AG-4431-S-16-0008_Specifications.pdf

SPECIFICATIONS

BUILDING 8 ROOF

REPLACEMENT

JAMIE WHITTEN DELTA STATES RESEARCH CENTER

STONEVILLE, MISSISSIPPI

Prepared For:

U.S. DEPARTMENT OF AGRICULTURE

Agricultural Research Service

Prepared By:

THE JOHNSON-McADAMS FIRM, P.A.

Greenwood, Mississippi

May 2014

TABLE OF CONTENTS Page 1

TITLE: BUILDING 8 ROOF REPLACEMENT

STONEVILLE, MISSISSIPPI

TABLE OF CONTENTS

Section Number Section Title

DIVISION 01 GENERAL REQUIREMENTS

01 00 01 Warranty of Construction 01 00 11 General Paragraphs 01 00 21 Contractor Quality Control 01 33 00 Submittal Procedures 01 50 00 Project Closeout 01 57 50 Temporary Environmental Controls

DIVISION 02 EXISTING CONDITIONS

02 41 00 Demolition

DIVISION 06 WOOD, PLASTICS, AND COMPOSITES

06 10 00 Rough Carpentry

DIVISION 07 THERMAL AND MOISTURE PROTECTION

07 22 00 Roof and Deck Insulation 07 52 00 Modified Bituminous Membrane Roofing 07 60 00 Flashing and Sheet Metal 07 92 00 Joint Sealants

APPENDIX “A” PHOTOGRAPHS

-- End of Table of Contents --

BUILDING 8 ROOF REPLACEMENT, USDA ARS, STONEVILLE, MS 1332A

SECTION 01 00 01 Page 1

SECTION 01 00 01

WARRANTY OF CONSTRUCTION

PART 1 GENERAL

1.1 WARRANTY OF CONSTRUCTION

1.1.1 General

In addition to any other warranties set out elsewhere in this contract, the Contractor warrants that work performed under this contract conforms to the contract requirements and is free of any defect of equipment, material or design furnished, or workmanship performed by the Contractor or any of his subcontractors or suppliers at any tier. Such warranty shall continue for a period of one year from the date of final acceptance of the project. Under this warranty, the Contractor shall remedy at his own expense any such failure to conform or any such defect. In addition, the Contractor shall remedy at his own expense any damage to Government owned or controlled real or personal property, when that damage is the result of the Contractor's failure to conform to contract requirements or any such defect of equipment, material, workmanship, or design. The Contractor shall also restore any work damaged in fulfilling the terms of this clause. The Contractor's warranty with respect to work repaired or replaced hereunder will run for one year from the date of such repair or replacement.

1.1.2 Notification and Compliance

The Government shall notify the Contractor in writing within a reasonable time after the discovery of any failure, defect, or damage. Should the Contractor fail to remedy any failure, defect, or damage described in paragraph 1.1.1 above within a reasonable time after receipt of notice thereof, the Government shall have the right to replace or repair and have the cost billed to the Contractor.

1.2 EXPRESSED WARRANTY

In addition to the other rights and remedies provided by this clause, all subcontractors', manufacturers', and suppliers' warranties expressed or implied, respecting any work and materials shall, at the direction of the Government, be enforced by the Contractor for the benefit of the Government.

In such case, if the Contractor's warranty under paragraph 1.1.1 above has expired, any suit directed by the Government to enforce a subcontractor's, manufacturer's, or supplier's warranty shall be at the expense of the Government. The Contractor shall obtain any warranties which the subcontractors, manufacturers, or suppliers would give in normal commercial practice. If so directed by the Contracting Officer, the Contractor shall require any such warranties to be executed in writing to the Government.

1.3 LATENT DEFECTS

The Warranty specified herein shall not limit the Government's rights with respect to latent defects, gross mistake, or fraud.

-- End of Section --

SECTION 01 00 11 Page 1

SECTION 01 00 11

GENERAL PARAGRAPHS

PART 1 GENERAL

1.1 DESCRIPTION OF WORK

1.1.1 Work To Be Done

The work to be done consists of furnishing all labor, materials, and equipment and performing all work in strict accordance with these specifications for Building 8 Roof Replacement, USDA, ARS, Stoneville, Mississippi.

1.1.2 Location

The site of work contemplated by this specification is at Buildings 8 located at USDA, ARS, Stoneville, Mississippi.

1.1.3 Principal Features of Work:

BASE BID

1. Demolition of existing TPO roofing membrane, tapered and non-tapered insulation, treated wood nailers, metal roof edge, pipe and curb flashings, down to tectum and concrete roof decks as indicated on drawings on Buildings 8.

2. Installation of fully adhered modified roofing system over fully adhered tapered insulation.

3. Installation of all flashings, gutters and downspouts as indicated on drawings.

ALTERNATE BID ITEM #1

1. Provide all labor and materials as required to remove existing cast concrete coping and install aluminum coping as detailed and specified.

1.2 SITE VISIT

A site visit and inspection tour will be held at Buildings 8, USDA at Stoneville, Mississippi. All potential bidders will be notified of the exact time and date and are strongly urged to attend the site visit.

Inspection may only be made at this time, unless prior written approval is obtained to inspect at another date and time. Contact:

U.S. Department of Agriculture

Agricultural Research Service – WBSC Attn: Mr. Huron Virden 141 Experiment Station Road Stoneville, MS 38776 Tel. No.: (662) 686-5388

1.3 COORDINATION OF WORK

1.3.1 Work space and space available for storing materials shall be subject to the approval of the Contracting Officer. Do not store materials and equipment in other than assigned areas.

SECTION 01 00 11 Page 2

1.3.2 Execute work so as to interfere as little as possible with normal functioning of the facility, including operations of utility services and any existing equipment, and with work being done by others.

1.3.3 Minimize interference of construction activities with the flow of traffic by keeping roads, walks and entrances to grounds, to parking areas and to occupied areas of buildings clear of construction materials, debris, construction equipment and vehicles except where noted on plans or in specifications. Provide unobstructed access to areas required to remain in operation.

