Attachment 1- Performance Work Statement.pdf

Performance Work Statement USS Bataan

1. Purpose

The USS Bataan received new griddles that require modification to the existing food service lines to accommodate the new equipment. Additionally, the USS Bataan requires the procurement of new proofing cabinets and installation to support the galley modifications. Manufacturer of the griddles is AccuTemp and the part number is EGD4403B3606-00. Manufacturer of the proofing cabinets is Crescor, and the model number 130-1836D or equivalent item.

2. Scope

The USS Bataan will be responsible for the disposal of old equipment from the ship and supplying the Contactor with the new griddles; however, the proofing boxes are required to be provided by the Contractor as stipulated below.

The Contractor shall provide personnel to complete the following functions:

CLIN 0001: Main Galley Modifications

Remove two (2) existing griddles and modify counters to accommodate new griddles.

Disconnect the griddles from the breaker and lift griddle out of the counter tops.

The Contractor will need to weld a support bar to accommodate the new 36” griddles.

Install new 36” griddles bolt SYM box on the underside of each griddle on existing framework. Run power using LSTSGU-9 cable and perform resistance checks.

Each 36” griddle provided will be replacing the pre-existing 72” griddles. Therefore, a total of four (4) 36” inch griddles will be installed in the space.

Install a support bar to maintain installation integrity Seal with permagum Mount controls in front panel of each griddle and bring up to 350 degrees to test of proper operation.

Provide and Install four (4) new proofing boxes.

o Proofing boxes shall be Crescor, model number 130-1836D or equivalent item o All contractor will have to do is disconnect the existing proofing boxes from power and remove them from the space and install the 4 new ones.

The Contractor shall be responsible for the removal and installation of griddles, and performing tests upon completion.

CLIN 0002: CPO Galley Modifications

Remove one (1) existing griddle and modify counters to accommodate the new griddle.

Disconnect the griddle from the breaker and lift griddle out of the counter tops.

Counter modification required: Existing griddle is 46”; however, the new griddle to be installed is 36”;

therefore, the counter will require modification to fit the griddle appropriately.

Run power using LSTSGU-9 cable and perform resistance checks.

Seal with permagum.

Mount controls in front panel of each griddle and bring up to 350 degrees to test of proper operation.

The contractors shall be responsible for the removal and installation of griddles, and performing tests upon

CLIN 0003: Wardroom Modifications

Remove one (1) existing griddle and modify counters to accommodate the two new 36” griddles.

Disconnect Griddle from breaker and lift griddle out of counter tops.

The Contractor will need to weld a support bar to accommodate new 36” griddles.

Install 2 new 36” griddles bolt SYM box on the underside of each griddle on existing framework. Run power using LSTSGU-9 cable and perform resistance checks.

o Each 36” griddle provided will be replacing the pre-existing 72” griddle. Therefore, a total of two

(2) 36” inch griddles will be installed in the space.

o Install a support bar to maintain installation integrity

Seal with permagum.

Mount controls in front panel of each griddle and bring up to 350 degrees to test of proper operation.

The contractors shall be responsible for the removal and installation of griddles, and performing tests upon

3. Period and Place of Performance

The location of performance is the USS Bataan located at 200 Ligon St Norfolk, Virginia NASSCO Ship Yards.

The required period of performance is the date of contract award to July 15, 2021.

4. 5237.102-90 Enterprise-wide Contractor Manpower Reporting Application (ECMRA)

Services Contract Reporting (SCR) requirements apply to this contract. The Contractor shall report required SCR data fields using the SCR section of the System for Award Management (SAM) at following web address:

https://sam.gov/SAM/.

Reporting inputs will be for the labor executed during the period of performance during each Government fiscal year (FY), which runs October 1 through September 30. While inputs may be reported any time during the FY, all data shall be reported no later than October 31 of each calendar year. Contractors may direct questions to the help desk, linked at https://sam.gov/SAM/.

***Wage Determination 2015-4341 Revision No. 15 Dated 12/21/2020 is incorporated into this contract, or its latest revision***

5. Contractor Unclassified Access to Federally Controlled Facilities, Sensitive Information, Information Technology (IT) Systems or Protected Health Information

Executive Order 13467, Reforming Processes Related to Suitability for Government Employee, Fitness for Contractor Employees and Eligibility for Access to Classified National Security Information, Homeland Security Presidential Directive (HSPD)-12, requires government agencies to develop and implement Federal security standards for Federal employees and contractors. The 5 CFR 32 Part 157 in concert with DoD Manual 1000.13, Vol 1, implements the Federal Standards.

