Bar Method)

PENNSYLVANIA DEPARTMENT OF TRANSPORTATION (PENNDOT)

PUB 408 (2020) Publication 408 Construction Specifications

U.S. ARMY CORPS OF ENGINEERS (USACE)

COE CRD-C 400 (1963) Requirements for Water for Use in Mixing or Curing

Concrete

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation; submittals not having a "G"" designation are for information only. Where used a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00

SUBMITTAL PROCEDURES:

SD-05 Design Data

Concrete Mixture Proportions; G SD-07

Certificates Waybills And Delivery Tickets

1.4 TEMPERATURE LIMITATIONS

The concrete shall be within the temperature range of 50 to 85 degrees Fahrenheit when placed. Mixing water shall be heated or cooled to attain the temperature range.

1.5 CONCRETE PLANT

1.5.1 Ready-Mix Plant

Ready-mixed concrete shall conform to ASTM C94/C94M except as otherwise specified. Batch tickets shall meet the requirements of ASTM C94/C94M and shall include additional information as specified in paragraph 14.2 of ASTM C94/C94M. Additional information shall include the weight of fine and coarse aggregate, amount of cementitious materials, amount of admixtures, free water on aggregates, batch water, amount of water that can be added on site, design water-cement ratio, and maximum size of aggregate.

1.5.2 Time Interval Between Mixing and Placing

When concrete is truck mixed or when a truck mixer or agitator is used for transporting concrete mixes by a concrete plant mixer, the concrete shall be delivered to the site of the work, and it shall be anticipated that concrete may remain on the truck for no more than 2 hours after concrete is delivered to the site.

1.5.3 Department of Transportation (DOT) Approved

The ready-mix concrete plant and the delivery trucks must be approved for the batching and delivery of concrete by the Department of Transportation of Pennsylvania (PENNDOT), West Virginia (WVDOH), or Ohio

(ODOT).

1.6 CONCRETE DESIGN REQUIREMENTS

Provide two concrete mixes: a Structural Concrete and a Fill Concrete. Required properties for each mix are outlined in the table below. Provided they meet all other requirements in this specification, a WVDOH Class B concrete may be used for Structural Concrete and a WVDOH Type C CLSM may be used for Fill Concrete.

Structural Concrete Fill Concrete

Compressive Strength, f'c (psi) 4000 at 28 days 800 at 28 days

Slump (in) 3 to 5 6 to 8

Maximum w/cm by mass 0.45 n/a

Air Content (percent) 4.5 to 7.5 n/a

Minimum Initial Set Time (minutes) 180 180

1.6.1 lkali-Aggregate Reactivity

Select a supplementary cementitious material replacement level capable of mitigating potential alkali-aggregate reactivity. Demonstrate mitigation of alkali-aggregate reactivity by one of the following methods:

a. Performance-based: Test the combination of cementitious materials in accordance with ASTM C1567.

Mitigation is achieved if expansion after 14 calendar days in solution is less than or equal to 0.10 percent.

W911WN24Q0006

b. Prescriptive: Follow guidance from Section 704 of PUB 408, and select minimum level of supplementary cementitious material based on aggregate reactivity for structure class S3.

1.7 CONCRETE MIXTURE PROPORTIONS

Concrete mixture proportions must be determined by the Contractor. For each class of concrete, submit concrete mixture proportions for review and approval at least 45 calendar days before placement. The submission shall be accompanied by test reports which show the proportions will produce concrete of the qualities indicated. All items listed below shall be included in the submittal:

a. The concrete mixture quantities (mass) per cubic yard and sources of all ingredients that will be used in the manufacture of the concrete shall be stated. The mass of the aggregates shall be in a saturated surface dry condition. The maximum water-cement ratio shall be stated.

b. Names, types, and quantities of the admixtures shall be stated. A retarder shall be used in the mixture. Manufacturer's literature of all admixtures used shall be submitted.

c. Certified copies of laboratory test reports for cementitious materials, including mill tests and all other test data, for cement, fly ash, slag cement, and silica fume.

d. For each aggregate source used, provide alkali-silica reactivity test results (ASTM C1293 or ASTM

C1260) and associated reactivity level. Provide documentation that potential alkali-silica reactivity is mitigated in accordance with paragraph Alkali-Aggregate Reactivity.

e. Test results showing the concrete is capable of producing the required strengths (ASTM

C39/C39M), slump (ASTM C143/C143M), air content (ASTM C231/C231M), and initial set time (ASTM C403/C403M) in accordance with the publications listed in parentheses.