1.3.4 The Contractor shall complete all work within 120 consecutive calendar days after Notice to Proceed. Within 14 calendar days after Contract Award, the Contractor shall provide the Government with a detailed schedule of dates on which the Contractor plans to accomplish the work. In addition, the Contractor shall notify the Contracting Officer 10 days in advance of starting work. A planned work schedule shall be submitted to the Contracting Officer for approval. The schedule shall include a detailed description of the methods and equipment to be used for each operation and the sequence of operations. This schedule shall be updated monthly and submitted to the Contracting Officer for approval.

1.3.5 The Contractor shall take all measures and provide all material necessary for protecting existing equipment, property, and ongoing operations in affected areas of construction against dust, noise and debris.

1.3.6 Power sources for the Contractor's operations will be available and supplied by the Government to the Contractor as long as its use does not interfere with the operations of the Government's facilities. Water sources will be available and supplied by the Government to the Contractor as long as its use does not interfere with the operations of any building. The Contractor is responsible for extending utility sources to his work locations. Such extensions shall be removed after work is completed, to the satisfaction of the Contracting Officer.

1.3.7 All references in the specifications to the Contracting Officer and

Contracting Officer's Representative shall constitute referrals initially to the Contracting Officer's Representative.

1.3.8 Contractor shall provide sanitary facilities for use by his employees and the employees of his subcontractors working on job site.

1.4 DRAWINGS

1.4.1 All dimensions shown of existing work and all dimensions required for work that is to be connected with existing work shall be verified by the Contractor by actual field measurements. Any work at variance with that specified or shown on the drawings, shall not be performed by the Contractor until the Contractor has received approval in writing from the Contracting Officer.

1.5 MATERIAL SAFETY DATA SHEETS (MSDS)

Material Safety Data Sheets must be submitted to the Contracting Officer prior to the commencement of any work with any substance that may be considered hazardous.

SECTION 01 00 11 Page 3

1.6 UTILITIES OR STRUCTURAL ITEMS CONFLICTING WITH PROPOSED CONSTRUCTION

In the event the Contractor finds an area where existing utilities or structural items conflict with proposed construction, the Contracting Officer shall be notified immediately. The Contractor shall then propose a method of solving the problem. Work shall not resume in the problem area until the Contractor has received written approval from the Contracting Officer. There shall be no additional cost to the Government.

1.7 ACCEPTANCE OF WORK

1.7.1 Final inspection will not be made until the contract work is completed. The Contractor shall notify in writing the Contracting Officer fifteen working days prior to the date on which the work will be ready for final inspection.

1.7.2 Final inspection and acceptance of the work shown by the drawings and specifications forming a part of this contract shall not be binding or conclusive on the Government if it shall be shown that (1) the Contractor has willfully or through collusion with persons or firms engaged in the performance of the contract supplied inferior materials, equipment, or workmanship, or (2) the Contractor has otherwise departed from the terms of the contract.

SECTION 01 00 21 Page 1

SECTION 01 00 21

CONTRACTOR QUALITY CONTROL

PART 1 GENERAL

1.1 GENERAL

This section covers the quality control inspection, sampling, and testing of all materials, services, and workmanship required to be performed by the contract drawings, specifications, and other contract requirements. The Contractor shall perform all quality control inspection, sampling, and testing required by this contract and shall review and certify that each submittal is correct and in strict conformance with the contract drawings and specifications for all shop drawings and lists of materials, fixtures, and equipment. All work performed under this contract shall be in strict accordance procedures and requirements detailed on the plans and specifications.

1.1.1 Certificate of Compliance

Upon completion of the contract work and prior to final acceptance, the Contractor shall submit to the Contracting Officer a certificate of compliance which states that all materials, equipment, design, and workmanship incorporated in the work are in strict compliance with contract drawings and specifications except for approved deviations. The certificates of compliance shall be signed and dated by both the manufacturer’s representative and the Contractor. Based upon this certificate of compliance and other contract requirements, the Contractor shall be responsible for correcting at his expense any defects, omissions, and deviations (other than those previously approved) which are detected during the contract period or during the one year warranty period as defined in

SECTION 01 00 01, WARRANTY OF CONSTRUCTION.

1.2 INSPECTION

The Contractor shall inspect all materials, services, and workmanship to assure conformance with contract requirements.

1.3 REVIEW AND APPROVAL OF SHOP DRAWINGS, SUBMITTALS, MATERIALS, FIXTURES,

AND EQUIPMENT

1.3.1 Prior to submission to the Government for approval, the Contractor shall review and certify that all shop drawings, submittals, lists of materials, fixtures, and equipment as called for under the various headings of these specifications are correct and in strict compliance with the contract drawings and specifications. These drawings, submittals and lists shall be accurate, complete, and adequately detailed. The top copy of data comprising each item listed on the transmittal form shall be identified as having received the quality control inspector's approval by being so stamped, signed and dated. Approval of shop drawings, submittals, materials, fixtures, and equipment by the Contracting Officer will not relieve the Contractor of the responsibility for any errors which may exist and the Contractor shall be responsible for the satisfactory construction of all work. All samples of materials submitted as required by these specifications shall be properly identified and labeled for ready identification, and upon being approved, stored at the site of the work for jobsite use until all work has been accepted by the Contracting Officer.

The Contractor shall provide four (4) sets of all shop drawings.

SECTION 01 00 21 Page 2

1.3.2 All proposed deviations required by the Contractor shall be noted in the "Remarks" column of the Form. The Contractor shall set forth in writing the reason for any deviations and annotate such deviations on the shop drawing. The Government reserves the right to rescind inadvertent approval of shop drawings containing unnoted deviations.

1.4 DAILY RECORDS

The Contractor shall maintain a daily record of quality control measures performed for each shift of Contractor or Subcontractor operations on an appropriate format. These records shall provide factual evidence that continuous quality control inspections have been performed, including but not limited to the following: job progress, problems encountered; problems resolved; type and number of inspections; results of inspections or tests including all computations; nature of defects; causes for rejection; safety violations; proposed remedial action; and corrective action taken. These records shall cover both conforming and defective items and shall include a statement that all supplies and materials incorporated in the work are in full compliance with the terms of the contract. The Contractor shall maintain a current record of all inspections and shall furnish to the Contracting Officer on a daily basis, legible copies of all inspection records for his permanent retention. The daily records of inspections shall cover all work placement subsequent to the previous report, and shall be verified by the Contractor's designated representative.

