Attachment 2 Applicable Clauses.pdf

CLAUSES

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

FAR Overhaul (DEVIATIONS JAN 2026): https://www.acquisition.gov/far-overhaul/far-part-deviation-guide CAR: https://www.ecfr.gov/current/title-48/chapter-13

(End of clause)

CLAUSES INCORPORATED BY REFERENCE:

52.203-17 Contractor Employee Whistleblower Rights (Nov 2023) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards(DEVIATION JAN 2026) 52.204-13 System For Award Management Maintenance (Deviation Jan 2026) 52.204-19 Incorporation By Reference Of Representations And Certifications (Dec 2014) 52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded (DEVIATION JAN 2026) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (DEVIATION JAN 2026) 52.219-8, Utilization of Small Business Concerns (DEVIATION JAN 2026) 52.219-28, Post-award Small Business Program Re-representation (DEVIATION JAN 2026) 52.222-3, Convict Labor (Jun 2003) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (DEVIATION JAN 2026) 52.222-36, Equal Opportunity for Workers with Disabilities (DEVIATION JAN 2026) 52.222-50, Combating Trafficking in Persons (DEVIATION JAN 2026) 52.223-23, Sustainable Products and Services (May 2024) 52.225-1, Buy American-Supplies (DEVIATION JAN 2026) 52.226-8, Encouraging Contractor Policies to Ban Text Messaging While Driving (May 2024) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Oct2018) 52.232-39 Unenforceability of Unauthorized Obligations (JUNE 2013) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) 52.233-3, Protest After Award (DEVIATION JAN 2026) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) 52.240-91 Security Prohibitions and Exclusions (DEVIATION JAN 2026) 52.252-5 Authorized Deviations in Clauses (NOV 2020) 1352.201-70 Contracting Officer Authority (APR 2010) 1352.209-73 Compliance With The Laws (APR 2010) 1352.209-74 Organizational Conflict Of Interest (APR 2010)

Full Text Clauses:

FAR 52.212-4 TERMS AND CONDITIONS—COMMERCIAL PRODUCTS AND COMMERCIAL

https://www.acquisition.gov/far-overhaul/far-part-deviation-guide https://www.acquisition.gov/far-overhaul/far-part-deviation-guide https://www.ecfr.gov/current/title-48/chapter-13

SERVICES (DEVIATION DATE)

(a) Definitions. The clause at Federal Acquisition Regulation (FAR) 52.202-1, Definitions, is incorporated by reference.

(b) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price.

If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post acceptance rights—

(1) Within a reasonable time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(c) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C. 3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract.

(d) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties.

(e) Disputes. This contract is subject to 41 U.S.C. chapter 71, Contract Disputes. Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal, or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause FAR 52.233-1, Disputes, which is incorporated in this contract by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract.

(f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence.

Examples of occurrences include acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. When an excusable delay occurs, the Contractor shall—

(1) Notify the Contracting Officer in writing as soon as possible;

(2) Remedy the delay as quickly as possible; and

(3) Notify the Contracting Officer when the occurrence is over.

(g) Invoice. The Government will handle invoices according to the Prompt Payment Act (31 U.S.C.

3903) and 5 CFR part 1315. The Contractor shall submit invoices to the address designated in the contract to receive invoices. An invoice must include the information required by 5 CFR part 1315.9(b).

(h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees, and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark, or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings.

(i) Payment—

(1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract.

(2) Prompt payment. The Government will make payment in accordance with the Prompt Payment Act ( 31 U.S.C. 3903) and prompt payment regulations at 5 CFR part 1315.

(3) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date that appears on the payment check or the specified payment date if an electronic funds transfer payment is made.

(4) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall—

(i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the—

(A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);

(B) Affected contract number and delivery order number, if applicable;

(C) Affected line item or subline item, if applicable;

(D) Contractor point of contact; and

(ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer.

(5) Interest.(i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C. 7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period as fixed by the Secretary until the amount is paid.

(ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.

(iii) Final decisions. The Contracting Officer will issue a final decision as required by FAR part 33 if–

(A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days;

(B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or

(C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see FAR part 32).

(iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment.