1.8 CONCRETE SAMPLING ON SITE

The Government will sample and test the concrete on site to determine compliance with the specifications.

PART 2 PRODUCTS

2.1 MATERIALS

2.1.1 Cementitious Materials

Cementitious materials shall be cement in combination with one or more of the following: fly ash, slag cement, and/or silica fume. Cementitious materials shall conform to the appropriate specifications listed below.

2.1.1.1 Cement

ASTM C150/C150M Type I or Type II, or ASTM C595/C595M Type 1L.

2.1.1.2 Fly Ash

ASTM C618, Class F.

2.1.1.3 Slag Cement

ASTM C989/C989M Grade 100 or 120.

2.1.1.4 Silica Fume

ASTM C1240.

2.1.2 Aggregates

Aggregates shall come from a source approved by PENNDOT, WVDOH, or ODOT. Provide alkali silica reactivity test data for aggregate sources as required by paragraph Concrete Mixture Proportions.

2.1.2.1 Coarse Aggregate

Coarse aggregate shall conform to ASTM C33/C33M, Class 4S.

2.1.2.2 Fine Aggregate

Fine aggregate shall conform to PENNDOT, WVDOH, or ODOT Type A concrete sand.

2.1.3 Water

Water for mixing and curing shall be fresh, clean potable, and free of injurious amounts of oil, acid, salt or alkali except that nonpotable water may be used if it meets the requirements of COE CRD-C 400

2.1.4 Admixtures

Air entraining, water reducing, or retarding admixtures shall conform to ASTM C494/C494M.

PART 3 EXECUTION

3.1 TRANSPORTING CONCRETE TO PLACEMENT SITE

Transport concrete to the placing site for use by the government.

The Government will be responsible for placing the concrete on-site.

3.2 WAYBILLS AND DELIVERY TICKETS

Before the final statement is allowed, file certified waybills and certified delivery tickets for all concrete actually used, as specified in the Submittals paragraph.

-- End of Section --

(End of Specifications)

CLAUSES INCORPORATED BY REFERENCE

52.212-4 Contract Terms and Conditions--Commercial Products and

Commercial Services

NOV 2023

ADDENDUM TO FAR 52.212-4

The following clauses are hereby included as an addendum to FAR 52.212-4, Contract Terms and Conditions – Commercial Items

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.222-20 Contracts for Materials, Supplies, Articles, and Equipment JUN 2020 52.223-3 Hazardous Material Identification And Material Safety Data FEB 2021 52.223-10 Waste Reduction Program MAY 2011 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

MAR 2023

252.203-7000 Requirements Relating to Compensation of Former DoD Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

JAN 2023

252.203-7002 Requirement to Inform Employees of Whistleblower Rights DEC 2022 252.204-7004 Antiterrorism Awareness Training for Contractors JAN 2023 252.204-7015 Notice of Authorized Disclosure of Information for Litigation

Support

JAN 2023

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services

JAN 2023

252.211-7003 Item Unique Identification and Valuation JAN 2023 252.223-7008 Prohibition of Hexavalent Chromium JAN 2023 252.225-7001 Buy American And Balance Of Payments Program--Basic JAN 2023 252.225-7005 Identification Of Expenditures In The United States JUN 2005 252.225-7012 Preference For Certain Domestic Commodities APR 2022 252.225-7052 Restriction on the Acquisition of Certain Magnets, Tantalum, and Tungsten.

