Revised_AG-7335-S-15-0011.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

741806

USDA-NRCS-OKLAHOMA STATE OFFICE

100 USDA, SUITE 206

STILLWATER OK 74074-2655

NRCS-OK-127335

USDA-NRCS

Attn: Sharla K. Goforth 100 USDA, Suite 206 Stillwater, OK 74074-2655

SHARLA GOFORTH 405-742-1231

x

05/26/2015

AG-7335-S-15-0011

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

Wetland Reserve Easement Program restoration of wetlands in Grady County, Oklahoma.

Estimated price range - $250,000 - $300,000

A site showing will be held on June 18th, 2015. Information on location and time of site showing can be found in section L.6 of the solicitation.

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

5 127 calendar days and complete it within ________________ ________________ calendar days after receiving

06/30/2015

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

USDA-NRCS-OKLAHOMA STATE OFFICE

100 USDA, SUITE 206

STILLWATER OK 74074-2655

NRCS-OK-127335

SHARLA K. GOFORTH

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 54

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

AG-7335-S-15-0011

FOB: Destination

001 Construction for Restoration of Wetlands on the property D & D Farms WRP

66733512016XS - Grady County

Items to be completed under this line item are detailed in Section B.

Product/Service Code: Y1QA

Product/Service Description: CONSTRUCTION OF

RESTORATION OF REAL PROPERTY (PUBLIC OR PRIVATE)

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

B.1

ITEM NO. SCHEDULE OF ITEMS SUPPLIES/SERVICES UNIT

1 STEEL PIPE WITH SCREWGATE WATER

CONTROL STRUCTURE 52 62.0 FT $ $

ROCK RIPRAP: STREAMBANK

STABILIZATION, ROCK CHECK DAMS, AND

VEGETATED OUTLET END TRENCH

61 4,445.0 TON

RIPRAP BEDDING: STREAMBANK

STABILIZATION, ROCK CHECK DAMS, AND

VEGETATED OUTLET END TRENCH

61 870.5 TON

4 MOBILIZATION/DEMOBILIZATION 200 1 LS $ XXXXXX $

5 REMOVAL OF DEBRIS AND STRUCTURES 202 1 LS $ XXXXXX $

6 EXCAVATION, SWALES 211 1,387 CY $ $

7 EXCAVATION, FULL CIRCLE DEEP-WATER

HABITATS 211 5,000 CY $ $

8 EMBANKMENT EXCAVATION AREA 1 & 2 211 2,605 CY $ $

9 EXCAVATION, VEGETATED OUTLET 211 747 CY $ $

10 EARTHFILL, ISLAND 212 600 CY $ $

11 EARTHFILL, WETLAND EMBANKMENT 212 9,186 CY $ $

12 EARTHFILL, EMBANKMENT ALONG BANK 212 550 CY $ $

HIGH DENSITY POLYETHYLENE (HDPE)

TUBING WITH INLINE WATER CONTROL

STRUCTURE

244 82 FT $ $

14 INLINE WATER CONTROL STRUCTURE

REPAIR 244 1 LS $ XXXXXX $

15 TURF REINFORCMENT MAT INSTALLATION 245 486 SY $ $

16 SPRIGGING, BERMUDAGRASS 270 3.8 AC $ $

17 SOLID SODDING, BERMUDAGRASS 272 600 SY $ $

18 NATIVE GRASS SEEDING 275 5.9 AC $ $

19 TEMPORARY COVER CROP 280 9.7 AC $ $

Total $

OFFEROR

TAX ID #

DUNS #

B.2

B.3 52.211-18 VARIATION IN ESTIMATED QUANTITY. (APR 1984)

One award for the aggregate of all items will be made under this solicitation.

GRADY COUNTY

Section B - Supplies or Services

D&D FARMS WETLANDS RESERVE PROGRAM PROJECT

Section 29 - T8N - R8W

AMOUNT

ESTIMATED

QUANTITY

UNIT

COST

SPEC

NO.

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

AG-7335-S-15-0011 Revised Page 4 of 54

SECTION C – DESCRIPTION/SPECIFICATIONS/WORK STATEMENT

C.1 AGAR 452.211-72 STATEMENT OF WORK/SPECIFICATIONS (FEB 1988)

The Contractor shall furnish the necessary personnel, material, equipment, services and facilities (except as otherwise specified), to perform the Statement of Work/Specifications referenced in Section J.

C.2 AGAR 452.211-73 ATTACHMENTS TO STATEMENT OF WORK/SPECIFICATIONS

(FEB 1988)

The attachments to the Statement of Work/Specifications listed in Section J are hereby made part of this solicitation and any resultant contract.

AG-7335-S-15-0011 Revised Page 5 of 54

SECTION D – PACKAGING AND MARKING

THERE ARE NO CLAUSES INCLUDED IN THIS SECTION

AG-7335-S-15-0011 Revised Page 6 of 54

SECTION E – INSPECTION AND ACCEPTANCE

E.1 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): http://www.acquisition.gov/far/index.html

E.2 52.246.12 INSPECTION OF CONSTRUCTION (AUG 1996)

AG-7335-S-15-0011 Revised Page 7 of 54 http://www.acquisition.gov/far/index.html

SECTION F – DELIVERIES OR PERFORMANCE

F.1 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): http://www.acquisition.gov/far/index.html

F.2 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR

1984) – ALTERNATE I (APR 1984)

The Contractor shall be required to:

(a) Commence work under this contract with 5 calendar days after the date the Contractor receives the notice to proceed.

