attachments.doc

AIR CONDITIONING: MOS CLASSROOMS #1312, Curlew Job Corps , Curlew , WA Solicitation # AG-05H7-S-08-9006 Attachments And WELDING SHOP #2815 VENTILATION

USDA – Forest Service

EXPERIENCE QUESTIONNAIRE

(Ref. FSH 6309.31 and 41 USC 1)

INSTRUCTIONS: See Box 11, Remarks, if extra space is needed to answer any questions below. Mark “X” in appropriate boxes.

1. CONTRACTOR NAME, ADDRESS, AND TELEPHONE NO.

( Company ( Co-partnership

( Corporation ( Individual

( Non-profit Organization

4. How many years do you or your firm have in the line of work contemplated by this solicitation?

5. How many years experience in contracting have you or your business had as a (a) prime contractor ____ and/or (b) sub-contractor ____?

6. List below the projects your business has completed within the last three years:

CONTRACT

AMOUNT

COMPLETED

NAME, ADDRESS, AND TELEPHONE NO. OF OWNER/PERSON TO CONTACT FOR PROJECT INFORMATION

7. List below all of your firm’s contractual commitments running concurrently with the work contemplated by this solicitation:

CONTRACT

NUMBER

DOLLAR AMT.

OF AWARD

(Units)

PERCENT

COMPLETED

DATE CONTRACT

COMPLETED

8a. Have you ever failed to complete any work awarded to you? ( Yes ( No

8b. Has work ever been completed by performance bond? ( Yes ( No

8c. If “Yes” to either item 8a or 8b specify location(s) and reason(s) why:

Previous edition is obsolete (OVER) FS-6300-27 (3/00)

9. Organization and work that will be available for this project.

a. (1) Minimum number of employees: _____ and a(2) Maximum number of employees: ______ ?

b. Are employees regularly on your payroll: ( Yes ( No

c. Specify equipment available for this contract: __________________________________________________________________

d. Estimate rate of progress below (such as 2.0 acres/man/day)

(1) Minimum progress rate: ________________________________ and (2) maximum progress rate: ________________________

10. List below the experience of the principal individuals of your business:

POSITION

YEARS

OF EXP.

MAGNITUDE AND TYPE OF WORK

11. List all the equipment (including vehicles) you plan to use on this contract. Provide a detailed description of the Equipment including your maintenance plan.

12. Contractor Inspection. Describe Contractor Self Inspection Procedures which you will use to insure quality for this contract.

13. Remarks. Specify Box Numbers (Attach sheets if extra space is needed to fully answer any above question):

CERTIFICATION

I certify that all of the statements made by me are complete and correct to the best of my knowledge and that any persons name as references are authorized to furnish the Forest Service with any information needed to verify my capability to perform this project.

12a. CERTIFYING OFFICIAL’S NAME AND TITLE

Attachment 3

General Decision Number: WA080003 03/07/2008 WA3

Superseded General Decision Number: WA20070003

State: Washington

Construction Type: Building

Counties: Adams, Asotin, Columbia, Douglas, Ferry, Garfield, Grant, Lincoln, Okanogan, Pend Oreille, Stevens, Walla Walla and Whitman Counties in Washington.

BUILDING CONSTRUCTION PROJECTS (does not include residential construction consisting of single family homes and apartments up to and including 4 stories)

Modification Number Publication Date

0 02/08/2008

1 02/15/2008

2 03/07/2008

* BOIL0242-002 10/01/2007

DOUGLAS AND OKANOGAN COUNTIES WHICH LIES WEST OF THE 120TH

MERIDIAN

Rates Fringes

BOILERMAKER......................$ 31.56 19.01

BRWA0003-002 06/01/2007

Rates Fringes

BRICKLAYER.......................$ 25.51 10.61

BRWA0003-007 06/01/2007

DOUGLAS AND OKANOGAN COUNTIES WHICH LIES WEST OF THE 120TH

MERIDIAN

Rates Fringes

TERRAZZO WORKER/SETTER...........$ 20.22 8.28

Tile & Terrazzo Finisher.........$ 16.14 8.28

Tile Layer.......................$ 20.22 8.28

CARP0001-007 06/01/2007

Rates Fringes

Carpenters:

