Contract_Terms_Conditions_and_Clauses.pdf

THIS PAGE IS INTENTIONALLY LEFT BLANK

(PAGE 2 OF THE STANDARD FORM 1449)

THIS PAGE IS INTENTIONALLY LEFT BLANK

(PAGE 3 OF STANDARD FORM 1449)

SECTION B – BID SCHEDULE

SEE ATTACHED __1___ PAGE(S) TO THIS PAGE

COPY OF CONTRACTOR’S PROPOSAL INSERT HERE

SECTION C – DESCRIPTION/SPECIFICATION

AGAR 452.211-72 Statement of Work/Specifications. (FEB 1988) The Contractor shall furnish the necessary supervision, personnel, material, equipment, services and facilities (except as otherwise specified), to perform the NRCS Specifications referenced in Section J, List of Documents, Exhibits, and Other Attachments.

AGAR 452.211-73 Attachments to Statements of Work/Specifications. (FEB 1988) The attachments to the Statement of Work/Specifications listed in Section J are hereby made party of this solicitation and any resultant contract.

52.212-4 -- Contract Terms and Conditions -- Commercial Items. (May 2015)

(a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights --

(1) Within a reasonable time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C.3727). However, when a third party makes payment (e.g., use of the Government wide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract.

(c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties.

(d) Disputes. This contract is subject to 41 U.S.C. chapter 71, Contract Disputes. Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at FAR 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract.

(e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference.

(f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(g) Invoice.

(1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include --

(i) Name and address of the Contractor;

(ii) Invoice date and number;

(iii) Contract number, contract line item number and, if applicable, the order number;

(iv) Description, quantity, unit of measure, unit price and extended price of the items delivered;

(v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading;

(vi) Terms of any discount for prompt payment offered;

(vii) Name and address of official to whom payment is to be sent;

(viii) Name, title, and phone number of person to notify in event of defective invoice; and

(ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract.

(x) Electronic funds transfer (EFT) banking information.

(A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract.

(B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer— System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer— Other Than System for Award Management), or applicable agency procedures.

(C) EFT banking information is not required if the Government waived the requirement to pay by EFT.

(2) Invoices will be handled in accordance with the Prompt Payment Act (31 U.S.C. 3903) and Office of Management and Budget (OMB) prompt payment regulations at 5 CFR part 1315.

(h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings.

(i) Payment.

(1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract.

(2) Prompt Payment. The Government will make payment in accordance with the Prompt Payment Act (31 U.S.C. 3903) and prompt payment regulations at 5 CFR Part 1315.

(3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-5(b) for the appropriate EFT clause.

(4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made.

(5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall—

(i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the—

(A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);

(B) Affected contract number and delivery order number, if applicable;

(C) Affected contract line item or subline item, if applicable; and

(D) Contractor point of contact.

(ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer.

(6) Interest.

(i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C. 7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period at fixed by the Secretary until the amount is paid.

(ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.

(iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if—

(A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days;

(B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or

(C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2).

(iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment.

(v) Amounts shall be due at the earliest of the following dates:

(A) The date fixed under this contract.

(B) The date of the first written demand for payment, including any demand for payment resulting from a default termination.

(vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on—

(A) The date on which the designated office receives payment from the Contractor;

(B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or

(C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.

(vii) The interest charge made under this clause may be reduced under the procedures prescribed in 32.608-2 of the Federal Acquisition Regulation in effect on the date of this contract.

(j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon:

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination.

(k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties.

(l) Termination for the Government’s convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor’s records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided.

(m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance.

In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession.

(o) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items.

(q) Other compliances. The Contractor shall comply with all applicable Federal, State and local laws, executive orders, rules and regulations applicable to its performance under this contract.

(r) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C.

1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 18 U.S.C.

431 relating to officials not to benefit; 40 U.S.C. chapter 37, Contract Work Hours and Safety Standards; 41 U.S.C. chapter 87, Kickbacks; 41 U.S.C. 4712 and 10 U.S.C. 2409 relating to whistleblower protections; 49 U.S.C. 40118, Fly American; and 41 U.S.C. chapter 21 relating to procurement integrity.

(s) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order:

(1) The schedule of supplies/services.

(2) The Assignments, Disputes, Payments, Invoice, Other Compliances, Compliance with Laws Unique to Government Contracts, and Unauthorized Obligations paragraphs of this clause.

(3) The clause at 52.212-5.

