Pagess_2-4.pdf

Amendment 1

SOLICITATION #AG-5F48-S-15-0014

ROCK COUNTY TRIO WRP RESTORATION PROJECT

Site Showing was conducted on Tuesday, 6/9/15 beginning at 9am CST. Site Showing participants are listed below:

Joe Schnell Iverson Construction Jordan Rowe Tallgrass Restoration Roger Thimm Wondra Construction Rod Paul Solutions 101 Josh Phillips Carrousel Excavating Tom Kluck Frank Silha & Sons

Amendment 1 also provides:

• updated Section B, Supplies or Services and Prices, which adds line item 10 for Temporary Seeding

• revised Sheet 30a of the Construction Plans that removes mulching from the plan.

PART I – THE SCHEDULE

SECTION B - SUPPLIES OR SERVICES AND PRICES

ROCK COUNTY TRIO WETLAND RESERVE PROGRAM (WRP) RESTORATION PROJECT

Solicitation requires bidding on all line items, failure to do so will disqualify the bid.

Line Item Description Estimated

Quantity Unit Unit Price Price

001 Mobilization/Demobilization 1 JOB xxxx

002 Excavation/Earthfill 1 LUMP SUM xxxx

003 Clearing 18.5 ACRE $

004 Tile Search & Tile Removal 8,100 LINEAR

FEET $

005 Water Control Structure & Pipes 1 JOB xxxx

006 Rock Riprap/Geotextile 1 JOB xxxx

007 Seeding Introduced Grasses 2.8 ACRE $

008 Seeding Native Grasses 65 ACRE $

009 Obstruction Removal 1 JOB xxxx

Temporary Seeding – line item will only be paid if needed/completed

67.8 ACRE $

TOTAL BID

PRICE $

FAR 52.211-18 Variation in Estimated Quantity (Apr 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

ONE AWARD FOR THE AGGREGATE OF ALL ITEMS WILL BE MADE AS A RESULT OF THIS SOLICITATION

Rock County Trio WRP Restoration Page 3 of 28 AG-5F48-S-15-0014

ROCK COUNTY TRIO WRP RESTORATION PROJECT