1.5 RECURRING DEFICIENCIES

If recurring deficiencies in an item or items being inspected by the Contractor indicate that the inspection system is not providing adequate quality control, the Contractor shall take such corrective measures as deemed necessary by the Contracting Officer.

1.6 CONFLICTS

In the event of a difference of opinion between the Contractor and the Contracting Officer, the Contracting Officer shall govern.

SECTION 01 33 00 Page 1

SECTION 01 33 00

SUBMITTAL PROCEDURES

1. SHOP DRAWINGS

The Contractor shall furnish the Contracting Officer six copies with such promptness as to cause no delay in this work or the work of any other contractors, one sepia copy of the shop drawings as required for the various subheadings for the Contracting Officer's approval. Shop drawings of any other subcontractor should be reviewed and approved by each subcontractor where their contract work comes in contact with or interferes with that of another subcontractor.

1.1 The Contracting Officer's approval, however, shall not relieve the

Contractor from responsibility for errors in shop drawings. Shop drawings are the instruments of the Contractor, not the Contracting Officer; the Drawings and Specifications shall always be final.

2. SAMPLES

Within and not later than thirty (30) days from the date of the General Contract, the General Contractor shall have secured and submitted to the Contracting Officer for his consideration, two samples of each kind and grade of materials and finish as noted under the various headings of the specifications. These samples shall be finished completely and shall accurately represent the work as it is proposed to be installed. The Contracting Officer will give immediate consideration to such samples and shall notify the General Contractor within ten (10) days after receipt of either approval or rejection. If such samples are rejected, the General Contractor shall, without delay, submit corrected samples for approval, and shall continue to do so until such approval is given the Contracting Officer. All approvals will be given by the Contracting Officer to the General Contractor in writing.

2.1 It shall be the Contractor's responsibility to obtain materials at such time as to cause no delay to the project. No allowance for additional time nor substitution of approved materials will be allowed for Contractor's negligence in late ordering of materials.

3. PRODUCT DATA

Submit six copies of preprinted material such as illustrations, standard schedules, performance charts, instructions, brochures, diagrams, manufacturer’s descriptive literature, catalog data, and other data to illustrate portion of work.

4. GOVERNMENT ACTIONS POSSIBLE

Submittals will be returned to the Contractor with one of the following notations:

a. Submittals marked “approved” or “approved as submitted” authorize

Contractor to proceed with work covered.

b. Submittals marked “approved as noted” or “approval except as noted; resubmission not required” authorize Contractor to proceed with work as noted provided the Contractor takes no exception to the notations.

c. Submittals marked “revise” and “resubmitall” or “disapproved”

SECTION 01 33 00 Page 2 indicate submittal is incomplete or does not comply with design concept or requirements of the contract documents and shall be resubmitted with appropriate changes. No work shall proceed for this item until resubmittal is approved.

5. SUBMITTAL REGISTER

Contractor shall submit items as listed on the attached Submittal Register.

S U

B M

IT

TA

L

FO

R M

,J an

P R

E V

IO

U

S E

D

IT

IO

N

IS

O

B S

O

LE

TE

P A

G E

O

F

P A

G E

SU

B

M

IT

TA

L

R

EG

IS

R

C O

N

TR

A C

T N

O

TI

TL

E A

N D

L O

C A

TI

N

IL

D

IN

G

R

O O

F R

E P

LA

C

E M

E N

T, U

S D

A A

R S

, S

TO

N E

V

IL

LE

, M

N

TR

A C

TO

T I V I T Y

T R

M

I T T A

L

T

D

S

C R

IP

TI

IT

M S

U B

M

IT

G

H

V

L A

I

F

W

N

TR

A

C

TO

R

S C

H E

D U

LE

D

A

N

TR

A C

TI

P

R O

V

IN

G A

U

TH

O R

Y

IL

ED

N

TR

D

A

TE

R

FR

A

PP

AU

TH

M

A R

K

B

AP

R O

V A

L N

E E

BY

TE

R

IA

L

N E

E

T I O

AC

TI

TE

F

PR

D

A

TE

R

TR

FW

V

IE

W E

R D

M

V

IE

W

E

AC

TI

(a

(b

(c

(d

(e

(f)

(g

(h

(i)

(j)

(k

(l)

(m

(n

(o

(p

(q

(r)

-0

P re co ns tru ct io n S ub m itt al s xi st in g C on di tio ns

1.

6.

-0

C er tif ic at es em ol iti on

P la n 1.

ot ifi ca

4.

-0

S ho p

D ra w in gs ai lin g S tri ps

2.

1.

-0

D es ig n

D a od ifi ca tio ns o f s tru ct ur m em be rs

-0

Te st R ep or ts re se rv at iv e-tre ed

-0

C er tif ic er tif ic at es o f g ra de

8.

se rv at iv e tre at m en t

-0

S ho p

D ra w oo d na ile

Ta pe re d ro of in su la tio n 2.

1.

-0

P ro du ct D

Fa st en er s sp ha lt

2.

3.

In su la tio n 2.

-0

Te st

R ep

Fl am e sp re ad a nd s m ok e

1.

de ve lo pe d ra tin

-0

C er tif ic

B M

IT

TA

L

FO

R M

,J an

P R

E V

IO

U

S E

D

IT

IO

N

IS

O

B S

O

G E

O

F

P A

G

M

IT

TA

L

R

EG

IS

N

TR

A C

T N

O

TI

TL

E A

N D

L O

C A

TI

IL

D

IN

G

R

O O

F R

E P

LA

C

E M

E N

T, U

S D

A A

R S

, S

TO

N E

V

IL

LE

N

TR

A C

S

C R

IP

TI

M S

U B

M

IT

N

TR

A

C

TO

R

S C

H E

D U

LE

D

A

N

TR

A C

TI

P

R O

V

IN

G A

U

TH

O R

N

TR

D

A

TE

R

A

M

A R

B

R O

V A

L N

E E

TE

R

IA

L

N E

E

AC

TI

TE

F

D

A

TE

R

V

IE

W E

R D

M

V

IE

W

E

AC

TI

(b

(c

(d

(e

(h

(n

(o

(p

(q qu ifi ca

-0

M an uf ac tu re r’s In st ru ct io fa en er s su la tio n

-0

S ho p

D ra w oo f p la n

1.