(b) Prosecute the work diligently, and

(c) Complete the entire work ready for use not later than December 1, 2015. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by July 27, 2015. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

F.3 52.211-12 Liquidated Damages—Construction. (Sep 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $294.35 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

F.4 52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

F.5 52.242-14 SUSPENSION OF WORK (APR 1984)

F.6 NRCSAR 4I-52.249-70 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

(NOV 2013)

(a) This clause specifies the procedure for determination of time extensions for unusually severe weather in accordance with FAR clause 52.249-10, Default (Fixed Priced Construction). In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

AG-7335-S-15-0011 Revised Page 8 of 54

(b) The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the baseline for monthly weather time evaluations.

The Contractor’s progress schedule must reflect those anticipated adverse weather delays in all weather dependent activities.

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

9 7 6 4 4 3 2 2 3 3 5 8

(c) Upon acknowledgement of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record the occurrence of adverse weather and resultant impact to normally scheduled work. An actual adverse weather delay must prevent work on critical activities for fifty (50) percent or more of the Contractor’s scheduled work day. The number of actual adverse weather days shall include days impacted by actual adverse weather (even if adverse weather occurred in the previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph (b) above, the Contractor may submit a written request for a modification for extension of performance time due to unusually severe weather. The Contracting Officer will convert any qualifying delays into calendar days, giving full consideration for equivalent fair weather days, and issue a modification in accordance with FAR clause 52.249-10, Default (Fixed Price Construction).

F.7 MAXIMUM WORKWEEK – CONSTRUCTION SCHEDULE

Within 10 calendar days after receipt of a written request from the Contracting Officer, the Contractor must submit the following in writing for approval, the hours (including the daily starting and stopping times) and the days of the week the Contract proposes to carry out the work.

The maximum workweek that will be approved is 8 hours per day, five days per week, Monday through Friday.

F.8 WORK PERFORMANCE ON HOLIDAYS

The Contractor shall not perform work on the following holidays except in the case of emergency as permitted elsewhere in this contract:

Independence Day Labor Day Thanksgiving Day Christmas Day New Year’s Day

The contract performance time has been established to allow for the non-working holidays stated above.

AG-7335-S-15-0011 Revised Page 9 of 54

The Contract may be permitted to work the following remaining designated Federal holidays provided he/she submits a letter to the Contracting Officer at least five (5) days in advance of the holiday.

Columbus Day Veterans Day Washington’s Birthday Martin Luther King, Jr.’s Birthday Memorial Day

AG-7335-S-15-0011 Revised Page 10 of 54

SECTION G – CONTRACT ADMINISTRATION DATA

G.1 DESIGNATED PAYMENT OFFICE CONTACT POINT

The contact point described below coordinates the issuance of payments under this contract. If the payment is not received within 5 days after the due date specified in the contract, contact the payment office designated below for information on when payment will be made.

USDA, National Finance Center Administrative Payments Branch (APB) Telephone: (800) 421-323 or (504) 426-6510

If questions arise on the amount paid, contact the contracting officer at the number or address shown in the contract.

G.2 INVOICE PAYMENT PLATFORM (IPP)

Electronic Invoicing and Payment Requirements – Invoice Payment Platform (IPP)

Invoices must be submitted electronically through the U.S. Department of the Treasury’s Invoice Payment Platform System (IPP).

The Contractor must the IPP website (https://ww.ipp.gov) to register, access, and use IPP for submitting invoices. Contractor assistance with enrollment can be obtained by calling (866) 973-3131.

Invoices submitted by means other than IPP will not be accepted unless the Contracting Officer authorizes alternate procedures in writing. The written authorization from the Contracting Officer shall be maintained in the contract file.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

1. Itemization of the amounts requested

2. Payment request certification from the clause

3. Release of claims (final payment only)

a. “I, (Name of Contractor), do hereby release the United States of America form any and all claims and liabilities of any character whatsoever arising under and by virtue of contract number (Identify Contract) dated (Date) as amended, except as stated. (Date of Release) (Signature of Contractor)

G.3 OTHER INVOICE REQUIREMENTS UNDER PROMPT PAYMENT FOR

CONSTRUCTION CONTRACTS

(1) In addition to the information required in Clause 52.232-27 Prompt Payment for Construction Contracts, and Clause 52.232-5, Payments Under Fixed Price Construction Contracts, the contractor shall provide the following:

AG-7335-S-15-0011 Revised Page 11 of 54 https://ww.ipp.gov/

(i) The original and one copy of each invoice are to be delivered to the Contracting Officer at the location shown in Block 24 of SF-1442.

(ii) One copy of each invoice is to be submitted simultaneously to the

Contracting Officer’s Representative who will be identified prior to a work start.

(2) The following must be attached to the original invoice submitted to the

Contracting Officer and to the copy submitted to the Contracting Officer’s Representative:

(i) A complete remittance address along with vendor identification number on the second line, if electronic funds transfer (EFT) is elected.

(ii) Billing period.

(iii) If requesting payment for materials delivered but not installed, contractor will provide evidence of title to the materials as required by FAR Clause 52.232-5, Payments Under Fixed Price Construction Contracts.

(iv) Itemization of payment requests by contract item number (CIN) as shown in Schedule B of the contract. Invoice will include the quantity performed that is being invoiced, the unit price and the CIN total price, and a sum total of amount of payment requested. Invoice will also include the cumulative quantities and amount by CIN.

