SolicitationFinal.pdf

Commercial Item thru FAC 2005-86 – 2/1/2016 AG-03R6-S-16-0053

Maintenance of Computer Controls

This is a 100 % Total Small Business Set Aside

FURNISHING QUOTATION:

Complete:

1. Schedule of Items,

2. Experience Questionnaire

3. Solicitation Provisions as your quote.

Please return to the address shown in Block 9. Place “Solicitation No. AG-03R6-S-16-0053” on the envelope or in the subject line.

SERVICES AND PRICES

Note 1: In order to be eligible for an award, potential contractors must comply with all requirements of FAR Clause 52.204-7, Central Contractor Registration.

Note 2: Quote on all items. Only quotes to the nearest cent will be accepted.

Note 3: Written Acceptance

Any contract resulting from this solicitation will require written acceptance within 10 days of receipt by the Contractor.

Note 4: Basis of Award

One award will be made. Offer of award will be made to the Quoter whose quote, as determined by the Contracting Officer is most advantageous to the Government, considering but not limited to factors such as price, Contractor capacity to do the work, experience with this type of work and past performance. The Experience Questionnaire will be used as part of this evaluation.

Offeror’s Name

Address

Phone No.

Contact Name

Email Address

DUNS No.

Tax Identification No.

Note 5: In order to be considered responsive to this solicitation, the quoter must submit the following:

1. A written Contractor Quality Control plan in accordance with Statement of Work.

2. Experience Questionnaire. Though any format is acceptable, a sample is attached for your convenience.

Note 6: Quotes may be e-mailed to tlmitchell@fs.fed.us, mailed or hand delivered by 2:30 p.m.

MT, June 30, 2016 to:

Lolo National Forest Service

Attn: Tami L. Mitchell

24 Fort Missoula Road

Missoula, MT 59804

Schedule of Items

Item

No.

Description Unit of Issue Unit

Price

Total Price

1 Maintenance July 15, 2016 through June 30, 2017 Month

2 Specialist Labor (Work not defined as Regular

Service)

Hourly

3 8:00 a.m – 5:00 p.m. Mon – Fri. except Holidays Hourly

4 5:00 a.m. - 8:00 p.m. Mon – Fri and Sat. 8:00 a.m.

– 5:00 p.m. Except Holidays

Hourly

5 All other hours and Holidays Hourly mailto:tlmitchell@fs.fed.us

SPECIFICATIONS FOR SERVICE AGREEMENT

USDA FOREST SERVICE, FIRE RETARDANT OPERATIONS,

SEWER LIFT STATIONS AND EXPLOSIVE CACHE SECURITY SYSTEMS

The following is alist of specifications for an On-Call Service Agreement for various electrical and technical systems which are located in Missoula at the Aerial Fire Depot.

On-Call Availability

Contractor is to provide on-call, on-site service. This contract provides 24 hour-a-day, 7 day-a-week coverage for service work as Emergency or Repair. A service technician will be dispatched within two

(2) hours of a call for all emergency or repair service work, unless other arrangements are mutually agreed upon. The contractor shall provide the Aerial Fire Depot with a pertinent emergency telephone numbers list.

Regular Service

Contractor will perform monthly and annual remedial and preventative maintenance as defined by items A-C in the following descriptions. Remedial and preventitive maintenance will be scheduled for normal working ours, defined as between the hours of 8:00 a.m. and 5:00 p.m., Monday through

Friday, excluding holidays.

Work Not Defined as Regular Service

Contractor is to provide labor, consulting and/or technical assistance to troubleshoot service, maintain and modify electrical and control systems as needed and oversee and direct emergency or repair work of mechanical systems.

- The contractor shall have an Unlimited Electrical Cntractor license for the State of

Montana and all service technicians shall have a valid Montana State Elkectrical license or enrolled in a certified electrical apprenticeship program.

- The contractor shall maintain a spare parts list and inventory (see attached list).

This work will be paid with a Credit Card when invoiced.

Main Sewer Lift Station and its Generator at the Aerial Fire Depot

1) System Description

a. This system collects and stores raw effluent from the National Weather Service, Aerial Fire Depot, Intermountain Fire Sciences Laboratory, and Missoula

Technology and Development Center. The facility pumps the effluent to the public main sewer line. Related equipment includes lift station wet wells, pumping equipment, pumping equipment enclosure, motor controllers, instrumentation, electrical distributin, portable emergency power generator unit, automatic transfer switch, remote notification system, wiring and piping.

2) Regular Service

a. Contractor will perform monthly service checks of all related equipment including systems status, fuel levels, voltage readings, historical operation data analysis, proper switch positions and general equipment condition checks as described on a monthly and annual checklist, to be developed by the contractor and approved by the government.

b. Contractor will perform monthly service test on all related equipment including gneerator test, emergency power operation test, pump operation test and alarms test as described on the monthly checklist.

c. Contactor will perform annual preventitive maintenance service including replacement of filters, snubbers, calibration of instrument and complete electrical controls and instrumentation inspection as described on an annual checklist. Each electrically operated device will be checked for proper grounding and personnel safety.