ADAMS, COLUMBIA, DOUGLAS

WHICH LIES EAST OF THE

120TH MERIDIAN, FERRY,

GRANT, OKANOGAN WHICH LIES

EAST OF THE 120TH MERIDIAN

AND WALLA WALLA COUNTIES

CARPENTERS/INSULATION

APPLICATOR.................$ 25.68 9.30

MILLWRIGHTS................$ 27.18 9.30

PILEDRIVERS................$ 25.95 9.30

ASOTIN, GARFIELD, LINCOLN,

PEND OREILLE, STEVENS, AND

WHITMAN COUNTIES

CARPENTERS/INSULATION

APPLICATOR.................$ 25.01 9.30

MILLWRIGHTS................$ 26.51 9.30

PILEDRIVERS................$ 25.27 9.30

Diver

ADAMS, COLUMBIA, DOUGLAS

WHICH LIES EAST OF THE

120TH MERIDIAN, FERRY,

GRANT, OKANOGAN WHICH LIES

EAST OF THE 120TH MERIDIAN

AND WALLA WALLA COUNTIES

ASSISTANT TENDER, ROV

TENDER/TECHNICIAN..........$ 26.95 9.30

DIVER STANDBY,

BELL/VEHICLE OR

SUBMERSIBLE OPERATOR NOT

UNDER PRESSURE.............$ 29.70 9.30

DIVER TENDER, ROV

OPERATOR, MANIFOLD

OPERATOR...................$ 28.70 9.30

DIVER WET..................$ 59.40 9.30

MANIFOLD OPERATOR-MIXED

GAS........................$ 32.70 9.30

ASOTIN, GARFIELD, LINCOLN,

PEND OREILLE, STEVENS, AND

WHITMAN COUNTIES

ASSISTANT TENDER, ROV

TENDER/TECHNICIAN..........$ 26.27 9.30

DIVER STANDBY,

BELL/VEHICLE OR

SUBMERSIBLE OPERATOR NOT

UNDER PRESSURE.............$ 29.02 9.30

DIVER TENDER, MANIFOLD

OPERATOR, ROV OPERATOR.....$ 28.02 9.30

DIVER WET..................$ 58.04 9.30

MANIFOLD OPERATOR-MIXED

GAS........................$ 32.02 9.30

ZONE PAY:

ZONE 1 0-40 MILES FREE

ZONE 2 41-65 MILES $2.25/PER HOUR

ZONE 3 66-100 MILES $3.25/PER HOUR

ZONE 4 OVER 100 MILES $4.75/PER HOUR

DISPATCH POINTS:

CARPENTERS/MILLWRIGHTS: PASCO (2819 W. SYLVESTER) or Main

Post Office of established residence of employee (Whichever is closest to the worksite).

AIR CONDITIONING: MOS CLASSROOMS #1312 Specifications Section 1500 Basic Mechanical Requirements

Part 1 General

1.1 Conditions and Requirements

A. Refer to BIDDING REQUIREMENTS, CONDITIONS OF THE CONTRACT, SUPPLEMENTARY CONDITIONS, and DIVISION 1 of these specifications, which govern work under DIVISION 15. Refer to other sections of these specifications for additional related requirements.

1.2 Scope of Requirements

A. The work covered by Division 15 of the specifications shall include but not limited to:

1. Furnishing all materials and supplying all labor, equipment, and services to install the complete mechanical systems as shown on the accompanying drawings and specified herein.

1.3 Codes, Permits and Fees

A. Mechanical work shall be in accordance with the following as adopted by the governing agencies, including amendments:

1. Applicable State and Local Codes and Ordinances

2. National Electrical Code

3. 2006 International Fire Code

4. 2006 International Mechanical Code

5. 2006 International Plumbing Code

6. Washington State Non-Residential Energy Code

7. Washington State Indoor Air Quality Code

1.4 Intent and Interpretations

A. It is the intent of these plans and specifications to result in a complete and working mechanical installation in complete accordance with all applicable codes and ordinances.

B. The drawings and these specifications are intended to supplement each other. Any details contained in either the drawings or these specifications shall be included as if contained in both.