(v) A listing of the amount included for work performed by each subcontractor under the contract.

(vi) A listing of the total amount of each subcontract under the contract.

(vii) A listing of the amounts previously paid to each such subcontractor under the contract

(viii) A signed certification as required by FAR Clause 52.232-5, Payments

Under Fixed Price Construction Contracts.

(ix) A copy of the payrolls and statements of compliance not previously submitted to cover the billing period.

(3) The FINAL invoice billing shall also contain the following RELEASE OF

CLAIMS statement as required by FAR 52.232-5, Payments Under Fixed Price Construction Contracts:

AG-7335-S-15-0011 Revised Page 12 of 54

I, (Name of Contractor), do hereby release the United States of America from any and all claims and liabilities of any character whatsoever arising under and by virtue of contract number (Identify Contract) dated (Date) as amended, except as stated.

(Date of Release) (Signature of Contractor)

G.4 CONTRACTING OFFICER’S AUTHORITY

The Contracting Officer (CO) is the only person authorized to approve changes to any of the requirements of this project. The authority remains solely with the CO. In the event that the Contractor effects any change at the direction of any person other than the CO, the change will be considered to have been made without authority and NO adjustment will be made in the contract price to cover any INCREASE in costs incurred as a result thereof.

G.5 CONTRACTING OFFICER’S REPRESENTATIVE

The Contracting Officer’s Representative (COR) is an individual designated in writing by the Contracting Officer (CO) to act as an authorized representative of the CO to perform specific contract administrative functions within the scope and limitations as defined by the CO in the COR’s appointment letter. This letter specifies the extent of the COR’s authority to act on behalf of the CO. The COR is not authorized to make any commitments or changes that will affect price, quality, quantity, delivery or any other term or condition of the contract. Any subsequent change to the COR or COR responsibilities will be confirmed, in writing, by the CO. A COR does not have the authority to and may never –

1. award, agree to, or execute any contract, contract modification, or notice of intent;

2. obligate, in any way, the payment of money by the Government;

3. make a final decision on any contract matter which is subject to the clause at

FAR 52.233-1, Disputes; or

4. terminate, for any cause, the contractor’s right to proceed.

If the contractor does not receive a copy of the COR appointment letter, the contractor is required to request a copy of it from the CO prior to commencing work. Individuals not designated in writing as a COR by the CO are not considered a COR and do not have the authority delegated to the COR. If the contractor considers any action or inaction by a COR, any other government employee (such as an inspector), or representative or agent of the government as a change to the contract terms and conditions they must notify the contracting officer immediately and not proceed with any such change until approved by the contracting officer

AG-7335-S-15-0011 Revised Page 13 of 54

SECTION H – SPECIAL CONTRACT REQUIREMENTS

H.1 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): http://www.acquisition.gov/far/index.html

H.2 AGAR 452.232-70 REIMBURSEMENT FOR BOND PREMIUMS – FIXED

PRICE CONSTRUCTION CONTRACTS (NOV 1996)

The Contract Price includes the total amount for premiums that the Contractor attributes to the furnishing of performance and payment bonds required by the contract. Reimbursement for bond premiums under the clause at FAR 52.232-5, Payments Under Fixed-Priced Construction Contracts, shall not cover any amount therefor not included in the contract price.

H.3 AGAR 52.236-72 Use of Premises. (NOV 1996)

(a) Before any camp, quarry, borrow pit, storage, detour, or bypass site, other than shown on the drawings, is opened or operated on USDA land or lands administered by the USDA, the Contractor shall obtain written permission from the Contracting Officer. A camp is interpreted to include a campsite or trailer parking area of any employee working on the project for the Contractor.

(b) Unless excepted elsewhere in the contract, the Contractor shall (i) provide and maintain sanitation facilities for the work force at the site and (ii) dispose of solid waste in accordance with applicable Federal, State and local regulations.

H.4 AGAR 452.236-73 ARCAEOLOGICAL OR HISTORIC SITES (FEB 1988)

If a previously unidentified archaeological or historic site(s) is encountered, the

Contractor shall discontinue work in the general area of the site(s) and notify the Contracting Officer immediately.

H.5 AGAR 452.236-74 CONTROL OF EROSION, SEDIMETATION, AND

POLLUTION (NOV 1996)

(a) Operations shall be scheduled and conducted to minimize erosion of soils and to prevent silting and muddying of streams, rivers, irrigation systems, and impoundments (lakes, reservoirs, etc.).

(b) Pollutants such as fuels, lubricants, bitumens, raw sewage, and other harmful materials shall not be discharged on the ground; into or nearby rivers, streams, or impoundments; or into natural or man-made channels. Wash water or waste from concrete or aggregate operations shall not be allowed to enter live streams prior to treatment by filtration, settling, or other means

AG-7335-S-15-0011 Revised Page 14 of 54 sufficient to reduce the sediment content to not more than that of the stream into which it is discharged.

(c) Mechanized equipment shall not be operated in flowing streams without written approval by the Contracting Officer.

H.6 AGAR 452.236-76 SAMPLES AND CERTIFICATES (FEB 1988)

When required by the specifications or the Contracting Officer, samples, certificates, and test date shall be submitted after award of the contract, prepaid, in time for proper action by the Contracting Officer or his/her designated representative. Certificates and test data shall be submitted in triplicate to show compliance with materials and construction specified in the contract performance requirements.

