Statement of Work.doc

SPECIFICATIONS

WFM-0801-09HF

NF AL Sub-project – Bankhead RD

Hazardous Fuels Reduction

DIVISION 100-GENERAL SPECIFICATIONS

110-Scope.

The project is described in detail in the “Specifications” section. The purpose of this project is to reduce or minimize catastrophic wildfires and restore fire dependent woodlands. This contract will mechanically reduce the density and continuity of small diameter vegetation (understory and midstory as specified in Division 211-Tree to be Treated) within ten project areas. The ten project areas located within 5 Units total approximately 1204 acres and are located within Winston County, Alabama. The total acreage to be treated is contingent upon available funds. The contractor will furnish all labor, supplies, tools, equipment, transportation and supervision to perform all work necessary to treat all woody stems specified in Division 211-Trees to be treated. All specified stems will be cut, mulched, chopped, slashed, mowed, severed or otherwise put on the ground with a mechanical cutting device as specified in Division 213-Fuels Treatment Procedures.

111-Description and Location.

All areas are within the boundaries of the Bankhead Ranger District, in Winston County, Alabama. The areas are located throughout the district. See Exhibits: Project Area Maps.

Treatment Units/Project Areas Legal

Acres

Completion Date

T10S R7W S 2

T9S R6W S 19

T11S R7W S 6,7,18

T9S R7W S 30,31

T10S R8W S 1,2

T8S R7W S 6

T8S R8W S 1

T10S R7W S 3,10

T10S R7W S 16,17

T10S R7W S 2,11

T7S R7W S 30

112-Description of Treatment Area(s).

The treatment areas include mature Pine/Hardwood and Pine stands. Vegetation in these areas consists of pine and hardwood pulpwood and saw–timber with interspersed hardwood and pine midstory and understory of various ages and sizes.

All treatment areas are accessible with existing roads or dozer lines.

Some units have multiple rock outcroppings in the treatment area.

113-Boundaries.

Boundaries of areas to be worked will be marked with orange flagging. In some areas, Forest Service roads and fire lines may be used as boundaries. A map is attached showing project boundaries. See Exhibits: Project Area Maps.

114-Contractor Furnished Items.

The contractor will furnish all materials and equipment needed to complete the contract.

115-Pre-work Conference

Prior to commencement of work on any of the treatment areas, a meeting, requested by the Contracting Officer, will be attended by the Contractor, Contractor’s Representatives, and delegated Forest Service representatives. The meeting will be held at a time and place mutually agreeable to the Contractor and Forest Service for the purpose of discussing work schedules, quality control, and review of the specifications. At this meeting the Contractor will provide written delegations of authority for his/her Contract Representative and Field Representatives. Contractor will provide, for Contracting Officer’s approval, a schedule of work for completing all Units and a quality control plan. Schedule of work will present a practicable work progress schedule showing the order in which work on each treatment unit will be started and completed. The schedule will show a self inspection plan, daily planned acreage accomplishments, number of workers, equipment and/or tools that will be used, and planned completion dates. The Quality Control Plan will identify who and how Contractor’s work will be self inspected and what documentation will be provided during and at the conclusion of work.

116-Performance and Acceptance

The Contractor shall provide the Contracting Officer or his/her representative written notification within 10 days of planned commencement of work.

The Contractor may only work in one treatment unit at a time and may not start work in another treatment unit until all work has been completed and accepted by the Contracting Officer Representative (COR) or unless otherwise agreed to in writing.

At completion of work in a treatment area, the Contractor will notify the Contracting Officer's Representative that the required work has been completed to standards and is ready for final inspection. Upon final inspection by the COR, the Contractor will be given written notice of acceptance. Upon written notice of acceptance, the Contractor is then authorized to move to the next work unit identified in the schedule of work.

Payment will be based upon written acceptance of all required work in a Treatment Unit by the Contracting Officer. When there is more than one Treatment area in a Treatment Unit, partial payments for completed and accepted work in one or more units can be made at the written request of the Contractor and with the written approval of the Contracting Officer.

117-Method of Measurement

Acres of treatment were determined by a Global Positioning System (GPS) and are considered to be actual acreages. Boundaries are identifiable on the ground by natural or man-made features such as roads, meadows, timber edge, fire lines, painted unit boundaries, orange glow flagged boundary line.

118-Safety The Contractor and the Contractor’s employees shall operate within the Occupational Health and Safety Administration (OSHA) standards for safety and safety equipment.

The Contractor and Contractor’s employees shall adhere to all safety regulations and guidelines applicable to this type of work. It is the contractor’s responsibility to know what safety regulations and guidelines are applicable to this type of work.