4.

-0

P ro du ct

D ifi ed

B itu m en

S he et s ha lt

Fi be rg la ss F el t rim ifi ed

B itu m en

R oo f C em en t

-M an uf ac tu re d A cc es so rie s en er s

A nd

P la te s

2.

ar ra nt y

-0

D es ig n

D d U pl ift

C al cu la

-0

C er tif ic

Q ua lif ic at io n of M an uf ac tu re r

1.

lif ic at io n of A pp lic lif ic at io n of

E ng in ee r o f

1.

ec d ill o f L ad in g 1.

5.

d U pl ift

R es is ta nc e

1.

Fi

R es is ta nc e 1.

-0

M an uf ac tu re r’s In st ru ct

B M

IT

TA

L

FO

R M

,J an

P R

E V

IO

U

S E

D

IT

IO

N

IS

O

B S

O

G E

O

F

P A

G

M

IT

TA

L

R

EG

IS

N

TR

A C

T N

O

TI

TL

E A

N D

L O

C A

TI

IL

D

IN

G

R

O O

F R

E P

LA

C

E M

E N

T, U

S D

A A

R S

, S

TO

N E

V

IL

LE

N

TR

A C

S

C R

IP

TI

M S

U B

M

IT

N

TR

A

C

TO

R

S C

H E

D U

LE

D

A

N

TR

A C

TI

P

R O

V

IN

G A

U

TH

O R

N

TR

D

A

TE

R

A

M

A R

B

R O

V A

L N

E E

TE

R

IA

L

N E

E

AC

TI

TE

F

D

A

TE

R

V

IE

W E

R D

M

V

IE

W

E

AC

TI

(b

(c

(d

(e

(h

(n

(o

(p

(q ifi ed B itu m en M em br an e

3.

3.

pp lic at n as hi ng

3.

Te m pe ra tu re

L im ita tio ns fo r 3.

2.

ha lt en er s 2.

8.

ol d W ea th er In st al la tio n

-1

C lo se ou t S ub m itt ar ra nt y fo rm at io n C ar d ru ct io ns

T o

G ov er nm en t so nn el

-0

S ho p

D ra w ut te ow ns po ut s

3.

pl as h pa e fla sh in g

3.

ou nt er fla sh in g

3.

hi ng a t r oo f p en et ra eg le rip e dg e

3.

op in g

3.

-1

C lo se ou t S ub m itt lit y C on tro l P la n

-0

P ro du ct D

B M

IT

TA

L

FO

R M

,J an

P R

E V

IO

U

S E

D

IT

IO

N

IS

O

B S

O

G E

O

F

P A

G

M

IT

TA

L

R

EG

IS

N

TR

A C

T N

O

TI

TL

E A

N D

L O

C A

TI

IL

D

IN

G

R

O O

F R

E P

LA

C

E M

E N

T, U

S D

A A

R S

, S

TO

N E

V

IL

LE

N

TR

A C

S

C R

IP

TI

M S

U B

M

IT

N

TR

A

C

TO

R

S C

H E

D U

LE

D

A

N

TR

A C

TI

P

R O

V

IN

G A

U

TH

O R

N

TR

D

A

TE

R

A

M

A R

B

R O

V A

L N

E E

TE

R

IA

L

N E

E

AC

TI

TE

F

D

A

TE

R

V

IE

W E

R D

M

V

IE

W

E

AC

TI

(b

(c

(d

(e

(h

(n

(o

(p

(q ea la nt s er s on d br ea ke ac ks to ps

-0

C er tif ic ea la nt

SECTION 01 50 00 Page 1

SECTION 01 50 00

PROJECT CLOSEOUT

1.1 AS-BUILT DRAWINGS

At the completion of the project, the Contracting Officer will furnish the

Contractor, free of charge, one set of drawings on which the Contractor will indicate all variations in locations, construction, equipment, etc.

from that shown on the original Drawings. They shall also indicate the exact location, size, etc. of the following:

a. Roofing work

1.2 SUBSTANTIAL COMPLETION AND COMPLETION OF PUNCH LIST CORRECTIONS

Set date and notify Contracting Officer as to time construction will be ready for preliminary punch list and, upon completion of that list, set time and date for inspection of punch list corrections. The failure to include any items on such list does not alter the responsibility of the Contractor to complete all Work in accordance with the Contract Documents. When the Contracting Officer on the basis of an inspection, determines that the Work or designated portion thereof is sufficiently complete, in accordance with the Contract Documents, so that the Owner or separate contractors can occupy or utilize the Work or designated portion thereof for the use for which it is intended, he will prepare a Certificate of Substantial Completion which shall establish the Date of Substantial Completion, shall state the responsibilities of the Owner and the Contractor for security, maintenance, heat, utilities, damage to the Work, and insurance, and shall fix the time within which the Contractor shall complete the items listed therein or attached thereto. Warranties required by the Contract Documents shall commence on the Date of Substantial Completion of the Work or designated portion thereof unless otherwise provided in the Certificate of Substantial Completion. The Certificate of Substantial Completion shall be submitted to the Owner and the Contractor for their written acceptance of the responsibilities assigned to them in such Certificate.

1.3 FINAL INSPECTION

The Contractor shall notify the Contracting Officer and Owner in writing 10 days prior to the date that the project will be ready for final inspection.