APPLICABILITY

This text applies to all DoD sponsored individuals who require CAC eligibility (or login and P/W if acceptable per contract) for: Physical access to DoD facilities or non-DoD facilities on behalf of DoD; Logical access to information systems (whether on site or remotely); or remote access to DoD networks that use only the CAC logon for user authentication, or access to sensitive and protected information. This applies to the Office of the Secretary of Defense, the Military Departments, the Office of the Chairman of the Joint Chiefs of Staff and the Joint Staff, the Combatant Commands, the Office of the Inspector General of the DoD, the Defense Agencies, the DoD Field Activities and all other organizational entities within the DoD (hereinafter referred to collectively as the "DoD Components").

Each contractor employee providing services at a Navy Command under this contract is required to obtain a Department of Defense Common Access Card (DoD CAC). Additionally, depending on the level of computer/network access, the contract employee will require a successful investigation as detailed below.

ACCESS TO FEDERAL FACILITIES

Per HSPD-12 and implementing guidance, all contractor employees working at a federally controlled base, facility or activity under this clause will require a DoD CAC. When access to a base, facility or activity is required contractor employees shall in-process with the Command’s Security Manager upon arrival to the Command and shall out-process prior to their departure at the completion of the individual’s performance under the contract.

START-UP PERIOD

All contractor resource onboarding documents must be submitted via the prime contractor. The prime contractor shall make all necessary preparations to assume full responsibility for productive performance of the performance start date.

Definition of “productive”:

a. Visit Authorization Request (VAR)

b. Contractor Information Sheet (CIS)

c. Completed EQIP (Electronic Investigation)

d. All contractor resource(s) must have an active JPAS profile.

e. Common Access Card (CAC)

Note (1): Invoicing by the contractor will begin as of the commencement of the performance period of services and no reimbursement will be paid by the government for efforts expended during the start-up period.

Note (2): Foreign Nationals are not allowed acces sot the functional/system side of Enterprise Resource Planning

(ERP).

ACCESS TO DOD INFORMATION TECHNOLOGY ( IT) SYSTEMS

In accordance with (IAW) Secretary of the Navy (SECNAV) M-5510.30, contractor employees who require access to DoN or DoD networks are categorized as IT-I, IT-II, or IT-III. The IT-II level, defined in detail in SECNAV M- 5510.30, includes positions which require access to sensitive information. Sensitive information includes information protected under the Privacy Act, to include Protected Health Information (PHI). All contractor employees under this contract who require access to Privacy Act protected information are therefore categorized no lower than IT-II. IT Levels are determined by the requiring activity’s Command Information System Security Manager (ISSM)/Information Assurance Manager (IAM).

Contractor employees requiring privileged or IT-I level access, (when specified by the terms of the contract) require a Single Scope Background Investigation (SSBI) or T5 or T5R equivalent investigation , which is a higher level investigation than the National Agency Check with Law and Credit (NACLC)/T3/T3R described below. Due to the privileged system access, an investigation suitable for High Risk national security positions is required. Individuals who have access to system control, monitoring, or administration functions (e.g. system administrator, database administrator) require training and certification to Information Assurance Technical Level 1, and must be trained and certified on the Operating System or Computing Environment they are required to maintain.

Access to sensitive IT systems is contingent upon a favorably adjudicated background investigation. When access to IT systems is required for performance of the contractor employee’s duties, such employees shall in-process with the Navy Command’s CSM and ISSM/IAM upon arrival to the Navy command and shall out-process prior to their departure at the completion of the individual’s performance under the contract. Completion and approval of a System Authorization Access Request Navy (SAAR-N) form is required for all individuals accessing Navy Information Technology resources. The decision to authorize access to a government IT system/network is inherently governmental. The contractor supervisor is not authorized to sign the SAAR-N; therefore, the government employee with knowledge of the system/network access required or the COR shall sign the SAAR-N as the “supervisor”.

The SAAR-N shall be forwarded to the Command’s Security Manager at least 30 days prior to the individual’s start date. Failure to provide the required documentation at least 30 days prior to the individual’s start date may result in delaying the individual’s start date.

When required to maintain access to required IT systems or networks, the contractor shall ensure that all employees requiring access complete annual Cyber Awareness training, and maintain a current requisite background investigation. The Contractor’s Security Representative shall contact the Command Security Manager for guidance when reinvestigations are required.