The Contractor shall provide a written, job-specific safety plan for the inherently hazardous conditions that exist during operations. Contractor’s safety plan shall identify and describe any inherently hazardous conditions and specific actions to reduce these hazards. This plan shall be provided to the Contracting Officer (CO) at the post award conference. Work shall not commence on this project if the Contractor fails to provide the CO with a safety plan.

When Contractor’s operations are in progress adjacent to roads open to public travel, the Contractor shall furnish, install and maintain temporary traffic controls signs which will provide adequate warning of hazardous or potentially hazardous conditions associated with Contractor’s operations.

119-Work Unit Trash Disposal

Contractor shall ensure that all Contractor generated trash, paper, cans, food, etc., is picked up by the Contractor or the Contractor’s crew(s). No trash shall be left at work units, along forest roads, or other forested areas.

120-Equipment Requirements

All heavy equipment, including tractors, dozers, and mulchers must be equipped with protective canopies or roll-over protection devices and fire extinguishers.

Mulching equipment must be of sufficient size and type capable of cutting and mulching midstory and understory trees, as well as mulching logs and stumps. (Minimum 100 Horse Power) The mulcher must be equipped with a horizontal shaft head with teeth/knives (a hammer type cutting head or swing-tooth flail drum). The horizontal shaft head may be directly or boom mounted to the carrier. There are no restrictions on drive train, i.e. rubber-tired or track mounted. Unit 2 will require some work to be done with hand tools (chainsaws, brush cutters, etc) on steep banks, near paved hiking trails, along Lewis Smith Lake, where equipment will not be allowed. Bids for this mechanical fuels project shall include a description of the equipment that will be used for the project. (rubber tire or tracked equipment, horsepower, etc.)

Transportation equipment shall meet DOT requirements and be capable of transporting required equipment over access roads.

All equipment including dozers, lowboys, trucks, mulchers etc. must be cleaned offsite prior to start of contract to prevent the introduction and spread of nonnative invasive species. Treatment units 2 and 5 have nonnative invasive species spread throughout the treatment units. Mandatory washing of equipment is required when moving any equipment from these units. A washing station will be provided at the Black Warrior Work Center on Highway 33.

Equipment shall be in good working condition and free of abnormal leakage of lubricants, fuel, coolants, and hydraulic fluid. Contractor shall remove from National Forest lands all contaminated soil, vegetation, debris, vehicle oil filters, batteries, oily rags, and waste oil resulting from use, servicing, repair, or abandonment of equipment.

DIVISION 200-TECHNICAL SPECIFICATIONS

210-Time of Treatment.

All units shall have treatments completed on or before March 31, 2011. Treatment Unit 2 shall only be treated during the winter months while the Corinth Recreation Area is closed to the public. Soil conditions suitable for operation will be determined by COR. See Exhibits: Project Area Maps 210a- Order of Treatment Treatment Units 2 and 4 shall be the first units treated, depending on seasonal closure of Corinth Recreation Area. The remaining order of treatment will be at the contractor’s discretion. See Exhibits: Project Area Maps.

211-Trees to be Treated.

All trees and shrubs less than 6.1 inches DBH will be treated/cut 212-Trees or other Vegetation NOT to be Treated.

1. All trees greater than 6.1 inches DBH

2. All trees and shrubs, regardless of DBH, designated as reserve trees by blue flagging.

3. Any trees marked with paint (i.e., red-property line, blue-resource protection area, orange-SPB reserve tree, or green-SMZ.).

4. Any flagged trees designating the unit boundary.

5. Recognizable den trees (i.e., those with cavities or crevices).

6. Naturally occurring snags (i.e., dead trees), unless they pose a safety hazard to the contractor.

7. Other trees, species, or size classes designated by the COR/INSPECTOR as work progresses.

213-Fuels Treatment Procedures.

1. All trees and shrubs selected for treatment by contract, COR or inspector must be felled using a mechanical cutting device. Mulching equipment must be of sufficient size and type capable of cutting and mulching midstory and understory trees up to 6 inches in DBH. (minimum 100 horse power)

2. Trees and shrubs designated for treatment that occur adjacent to roads, pipelines, fire lines, managed wildlife openings, or trails will be felled away from those structures. Slash and debris felled in structures mentioned above will be pulled into the treatment unit.

3. All trees and shrubs designated for treatment will be completely severed from the stump. No trees will be removed from the treatment areas.

4. Trees and shrubs designated for felling will be cut as close to ground level as practicable without disturbing the soil, but not higher than 8-inches from ground level.