An inspection of the project will be made by the Contracting Officer and Contractor at a mutually agreed upon time. If the project is complete, in the opinion of the Contracting Officer, the Contracting Officer shall issue a certificate as set forth hereinafter. Minor unfinished items of work may be excluded from the certificate. The Contracting Officer and Contractor shall mutually agree on a date for the completion of these items of work.

Should the Contractor fail to complete the work within the agreed time, the Owner shall have the option of having the unfinished work completed.

1.4 RELEASE OF LIENS AND CERTIFICATION ALL BILLS ARE PAID

SECTION 01 50 00 Page 2

The Contractor, before final acceptance is given by the Contracting Officer, shall furnish for himself and all sub-contractors, in triplicate, duly certified by a notary, a full release of liens, damages, and a guarantee that all materials and labor are paid in accordance with the Contractual Documents.

1.5 GUARANTEE

The Contractor, before final acceptance by the Contracting Officer, shall furnish the Owner, in triplicate, a written notarized guarantee. All Contractors shall guarantee their work for a period of one year from the date of Substantial Completion as stated by the Contracting Officer.

Neither the final Certificate for Payment, nor any provision in the Contract Documents shall relieve the contractors of their responsibility for negligence or defective materials or workmanship within the extent and period covered by law; and upon written notice he shall remedy any defects due thereto, and pay all expenses for any damages to other work resulting therefrom. Emergency defective workmanship and defective materials within the year's guarantee shall be corrected within a few days after receipt of a written order from the Contracting Officer. Any items that are not considered of an emergency nature by the Contracting Officer may be corrected prior to the expiration of the Guarantee period.

1.5.1 The wording for the Guarantee shall be as follows:

"We hereby guarantee all work performed by us on the above captioned project to be free from defective materials and workmanship for a period of one year, or for such longer period of time as may be called for in the Contractual Documents for such portions of the work."

1.6 OTHER FINAL DOCUMENTS

Deliver to the Owner, through the Contracting Officer, all required bonds, warranties, individual guarantees, etc. that are required by the various following sections of these specifications.

1.7 ACCEPTANCE

Upon satisfactory submittal of the above documents the Contracting Officer shall issue to the Owner a certificate recommending final acceptance of the project. Minor unfinished items of work may be listed on the certificate and excepted from final acceptance. A sum sufficient to cover the cost of completing these unfinished items of work will be withheld by the Owner from the final payment. All other funds including retainage shall be due and payable upon receipt by the Owner of the Contracting Officer's certificate.

Upon certification by the Contracting Officer that the items of work have been completed, all monies withheld by the Owner shall be due the Contractor.

SECTION 01 57 50 Page 1

SECTION 01 57 50

TEMPORARY ENVIRONMENTAL CONTROLS

1.1 APPLICABLE PUBLICATIONS

The publications listed below form a part of this specification to the extent referenced. The publications are referred to in the text by the basic designation only.

ENVIRONMENTAL PROTECTION AGENCY (EPA)

40 CFR 112 Regulations on Oil Pollution Prevention

40 CFR 261 Regulations Identifying Hazardous Waste

40 CFR 262 Regulations for Hazardous Waste Generators

40 CFR 263 Regulations for Hazardous Waste Transporters

40 CFR 264 Regulations for Owners and Operators of Permitted

Hazardous Waste Facilities

40 CFR 403 General Pretreatment Standards

PL 96 510 Comprehensive Environmental Response Compensation and Liability Act of 1980

DEPARTMENT OF TRANSPORTATION (DOT)

49 CFR 171 Standards for Transportation of Hazardous Materials

49 CFR 172 Hazardous Materials Tables and Regulations

49 CFR 178 Regulations for Shipping Container Specifications

1.2 DEFINITIONS

1.2.1 Sediment

Soil and other debris that have eroded and have been transported by runoff water or wind.

1.2.2 Solid Waste

Rubbish, debris, garbage, and other discarded solid materials, except hazardous waste as defined in paragraph entitled, "Hazardous Waste," resulting from industrial, commercial, and agricultural operations and from community activities.

1.2.3 Rubbish

Combustible and noncombustible wastes such as paper, boxes, glass, crockery, metal, lumber, cans, and bones.

1.2.4 Debris

Combustible and noncombustible wastes such as ashes and waste materials resulting from construction or maintenance and repair work, leaves, and tree

SECTION 01 57 50 Page 2 trimmings.

1.2.5 Chemical Waste

This includes salts, acids, alkalies, herbicides, pesticides, and organic chemicals.

1.2.6 Sanitary Wastes

1.2.6.1 Sewage

Waste characterized as domestic sanitary sewage.

1.2.6.2 Garbage

Refuse and scraps resulting from preparation, cooking, dispensing, and consumption of food.

1.2.7 Hazardous Waste

Hazardous substances as defined in 40 CFR 261 or as defined by applicable state and local regulations.

1.2.8 Oily Waste

Petroleum products and bituminous materials.

1.2.9 Landscape Features

Trees, plants, shrubs and ground covers.

1.2.10 Hazardous Substances

As defined in EPA PL 96-510.

1.2.11 Hazardous Materials

As defined in DOT Regulation 49 CFR 171 and listed in 49 CFR 172.

1.3 ENVIRONMENTAL PROTECTION REQUIREMENTS

Provide and maintain, during the life of the contract, environmental protection as defined. Plan for and provide environmental protective measures to control pollution that develops during normal construction practice. Plan for and provide environmental protective measures required to correct conditions that develop during the construction of permanent or temporary environmental features associated with the project. Comply with Federal, state, and local regulations pertaining to the environment, including water, air, solid waste, hazardous waste and substances, oily substances and noise pollution.

PART 2 EXECUTION

2.1 NATURAL RESOURCES

Preserve the natural resources within the project boundaries and outside the limits of permanent work. Restore to an equivalent or improved condition upon completion of work. Confine construction activities to within the limits of the work indicated or specified.

2.1.1 Landscape Features

SECTION 01 57 50 Page 3

Do not remove, cut, deface, injure, or destroy existing landscape features without the Contracting Officer's permission. Do not fasten or attach ropes, cables, or guys to existing nearby trees for anchorages, unless authorized by the Contracting Officer. Where such use of attach ropes, cables, or guys is authorized, the Contractor shall be responsible for any resultant damage.

