Revised_Section_F.pdf

Solicitation No. AG-SPEC-S-17-0008

Updated thru FAC 2005-89 eff 11/1/2016 Page 8 of 38

F - DELIVERIES OR PERFORMANCE

52.236-15 Schedules for Construction Contracts. (Apr 1984) 52.242-14 Suspension of Work. (Apr 1984)

52.211-10 Commencement, Prosecution, and Completion of Work. (Apr 1984) The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 167 days. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 -- Liquidated Damages – Construction. (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $773.37 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of Clause)

52.211-13 -- Time Extensions. (Sept 2000) Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

(End of Clause)

4I-52.249-70 Time Extensions for Unusually Severe Weather. (Nov 2013)

(a) This clause specifies the procedure for determination of time extensions for unusually severe weather in accordance with FAR clause 52.249-10, Default (Fixed-Price Construction). In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project.

The delay must be beyond the control and without the fault or negligence of the Contractor.

(b) The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the baseline for monthly weather time evaluations. The Contractor's progress schedule must reflect those anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON A 6 DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(15) (11) (8) (6) (5) (7) (7) (6) (5) (3) (9) (13 )

Prioritized Site List - Revsied Section F

Solicitation No. AG-SPEC-S-17-0008

Updated thru FAC 2005-89 eff 11/1/2016 Page 9 of 38

(c) Upon acknowledgement of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record the occurrence of adverse weather and resultant impact to normally scheduled work. An actual adverse weather delay must prevent work on critical activities for fifty (50) percent or more of the Contractor's scheduled work day. The number of actual adverse weather days shall include days impacted by actual adverse weather (even if adverse weather occurred in the previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph (b) above, the Contractor may submit a written request for a modification for extension of performance time due to unusually severe weather. The Contracting Officer will convert any qualifying delays into calendar days, giving full consideration for equivalent fair weather days, and issue a modification in accordance with FAR clause 52.249-10, Default (Fixed-Price Construction).

(End of Clause)

Maximum Workweek – Construction Schedule Within 3 calendar days after receipt of a written request from the Contracting Officer, the Contractor must submit the following in writing for approval, the hours (including the daily starting and stopping times) and days of the week the Contractor proposes to carry out the work.

The maximum workweek that will be approved is 10 hours per day, 6 days per week, Monday through Saturday.

Work Performance on Holidays The Contractor shall not perform work on the following holidays except in the case of emergency as permitted elsewhere in this contract:

Independence Day Labor Day Thanksgiving Day Christmas Day New Year's Day

The contract performance time has been established to allow for the non-working holidays stated above.

The Contractor may be permitted to work the following remaining designated Federal holidays provided that he/she submits a letter of request to the Contracting Officer at least five (5) days in advance of the holiday.

Columbus Day Veterans Day Washington's Birthday Martin Luther King, Jr.'s Birthday Memorial Day

Prioritized Work Sites The Contractor shall work on the EWP repair sites in the following order:

1. 122 Jefferson Davis Blvd.

2. West Stiers

3. Order of the remaining 4 sites at the contractor’s discretion

Prioritized Site List - Revsied Section F