Samples shall be submitted in duplicate by the Contractor, except as otherwise specified, to show compliance with the contract requirements. Materials or equipment for which samples, certifications or test data are required shall not be used in the work until approved in writing by the Contracting Officer.

H.7 52.236-13 ACCIDENT PREVENTION (ALTERNATE 1) (NOV 1991)

(a) The Contractor shall provide and maintain work environments and procedures which will –

(1) Safeguard the public and Government personnel, property, materials, supplies, and equipment exposed to Contractor operations and activities;

(2) Avoid interruptions of Government operations and delays in project completion dates; and

(3) Control costs in the performance of this contract.

(b) For these purposes on contracts for construction or dismantling, demolition, or removal of improvements, the Contractor shall –

(1) Provide appropriate safety barricades, signs, and signal lights;

(2) Comply with the standards issued by the Secretary of Labor at 29

CFR Part 1926 and 29 CFR Part 1910; and

(3) Ensure that any additional measures the Contracting Officer determines to be reasonably necessary for the purposes are taken.

(c) If this contract is for construction or dismantling, demolition or removal of improvements with any Department of Defense agency or component, the Contractor shall comply with all pertinent provisions of the latest version of U.S. Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1, in effect on the date of the solicitation.

(d) Whenever the Contracting Officer becomes aware of any noncompliance with these requirements or any condition which poses a serious or imminent danger to the health or safety of the public or Government personnel, the Contracting Officer shall notify the Contractor orally, with written confirmation, and request immediate initiation of corrective action. This notice, when delivered to the Contractor or the Contractor’s representative at the work site, shall be deemed sufficient notice of noncompliance and the corrective action is required. After receiving the notice, the Contractor shall immediately take corrective action. If the Contractor fails or refuses to promptly take corrective

AG-7335-S-15-0011 Revised Page 15 of 54 action, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. The Contractor shall not be entitled to any equitable adjustment of the contract price or extension of the performance schedule on any stop work order issued under this clause.

(e) The Contractor shall insert this clause, including this paragraph (e), with appropriate changes in the designation of the parties, in subcontracts.

(f) Before commencing the work, the Contractor shall –

(1) Submit a written proposed plan for implementing this clause. The plan shall include an analysis of the significant hazards to life, limb, and property inherent in contract work performance and a plan for controlling these hazards; and

(2) Meet with representatives of the Contracting Officer to discuss and develop a mutual understanding relative to administration of the overall safety program.

H.8 52.252-4 ALTERATIONS IN CONTRACT (APR 1984)

Portions of this contract are altered as follows:

52.236-13 Accident Prevention is altered to include the following: NRCS Supplement to OSHA, Parts 1910 and 1926, Construction Standards and Interpretations

NATURAL RESOURCES CONSERVATION SERVICE

SUPPLEMENT TO OSHA PARTS 1910 AND 1926

CONSTRUCTION INDUSTRY STANDARDS AND INTERPRETATIONS

The contractor shall comply with OSHA (Occupational Safety and Health Administration) Parts 1910 and 1926, Construction Industry Standards and Interpretations, and with this supplement.

Requests for variances or waivers from this supplement are to be made to the contracting officer in writing supported by evidence that every reasonable effort has been made to comply with the contractual requirements. A written request for a waiver or a variance shall include--

(1) Specific reference to the provision or standard in question;

(2) An explanation as to why the waiver is considered justified; and

(3) The contractor's proposed alternative, including technical drawings, materials, or equipment specifications needed to enable the contracting officer to render a decision.

No waiver or variance will be approved if it endangers any person. The contractor shall not proceed under any requested

AG-7335-S-15-0011 Revised Page 16 of 54 revision of a provision until the contracting officer has given written approval.

The contractor is to hold and save harmless the Natural Resources Conservation Service free from any claims or causes of action whatsoever resulting from the contractor or subcontractors proceeding under a waiver or approved variance. Copies of OSHA Part 1910 and 1926, Construction Industry Standards and Interpretations, may be obtained from:

Superintendent of Documents U. S. Government Printing Office Washington, D.C. 20402

GENERAL CONTRACTOR REQUIREMENTS

1.1 SAFETY PROGRAM. Each contractor is to demonstrate that he or she has the facilities for conducting a safety program commensurate with the work under the contract. The contractor is to submit a written safety program to the contracting officer for approval before the start of construction operations. The program is to specifically state what provisions the contractor proposes to take for the health and safety of all employees.

1.2 PRECONSTRUCTION SAFETY MEETING. Representatives for

the contractor are to meet with the contracting officer (CO) or the CO's representative before the start of construction to discuss the safety program and the implementation of all health and safety standards pertinent to the work under this contract.

1.3 JOINT SAFETY POLICY COMMITTEE. The contractor or

designated onsite representative is to participate in monthly meetings of a Joint Safety Committee, composed of Natural Resources Conservation Service and contractor supervisory personnel. At these meetings the contractor's project manager and the Contracting Officer will review the effectiveness of the contractor's safety effort, resolve current health and safety problems, and coordinate safety activities for upcoming work.

1.4 SAFETY PERSONNEL. Each contractor is to designate a

competent supervisory employee satisfactory to the Contracting officer to administer the safety program.