2.1.1.1 Protection

Protect existing landscape features which are to remain and which may be injured, bruised, defaced, or otherwise damaged by construction operations.

By approved excavation, remove trees with 30 percent or more of their root systems destroyed.

2.1.1.2 Replacement

Remove existing landscape features scarred or damaged by equipment operations, and replace with equivalent, undamaged features. Obtain the Contracting Officer's approval before replacement.

2.1.2 Water Resources

2.1.2.1 Oily and Hazardous Substances

Prevent oily or other hazardous substances from entering the ground, drainage areas, or local bodies of water. Take precautions to ensure that no oil or other hazardous material is released to the water, land, sanitary sewer system, or storm sewer system. Environmental requirements for the prevention of oil spills are contained in 40 CFR 112. For oil and hazardous substance spills which may be large enough to violate Federal, State or Local Regulations, the Contracting Officer shall be verbally notified immediately. Clean up any spills of oil or hazardous substances which result from the Contractor's operations. If the Contractor can not clean up any spill in a timely manner, the Government will perform the cleanup at the Contractor's expense.

2.1.3 Fish and Wildlife Resources

Do not disturb fish and wildlife. Do not alter water flows or otherwise disturb the native habitat adjacent to the project and critical to the survival of fish and wildlife, except as indicated or specified.

2.2 HISTORICAL AND ARCHEOLOGICAL RESOURCES

Carefully preserve and report immediately to the Contracting Officer items having possible historical or archeological interest which are discovered in the course of work. Protect monuments, markers, and works of art.

2.3 EROSION AND SEDIMENT CONTROL

2.3.1 Burnoff

Burnoff of the ground cover is prohibited.

2.3.2 Protection of Erodible Soils

Immediately finish the earthwork brought to a final grade, as indicated or specified. Immediately protect the side slopes and back slopes upon completion of rough grading. Plan and conduct earthwork to minimize the duration of exposure of unprotected soils.

SECTION 01 57 50 Page 4

2.3.3 Temporary Protection of Erodible Soils

Provide the following methods to prevent erosion and control sedimentation.

2.3.3.1 Mechanical Retardation and Control of Runoff

Mechanically retard and control the rate of runoff from the construction site. Provide diversion ditches, benches, and berms to retard and divert runoff to protected drainage courses.

2.3.3.2 Seeding

Provide seeding where ground is disturbed. Include topsoil or nutriment during the seeding operation necessary to establish or re-establish a suitable stand of grass.

2.4 SOLID AND SANITARY WASTES

Pick up solid wastes, and place in containers which are regularly emptied.

Prevent contamination of the site and other areas when handling and disposing wastes. On completion, leave the areas clean. Control and dispose of wastes.

2.4.1 Disposal of Solid Wastes

Dispose of solid wastes in accordance with the requirements specified.

2.4.1.1 Removal From Government Property

Remove solid wastes from Government property.

2.4.2 Garbage Disposal

Place garbage in approved containers, and move to a pickup point or disposal area, where directed.

2.4.3 Sewage, Odor, and Pest Control

Dispose of sewage through connection to a municipal or district sanitary sewage system, where such a system is not available, use chemical toilets.

Empty wastes into a municipal, district, or station sanitary sewage system.

Provide pest control and elimination of odors. No substances shall be disposed of which will interfere with treatment plant operations in accordance with 40 CFR 403.

2.5 HAZARDOUS WASTES

2.5.1 General

Handle generated hazardous wastes in accordance with 40 CFR 262. Store hazardous waste in approved containers in accordance with 49 CFR 178. Label to identify the type of waste and the date the container was filled. Remove the containers from the project site, and store and dispose of hazardous waste in accordance with 40 CFR 263 and 264. For hazardous wastes spills, verbally notify the Contracting Officer immediately.

2.5.2 Petroleum Products

Conduct the fueling and lubricating of equipment and motor vehicles to protect against spills and evaporation. Dispose of lubricants and excess

SECTION 01 57 50 Page 5 oils.

2.6 DUST

Keep dust down at all times, including during nonworking periods. Sprinkle or treat, with dust suppressants, the soil at the site, haul roads, and other areas disturbed by operations. Dry power brooming will not be permitted. Instead, use vacuuming, wet mopping, wet sweeping, or wet power brooming. Air blowing will be permitted only for cleaning nonparticulate debris such as steel reinforcing bars.

2.7 ABRASIVE BLASTING

Provide tarpaulin drop cloths and windscreens to enclose abrasive blasting operations to confine and collect dust, abrasive agent, paint chips, and other debris. Dispose of abrasive blasting debris.

2.8 NOISE

Make the maximum use of low-noise emission products, as certified by the EPA. Blasting or use of explosives will not be permitted without written permission from the Contracting Officer, and then only during the designated times.

2.9 FOOD

Preparation, cooking and dispensing of food products will not be permitted.

2.10 TEMPORARY CONSTRUCTION

Remove temporary construction facilities including haul roads, work areas, structures, foundations of temporary structures, and stockpiles of excess or waste materials. Grade temporary roads, parking areas, and temporarily used areas to conform with surrounding contours.

Section 02 41 00 Page 1

SECTION 02 41 00

DEMOLITION

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the

AMERICAN SOCIETY OF SAFETY ENGINEERS (ASSE/SAFE)

ASSE/SAFE A10.6 (2006) Safety Requirements for Demolition

Operations

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2008) Safety and Health Requirements Manual

U.S. DEFENSE LOGISTICS AGENCY (DLA)

DLA 4145.25 (June 2000) Storage and Handling of Liquefied and Gaseous Compressed Gases and Their Full and Empty Cylinders

U.S. DEPARTMENT OF DEFENSE (DOD)

DOD 4000.25-1-M (2006; Notice 1) Requisitioning and Issue

Procedures

MIL-STD-129 (Rev P; Notice 3; Change 4) Military Marking for Shipment and Storage

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

40 CFR 61 National Emission Standards for Hazardous Air

Pollutants

49 CFR 173.301 Shipment of Compressed Gases in Cylinders and

Spherical Pressure Vessels

1.2 GENERAL REQUIREMENTS

Do not begin demolition until authorization is received from the Contracting Officer. The work of this section is to be performed in a manner that maximizes salvage and recycling of materials. Remove rubbish and debris from the project site; do not allow accumulations inside or outside the buildings. The work includes demolition of identified items and materials, and removal of resulting rubbish and debris. Remove rubbish and debris from Government property daily, unless otherwise directed. Store materials that cannot be removed daily in areas specified by the Contracting Officer. In the interest of occupational safety and health, perform the work in accordance with EM 385-1-1, Section 23, Demolition, and other applicable Sections.