A. Explosives Cache

1) Regular Service

a. Contractor will perform monthly service checks of equipment including system status, and general equipment condition check as descried on a monthly checklist.

b. Contractor will perform quarterly service test of related equipment includng entry door switch, motion sensor, transmitter, repeater, receiver, auto dailer, on-call list and remote notification system as described on the monthly checklist.

c. Contractor will perform annual preventative maintenance service including replacement of transmitter, battery, calibration of devices and complete electrical controls and instrumentation inspection as described on the annual checklist.

d. Annual replacement of the items on the spare parts list will be installed and replaced at no charge while the contract is in effect.

B. Retardant Loading System

1) System Description

a. Product is transferred from the retardant storage tanks to the tanks in an air tanker plane using a system of tanks, pipes, hoses, pumps, valves, controllers, instruments, PLC’s and keypad display units. The operator enters the tail number of the air tanker into the key pad/display unit and accepts or modifies the information displayed about that particular air tanker. When the operator presses start, the control system sequences the valves and pumps to automatically load the air tanker to help prevent loading it above its contracted weight. A load information sheet is printed for each load.

2) Regular Service

a. Contractor will perform monthly review (during fire season) of system

Operation with the current opearator(s) and teach, advise or consult as needed (not to exceed 10 hours per season).

b. Contractor will perform an annual safety inspection of the retardant plant’s electrical distribution equipment, motor controllers, motors, instruments, power wiring and control wiring for proper electrical gounding, bonding and general electrical personnel safety.

c. Contractor will perform an annual calibration of the mass flow meter transmitters, PLC analog inputs, scaled outputs, DTAM display and

DRT displays. Variables to be calibrated include flow rate, flow totalizer, density, and temperature. Time will be displayed accurately in gallons per minute, pounds per minute, gallons, specific gravity units, deg F and minutes. The Government will provide one 1500 gallon water tank and personnel to assist with piping and testing during calibration process. A completed checklist will b given to the government upon completion.

d. Contractor will perform an annual check of retardant loading equipment for proper operation and function.

e. Contractor will perform an annual review of the current list of air tankers on contract and update the PLC and DTAM programs accordingly.

f. Annual replacement of items on the spare parts list be installed and replaced at no charge, while the contract is in effect.

Electrical Spare Parts List

Equipment Part No. Description Quantity

MD-1 FRN-R-600 600 amp fuse 3

P-1 & 2 FRN-R-100 100 amp fuse 3

3P-3 & 5 FRN-R-70 70 amp fuse 3

MX1-4 FRN-R-70 70 amp fuse 3

P-4 FRN-R-50 50 amp fuse 3

MD2 FRN-R-15 15 amp fuse 3

O1-1, 3, 5 3AG-2 Glass Fuse 10

CP 3AG-5 Glass Fuse 10

CP 3AG-10 Glass Fuse 5

OI-1 20 amp 1 pole breaker 1

LP-1 20 amp 1 pole breaker 1

LP-1 100 amp 2 pole breaker 1

P-1 & 2 Thermal Overloads 3

P-3 & 5 Thermal Overloads 3

MX-1-4 Thermal Overloads 3

P-4 Thermal Overloads 3

R Recv 3 volt lithium battery 1

R Trans 3 volt lithium battery 2

MD-1 Pilot light lamp 5

P 1 & 2 120 volt 2 pole relay

CONTRACT CLAUSES

52.204-19 – Incorporation by Reference of Representations and Certifications. (Dec 2014)

The Contractor’s representations and certifications, including those completed electronically via the

System for Award Management (SAM), are incorporated by reference into the contract.

FAR 52.212-4 Contract Terms and Conditions - Commercial Items (May 2015)

(a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights --

(1) Within a reasonable time after the defect was discovered or should have been discovered;

and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any

Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C.3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the

Contractor may not assign its rights to receive payment under this contract.

(c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties.

(d) Disputes. This contract is subject to 41 U.S.C. chapter 71, Contract Disputes. Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at FAR 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract.

(e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference.

(f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of

God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The

Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(g) Invoice.

(1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include --

(i) Name and address of the Contractor;

(ii) Invoice date and number;

(iii) Contract number, contract line item number and, if applicable, the order number;

(iv) Description, quantity, unit of measure, unit price and extended price of the items delivered;

(v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading;

(vi) Terms of any discount for prompt payment offered;

(vii) Name and address of official to whom payment is to be sent;

(viii) Name, title, and phone number of person to notify in event of defective invoice;

and

(ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract.

(x) Electronic funds transfer (EFT) banking information.