1.5 SAFETY MEETINGS. A minimum of one "one-the-job" or

"toolbox" safety meeting is to be conducted each week by all field supervisors for all construction personnel at the job site. The

AG-7335-S-15-0011 Revised Page 17 of 54 contractor is to also conduct regularly scheduled supervisory safety meetings at least monthly for all levels of job supervision.

1.6 SAFETY INSPECTION. The contractor shall perform frequent and regular safety inspections of the jobsite, materials, and equipment, and shall correct deficiencies.

1.7 FIRST AID TRAINING. Every contractor foreman's work crew

must include an employee who has a current first aid certificate from the Mine Safety and Health Administration, American Red Cross, or other state-approved organization.

1.8 REPORTS. Each contractor is to maintain an accurate record of all job related deaths, diseases, or disabling injuries. The records shall be maintained in a manner approved by the contracting officer. A copy of all reports is to be provided to the contracting officer. All fatal or serious injuries are to be reported immediately to the contracting officer, and every assistance is to given to the investigation of the incident, including submission of a comprehensive narrative report to the contracting officer. Other occurrences with serious accident potential, such as equipment failures, slides and cave-ins, must also be reported immediately. The contractor is to assist and cooperate fully with the contracting officer in conducting accident investigations. The contracting officer is to be furnished all information and data pertinent to investigation of the accident.

FIRST-AID AND MEDICAL FACILITIES

2.1 FIRST AID KITS. A 16-unit first aid kit approved by the American Red Cross is to be provided at accessible, well identified, locations at the ratio of at least 1 kit for each 25 employees. The first aid kits are to be moisture proof and dust tight, and the contents of the kits are to be replenished as used or as they become ineffective or outdated.

2.2 EMERGENCY FIRST AID. At least one employee certified to

administer emergency first aid must be available on each shift and duly designated by the contractor to care for injured employees. The names of the certified employees shall be posted at the job site.

2.3 COMMUNICATION AND TRANSPORTATION. Prior to the start to

work, the contractor is to make necessary arrangements for prompt and dependable communications, transportation, and medical care for injured employees. At least one stretcher and two blankets shall be readily available for transporting injured employees.

AG-7335-S-15-0011 Revised Page 18 of 54

2.4 FIRST AID AND MEDICAL REPORTS. The contractor is to

maintain a record system for first aid and medical treatment on the jobsite. Such records are to be readily available to the contracting officer and are to include:

(a) A daily treatment log listing chronologically all persons treated for occupational injuries and illnesses;

(b) Cumulative record of injury for each individual;

(c) Monthly statistical records of occupational injuries, classified by type and nature of injury; and

(d) Required records for worker's compensation.

2.5 SIGNS AND DIRECTIONAL MARKINGS. Adequate identification

and directional markers are to be provided to readily denote the location of all first aid stations.

2.6 EMERGENCY LISTING. A listing of telephone numbers and

addresses of doctor, rescue squad, hospital, police, and fire departments is to be provided at all first aid locations.

PHYSICAL QUALIFICATION OF EMPLOYEES

3.1 GENERAL REQUIREMENTS. Persons employed throughout the

contract are to be physically qualified to perform their assigned duties.

Employees must not knowingly be permitted or required to work while their ability or alertness is impaired by fatigue, illness, or other reason that may jeopardize themselves or others.

3.2 HOIST OPERATORS. Operators of cranes, cableways, and other, hoisting equipment shall be examined annually by a physician and provided with a certification stating that they are physically qualified to safely operate hoisting equipment. The contractor is to submit a copy of each certification to the contracting officer.

3.3 MOTOR VEHICLE OPERATORS. Operators of motor vehicles

engaged primarily in the transportation of personnel are to be 18 years of age or older and have a valid state operator's permit or license for the equipment being operated. The operators must have passed a physical examination administered by a licensed physician within the part year showing that they are physically qualified to operate vehicles safely.

AG-7335-S-15-0011 Revised Page 19 of 54

PERSONAL PROTECTIVE EQUIPMENT

4.1 HARDHAT AREAS. The entire jobsite, with the exception of

offices, will be considered a hardhat area. All persons entering the area are, without exception, required to wear hardhats. The contractor shall provide hardhats to visitors entering hardhat areas.

4.1.1 LABELS. Hardhats shall bear a manufacturer's label indicating design compliance with the appropriate ANSI (American National Standards Institute) standard.

4.2 POSTING. Signs at least 3 by 4 feet worded as follows with red letters (minimum 6 inches high) with white background shall be erected at access points to designated hardhat areas:

CONSTRUCTION AREA -- HARDHATS REQUIRED BEYOND THIS

POINT

These signs are to be furnished and installed by the contractor at entries to shops, construction yards, and job access points.

MACHINERY AND MECHANIZED EQUIPMENT

5.1 SAFE CONDITION. Before any machinery or mechanized

equipment is initially used on the job, it must be inspected and tested by qualified personnel and determined to be in safe operating condition and appropriate for the intended use. Operators shall inspect their equipment prior to the beginning of each shift. Any deficiencies or defects shall be corrected prior to using the equipment. Safety equipment, such as seatbelts, installed on machinery is to be used by equipment operators.

5.2 TAGGING AND LOCKING. The controls of power-driven

equipment under repair are to be locked. An effective lockout and tagging procedure is to be established, prescribing specific responsibility and safety procedures to be followed by the persons performing repair work.