INTERIM ACCESS

The Command's Security Manager may authorize issuance of a DoD CAC and interim access to a DoN or DoD unclassified computer/network upon a favorable review of the investigative questionnaire and advance favorable fingerprint results. When the results of the investigation are received and a favorable determination is not made, the contractor employee working on the contract under interim access will be denied access to the computer network and this denial will not relieve the contractor of his/her responsibility to perform.

DENIAL OR TERMINATION OF ACCESS

The potential consequences of any requirement under this clause including denial or termination of physical or system access in no way relieves the contractor from the requirement to execute performance under the contract within the timeframes specified in the contract. Contractors shall plan ahead in processing their employees and subcontractor employees. The contractor shall insert this clause in all subcontracts when the subcontractor is permitted to have unclassified access to a federally controlled facility, federally-controlled information system/network and/or to government information, meaning information not authorized for public release.

CONTRACTOR’S SECURITY REPRESENTATIVE

The contractor shall designate an employee to serve as the Contractor’s Security Representative. Within three work days after contract award, the contractor shall provide to the requiring activity’s Security Manager and the Contracting Officer, in writing, the name, title, address and phone number for the Contractor’s Security Representative. The Contractor’s Security Representative shall be the primary point of contact on any security matter. The Contractor’s Security Representative shall not be replaced or removed without prior notice to the Contracting Officer and Command Security Manager.

BACKGROUND INVESTIGATION REQUIREMENTS AND SECURITY APPROVAL PROCESS FOR

CONTRACTORS ASSIGNED TO NATIONAL SECURITY POSITIONS OR PERFORMING SENSITIVE

DUTIES

Navy security policy requires that all positions be given a sensitivity value based on level of risk factors to ensure appropriate protective measures are applied. Contractor employees under this contract are recognized as Non-Critical Sensitive [ADP/IT-II] positions when the contract scope of work require physical access to a federally controlled base, facility or activity and/or requiring access to a DoD computer/network, to perform unclassified sensitive duties. This designation is also applied to contractor employees who access Privacy Act and Protected Health Information (PHI), provide support associated with fiduciary duties, or perform duties that have been identified as National Security Positions. At a minimum, each contractor employee must be a US citizen and have a favorably completed NACLC or T3 or T3R equivalent investigation to obtain a favorable determination for assignment to a non-critical sensitive or IT-II position. The investigation consists of a standard NAC and a FBI fingerprint check plus law enforcement checks and credit check. Each contractor employee filling a non-critical sensitive or IT-II position is required to complete:

SF-86 Questionnaire for National Security Positions (or equivalent OPM investigative product) Two FD-258 Applicant Fingerprint Cards (or an electronic fingerprint submission) Original Signed Release Statements

Failure to provide the required documentation at least 30 days prior to the individual’s start date shall result in delaying the individual’s start date. Background investigations shall be reinitiated as required to ensure investigations remain current (not older than 10 years) throughout the contract performance period. The Contractor’s Security Representative shall contact the Command Security Manager for guidance when reinvestigations are required.

Regardless of their duties or IT access requirements ALL contractor employees shall in-process with the CSM upon arrival to the command and shall out-process prior to their departure at the completion of the individual’s performance under the contract. Employees requiring IT access shall also check-in and check-out with the Navy Command’s ISSM/IAM. Completion and approval of a System Authorization Access Request Navy (SAAR-N) form is required for all individuals accessing Navy Information Technology resources. The SAAR-N shall be forwarded to the Navy Command’s Security Manager at least 30 days prior to the individual’s start date. Failure to provide the required documentation at least 30 days prior to the individual’s start date shall result in delaying the individual’s start date.

The contractor shall ensure that each contract employee requiring access to IT systems or networks complete annual Cyber Awareness training, and maintain a current requisite background investigation. Contractor employees shall accurately complete the required investigative forms prior to submission to the Command Security Manager. The Command’s Security Manager will review the submitted documentation for completeness prior to submitting it to the Office of Personnel Management (OPM); Potential suitability or security issues identified may render the contractor employee ineligible for the assignment. An unfavorable determination is final (subject to SF-86 appeal procedures) and such a determination does not relieve the contractor from meeting any contractual obligation under the contract.

The Command’s Security Manager will forward the required forms to OPM for processing. Once the investigation is complete, the results will be forwarded by OPM to the DoD Central Adjudication Facility (CAF) for a determination.

