INDIAN SUITE MAST SECTION_F.docx

F - Deliveries or Performance

Work Timing The Contractor shall begin work within ____5______ calendar days after the effective date of the Notice to Proceed and shall prosecute the work at a rate that will result in completion of all work within the following time frame:

Item No. Estimated Start Work Date Contract Time (Calendar Days)

All June 5, 2010 80 days

Failure to begin work on schedule will make the contract subject to immediate termination for default.

Delays due to normal adverse weather, weekends, and holidays have been included in the calculation of contract time. The Government reserves the right to set the priority of items or subitems. Contractor shall complete all work on one subitem before proceeding to another.

Winter Shutdown When winter weather sets in and the continuation of work is impractical, the Contracting Officer may authorize a total suspension until such time as work can proceed. During the period of total suspension, the calendar days elapsed WILL be charged against the contract time. For example, if contract award is made on September 24, 2009, the completion date for the contract would be no later than September 24, 2010.

FAR 52.252-2 Clauses Incorporated by Reference (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): www.acquisition.gov/far/ and www.usda.gov/procurement/policy/agar.html

FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES

AGAR 452.215-73 POST AWARD CONFERENCE (NOV 1996)

A post award conference with the successful offeror is required. It will be scheduled after the date of contract award. The conference will be held at:

U. S. Forest Service Yuba River Ranger District 15924 Highway 49 Camptonville, California 95922