5.3 HAUL ROAD FOR EQUIPMENT

5.3.1 ROAD MAINTENANCE. The contractor shall maintain all

roadways, including haul roads and access roads, in a safe condition so as to eliminate or control dust and ice hazards. Wherever dust is a hazard adequate dust-laying equipment shall be available at the jobsite and utilized to control dust.

AG-7335-S-15-0011 Revised Page 20 of 54

5.3.2 SINGLE LANE HAUL ROADS. Single-lane haul roads with two-way traffic shall have adequate turnouts. Where turnouts are not practical, a traffic control system shall be provided to prevent accidents.

5.3.3 TWO-WAY HAUL ROADS. On two-way haul roads, arrangements are to be such that vehicles travel on the right side wherever possible. Signs and traffic control devices are to be employed to indicate clearly any variations from a right-hand traffic pattern. The road shall be wide enough to permit safe passage of opposing traffic, considering the type of hauling equipment used.

5.3.4 DESIGN AND CONSTRUCTION OF HAUL ROADS. Haul road

design criteria and drawings, if requested by the contracting officer, are to be submitted for approval prior to road construction. Sustained grades shall not exceed 12 percent and all curves shall have open-sight line with as great a radius as practical. All roads shall be posted with curve signs and maximum speed limits that will permit the equipment to be stopped within one-half the minimum sight distance.

5.3.5 OPERATORS. Machinery and mechanized equipment shall be

operated only by authorized qualified persons.

5.3.6 RIDING ON EQUIPMENT. Riding on equipment by

unauthorized personnel is prohibited. Seating and safety belts shall be provided for the operator and all passengers.

5.3.7 GETTING ON OR OFF EQUIPMENT. Getting on or off

equipment while the equipment is in motion is prohibited.

5.3.8 HOURS OF OPERATION. Except in emergencies, an

equipment operator shall not operate any mobile or hoisting equipment for more than 12 hours without an 8-hour rest interval away from the job.

5.4 POWER CRANES AND HOISTS (TRUCK CRANES, CRAWLER

CRANES, TOWER CRANES, GANTRY CRANES, HAMMERHEAD

CRANES, DERRICKS, CABLEWAYS, AND HOISTS)

5.4.1 PERFORMANCE TEST. Before initial onsite operation, at 12-month intervals, and after major repairs or modification, power cranes, derricks, cableways, and hoists must satisfactorily complete a performance test to demonstrate the equipment's ability to safety handle and maneuver the rated loads. The tests shall be conducted in the presence of a representative of the contracting officer. Test data shall be recorded and a copy furnished the contracting officer.

AG-7335-S-15-0011 Revised Page 21 of 54

5.4.2. PERFORMANCE TEST--POWER CRANES (Crawler mounted, truck mounted, and wheel mounted). The performance test is to be carried out with outriggers set and with a test load weighing 110 percent of the rated load. In testing cableways the test load is to be traveled to the upstream and downstream limits of travel and thoroughly performance tested in at least three travel positions, including both limits of travel.

5.4.3. PERFORMANCE TEST--DERRICKS, GANTRY CRANES,

TOWER CRANES, CABLEWAYS, AND HOISTS, INCLUDING

OVERHEAD CRANES. This equipment is to be performance tested with a test load weighing 110 percent of the rated load. In testing cableways, the test load is to be traveled to the upstream and downstream limits of travel and thoroughly performance tested in at least three travel positions, including both limits of travel.

5.4.4 BOOM ANGLE INDICTOR. Power cranes (includes draglines)

with booms capable of moving in the vertical plane shall be provided with a boom angle indicator in good working order.

5.4.5 CRANE TEST CERTIFICATION. The performance test required by 5.4.2 and 5.4.3 is fulfilled if the contractor provides the contracting officer a copy of the certificate of inspection made within the past 12 months by a qualified person or by a government or private agency satisfactory to the contracting officer.

5.4.6 POSTING FOR HIGH VOLTAGE LINES. A notice of the 10- foot (or greater) clearance required by OSHA 1926.550, Subpart N, shall be posted in the operator's cab of cranes, shovels, boom-type concrete pumps, backhoes and related equipment.

5.4.7 BOOM STOPS. Cranes or derricks with cable-supported booms, except draglines, shall have a device attached between the gantry of the A-frame and the boom chords to limit the elevation of the boom.

The device shall control the vertical motions of the boom with increasing resistance from 83 or less, until completely stopping the boom at not over 87 above horizontal.

5.4.8 SAFETY HOOKS. Hooks used in hoisting personnel or hoisting loads over construction personnel or in the immediate vicinity of construction personnel shall be forged steel equipped with safety keepers. When shackles are used under these conditions, they shall be of the locking type or have the pin secured to prohibit turning.

5.5 ROLLOVER PROTECTIVE STRUCTURES (ROPS)

AG-7335-S-15-0011 Revised Page 22 of 54

5.5.1 ROLLOVER PROTECTIVE STRUCTURES. OSHA 1926

Subpart W Overhead Protection Sections 1000 and 1002 are applicable regardless of the year in which the equipment was manufactured and regardless of the struck capacity of the equipment.

5.5.2 EQUIPMENT REQUIRING ROPS. The requirement for ROPS

meeting 5.5.1 above applies to crawler and rubber-tired tractors such as dozers, push and pull tractors, winch tractors with backhoes, and mowers; off-highway, self-propelled, pneumatic-tired earthmovers, including cabs). These requirements shall also apply to agricultural and industrial tractors and similar equipment.

