Attachment 6 ASI 02 REV 02 REMOVE ALTERNATES.pdf

This document is an Architect's Supplemental Instructions (ASI) for the Reconfigure Outpatient Rehab Medicine project at the Olin E. Teague Veterans Center in Temple, Texas. The ASI, issued by Enapay, LLC, revises the project drawings and specifications to remove all project alternates, specifically affecting sheets A-000, A-001, and specification section 01 32 16.15. The revision is dated 03/24/2025 and is part of VA Project #674-21-101, indicating a modification to the original project scope to streamline the contract requirements.

The supplemental instructions detail comprehensive project scheduling requirements, including the contractor's responsibilities for developing and maintaining a Critical Path Method (CPM) plan, submitting monthly computer-produced time/cost schedules, and providing detailed project schedule updates. Key requirements include breaking work into activities/events of no more than 20 work days, submitting schedule changes within specified timeframes, and ensuring all general contractor and subcontractor work activities are included. The document emphasizes the need for precise schedule tracking, cost loading of activities, and coordination with the Contracting Officer's Representative (COTR) throughout the project lifecycle.