JAN 2023

252.225-7056 Prohibition Regarding Business Operations with the Maduro Regime

JAN 2023

252.225-7060 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region

JUN 2023

252.225-7972 (Dev) Prohibition on the Procurement of Foreign-Made Unmanned Aircraft Systems (DEVIATION 2020-O0015)

MAY 2020

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports

DEC 2018

252.232-7010 Levies on Contract Payments DEC 2006 252.243-7002 Requests for Equitable Adjustment DEC 2022 252.243-7999 (Dev) Section 3610 Reimbursement. (DEVIATION 2020-O0021) AUG 2020 252.244-7000 Subcontracts for Commercial Products or Commercial

Services

252.247-7023 Transportation of Supplies by Sea JAN 2023

CLAUSES INCORPORATED BY FULL TEXT

52.204-21 BASIC SAFEGUARDING OF COVERED CONTRACTOR INFORMATION SYSTEMS (NOV 2021)

(a) Definitions. As used in this clause--

Covered contractor information system means an information system that is owned or operated by a contractor that processes, stores, or transmits Federal contract information.

Federal contract information means information, not intended for public release, that is provided by or generated for the Government under a contract to develop or deliver a product or service to the Government, but not including information provided by the Government to the public (such as on public websites) or simple transactional information, such as necessary to process payments.

Information means any communication or representation of knowledge such as facts, data, or opinions, in any medium or form, including textual, numerical, graphic, cartographic, narrative, or audiovisual (Committee on National Security Systems Instruction (CNSSI) 4009).

Information system means a discrete set of information resources organized for the collection, processing, maintenance, use, sharing, dissemination, or disposition of information (44 U.S.C. 3502).

Safeguarding means measures or controls that are prescribed to protect information systems.

(b) Safeguarding requirements and procedures.

(1) The Contractor shall apply the following basic safeguarding requirements and procedures to protect covered contractor information systems. Requirements and procedures for basic safeguarding of covered contractor information systems shall include, at a minimum, the following security controls:

(i) Limit information system access to authorized users, processes acting on behalf of authorized users, or devices (including other information systems).

(ii) Limit information system access to the types of transactions and functions that authorized users are permitted to execute.

(iii) Verify and control/limit connections to and use of external information systems.

(iv) Control information posted or processed on publicly accessible information systems.

(v) Identify information system users, processes acting on behalf of users, or devices.

(vi) Authenticate (or verify) the identities of those users, processes, or devices, as a prerequisite to allowing access to organizational information systems.

(vii) Sanitize or destroy information system media containing Federal Contract Information before disposal or release for reuse.

(viii) Limit physical access to organizational information systems, equipment, and the respective operating environments to authorized individuals.

(ix) Escort visitors and monitor visitor activity; maintain audit logs of physical access; and control and manage physical access devices.

(x) Monitor, control, and protect organizational communications (i.e., information transmitted or received by organizational information systems) at the external boundaries and key internal boundaries of the information systems.

(xi) Implement subnetworks for publicly accessible system components that are physically or logically separated from internal networks.

(xii) Identify, report, and correct information and information system flaws in a timely manner.

(xiii) Provide protection from malicious code at appropriate locations within organizational information systems.

(xiv) Update malicious code protection mechanisms when new releases are available.

(xv) Perform periodic scans of the information system and real-time scans of files from external sources as files are downloaded, opened, or executed.

(2) Other requirements. This clause does not relieve the Contractor of any other specific safeguarding requirements specified by Federal agencies and departments relating to covered contractor information systems generally or other Federal safeguarding requirements for controlled unclassified information (CUI) as established by Executive Order 13556.

(c) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (c), in subcontracts under this contract (including subcontracts for the acquisition of commercial products or commercial services, other than commercially available off-the-shelf items), in which the subcontractor may have Federal contract information residing in or transiting through its information system.

(End of clause)

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (SEP 2023)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern--

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph

(d) of this clause.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13

CFR 121.103.