C. Items not specifically mentioned in the specifications or noted on the drawings, but which are obviously necessary to make a complete working installation shall be included.

1.5 Drawings

A. Mechanical drawings show general arrangement of piping, ductwork, equipment, etc. Drawings shall be followed as closely as actual building construction and work of other trades will permit.

B. Mechanical drawings are diagrammatic only. Consequently, all required duct and pipe offsets are not indicated on the drawings. Offsets as required to meet the design intent of the drawings shall be provided under Division 15.

1.6 Guarantee

A. The Mechanical equipment, materials, and installation shall be guaranteed for a period of one (1) year unless an individual item or specification is otherwise noted as longer. All defects in mechanical work and/or equipment furnished under Division 15 that develop at any time during the one year guarantee period shall be corrected at no cost to the owner, including any expenses for cutting, patching, and repairing made necessary by corrections of unsatisfactory work and/or damage resulting from incorrect equipment operation.

B. The guarantee period shall begin upon the Date of Acceptance. When Acceptance is granted for portions of the Mechanical system at different times, the guarantee for each portion of the Mechanical system shall begin upon Acceptance of that portion of the Mechanical system.

C. Equipment warranties in addition to this guarantee shall be provided as noted in the individual specification sections.

Part 2 Products

2.1 Equipment and Materials – Standards and Codes

A. Materials used under this Contract, unless specifically noted otherwise, shall be new and of the latest and most current model line produced by the manufacturer. Outdated “new” equipment is not acceptable. Each item of equipment and material shall conform to the latest Standard Specifications of the American Society for Testing Materials and shall conform to any applicable standards of the United States Department of Commerce.

B. Motor and equipment name plates as well as applicable UL and AGA labels shall be in place when Project is turned over to the Owner.

C. Motor efficiencies shall meet or exceed the requirements of the applicable energy code.

D. All electrically driven or connected equipment shall be provided with UL or equivalent label and/or listing in accordance with the requirements of the NEC.

E. Equipment shall be UL listed as an assembly where listing/labeling program is available for that type of equipment.

2.2 Equipment/Material Substitutions

A. Throughout these specifications and drawings, various materials, equipment, apparatus, etc., are specified or scheduled by manufacturer, brand name, type or catalog number. Such designation is to establish standards of desired quality and construction and shall be the basis of design and the bid.

B. Substitutions will not be permitted without written approval.

C. Where two or more manufacturer designations are listed in these specifications, choice will be optional with the Contractor except that where more than one manufacturer is listed and only one manufacturer’s catalog number is specified or only one manufacturer scheduled on the drawings (basis of design), that standard of quality, dimensional characteristics, capacities, and construction shall be maintained by materials or equipment supplied by the other manufacturer(s).

D. Substituted equipment with efficiencies less than 95 % of the basis of design efficiency shall not be considered equal to the basis of design.

E. If the Division 15 Contractor uses manufacturers other than the basis of design, the Contractor shall be responsible for:

1. Insuring the substituted item will fit the available space while allowing proper maintenance access

2. Any changes required by other Contractors caused by the substituted equipment

3. Changes in electrical requirements: See “Equipment Substitutions – Electrical Characteristics” below

4. Changes in structural design due to weight differences

F. In the event other than specified equipment is used and will not fit job site conditions, this Contractor shall assume responsibility for replacement with items indicated as the basis of design.

2.3 Equipment Substitutions – Electrical Characteristics

A. Products furnished other than the basis of design shall have similar electrical characteristics as the scheduled or specified equipment. The Contractor shall be responsible for any electrical changes caused by products not in accordance with this requirement.

2.4 Submittals For Review

A. Shop drawings, catalog information and material schedules shall be submitted for approval on all specified materials and equipment in Division 15 prior to ordering.

B. Provide specific wiring diagrams for all equipment requiring electrical or control wiring. Upon approval, copies of these diagrams shall be forwarded to pertinent contractors.

C. Furnish complete shop drawing/catalog data for equipment and materials to be used in the work for review. Allow sufficient time for developing shop drawings, processing and review time so that the installation will not be delayed.