Section 02 41 00 Page 2

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor Quality Control approval. The following shall be submitted in accordance with Section 01 33

00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Existing Conditions; G

SD-07 Certificates

Demolition Plan; G

Notifications; G

Proposed demolition and removal procedures for approval before work is started.

1.4 REGULATORY AND SAFETY REQUIREMENTS

Comply with federal, state, and local hauling and disposal regulations. In addition to the requirements of the "Contract Clauses," conform to the safety requirements contained in ASSE/SAFE A10.6.

1.4.1 Notifications

1.4.1.1 General Requirements

Furnish timely notification of demolition projects to Federal, State, regional, and local authorities in accordance with 40 CFR 61, Subpart M.

Notify the Regional Office of the United States Environmental Protection Agency (USEPA), State's environmental protection agency, local air pollution control district/agency and the Contracting Officer in writing 10 working days prior to the commencement of work in accordance with 40 CFR 61, Subpart M.

1.5 DUST AND DEBRIS CONTROL

Prevent the spread of dust and debris to occupied portions of the building and avoid the creation of a nuisance or hazard in the surrounding area. Do not use water if it results in hazardous or objectionable conditions such as, but not limited to, ice, flooding, or pollution.

1.6 PROTECTION

1.6.1 Traffic Control Signs

Where pedestrian and driver safety is endangered in the area of removal work, use traffic barricades with flashing lights. Notify the Contracting Officer prior to beginning such work.

1.6.2 Existing Conditions Documentation

Before beginning any demolition or deconstruction work, survey the site and examine the drawings and specifications to determine the extent of the work.

Section 02 41 00 Page 3

Record existing conditions in the presence of the Contracting Officer showing the condition of structures and other facilities adjacent to areas of alteration or removal. Photographs sized 4 inch will be acceptable as a record of existing conditions. Include in the record the elevation of the top of foundation walls, finish floor elevations, possible conflicting electrical conduits, plumbing lines, alarms systems, the location and extent of existing cracks and other damage and description of surface conditions that exist prior to before starting work. It is the Contractor's responsibility to verify and document all required outages which will be required during the course of work, and to note these outages on the record document.

1.6.3 Items to Remain in Place

Take necessary precautions to avoid damage to existing items to remain in place, to be reused, or to remain the property of the Government. Repair or replace damaged items as approved by the Contracting Officer. Coordinate the work of this section with all other work indicated. Construct and maintain shoring, bracing, and supports as required. Ensure that structural elements are not overloaded. Increase structural supports or add new supports as may be required as a result of any cutting, removal, deconstruction, or demolition work performed under this contract. Do not overload structural elements. Provide new supports and reinforcement for existing construction weakened by demolition, deconstruction, or removal work. Repairs, reinforcement, or structural replacement require approval by the Contracting Officer prior to performing such work.

1.6.4 Existing Construction Limits and Protection

Do not disturb existing construction beyond the extent indicated or necessary for installation of new construction. Provide temporary shoring and bracing for support of building components to prevent settlement or other movement. Provide protective measures to control accumulation and migration of dust and dirt in all work areas. Remove dust, dirt, and debris from work areas daily.

1.6.5 Weather Protection

For portions of the building to remain, protect building interior and materials and equipment from the weather at all times. Where removal of existing roofing is necessary to accomplish work, have materials and workmen ready to provide adequate and temporary covering of exposed areas.

1.6.6 Trees

Protect trees within the project site which might be damaged during demolition or deconstruction, and which are indicated to be left in place, by a 6 foot high fence. Erect and secure fence a minimum of 5 feet from the trunk of individual trees or follow the outer perimeter of branches or clumps of trees. Replace any tree designated to remain that is damaged during the work under this contract with like-kind or as approved by the Contracting Officer.

1.6.7 Utility Service

Maintain existing utilities indicated to stay in service and protect against damage during demolition operations.

Section 02 41 00 Page 4

1.6.8 Facilities

Protect electrical and mechanical services and utilities. Where removal of existing utilities and pavement is specified or indicated, provide approved barricades, temporary covering of exposed areas, and temporary services or connections for electrical and mechanical utilities. Floors, roofs, walls, columns, pilasters, and other structural components that are designed and constructed to stand without lateral support or shoring, and are determined to be in stable condition, must remain standing without additional bracing, shoring, or lateral support until demolished or deconstructed, unless directed otherwise by the Contracting Officer. Ensure that no elements determined to be unstable are left unsupported and place and secure bracing, shoring, or lateral supports as may be required as a result of any cutting, removal, deconstruction, or demolition work performed under this contract.

1.6.9 Protection of Personnel

Before, during and after the demolition work the Contractor shall continuously evaluate the condition of the structure being demolished and take immediate action to protect all personnel working in and around the project site. No area, section, or component of floors, roofs, walls, columns, pilasters, or other structural element will be allowed to be left standing without sufficient bracing, shoring, or lateral support to prevent collapse or failure while workmen remove debris or perform other work in the immediate area.

1.7 BURNING

The use of burning at the project site for the disposal of refuse and debris will not be permitted.

1.8 RELOCATIONS

Perform the removal and reinstallation of relocated items as indicated with workmen skilled in the trades involved. Items to be relocated which are damaged by the Contractor shall be repaired or replaced with new undamaged items as approved by the Contracting Officer.