5.5.3 EQUIPMENT REQUIRING SEATBELTS. The requirements for

seatbelts as specified in OSHA Subpart 0, Motor Vehicles, Mechanized Equipment, and Marine Operations, Section 1926.602 shall also apply to self-propelled compactors and rollers, and rubber-tired skid-steer equipment.

5.6 LADDERS AND SCAFFOLDING.

5.6.1 LADDERS. OSHA 1926, Subpart L - Section 450. Ladders

shall be used as work platforms only when use of small hand tools or handling of light material is involved. No work requiring lifting of heavy materials or substantial exertion shall be done from ladders.

5.6.2 SCAFFOLDING. OSHA 1926, Subpart L - Section 451.

Scaffolds, platforms or temporary floors shall be provided for all work except that which can be done safely from the ground or similar footing.

5.6.3 SAFETY BELTS, LIFELINE, AND LANDYARDS. OSHA

1926, Subpart E, Section 104. Lifelines, safety belts and lanyards independently attached or attended, shall be used when performing such work as the following when the requirements of

5.6.1 and 5.6.2 above cannot be met.

a. Work on stored material in hoppers, bins, silos, tanks or other confined spaces.

b. Work on hazardous slopes, structural steel, or poles;

erection or dismantling of safety nets, typing reinforcing bars;

and work from or other unguarded locations at elevations greater than 6 feet.

AG-7335-S-15-0011 Revised Page 23 of 54

c. Work on skids and platforms used in shafts by crews when the skip or cage does not block the opening to within 1 foot of the sides of the shaft, unless cages are provided.

AG-7335-S-15-0011 Revised Page 24 of 54

PART II – CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

I.1 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): http://www.acquisition.gov/far/index.html