D. Shop drawings shall be reviewed, approved and stamped by the Contractor prior to submitting to Owner’s Representative for approval. Submittals without such approval will be returned without review.

E. Submit two copies of information. Data shall be black and white, on 8½ inch × 11 inch (A4) or 11 inch × 17 inch, single, one-sided sheets suitable for copying. Drawings and catalog data must be clean, neat copies. FAX material or other poor quality copies will not be acceptable.

F. Where choices of options and accessories are available or specified, provide written description of what is to be furnished. If necessary, list page numbers where submitted items are described.

G. State sizes, capacities, brand names, motor HP, electrical characteristics, accessories, materials, gauges, dimensions, and other pertinent information.

H. Highlight/Underline applicable data.

I. If material or equipment is not as specified or submittal is not complete, it will be rejected. Only complete submittal including all applicable specification sections will be reviewed.

J. Catalog data or shop drawings for equipment which are noted as being reviewed shall not supersede Contract Documents.

K. Review comments shall not relieve the Contractor from responsibility for deviations from Contract Documents unless attention has been called to such deviations in writing at time of submission, nor shall they relieve this Contractor from responsibility for errors in items submitted.

L. Check work described by catalog data with Contract Documents for deviations and errors.

M. Submit two (2) copies of each shop drawing. One stamped copy will be retained by the Contracting Officer, one will be retained by the Owner and a single stamped and reviewed copy will be returned to the Contractor. The Contractor shall be responsible for distribution of required number of reviewed copies to parties other than the Owner’s Representative(s).

N. Operation and maintenance data for individual equipment shall also be provided subsequent to approval of equipment submittals in a separate binder meeting the same requirements as the submittal binder.

O. All submittals and re-submittals as required shall be provided with a cover page incorporating a table similar to that provided at the end of this section. The appropriate box(es) shall be checked on each line item for all submittals.

Part 3 Execution

3.1 Locations

A. Coordination of Division 15 equipment and systems to the available space, with other trades and to the access routes through the construction shall be the Contractor’s responsibility.

B. Drawings are diagrammatic. Make offsets, transitions, and changes in direction of pipes and ducts as required to maintain proper head room and pitch of sloping lines and avoid structural, electrical, pipe and duct interferences whether or not indicated on Drawings. Furnish fittings, etc., as required to make these offsets, transitions and changes in direction at no additional cost to the Government.

C. Determine exact route and location of each pipe and coordinate and obtain approval for changes from the layout indicated on the drawings with the Contracting Officer.

D. Locations of equipment and devices, as shown on the drawings, are approximate unless dimensioned. Verify the physical dimensions of each item of mechanical equipment to fit the available space and promptly notify the Contracting Officer prior to roughing-in if conflicts appear.

E. All piping, wiring, equipment, ductwork, tubing, etc., shall be concealed within building construction unless otherwise noted, or in mechanical rooms.

3.2 Cutting and Patching

A. All cutting and patching of new construction required for the installation of systems and equipment specified in Division 15 shall be the responsibility of the Division 15 Contractor. All cutting shall be accomplished with masonry saws, drills or similar equipment to provide neat uniform openings.

B. Walls, floors, ceilings and roof shall be patched and repaired with materials of same quality and appearance as adjacent surfaces unless otherwise shown. Surface finishes shall exactly match existing finishes of same materials. All patching shall meet the approval of the Owner’s Representative.

C. All cutting and patching made necessary to repair defective equipment, defective workmanship or be neglect of this Contractor to properly anticipate his requirements shall be included in Division 15.

D. Cut carefully to minimize necessity for repairs to existing work. Do not cut beams, columns, or trusses or other structural members without the Owner Representative’s written approval.

3.3 Product Delivery, Storage, and Handling

A. Follow manufacturer’s directions in delivery, storage, protection, and installation of equipment and materials.

B. Promptly notify Contracting Officer in writing of conflicts between requirements of Contract Documents and Manufacturer’s directions and obtain written instructions from Owner’s Representative before proceeding with work. The Contractor shall bear expenses arising from correcting deficiencies of work that do not comply with manufacturer’s directions or such written instructions from Contracting Officer.

