ASHE21-2001_ADD 1R.pdf

PDF 211 KB Posted

Attached to
ASHE 21-2001 UPGRADE COMM FACILITIES AND INFRASTRUCTURE AVIANO AB, ITALY
Solicitation number
FA568223R0003
Issued by

About this file

This federal contract opportunity notice solicits proposals for upgrade works at communication facilities and infrastructure at Aviano Air Base in Italy. The work includes generator replacement and escort requirements during execution. The solicitation number is FA568223R0003 and is between $1 million to $5 million in magnitude. Interested vendors must have an active System for Award Management registration and an active Standard Occupational Classification certification in category OG11 at time of proposal submission and award. The work will be performed according to Italian law DLgs. 81/2008 and Defense Federal Acquisition Regulation Supplement 225.1103(3). A site visit is scheduled as specified in the solicitation, and proposals are due by the date listed in Standard Form 1442 block 7. The Department of the Air Force United States Air Forces in Europe - Air Forces Africa is the issuing agency.

View the file

Other files

On GovTribe

Work with this file

  • Download the original file
  • Contacts named in this file
  • Similar government files
  • Ask GovTribe AI about this file

Text version

31st FIGHTER WING 31st CIVIL ENGINEERING SQUADRON

31st CES/CENM PROJECT MANAGEMENT ELEMENT

Project ASHE 21-2001 ADDENDUM # 1R

31CES/CENM

PROJECT ASHE 21-2001

ASHE 21-2001 UPGRADE COMM FACILITIES AND

INFRASTRUCTUREAVIANO AB, ITA

ADDENDUM #1R

Date: March 02nd, 2023

ADDEDUNDUM #1

1) Part IVa Item 3, Bldg.11341 Change to read:

Generator set brand BRUNO GX series mod. GX141F SUPERSILENCED OR EGUAL APPROVED….

2) Section AC1-2- Change to read:

………….… During work execution Contractor shall be escorted all time by gvt personnel.

Contractor shall be responsible to notify promptly the Contracting Officer of any delays or changes of the escort service and of any Government delays that will impact and cause a delays or change the approved Work Plan. The Contractor shall be entitled to adequate contract time extension at no expenses to the Government when the delays are not caused by his fault or negligence.”…….

File details come from the government source that posted it. Updated .