(v) Amounts shall be due at the earliest of the following dates:

(A) The date fixed under this contract.

(B) The date of the first written demand for payment, including any demand for payment resulting from a termination for cause.

(vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on-

(A) The date on which the designated office receives payment from the Contractor;

(B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or

(C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.

(vii) The interest charge made under this clause may be reduced under the procedures for interest credits prescribed in FAR part 32 in effect on the date of this contract.

(j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon—

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination.

(k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties.

(l) Termination for the Government’s convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor’s records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided.

(m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. The Government will send a cure notice to the Contractor, unless the reason for the termination is late delivery. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession.

(o) Warranty. The Contractor warrants and implies that the items delivered under this contract are merchantable and fit for use for the particular purpose described in this contract.

(p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items.

(q) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 40 U.S.C. chapter 37, Contract Work Hours and Safety Standards; 41 U.S.C. chapter 87, Kickbacks; 49 U.S.C. 40118, Government-financed air transportation; and 41 U.S.C. chapter 21 relating to procurement integrity.

(r) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order:

(1) The schedule of supplies/services;

(2) The Disputes, Payments, Invoice, Compliance with Laws Unique to Government Contracts, and Unauthorized Obligations paragraphs of this clause;

(3) Other contract clauses incorporated in the solicitation or contract;

(4) Addenda to this solicitation or contract;

(5) Solicitation provisions incorporated in the solicitation;

(6) Other paragraphs of this clause;

(7) Other documents, exhibits, and attachments; and

(8) The specification.

(s) Unauthorized obligations.

(1) Except as stated in paragraph (s)(2) of this clause, when any supply or service acquired under this contract is subject to any End User License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C. 1341), the following shall govern:

(i) Any such clause is unenforceable against the Government.

(ii) Neither the Government nor any Government-authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an “I agree” click box or other comparable mechanism (e.g., “click-wrap” or “browse-wrap” agreements), execution does not bind the Government or any Government authorized end user to such clause.

(iii) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement.

(2) Paragraph (s)(1) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures.

(t) Comptroller General examination of record. This paragraph applies if this contract was awarded using other than sealed bid procedures and is in excess of the simplified acquisition threshold on the date of award of this contract.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices, at all reasonable times, the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR part 4, longer period required by statute, or periods specified in other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This clause does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(u) Incorporation by reference. The Contractor’s representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

1352.233-70 AGENCY PROTESTS (APR 2010)

(a) An agency protest may be filed with either: (1) the contracting officer, or (2) at a level above the contracting officer, with the appropriate agency Protest Decision Authority. See 64 Fed.

Reg. 16,651 (April 6, 1999)

(b) Agency protests filed with the Contracting Officer shall be sent to the following address:

ATTN: Forest Crumpler, CONTRACTING OFFICER 100 Bureau Drive, MS 1640 Gaithersburg, MD 20899

(c) Agency protests filed with the agency Protest Decision Authority shall be sent to the following address: ATTN: NIST PROTEST CONTROLLER 100 Bureau Drive, MS 1640 Gaithersburg, MD 20899

(d) A complete copy of all agency protests, including all attachments, shall be served upon the Contract Law Division of the Office of the General Counsel within one day of filing a protest with either the Contracting Officer or the Protest Decision Authority.

(e) Service upon the Contract Law Division shall be made as follows:

U.S. Department of Commerce Office of the General Counsel Chief, Contract Law Division Room 5893 Herbert C. Hoover Building 14th Street and Constitution Avenue, N.W.

Washington, D.C. 20230.

FAX: (202) 482-5858

1352.233-71 GAO AND COURT OF FEDERAL CLAIMS PROTESTS (APR 2010)

(a) A protest may be filed with either the Government Accountability Office (GAO) or the Court of Federal Claims unless an agency protest has been filed.

(b) A complete copy of all GAO or Court of Federal Claims protests, including all attachments, shall be served upon (i) the Contracting Officer, and (ii) the Contract Law Division of the Office of the General Counsel, within one day of filing a protest with either GAO or the Court of Federal Claims.

(c) Service upon the Contract Law Division shall be made as follows:

U.S. Department of Commerce Office of the General Counsel Chief, Contract Law Division Room 5893 Herbert C. Hoover Building 14th Street and Constitution Avenue Washington, D.C. 20230.