C. Deliver equipment and material to site and tightly cover and protect against dirt, water, and chemical or mechanical injury but have readily accessible for inspection. Store items subject to moisture damage (such as controls) in a dry, heated space.

D. Notify Contracting Officer of equipment delivery dates twenty-four (24) hours in advance of delivery.

E. The Contractor shall be responsible for protection of equipment furnished in this Division from vandalism and weather during all phases of construction. Damaged equipment shall be restored to like new condition or replaced at the Contractor’s expense.

F. Ductwork shall be stored on pallets off of grade. Internally lined ductwork and air handling equipment shall be kept dry. Internal insulation that has been allowed to become wet will be rejected. Air handling equipment that has been allowed to become wet may be rejected.

G. Any factory painted equipment scratched or marred during shipment or construction shall be restored to original “new” condition. This includes complete repainting if necessary to provide exact paint match.

SECTION 15784 DUCTLESS SPLIT AIR CONDITIONERS

PART I GENERAL

1.1

SECTION INCLUDES

A. Under ceiling ductless split air cooling only units with condenser. Provide fresh air capability

1.2

SUBMITTALS

A. Product data: Provide rated capacities, weights, specialties and accessories, electrical requirements and wiring diagrams

1.3

DELIVERY, STORAGE, AND PROTECTION

A. Comply with manufacturer’s installation instructions for rigging, unloading, and transporting units

B. Protect units from physical damage

PART II PRODUCTS

2.1

SPLIT SYSTEM MANUFACTURERS

A. Carrier

B. Trane

2.2

DIRECT EXPANSION FAN COIL UNITS

A. Description: Indoor, direct-expansion, high wall mounted fan coil. Unit shall come complete with cooling coil, fan, power vent, fan motor, piping connectors, electrical controls, internal condensate pump, and fresh air intake, and mounting brackets.

B. Unit Cabinet: Cabinet shall be constructed of zinc-coated steel. Fully insulated discharge and inlet grilles shall be attractively styled, high-impact polystyrene. Cabinet shall have filter tracks and cleanable filters.

C. Fan: Fan shall be a tangential, direct drive blower type with air intake at the upper from face of the unit and discharge at the bottom front. Automatic, motor-driven vertical air sweep shall be provided. Air sweep operation shall be user selectable.

D. Coil: Coil shall be copper tube with aluminum fins and galvanized steel tube sheets. Fins will be bonded to the tubes by mechanical expansion. A drip pan under the coil shall have a factory installed condensate pump and drain connection for hose attachment to remove condensate.

E. Motors: Motor shall be totally enclosed and permanently lubricated with inherent protection. Fan motor shall be 3 speed.

F. Controls:

1. Controls shall be 24 v and shall be easily operated by the user from a wall-mounted control unit. Float control shall be in the condensate sump to shut unit down in case of pump malfunction. A wall-mounted electromechanical thermostat with 3 fan speed selections, and an auto/manual switch shall be supplied for field installation. The R-22 refrigerant is controlled with a piston-type refrigerant metering device, and evaporator coil freeze shall be provided.

2. Electronic Programmable Thermostat: Thermostat shall be commercial grade and shall provide 7-day, 4-event scheduling. Integral sub-base shall be included. Thermostat shall also provide 3-speed fan switchover capability, air sweep, and changeover, and shall not require a battery to retain memory.

2.3

AIR COOLED CONDENSING UNIT

A. Description: Factory assembled, single piece, air-cooled outdoor unit. Contained within enclosure shall be all factory wiring, piping, controls, compressor, full charge of R-22 refrigerant and special features required prior to field start-up; R410a FCU Cooling 2.5 ton Under-ceiling 208/230-1-60 or equal

B. Unit Cabinet:

1. Unit cabinet shall be constructed of galvanized-steel, bonderized and coated with a baked-enamel finish.

2. Unit access panels shall be removable with minimal screws and shall provide full access to the compressor, fan, and control components.

3. Outdoor compartment shall be isolated and have an acoustic lining to assure quiet operation.

C. Fans:

1. Outdoor fans shall be direct-drive propeller type, and shall discharge air horizontally. Fans shall blow air through the outdoor coil.