If the contractor employee already possesses a current favorably adjudicated investigation, the contractor shall submit a Visit Authorization Request (VAR) via the Joint Personnel Adjudication System (JPAS) or a hard copy VAR directly from the contractor’s Security Representative. Although the contractor will take JPAS “Owning” role over the contractor employee, the Navy command will take JPAS "Servicing" role over the contractor employee during the hiring process and for the duration of assignment under that contract. The contractor shall include the IT Position Category per SECNAV M-5510.30 for each employee designated on a VAR. The VAR requires annual renewal for the duration of the employee’s performance under the contract.

BACKGROUND INVESTIGATION REQUIREMENTS AND SECURITY APPROVAL PROCESS FOR

CONTRACTORS ASSIGNED TO OR PERFORMING NON-SENSITIVE DUTIES

Contractor employee whose work is unclassified and non-sensitive (e.g., performing certain duties such as lawn maintenance, vendor services, etc. ...) and who require physical access to publicly accessible areas to perform those duties shall meet the following minimum requirements:

Must be either a US citizen or a US permanent resident with a minimum of 3 years of legal residency in the United

States (as required by The Deputy Secretary of Defense DTM 08-006 or its subsequent DoD instruction) and Must have a favorably completed National Agency Check with Written Inquiries (NACI) or T1 investigation equivalent including a FBI fingerprint check prior to installation access.

To be considered for a favorable trustworthiness determination, the Contractor’s Security Representative must submit for all employees each of the following:

SF-85 Questionnaire for Non-Sensitive Positions Two FD-258 Applicant Fingerprint Cards (or an electronic fingerprint submission) Original Signed Release Statements

The contractor shall ensure each individual employee has a current favorably completed National Agency Check with Written Inquiries (NACI) or T1 equivalent investigation, or ensure successful FBI fingerprint results have been gained and investigation has been processed with OPM

Failure to provide the required documentation at least 30 days prior to the individual’s start date may result in delaying the individual’s start date.

* Consult with your CSM and ISSM/IAM for local policy when IT-III (non-sensitive) access is required for non-US citizens outside the United States.

6. AbilityOne

NAVSUP FLCN may utilize contractor support through the AbilityOne Program, as needed, to perform contract closeout functions for this acquisition. Information, including business sensitive/confidential or proprietary data, that the offeror provides to the Government or information already in the possession of the Government may be viewed and utilized by the AbilityOne Program support contractor personnel during the course of its contract performance.

The information that may be made available to the support contractor may include, for example, pricing and technical proposals, historical contract, pricing and performance information, Commercial Asset Visibility (CAV) reporting information and similar data/information.

By submission of a proposal in response to this solicitation, the offeror and its subcontractors consent to a release of their business sensitive/confidential or proprietary data to the Government's AbilityOne Program support contractor personnel in order to perform close out services. Prior to the release of any such information to the support contractor, the support contractor will have in place with the Government a Non-Disclosure/Non-Use Agreement in accordance with the terms of the AbilityOne Program support contract.

Offerors may execute their own Non-Disclosure Agreement with the AbilityOne Program (AbilityOne contact information available from the contracting point of contact). The support contractor must provide copies of the executed agreements to the Contracting Officer and the Contracting Officer's Representative (COR) for the support contract; and the offeror/contractor for this acquisition must provide copies of the executed Agreement to the Contracting Officer for this acquisition. If the offeror/contractor seeks such a Non-Disclosure Agreement with the AbilityOne Program support contractor, the Agreement must be executed no later than the date of final delivery under the resulting NAVSUP FLCN contract.

7. AUTHORIZED CHANGES ONLY BY THE CONTRACTING OFFICER

(a) Except as specified in paragraph (b) below, no order, statement, or conduct of Government personnel who visit the Contractor's facilities or in any other manner communicate with Contractor personnel during the performance of this contract shall constitute a change under the "Changes" clause of this contract.

(b) The Contractor shall not comply with any order, direction or request of Government personnel unless it is issued in writing and signed by the Contracting Officer, or is pursuant to specific authority otherwise included as a part of this contract.

(c) The Contracting Officer is the only person authorized to approve changes in any of the requirements of this contract and notwithstanding provisions contained elsewhere in this contract, the said authority remains solely with the Contracting Officer. In the event the Contractor effects any change at the direction of any person other than the Contracting Officer, the change will be considered to have been made without authority and no adjustment will be made in the contract price to cover any increase in charges incurred as a result thereof. The address and telephone number of the Contracting Officer is:

NAME: Amber Bradley EMAIL ADDRESS: amber.bradley@navy.mil

TELEPHONE: 757-443-1968