Revised_Bid_Schedule.pdf

Solicitation No. AG-SPEC-S-17-0005

Updated thru FAC 2005-89 eff 11/1/2016 Page 4 of 37

PART I – THE SCHEDULE

B - SUPPLIES OR SERVICES AND PRICES

This solicitation requires bidding on all line items, failure to do so will disqualify the bid.

Item No.

Supplies/Services Spec.

No.

Quantity Unit Price Unit Amount

1 Clearing and Grubbing 2 1 XXXX LS 2 Structure Removal 3 1 XXXX LS 3 Protective Cover 6 1 XXXX LS 4 Mobilization and Demobilization 8 1 XXXX LS 5 Rock Riprap 61 1,225* TONS 6 Geotextile 95 2,050* SY 7 Concrete Grout 410 205* CY

TOTAL BID $

52.211-18 Variation in Estimated Quantity. (Apr 1984) If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract.

Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

(End of clause)

Quantities marked with an * above are estimated quantities and the clause FAR 52.211-18, 52.211-18 Variation in Estimated Quantity, applies.

ONE AWARD FOR THE AGGREGATE OF ALL ITEMS WILL BE MADE AS A RESULT OF THIS

SOLICITATION

Revised Bid Schedule - Page 4