(b) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, when the Contracting Officer explicitly requires it for an order issued under a multiple-award contract.

(d) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document/support--table-size-standards.

(e) The small business size standard for a Contractor providing an end item that it does not manufacture, process, or produce itself, for a contract other than a construction or service contract, is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition--

(1) Was set aside for small business and has a value above the simplified acquisition threshold;

(2) Used the HUBZone price evaluation preference regardless of dollar value, unless the Contractor waived the price evaluation preference; or

(3) Was an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(f) Except as provided in paragraph (h) of this clause, the Contractor shall make the representation(s) required by paragraph (b) and (c) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause, or with its offer for an order (see paragraph (c) of this clause), that the data have been validated or updated, and provide the date of the validation or update.

(g) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (f) or (h) of this clause.

(h) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

(1) The Contractor represents that it [ ] is, [ ] is not a small business concern under NAICS Code 327320 assigned to contract number TBD.

(2) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1001.

(3) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not a women-owned small business concern.

(4) Women-owned small business (WOSB) joint venture eligible under the WOSB Program. The Contractor represents that it [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [The Contractor shall enter the name and unique entity identifier of each party to the joint venture: .]

(5) Economically disadvantaged women-owned small business (EDWOSB) joint venture. The Contractor represents that it [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [The Contractor shall enter the name and unique entity identifier of each party to the joint venture: .]

(6) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not a veteran-owned small business concern.

(7) [Complete only if the Contractor represented itself as a veteran-owned small business concern in paragraph (h)(6) of this clause.] The Contractor represents that it [ ] is, [ ] is not a service-disabled veteran-owned small business concern.

(8) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that--

(i) It [ ] is, [ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and

(ii) It [ ] is, [ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126, and the representation in paragraph (h)(8)(i) of this clause is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The Contractor shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: .] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

[Contractor to sign and date and insert authorized signer's name and title.]

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

The full text of FAR clauses and provisions can be found at https://www.acquisition.gov/

The full text of DFARS clauses and provisions can be found at https://www.acq.osd.mil/dpap/dars/dfarspgi/current/index.html

52.252-4 ALTERATIONS IN CONTRACT (APR 1984)

Portions of this contract are altered as follows:

Alterations, if applicable, will be incorporated by contract modification.

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (NOV 2020)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any Defense Federal Acquisition Regulation Supplement (48 CFR Chapter 2) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR

EXECUTIVE ORDERS--COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (DEC 2023)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (DEC 2023) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (NOV 2015).

(5) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (MAR 2023) (31 U.S.C. 3903 and 10 U.S.C. 3801).

(6) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(7) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004s) (Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services: [Contracting Officer check as appropriate.]

___ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (JUN 2020), with Alternate I (NOV 2021) (41 U.S.C. 4704 and 10 U.S.C. 4655).

___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (NOV 2021) (41 U.S.C. 3509).

___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (JUN 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

___ (4) 52.203-17, Contractor Employee Whistleblower Rights (NOV 2023) (41 U.S.C. 4712); this clause does not apply to contracts of DoD, NASA, the Coast Guard, or applicable elements of the intelligence community--see FAR 3.900(a).

___ (5) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (JUN 2020) (Pub. L.

109-282) (31 U.S.C. 6101 note).

___ (6) [Reserved]

___ (7) 52.204-14, Service Contract Reporting Requirements (OCT 2016) (Pub. L. 111-117, section 743 of Div.

C).

___ (8) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (OCT 2016) (Pub.

L. 111-117, section 743 of Div. C).

XXX (9) 52.204-27, Prohibition on a ByteDance Covered Application (JUN 2023) (Section 102 of Division R of Pub. L. 117-328).

___ (10) 52.204-28, Federal Acquisition Supply Chain Security Act Orders--Federal Supply Schedules, Governmentwide Acquisition Contracts, and Multi-Agency Contracts. (DEC 2023) (Pub. L. 115-390, title II).