FAX: (202) 482-5858

1352.246-70 PLACE OF ACCEPTANCE (APR 2010)

(a) The Contracting Officer or the duly authorized representative will accept supplies and services to be provided under this contract.

(b) The place of acceptance will be:

National Institute of Standards and Technology 100 Bureau Drive, Gaithersburg, MD 20899 (End of clause)

NIST LOCAL-53 CONTRACT PERFORMANCE DURING CHANGES IN NIST OPERATING STATUS

All contractors performing work on active contracts at the U.S. Department of Commerce (DOC), National Institute of Standards and Technology (NIST) campuses and/or working in NIST workspaces should go to the www.nist.gov website and under the "About NIST" tab click on "Visit". This site includes information about campus access and security information; identification requirements; parking information and more.

Contractor personnel are required to check the appropriate campus operating status and personnel requirements at https://www.nist.gov/campus-status daily prior to arriving on site. All personnel must adhere to the requirements set forth in the operating status.

Unless otherwise stated in the contract terms and conditions, normal days of business operation are Monday through Friday, excluding Federal Holidays. However, throughout the contract period of performance, there may be circumstances beyond the control of NIST that will impact normal days of business operation such as inclement weather, power outages, etc. In circumstances such as these, the Contractor must call the appropriate NIST campus status line to verify the operating status:

Gaithersburg Campus Operating Status Line:

(301) 975-8000

(800) 437-4385 x8000 (toll free) Boulder Campus Operating Status Line:

(303) 497-4000

(303) 497-3000 option 2

In the event of a lapse in appropriation, access to Government facilities and resources, including equipment and systems will be limited to excepted personnel for both Federal employees and contractor personnel. If performance of the contract is onsite and/or requires Government interaction, unless the contractor has been, or is notified that it is required to work under an excepted status, the contractor must stop work. The work stoppage shall remain in effect until the lapse is resolved and notification is provided via the NIST website at www.nist.gov (banner on front page) and/or the NIST operating status line(s). Additionally, contractors are encouraged to monitor public broadcasts or the Office of Personnel Management's website at www.opm.gov for the Federal Government operating status.

NIST will provide notification to all contractors that are determined to have excepted status.

All excepted contractors are required to continue performance and communicate with the appointed Contracting Officer's Representative (COR) for further guidance, or NIST Contracting Officer if a COR is not appointed.

Contractors with active supply or service contracts that are fully funded at the time of contract award and do not require access to Government facilities, resources, or active administration by Government personnel in a manner that would not cause the Government to incur additional obligations during the lapse in appropriation may continue performance.

Please note that in all circumstances that impact operations on the NIST campuses, contractors are expected to follow all direction guidance provided by NIST authorities.

NIST LOCAL-54 ELECTRONIC BILLING INSTRUCTIONS

NIST requires that Invoice/Voucher submissions are sent electronically via email to

INVOICE@NIST.GOV.

Each Invoice or Voucher submitted shall include the following:

(1) Contract number;

(2) Contractor name and address;

(3) Unique entity identifier (see www.sam.gov for the designated entity for establishing unique entity identifiers);

(4) Date of invoice;

(5) Invoice number;

(6) Amount of invoice and cumulative amount invoiced to-date;

(7) Contract Line Item Number (CLIN);

(8) Description, quantity, unit of measure, unit price, and extended price of supplies/services delivered;

(9) Prompt payment discount terms, if offered; and

(10) Any other information or documentation required by the contract.

NIST LOCAL-56 INVOICING PROCESSING PLATFORM-ALTERNATE I (DEC 2022)

Upon written notice from the contracting officer the following supersedes all other instructions for the submission of payment requests. Accordingly, following written notice payment requests must be submitted electronically through the U.S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable payment request or invoicing instructions, Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

The Contractor must use the IPP website to register, access, and use IPP for submitting payment requests. If not already enrolled, the Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email within three to five business days of the addition of the contract award to IPP. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email: IPPCustomerSupport@fiscal.treasury.gov or phone

(866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting payment requests, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation. Contact the contracting officer for more information on submitting a waiver request