(4) Addenda to this solicitation or contract, including any license agreements for computer software.

(5) Solicitation provisions if this is a solicitation.

(6) Other paragraphs of this clause.

(7) The Standard Form 1449.

(8) Other documents, exhibits, and attachments.

(9) The specification.

(t) System for Award Management (SAM).

(1) Unless exempted by an addendum to this contract, the Contractor is responsible during performance and through final payment of any contract for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government’s reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document.

(2)

(i) If a Contractor has legally changed its business name, “doing business as” name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in Subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day’s written notification of its intention to:

(A) Change the name in the SAM database;

(B) Comply with the requirements of Subpart 42.12 of the FAR;

(C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide with the notification sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (t)(2)(i) of this clause, or fails to perform the agreement at paragraph (t)(2)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the “Suspension of Payment” paragraph of the electronic funds transfer (EFT) clause of this contract.

(3) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims (see FAR Subpart 32.8, Assignment of Claims). Assignees shall be separately registered in the SAM database. Information provided to the Contractor’s SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the “Suspension of payment” paragraph of the EFT clause of this contract.

(4) Offerors and Contractors may obtain information on registration and annual confirmation requirements via SAM accessed through https://www.acquisition.gov.

(u) Unauthorized Obligations.

(1) Except as stated in paragraph (u)(2) of this clause, when any supply or service acquired under this contract is subject to any End Use License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C. 1341), the following shall govern:

(i) Any such clause is unenforceable against the Government.

(ii) Neither the Government nor any Government authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an “I agree” click box or other comparable mechanism (e.g., “click-wrap” or “browse-wrap” agreements), execution does not bind the Government or any Government authorized end user to such clause.

https://www.acquisition.gov/

(iii) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement.

(2) Paragraph (u)(1) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures.

(v) Incorporation by reference. The Contractor’s representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

(End of Clause)

52.212-5 Contract Terms and Conditions Required to Implement Statues or Executive Orders – Commercial Items (JAN 2013)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015)

(2) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(3) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77, 108- 78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.]

___ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

X (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009).

___ (4) 52.204-10, Reporting Executive compensation and First-Tier Subcontract Awards (Oct 2015) (Pub. L. 109-282) (31 U.S.C. 6101 note).

___ (5) [Reserved] ___ (6) 52.204-14, Service Contract Reporting Requirements (Jan 2014) (Pub. L. 111-117, section 743 of Div. C).

___ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Jan 2014) (Pub. L. 111-117, section 743 of Div. C).

X (8) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015) (31 U.S.C. 6101 note).

___ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313).

___ (10) [Reserved] ___ (11) (i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C.

657a).

___ (ii) Alternate I (Nov 2011) of 52.219-3.

___ (12) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C.

657a).

___ (ii) Alternate I (Jan 2011) of 52.219-4.

___ (13) [Reserved] X (14) (i) 52.219-6, Notice of Total Small Business Aside (Nov 2011) (15 U.S.C. 644).

___ (ii) Alternate I (Nov 2011).

___ (iii) Alternate II (Nov 2011).

___ (15) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).

___ (ii) Alternate I (Oct 1995) of 52.219-7.

___ (iii) Alternate II (Mar 2004) of 52.219-7.

___ (16) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)).

___ (17) (i) 52.219-9, Small Business Subcontracting Plan (Oct 2015) (15 U.S.C. 637 (d)(4)).

___ (ii) Alternate I (Oct 2001) of 52.219-9.

___ (iii) Alternate II (Oct 2001) of 52.219-9.

___ (iv) Alternate III (Oct 2015) of 52.219-9.

___ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)).

___ (19) 52.219-14, Limitations on Subcontracting (Nov 2011) (15 U.S.C. 637(a)(14)).

___ (20) 52.219-16, Liquidated Damages—Subcontracting Plan (Jan 1999) (15 U.S.C.

637(d)(4)(F)(i)).

___ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657f).

___ (22) 52.219-28, Post Award Small Business Program Representation (Jul 2013) (15 U.S.C.

632(a)(2)).

___ (23) 52.219-29, Notice of Set-Aside for Economically Disadvantaged Women-Owned Small Business (EDWOSB) Concerns (Jul 2013) (15 U.S.C. 637(m)).

___ (24) 52.219-30, Notice of Set-Aside for Women-Owned Small Business (WOSB) Concerns Eligible Under the WOSB Program (Jul 2013) (15 U.S.C. 637(m)).