___ (11)(i) 52.204-30, Federal Acquisition Supply Chain Security Act Orders--Prohibition. (DEC 2023) (Pub. L.

115-390, title II).

___ (ii) Alternate I (DEC 2023) of 52.204-30.

XXX (12) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (NOV 2021) (31 U.S.C. 6101 note).

___ (13) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (OCT 2018) (41 U.S.C. 2313).

____ (14) [Reserved]

____ (15) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (OCT 2022) (15 U.S.C. 657a).

____ (16) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2022) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

____ (17) [Reserved]

XXX (18)(i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2020) (15 U.S.C. 644).

____ (ii) Alternate I (MAR 2020) of 52.219-6.

____ (19)(i) 52.219-7, Notice of Partial Small Business Set-Aside (NOV 2020) (15 U.S.C. 644).

____ (ii) Alternate I (MAR 2020) of 52.219-7.

____ (20) 52.219-8, Utilization of Small Business Concerns (SEP 2023) (15 U.S.C. 637(d)(2) and (3)).

____ (21)(i) 52.219-9, Small Business Subcontracting Plan (SEP 2023) (15 U.S.C. 637(d)(4)).

____ (ii) Alternate I (NOV 2016) of 52.219-9.

____ (iii) Alternate II (NOV 2016) of 52.219-9.

____ (iv) Alternate III (JUN 2020) of 52.219-9.

____ (v) Alternate IV (SEP 2023) of 52.219-9.

____ (22) (i) 52.219-13, Notice of Set-Aside of Orders (MAR 2020) (15 U.S.C. 644(r)).

____ (ii) Alternate I (MAR 2020) of 52.219-13.

____ (23) 52.219-14, Limitations on Subcontracting (OCT 2022) (15 U.S.C. 657s).

____ (24) 52.219-16, Liquidated Damages—Subcontracting Plan (SEP 2021) (15 U.S.C. 637(d)(4)(F)(i)).

____ (25) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (OCT 2022) (15 U.S.C.

657f).

____ (26) (i) 52.219-28, Post-Award Small Business Program Rerepresentation (SEP 2023) (15 U.S.C. 632(a)(2)).

____ (ii) Alternate I (MAR 2020) of 52.219-28.

____ (27) 52.219-29, Notice of Set-Aside for, or Sole-Source Award to, Economically Disadvantaged Women- Owned Small Business Concerns (OCT 2022) (15 U.S.C. 637(m)).

____ (28) 52.219-30, Notice of Set-Aside for, or Sole-Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (OCT 2022) (15 U.S.C. 637(m)).

____ (29) 52.219-32, Orders Issued Directly Under Small Business Reserves (MAR 2020) (15 U.S.C. 644(r)).

XXX (30) 52.219-33, Nonmanufacturer Rule (SEP 2021) (15 U.S.C. 657s).

XXX (31) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

XXX (32) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (NOV 2023) (E.O. 13126).

XXX (33) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

XXX (34)(i) 52.222-26, Equal Opportunity (SEP 2016) (E.O. 11246).

____ (ii) Alternate I (FEB 1999) of 52.222-26.

XXX (35)(i) 52.222-35, Equal Opportunity for Veterans (JUN 2020) (38 U.S.C. 4212).

____ (ii) Alternate I (JUL 2014) of 52.222-35.

XXX (36)(i) 52.222-36, Equal Opportunity for Workers with Disabilities (JUN 2020) (29 U.S.C. 793).

____ (ii) Alternate I (JUL 2014) of 52.222-36.

XXX (37) 52.222-37, Employment Reports on Veterans (JUN 2020) (38 U.S.C. 4212).

XXX (38) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O.

13496).

XXX (39)(i) 52.222-50, Combating Trafficking in Persons (NOV 2021) (22 U.S.C. chapter 78 and E.O. 13627).

____ (ii) Alternate I (MAR 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

____ (40) 52.222-54, Employment Eligibility Verification (MAY 2022). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in FAR 22.1803.)