1.9 REQUIRED DATA

Prepare a Demolition Plan. Include in the plan procedures for careful removal and disposition of materials specified to be salvaged, coordination with other work in progress a detailed description of methods and equipment to be used for each operation and of the sequence of operations. Identify components and materials to be salvaged for reuse or recycling with reference to paragraph Existing Facilities to be Removed. Append tracking forms for all removed materials indicating type, quantities, condition, destination, and end use. Coordinate with Waste Management Plan. Include statements affirming Contractor inspection of the existing roof deck and its suitability to perform as a safe working platform or if inspection reveals a safety hazard to workers, state provisions for securing the safety of the workers throughout the performance of the work. Provide procedures for safe conduct of the work in accordance with EM 385-1-1. Plan shall be approved by Contracting Officer prior to work beginning.

Section 02 41 00 Page 5

1.10 ENVIRONMENTAL PROTECTION

Comply with the Environmental Protection Agency requirements specified.

1.11 USE OF EXPLOSIVES

Use of explosives will not be permitted.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

3.1 EXISTING FACILITIES TO BE REMOVED

Inspect and evaluate existing structures on site for reuse. Existing construction scheduled to be removed for reuse shall be disassembled.

Dismantled and removed materials are to be separated, set aside, and prepared as specified, and stored or delivered to a collection point for reuse, remanufacture, recycling, or other disposal, as specified. Materials shall be designated for reuse on site whenever possible.

3.1.1 Paving and Slabs

Remove sawcut concrete and asphaltic concrete paving and slabs as indicated to a depth of 6 inches below existing adjacent grade.

3.1.2 Roofing

Remove existing roof system and associated components in their entirety down to existing roof deck. Remove roofing system and insulation without damaging the roof deck. Sequence work to minimize building exposure between demolition or deconstruction and new roof materials installation.

3.1.2.1 Temporary Roofing

Install temporary roofing and flashing as necessary to maintain a watertight condition throughout the course of the work. Remove temporary work prior to installation of permanent roof system materials unless approved otherwise by the Contracting Officer.

3.1.2.2 Reroofing

When removing the existing roofing system from the roof deck, remove only as much roofing as can be recovered by the end of the work day, unless approved otherwise by the Contracting Officer. Do not attempt to open the roof covering system in threatening weather. Reseal all openings prior to suspension of work the same day.

3.2 DISPOSITION OF MATERIAL

3.2.1 Title to Materials

Except for salvaged items specified in related Sections, and for materials or equipment scheduled for salvage, all materials and equipment removed and not reused or salvaged, shall become the property of the Contractor and

Section 02 41 00 Page 6 shall be removed from Government property. Title to materials resulting from demolition and deconstruction, and materials and equipment to be removed, is vested in the Contractor upon approval by the Contracting Officer of the Contractor's demolition, deconstruction, and removal procedures, and authorization by the Contracting Officer to begin demolition and deconstruction. The Government will not be responsible for the condition or loss of, or damage to, such property after contract award.

Showing for sale or selling materials and equipment on site is prohibited.

3.2.2 Transportation Guidance

Ship all ODS containers in accordance with MIL-STD-129, DLA 4145.25 (also referenced one of the following: Army Regulation 700-68, Naval Supply Instruction 4440.128C, Marine Corps Order 10330.2C, and Air Force Regulation 67-12), 49 CFR 173.301, and DOD 4000.25-1-M.

3.3 CLEANUP

Remove debris and rubbish from basement and similar excavations. Remove and transport the in a manner that prevents spillage on streets or adjacent areas. Apply local regulations regarding hauling and disposal.

3.4 DISPOSAL OF REMOVED MATERIALS

3.4.1 Regulation of Removed Materials

Dispose of debris, rubbish, scrap, and other nonsalvageable materials resulting from removal operations with all applicable federal, state and local regulations as contractually specified in the Waste Management Plan.

Storage of removed materials on the project site is prohibited.

3.4.2 Burning on Government Property

Burning of materials removed from demolished and deconstructed structures will not be permitted on Government property.

3.4.3 Removal from Government Property

Transport waste materials removed from demolished and deconstructed structures, except waste soil, from Government property for legal disposal.

Dispose of waste soil as directed.

Section 06 10 00 Page 1

SECTION 06 10 00

ROUGH CARPENTRY

1.1 REFERENCES

The publications listed below form a part of this specification to the

AMERICAN FOREST & PAPER ASSOCIATION (AF&PA)

AF&PA T10 (2001) Wood Frame Construction Manual for

One- and Two-Family Dwellings

AF&PA T101 (2001) National Design Specification (NDS)for

Wood Construction

AMERICAN LUMBER STANDARDS COMMITTEE (ALSC)

ALSC PS 20 (1970) American Softwood Lumber Standard

AMERICAN WOOD PROTECTION ASSOCIATION (AWPA)

AWPA C1 (2003) All Timber Products - Preservative

Treatment by Pressure Processes

AWPA C2 (2003) Lumber, Timber, Bridge Ties and Mine

Ties - Preservative Treatment by Pressure Processes

AWPA C28 (2003) Standard for Preservative Treatment of

Structural Glued Laminated Members and Lamination Before Gluing of Southern Pine, Coastal Douglas Fir, Hemfir and Western Hemlock by Pressure Processes

AWPA C9 (2003) Plywood - Preservative Treatment by

Pressure Processes

AWPA M2 (2001) Standard for Inspection of Treated

Wood Products

AWPA M6 (1996) Brands Used on Forest Products

AWPA P5 (2005) Standard for Waterborne Preservatives

AWPA T1 (2004; R 2005) Use Category System:

Processing and Treatment Standard

AWPA U1 (2004; R 2005) Use Category System: User

Specification for Treated Wood

ASME INTERNATIONAL (ASME)

Section 06 10 00 Page 2

ASME B18.2.1 (1996; Addenda A 1999; Errata 2003; R 2005) Square and Hex Bolts and Screws (Inch Series)

ASME B18.2.2 (1987; R 2005) Standard for Square and Hex

N…