X (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

___ (26) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (Jan 2014) (E.O.

13126).

X (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

X (28) 52.222-26, Equal Opportunity (Apr 2015) (E.O. 11246).

X (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

X (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

X (31) 52.222-37, Employment Reports on Veterans (Oct 2015) (38 U.S.C. 4212).

___ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

___ (33) (i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O.

13627).

___ (ii) Alternate I (Mar 2015) of 52.222-50, (22 U.S.C. chapter 78 and E.O. 13627).

___ (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

___ (35) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

___ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

___ (36) (i) 52.223-13, Acquisition of EPEAT® -Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514

___ (ii) Alternate I (Oct 2015) of 52.223-13.

___ (37) (i) 52.223-14, Acquisition of EPEAT® -Registered Television (Jun 2014) (E.O.s 13423 and 13514).

___ (ii) Alternate I (Jun 2014) of 52.223-14.

___ (38) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C.

8259b).

___ (39) (i) 52.223-16, Acquisition of EPEAT® -Registered Personal Computer Products (Oct 2015) (E.O.s 13423 and 13514).

___ (ii) Alternate I (Jun 2014) of 52.223-16.

X (40) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving (Aug 2011) (E.O. 13513).

X (41) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83).

___ (42) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112- 41, 112-42, and 112-43).

___ (ii) Alternate I (May 2014) of 52.225-3.

___ (iii) Alternate II (May 2014) of 52.225-3.

___ (iv) Alternate III (May 2014) of 52.225-3.

___ (43) 52.225-5, Trade Agreements (Nov 2013) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

X (44) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

___ (45) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

___ (46) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

___ (47) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).

___ (48) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C.

4505), 10 U.S.C. 2307(f)).

___ (49) 52.232-30, Installment Payments for Commercial Items (Oct 1995) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

X (50) 52.232-33, Payment by Electronic Funds Transfer— System for Award Management (Jul 2013) (31 U.S.C. 3332).

___ (51) 52.232-34, Payment by Electronic Funds Transfer—Other Than System for Award Management (Jul 2013) (31 U.S.C. 3332).

___ (52) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

___ (53) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

___ (54) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631).

___ (ii) Alternate I (Apr 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.] ___ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495) ___ (2) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67.).

___ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

___ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (Multiple Year and Option Contracts) (May 2014) (29 U.S.C.206 and 41 U.S.C. chapter 67).

___ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

___ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C.

chapter 67).

___ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67).

___ (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2014) (E.O. 13658).

___ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792).

___ (10) 52.237-11, Accepting and Dispensing of $1 Coin (Sep 2008) (31 U.S.C. 5112(p)(1)).

(d) Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records -- Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e)

(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c) and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause—

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C.

3509).

(ii) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(iii) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in accordance with paragraph (1) of FAR clause 52.222-17.

(iv) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(v) 52.222-26, Equal Opportunity (Apr 2015) (E.O. 11246).

(vi) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

(vii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

(viii) 52.222-37, Employment Reports on Veterans (Oct 2015) (38 U.S.C. 4212).

(ix) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(x) 52.222-41, Service Contract Labor Standards (May 2014), (41 U.S.C. chapter 67).

(xi) ____ (A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627).

___ (B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 E.O. 13627).

(xii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67.)

(xiii) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67)

(xiv) 52.222-54, Employment Eligibility Verification (Oct 2015) (E. O. 12989).

(xv) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2014) (E.O. 13658).

(xvi) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xvii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xviii) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the contractor may include in its subcontracts for commercial and non-commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

SECTION D – PACKAGING AND MARKING

THERE ARE NO CLAUSES INCLUDED IN THIS SECTION

SECTION E – INSPECTION AND ACCEPTANCE

52.252.2 Clauses Incorporated by Reference (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address:

http://acquisition.gov/com/far/index.html

52.246-12 Inspection of Construction (AUG 1996)

(a) Definition. “Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not—

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may—

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

(End of clause)

NRCS inspection and acceptance under this contract will be accomplished by the Contract Inspector (CI)

SECTION F – DELIVERIES OR PERFORMANCE

452.211-74 PERIOD OF PERFORMANCE. (FEB 1988)

The period of performance of this contract is estimated from

90 calendar days after receipt of the Notice to Proceed

52.211-10 Commencement, Prosecution, and Completion of Work (APR 1984) As prescribed in 11.404(b), insert the following clause in solicitations and contracts when a fixed-price construction contract is contemplated. The clause may be changed to accommodate the issuance of orders under indefinite-delivery contracts for construction.