NUMBER TITLE DATE

52.203-3 GRATUITIES APR 1984

52.203-5 COVENANT AGAINST CONTINGENT FEES MAY 2014

52.203-7 ANTI-KICKBACK PROCEDURES MAY 2014

52.203-8 CANCELLATION, RESCISSION, AND MAY 2014

RECOVERY OF FUNDS FOR ILLEGAL OR

IMPROPER ACTIVITY

52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL MAY 2014

OR IMPROPER ACTIVITY

52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE OCT 2010

CERTAIN FEDERAL TRANSACTIONS

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER APR 2014

RIGHTS AND REQUIREMENT TO INFORM

EMPLOYEES OF WHISTLEBLOWER RIGHTS

52.204-4 PRINTED OR COPIED DOUBLE-SIDED ON MAY 2011

POSTCONSUMER FIBER CONTENT PAPER

52.204-10 REPORTING EXECUTIEVE COMPENSTATION JUL 2013

AND FIRST-TIER SUBCONTRACT AWARDS

52.204-13 SYSTEM FOR AWARD MANAGEMENT JUL 2013

MAINTENANCE

52.204-18 COMMERCIAL AND GOVERNMENT ENTITY NOV 2014

CODE MAINTENANCE

52.209-6 PROTECTING THE GOVERNMENT’S AUG 2013

INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED,

OR PROPOSED FOR DEBARRMENT

52.209-10 PROHIBITION ON CONTRACTING WITH DEC 2014

INVERTED DOMESTIC CORPORATIONS

52.211-18 VARIATION IN ESTIMATED QUANTITY APR 1984

52.214-29 ORDER OF PRECEDENCE – SEALED JAN 1986

BIDDING

52.219-6 NOTICE OF TOTAL SMALL BUSINESS SET- NOV 2011

ASIDE

52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS OCT 2014

52.219-14 LIMITATIONS ON SUBONTRACTING NOV 2011

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM JUL 2013

REPRESENTATION

52.222-3 CONVICT LABOR JUN 2003

52.222-4 CONTRACT WORK HOURS AND SAFETY MAY 2014

AG-7335-S-15-0011 Revised Page 25 of 54

STANDARDS – OVERTIME COMPENSATION

52.222-6 CONSTRUCTION WAGE RATE MAY 2014

REQUIREMENTS

52.222-7 WITHOLDING FUNDS FEB 1988

52.222-8 PAYROLLS AND BASIC RECORDS JUN 2010

52.222-9 APRENTICES AND TRAINEES JUL 2005

52.222-10 COMPLIANCE WITH COPELAND ACT FEB 1988

REQUIREMENTS

52.222-11 SUBCONTRACTS (LABOR STANDARDS) JUL 2005

52.222-12 CONTRACT TERMINATION-DEBARRMENT FEB 1988

52.222-13 COMPLIANCE WITH CONSTRUCTION WAGE MAY 2014

RATE REQUIREMENTS AND RELATED

REGULATIONS

52.222-14 DISPUTES CONCERNING LABOR STANDARDS FEB 1988

52.222-15 CERTIFICATION OF ELIGIBILITY FEB 1988

52.222-21 PROHIBITION OF SEGREGRATED FACILITIES FEB 1999

52.222-26 EQUAL OPPORTUNITY MAR 2007

52.222-27 AFFIRMATIVE ACTION COMPLIANCE FEB 1999

REQUIREMENTS FOR CONSTRUCTION

52.222-35 EQUAL OPPORTUNITY FOR VETERANS JUL 2014

52.222-37 EMPLOYMENT REPORTS ON VETERANS JUL 2014

52.222-40 NOTIFICATION OF EMPLOYEE RIGHTS DEC 2010

UNDER THE NATIONAL LABOR RELATIONS

ACT

52.222-50 COMBATING TRAFFICKING IN PERSONS FEB 2009

52.222-55 MINIMUM WAGES UNDER EXECUTIVE DEC 2014

ORDER 13658

52.223-2 AFFIRMATIVE PROCUREMENT OF BIOBASED SEP 2013

PRODUCTS UNDER SERVICE AND

CONSTRUCTION CONTRACTS

52.223-3 HAZARDOUS MATERIAL IDENTIFICATION JAN 1997

AND MATERIAL SAFETY DATA

ALTERNATE I JUL 1995

52.223-6 DRUG-FREE WORKPLACE MAY 2001

52.223-18 ENCOURAGING CONTRACTOR POLICIES AUG 2011

TO BAN TEXT MESSAGING WHILE DRIVING

52.225-9 BUY AMERICAN-CONSTRUCTION MATERIALS MAY 2014

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN JUN 2008

PURCHASES

52.228-1 BID GUARANTEE SEP 1996

52.228-2 ADDITIONAL BOND SECURITY OCT 1997

52.228-11 PLEDGES OF ASSETS JAN 2012

52.228-12 PROSPECTIVE SUBCONTRACTOR MAY 2014

REQUESTS FOR BONDS

52.228-14 IRREVOCABLE LETTER OF CREDIT NOV 2014

52.228-15 PERFORMANCE AND PAYMENT BONDS - OCT 2010

CONSTRUCTION

52.229-3 FEDERAL, STATE, AND LOCAL TAXES FEB 2013

52.232-5 PAYMENTS UNDER FIXED-PRICED SEP 2002

CONSTRUCTION CONTRACTS

52.232-23 ASSIGNMENT OF CLAIMS JAN 1986

AG-7335-S-15-0011 Revised Page 26 of 54

52.232-27 PROMPT PAYMENT FOR CONSTRUCTION JUL 2013

CONTRACTS

52.232-33 PAYMENT BY ELECTRONIC FUNDS JUL 2013

TRANSFER- SYSTEM FOR AWARD

MANAGEMENT

52.232-39 UNENFORCEABLILITY OF UNAUTHORIZED JUN 2013

OBLIGATIONS

52.232-40 PROVIDING ACCELERATED PAYMENTS TO DEC 2013

SMALL BUSINESS SUBCONTRACTORS

52.233-1 DISPUTES JUL 2002

52.233-3 PROTESTS AFTER AWARD AUG 1996

52.233-4 APPLICABLE LAW FOR BREACH OF AUG 1996

CONTRACT CLAIM

52.236-2 DIFFERING SITE CONDITIONS APR 1984

52.236-3 SITE INVESTIGATION AND CONDITIONS APR 1984

AFFECTING THE WORK

52.236-5 MATERIAL AND WORKMANSHIP APR 1984

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR APR 1984

52.236-7 PERMITS AND RESPONSIBILITIES NOV 1991

52.236-8 OTHER CONTRACTS APR 1984

52.236-9 PROTECTION OF EXISTING VEGETATION, APR 1984

STRUCTURES, EQUIPMENT, UTILITIES,

AND IMPROVEMENTS

52.236-10 OPERATIONS AND STORAGE AREAS APR 1984

52.236-11 USE AND POSSESSION PRIOR TO APR 1984

COMPLETION

52.236-12 CLEANING UP APR 1984

52.236-16 QUANTITY SURVEYS APR 1984

52.236-17 LAYOUT OF WORK APR1984

52.236-21 SPECIFICATIONS AND DRAWINGS FOR FEB 1997

CONSTRUCTION

52.236-26 PRECONSTRUCTION CONFERENCE FEB 1995

52.242-13 BANKRUPTCY JUL 1995

52.243-4 CHANGES JUN 2007

52.244-2 SUBCONTRACTS OCT 2010

52.244-6 SUBCONTRACTS FOR COMMERCIAL ITEMS OCT 2014

52.248-3 VALUE ENGINEERING-CONSTRUCTION OCT 2010

ALTERNATE II

52.249-2 TERMINATION FOR CONVENIENCE OF THE SEP 1996

GOVERNMENT (FIXED PRICE)

52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) APR 1984

52.252-2 CLAUSES INCORPORATED BY REFERENCE FEB 1998

52.252-4 ALTERATIONS IN CONTRACT APR 1984

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES APR 1984

52.253-1 COMPUTER GENERATED FORMS JAN 1991

I.2 52.222-35 EQUAL OPPORTUNITY FOR VETERANS (JUL 2014)

(a) Definitions. As used in this clause--

AG-7335-S-15-0011 Revised Page 27 of 54

“Active duty wartime or campaign badge veteran,” “Armed Forces service medal veteran,” “disabled veteran,” “protected veteran,” “qualified disabled veteran,’ and “recently separated veteran” have the meanings given at FAR 22.1301.

(b) Equal opportunity clause. The Contractor shall abide by the requirements of the equal opportunity clause at 41 CFR 60-300.5(a), as of March 24, 2014. This clause prohibits discrimination against qualified protected veterans, and requires affirmative action by the Contractor to employ and advance in employment qualified protected veterans.

(c) Subcontracts. The Contractor shall insert the terms of this clause in subcontracts of $100,000 or more unless exempted by rules, regulations, or orders of the Secretary of Labor.