2. Outdoor fans shall be totally-enclosed, single-phase motors with class B insulation and permanently-lubricated sleeve bearings. Motor shall be protected by internal thermal overload protection.

3. Shaft shall have inherent corrosion resistance.

4. Fan blades shall be corrosion resistant and shall be statically and dynamically balanced.

5. Outdoor fan openings shall be equipped with PVC coasted protection grille over fan and coil.

D. Compressor:

1. Compressor shall be fully hermetic reciprocating or scroll type.

2. Compressor shall be equipped with oil system, operating oil charge, and motor. Internal overloads shall protect the compressor from over temperature and over current. Scroll compressors shall also have high discharge gas temperature protection if required.

3. Motor shall be NEMA rated class F, suitable for operation in a refrigerant atmosphere.

4. Reciprocating compressors shall be equipped with crankcase heaters to minimize liquid refrigerant accumulation in compressor during shutdown and to prevent refrigerant dilution of oil.

5. Compressor assembly shall have internal spring isolation.

E. Outdoor Coil: Coil shall be constructed of aluminum fins mechanically bonded to internally enhanced, seamless copper tubes which are cleaned, dehydrated, and sealed.

F. Refrigerant circuit components shall include brass external liquid line service value with service gage port connections, suction line service valve with service gage connection port, service gage port connection on compressor suction and discharge lines with Schrader-type fittings with brass caps, accumulator, pressure relief, and a full charge of refrigerant.

G. Control and Safeties:

1. Operating controls and safeties shall be factory selected, assembled, and tested. The minimum control functions and safeties shall include the following:

a. Controls:

1) Time delay restart to prevent compressor reverse rotation

2) Automatic restart on power failure

3) Safety lockout if any outdoor unit safety is open

4) A time delay control sequence provided through the fan coil board, thermostat, or controller

5) High-pressure and liquid line low-pressure switches

6) Automatic outdoor-fan motor protection

7) Start capacitor and relay (single-phase units without scroll compressors)

b. Safeties:

1) System diagnostics

2) Compressor motor current and temperature overload protection

3) High pressure relief

4) outdoor fan failure protection

H. Electrical Requirements:

1. Unit electrical power shall be a single point connection

2. Unit control voltage to the indoor-fan coil shall be 24 v

3. High and low voltage terminal block connections

4. Provide normal disconnect

I. Miscellaneous Features:

1. Low-ambient kit

a. Control shall regulate fan-motor cycle sin response to saturated condensing pressure of the unit. The control shall be capable of maintaining a condensing temperature of 100 F ±10 F with outdoor temperatures to -20 F. Installation of kit shall not require changing the outdoor-fan motor

2. Liquid Solenoid Valve:

a. This electronically operated shutoff valve shall close and open in response to compressor operation; the valve should be use with all long-lines applications (over 100ft)

3. Winter Start Control:

a. Field supplied and installed winter start control shall permit start-up for cooling operation under low-load conditions and at low-ambient temperatures by bypassing the low-pressure switch for a 3-minute delay period

4. Crankcase heater:

a. Unit shall be shipped with a clamp-on compressor oil sump heater for field installation

5. Fresh air intake mounting kit

6. Wind baffle

J. Performance: See schedule on drawings for capacities, manufacturer, and model number

PART III EXECUTION

3.1 FAN COIL AND CONDENSING UNIT INSTALLATION

A. Install in accordance with manufacturer’s instructions and as indicated on drawings

B. Install units on contractor furnished pre-cast concrete pad with neoprene pad or washer for vibration isolation

C. Pipe condensate from drain pan to nearest floor drain or location show on plans

D. Provide full charge of oil

E. Charge system with refrigerant and test entire system for leaks after completion of installation. Repair leaks, put system into operation, and test equipment performance

F. Shut down system if initial start-up takes place in winter and machines are to remain inoperative. Repeat start-up and testing operation at beginning of first cooling season

G. Provide cooling season start-up and winter season shut-down for first year of operation

3.2 PACKAGED TERMINAL COOLING UNIT

A. Install per manufacturer’s recommendations

B. Provide control wiring from AC unit to remote wall-mounted thermostat

PAGE