The Contractor shall be required to (a) commence work under this contract within five (5) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than TBD. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.236-1 Performance of Work by the Contractor (APR 1984) As prescribed in 36.501(b), insert the following clause: [Complete the clause by inserting the appropriate percentage consistent with the complexity and magnitude of the work and customary or necessary specialty subcontracting (see 36.501(a)).]

The Contractor shall perform on the site, and with its own organization, work equivalent to at least fifty percent (50%) of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

(End of clause)

Actual Damages (NRCS, FEB 1993) If the Contractor fails to complete the work within the time specified in the contract, or any extension thereof, the Contractor shall pay to the Government actual damages for each calendar day of the delay. Actual damages will be based upon the costs incurred by the Government including but not limited to personnel costs, travel, etc. The amount of such costs will be deducted from monies due or to become due to the Contractor.

https://www.acquisition.gov/far/current/html/Subpart%2011_4.html#wp1077932 https://www.acquisition.gov/far/current/html/Subpart%2036_5.html#wp1076708 https://www.acquisition.gov/far/current/html/Subpart%2036_5.html#wp1076708

SECTION G – CONTRACT ADMINISTRATION DATA

Contracting Officer means a person with the authority to enter into, administer and/or terminate contracts and make related determinations and findings. The Contracting Officer signs all contractual documents, approves, and signs discrepancies, and administers the contracts. The Contracting Officer is the only individual authorized to make changes to a contract, such as specification, period of performances, and dollar amount.

The Contract Administrator for this procurement action is: Danny Mandell, USDA NRCS

The Contracting Officer for this procurement action is: Danny Mandell, USDA NRCS

All correspondence including modification proposals, extension requests, and contract submittals shall be submitted to the Contract Administrator. The address is as follows:

U.S Mail Address Hand Carry Address USDA Natural Resources Conservation Service USDA Natural Resources Conservation Service Attn: Contract Service Branch (CSB) Attn: Contract Service Branch (CSB) 101 South Main Street 101 South Main Street Temple, Texas 76501 Temple, Texas 76501 Telephone Numbers (254) 742-9923

FAX: (254) 742-9929

Email: danny.mandell@wdc.usda.gov

Office Hours: 8:00 A.M. to 4:30 P.M. Central Standard Time (CDT), Monday thru Friday (Except Federal Holidays)

INVOICES

Invoices shall be prepared and submitted in accordance with the provisions of FAR Clauses 52.232-1, Payments (APR 1984) and FAR 52.232-25, Prompt Payment (FEB 2002). Contractor shall submit ORIGINAL invoice only. At a minimum, invoice(s) must include the following information:

1. Name of Contractor

2. Tax ID Number

3. Contract No.

4. Date of Services.

5. Itemized list of supplies or services furnished

6. Quantity, unit price, and extension of each item.

NRCSAR 41-52-232-70 Designated Payment Office Contact (NRCS, AMB, AUG 1989) The contact point described below coordinates the issuance of payments under this contract. If payment is not received within 5 days after the due date specified in the contract, contact the payment office designated below for information on when payment will be made.

Danny Mandell USDA Natural Resources Conservation Service 101 S Main Street Temple, Texas 76501 Tel. (254) 742-9923

If questions arise on the amount paid, contact the Contracting Officer at the number or address shown in the contract.

mailto:danny.mandell@wdc.usda.gov

SECTION H – SPECIAL CONTRACT REQUIREMENTS

INFORMATION CONCERNING SAFETY AND ENVIRONMENTAL

All contract work shall be performed in accordance with all applicable federal, state, and local safety and environmental laws and regulations.

4I-52.249-70 Time Extensions for Unusually Severe Weather (NOV 2013)

(a) This clause specifies the procedure for determination of time extensions for unusually severe weather in accordance with FAR clause 52.249-10, Default (Fixed-Price Construction). In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

(b) The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the baseline for monthly weather time evaluations. The Contractor's progress schedule must reflect those anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (insert appropriate length of work week) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(Insert number of calendar days for every month regardless of the period of performance.)