5. When felled, cut trees will not be left hanging or lodged on nearby trees.

6. Slash will not be higher than two feet from ground level.

7. All trees and shrubs designated for treatment will be removed from within 12 inches of trees to be retained.

8. Equipment will not be operated in riparian areas designated by flagging or within thirty feet of Lewis Smith Lake. Steel tracked machinery shall not cross paved roads or trails.

9. The contractor shall avoid any damage to improvements such as, but not limited to, roads, gates, signs, culverts, bridges, fences, utility poles, paved roads, paved or unpaved hiking trails, and survey markers. The contractor will be required to repair or pay fair market value to replace any damaged improvements.

10. Trees to be retained and designated reserve trees will not be damaged by the Contractor’s operations. Accidental nicking (scuffing of bark exposing the cambium layer or inter wood) of reserve or retention trees shall be immediately repaired with nursery tree heal paint by the contractor.

11. All trees larger than 6.1 inches in diameter will be protected from damage. Damage is defined as: bumping or pushing of tree that results in root damage; scaring of the bole of the trees where 144 square inches or more of the cambium layer is exposed; side-washing of the tree resulting in the breakage of 50 percent or more of the crown limbs; and brakeage or cracking of the main bole of the tree.

12. Should damage, as defined in #11, occur through mistake or negligence, the Contractor will be assessed liquidated damages at the following rate: $9.25 per tree for all trees larger than 9.6 inches DBH and $1.00 per tree for all reserve trees between 6.1 inches and 9.5 inches DBH. Trees that are damaged will not be removed by the contractor even if the contractor is assessed liquidated damages.

13. When the Contractor’s operations are in progress adjacent to Forest Service roads open to public travel, the Contractor shall furnish, install and maintain all temporary traffic controls which provide the user with adequate warning of hazardous or potentially hazardous conditions associated with the Contractor’s operations.

14. The Contractor shall ensure all equipment moved onto National Forest land is clean and free of soil, seeds, and vegetative matter or other debris that could contain or hold seeds.

DIVISION 300 – GENERAL INSPECTION AND ACCEPTANCE SPECIFIC TO ALL BID ITEMS.

300-Inspection of Services

Definition. “Services” as used in this clause, includes services performed, workmanship, and materials furnished or utilized in the performance of services.

The Contracting Officer or the Contracting Officer’s duly authorized representative will inspect and accept the services to be provided under this contract.

The Contracting Officer's Representative or a designated Inspector will make periodic inspections as work progresses at such intervals as is necessary to ensure compliance with the contract specifications and provisions. The Contractor may observe the inspection while it is being made.

The Contractor shall provide and maintain an inspection system that is acceptable to the Government that covers the Services under this contract.

The Government has the right to inspect and test all Services called for by the contract, to the extent practicable at all times and places during the term of the contract. The Government will perform inspections and tests in a manner that will not unduly delay the work.

If any of the Services do not meet contract requirements, the Government may require the Contractor to perform the Services again in accordance with contract requirements, without increase in the amount of the Quote Item. When defects in Services cannot be corrected by re-performance, the Government may: (1) require the Contractor to take necessary action to ensure that future performance meets contract requirements; and (2) reduce the Quote Item value to reflect the reduced value of the Services performed.

If the Contractor fails to perform the Service again or to take the necessary action to ensure future performance meets contract requirements, the Government may, (1) by contract or otherwise, perform the Service and charge the Contractor costs incurred by the Government that are directly related to the performance of such Service or (2) initiate breach of contract actions.

Government will randomly review the manner in which the Contractor is conducting the Quality Control Program by both reviewing Contractor records and observing actual performance. Government may inspect any area within treatment units and compare records and/or do all of the above. If Government inspection shows a difference in results as compared to the Contractor’s inspection, then the Government may elect to inspect the unit at the Contractors expense, not limited to, but including time and mileage.

Upon completion of work, the Contractor shall notify the Contracting Officer or Contracting Officer's Representative that work has been completed. The Contracting Officer's Representative or Inspector will then make an overall inspection of the work completed.

310-Acceptance of Work

Work will be accepted when the work is completed according to the contract specifications. If the work completed is accepted, the Contractor shall proceed according to the Work Progress Schedule. If the work is not accepted, the Contractor shall not receive payment until completing any remedial work required for acceptance. If the area cannot be brought up to specifications, credits or payments will be reduced or not be awarded.

Non-conformance with any of the specifications will classify the work as unsatisfactory and rework may be required to bring the work up to standard.

Acceptance of units worked will be reserved until a final inspection is held. If said Contractor moves to another unit and describes the unit left as being completed and upon inspection, the Contracting Officer's Representative or Inspector determines the work unacceptable, said Contractor shall be required to return and complete all unacceptable work at no additional cost to the Government.

PAGE