____ (41)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (MAY 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

____ (ii) Alternate I (MAY 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

____ (42) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (JUN 2016) (E.O. 13693).

____ (43) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners

(JUN 2016) (E.O. 13693).

XXX (44)(i) 52.223-13, Acquisition of EPEAT® Registered Imaging Equipment (JUN 2014) (E.O.s 13423 and 13514).

____ (ii) Alternate I (OCT 2015) of 52.223-13.

____ (45)(i) 52.223-14, Acquisition of EPEAT® Registered Televisions (JUN 2014) (E.O.s 13423 and 13514).

____ (ii) Alternate I (JUN 2014) of 52.223-14.

____ (46) 52.223-15, Energy Efficiency in Energy-Consuming Products (MAY 2020) (42 U.S.C. 8259b).

____ (47)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (OCT 2015) (E.O.s 13423 and 13514).

____ (ii) Alternate I (JUN 2014) of 52.223-16.

XXX (48) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (JUN 2020) (E.O.

13513).

XXX (49) 52.223-20, Aerosols (JUN 2016) (E.O. 13693).

XXX (50) 52.223-21, Foams (JUN 2016) (E.O. 13693).

____ (51)(i) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

____ (ii) Alternate I (JAN 2017) of 52.224-3.

____ (52) (i) 52.225-1, Buy American--Supplies (OCT 2022) (41 U.S.C. chapter 83).

____ (ii) Alternate I (OCT 2022) of 52.225-1.

____ (53)(i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (NOV 2023) (19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, 19 U.S.C. chapter 29 (sections 4501-4732), Public Law 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

____ (ii) Alternate I [Reserved].

____ (iii) Alternate II (DEC 2022) of 52.225-3.

____ (iv) Alternate III (NOV 2023) of 52.225-3.

____ (v) Alternate IV (OCT 2022) of 52.225-3.

____ (54) 52.225-5, Trade Agreements (NOV 2023) 19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

XXX (55) 52.225-13, Restrictions on Certain Foreign Purchases (FEB 2021) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

____ (56) 52.225-26, Contractors Performing Private Security Functions Outside the United States (OCT 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

____ (57) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (NOV 2007) (42 U.S.C. 5150

____ (58) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (NOV 2007) (42 U.S.C.

5150).

____ (59) 52.229-12, Tax on Certain Foreign Procurements (FEB 2021).

____ (60) 52.232-29, Terms for Financing of Purchases of Commercial Products and Commercial Services (NOV 2021) (41 U.S.C. 4505, 10 U.S.C. 3805).

____ (61) 52.232-30, Installment Payments for Commercial Products and Commercial Services (NOV 2021) (41 U.S.C. 4505, 10 U.S.C. 3805).

XXX (62) 52.232-33, Payment by Electronic Funds Transfer—System for Award Management (OCT 2018) (31 U.S.C. 3332).

____ (63) 52.232-34, Payment by Electronic Funds Transfer—Other than System for Award Management (JUL 2013) (31 U.S.C. 3332).

____ (64) 52.232-36, Payment by Third Party (MAY 2014) (31 U.S.C. 3332).

____ (65) 52.239-1, Privacy or Security Safeguards (AUG 1996) (5 U.S.C. 552a).

XXX (66) 52.242-5, Payments to Small Business Subcontractors (JAN 2017)(15 U.S.C. 637(d)(13)).

____ (67)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (NOV 2021) (46 U.S.C.

55305 and 10 U.S.C. 2631).

____ (ii) Alternate I (APR 2003) of 52.247-64.

____ (iii) Alternate II (NOV 2021) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services: [Contracting Officer check as appropriate.]

_____ (1) 52.222-41, Service Contract Labor Standards (AUG 2018) (41 U.S.C. chapter 67).

_____ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (MAY 2014) (29 U.S.C. 206 and 41 U.S.C.

chapter 67).

_____ (3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (Multiple Year and Option Contracts) (AUG 2018) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

_____ (4)…