(c) Upon acknowledgement of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record the occurrence of adverse weather and resultant impact to normally scheduled work. An actual adverse weather delay must prevent work on critical activities for fifty

(50) percent or more of the Contractor's scheduled work day. The number of actual adverse weather days shall include days impacted by actual adverse weather (even if adverse weather occurred in the previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph (b) above, the Contractor may submit a written request for a modification for extension of performance time due to unusually severe weather. The Contracting Officer will convert any qualifying delays into calendar days, giving full consideration for equivalent fair weather days, and issue a modification in accordance with FAR clause 52.249-10, Default (Fixed-Price Construction).

(End of clause)

42.503-1 Postaward Conference (NOV 1996) A post award conference with the successful offeror is required. It will be scheduled within 5 days after the date of contract award. The conference will be held at: Date, time and location to be determined (TBD)

452.236-73 Archaeological or Historic Sites (FEB 1988) If a previously unidentified archaeological or historic site(s) is encountered, the Contractor shall discontinue work in the general area of the site(s) and notify the Contracting Officer immediately.

452.236-74 Control of Erosion, Sedimentation, and Pollution (NOV 1996)

(a) Operations shall be scheduled and conducted to minimize erosion of soils and to prevent silting and muddying of streams, rivers, irrigation systems, and impoundments (lakes, reservoirs, etc.)

(b) Pollutants such as fuels, lubricants, bitumens, raw sewage, and other harmful materials shall not be discharged on the ground; into or nearby rivers, streams, or impoundments; or into natural or man-made channels. Wash water or waste from concrete or aggregate operations shall not be allowed to enter live streams prior to treatment by filtration, settling, or other means sufficient to reduce the sediment content to not more than that of the stream into which it is discharged.

(C) Mechanized equipment shall not be operated in flowing streams without written approval by the Contracting Officer.

452.236-75 Maximum Workweek - Construction Schedule (NOV 1996) Within five (5) calendar days after receipt of a Notice to Proceed, the Contractor must submit the following in writing for approval:

(a) A schedule as required by FAR Clause 52.236-15, “Schedules for Construction Contracts” and

(b) The hours (including the daily starting and stopping time) and days of the week the Contractor proposes to carry out the work.

The maximum workweek that will be approved is MONDAY THROUGH FRIDAY, 8 HOURS a DAY, during daylight hours.

(c) The contractor shall not perform any work on the following holidays except in the case of an emergency as permitted elsewhere in this contract: NEW YEAR’S DAY, MEMORIAL DAY, INDEPENDENCE DAY, LABOR DAY, THANKSGIVING DAY AND CHRISTMAS DAY.

Contract performance time has been established to allow for the non-working holidays stated above.

The contractor may be permitted to work on the following designated Federal holidays provided he/she submits a letter of request to the Contracting Officer at least ten (10) calendar days in advance of the holiday: COLUMBUS DAY, MARTIN LUTHER DAY, JR. DAY, VETERANS

DAY, AND PRESIDENT’S DAY.

452.236-76 Samples and Certificates (FEB 1988) When required by the specifications or the Contracting Officer, samples, certificates, and test data shall be submitted after award of the contract, prepaid, in time for proper action by the Contracting Officer or his/her designated representative. Certificates and test data shall be submitted in triplicate to show compliance with materials and construction specified in the contract performance requirements.

Samples shall be submitted in duplicate by the Contractor, except, as otherwise specified, to show compliance with the contract requirements. Materials or equipment for which samples, certifications or test data are required shall not be used in the work until approved in writing by the Contracting Officer.

52.236-13 Accident and Prevention (NOV 1991)

(a) The Contractor shall provide and maintain work environments and procedures which will—

(1) Safeguard the public and Government personnel, property, materials, supplies, and equipment exposed to Contractor operations and activities;

(2) Avoid interruptions of Government operations and delays in project completion dates; and

(3) Control costs in the performance of this contract.

(b) For these purposes on contracts for construction or dismantling, demolition, or removal of improvements, the Contractor shall—

(1) Provide appropriate safety barricades, signs, and signal lights;

(2) Comply with the standards issued by the Secretary of Labor at 29 CFR Part 1926 and 29 CFR

Part 1910; and

(3) Ensure that any additional measures the Contracting Officer determines to be reasonably necessary for the purposes are taken.

(c) If this contract is for construction or dismantling, demolition or removal of improvements with any

Department of Defense agency or component, the Contractor shall comply with all pertinent provisions of the latest version of U.S. Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1, in effect on the date of the solicitation.

(d) Whenever the Contracting Officer becomes aware of any noncompliance with these requirements or any condition which poses a serious or imminent danger to the health or safety of the public or Government personnel, the Contracting Officer shall notify the Contractor…