(A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract.

(B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds

Transfer— System for Award Management, or 52.232-34, Payment by

Electronic Funds Transfer—Other Than System for Award Management), or applicable agency procedures.

(C) EFT banking information is not required if the Government waived the requirement to pay by EFT.

(2) Invoices will be handled in accordance with the Prompt Payment Act (31 U.S.C. 3903) and Office of Management and Budget (OMB) prompt payment regulations at 5 CFR part

1315.

(h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings.

(i) Payment.

(1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract.

(2) Prompt Payment. The Government will make payment in accordance with the Prompt

Payment Act (31 U.S.C. 3903) and prompt payment regulations at 5 CFR Part 1315.

(3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-

5(b) for the appropriate EFT clause.

(4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made.

(5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall—

(i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the—

(A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);

(B) Affected contract number and delivery order number, if applicable;

(C) Affected contract line item or subline item, if applicable; and

(D) Contractor point of contact.

(ii) Provide a copy of the remittance and supporting documentation to the Contracting

Officer.

(6) Interest.

(i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the

Secretary of the Treasury as provided in 41 U.S.C. 7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period at fixed by the Secretary until the amount is paid.

(ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.

(iii) Final decisions. The Contracting Officer will issue a final decision as required by

33.211 if—

(A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days;

(B) The Contractor fails to liquidate a debt previously demanded by the

Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or

(C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2).

(iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment.

(v) Amounts shall be due at the earliest of the following dates:

(A) The date fixed under this contract.

(B) The date of the first written demand for payment, including any demand for payment resulting from a default termination.

(vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on—

(A) The date on which the designated office receives payment from the

Contractor;

(B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or

(C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.

(vii) The interest charge made under this clause may be reduced under the procedures prescribed in 32.608-2 of the Federal Acquisition Regulation in effect on the date of this contract.

(j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the

Government upon:

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination.

(k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties.

(l) Termination for the Government’s convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the

Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The

Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the

Contractor’s records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided.

(m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession.

(o) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items.

(q) Other compliances. The Contractor shall comply with all applicable Federal, State and local laws, executive orders, rules and regulations applicable to its performance under this contract.

(r) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31

U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 18 U.S.C. 431 relating to officials not to benefit; 40 U.S.C. chapter 37, Contract Work

Hours and Safety Standards; 41 U.S.C. chapter 87, Kickbacks; 41 U.S.C. 4712 and 10 U.S.C. 2409 relating to whistleblower protections; 49 U.S.C. 40118, Fly American; and 41 U.S.C. chapter 21 relating to procurement integrity.

(s) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order:

(1) The schedule of supplies/services.

(2) The Assignments, Disputes, Payments, Invoice, Other Compliances, Compliance with

Laws Unique to Government Contracts, and Unauthorized Obligations paragraphs of this clause.

(3) The clause at 52.212-5.

(4) Addenda to this solicitation or contract, including any license agreements for computer software.

(5) Solicitation provisions if this is a solicitation.

(6) Other paragraphs of this clause.

(7) The Standard Form 1449.

(8) Other documents, exhibits, and attachments.

(9) The specification.

(t) System for Award Management (SAM).

(1) Unless exempted by an addendum to this contract, the Contractor is responsible during performance and through final payment of any contract for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government’s reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the

Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete.

Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document.

(2)

(i) If a Contractor has legally changed its business name, “doing business as” name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in Subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day’s written notification of its intention to:

(A) Change the name in the SAM database;

(B) Comply with the requirements of Subpart 42.12 of the FAR;

(C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide with the notification sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (t)(2)(i) of this clause, or fails to perform the agreement at paragraph (t)(2)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the

“Suspension of Payment” paragraph of the electronic funds transfer (EFT) clause of this contract.

(3) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims (see FAR Subpart 32.8, Assignment of Claims). Assignees shall be separately registered in the SAM database. Information provided to the Contractor’s SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the

“Suspension of payment” paragraph of the EFT clause of this contract.

(4) Offerors and Contractors may obtain information on registration and annual confirmation requirements via SAM accessed through https://www.acquisition.gov.

(u) Unauthorized Obligations.

(1) Except as stated in paragraph (u)(2) of this clause, when any supply or service acquired under this contract is subject to any End Use License Agreement (EULA), Terms of Service

(TOS), or similar legal instrument or agreement, that includes any clause requiring the

Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C.

1341), the following shall govern:

(i) Any such clause is unenforceable against the Government.

(ii) Neither the Government nor any Government authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an “I agree” click box or other comparable mechanism

(e.g., “click-wrap” or “browse-wrap” agreements), execution does not bind the

Government or any Government authorized end user to such clause.

https://www.acquisition.gov/

(iii) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement.

(2) Paragraph (u)(1) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures.

(v) Incorporation by reference. The Contractor’s representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

FAR 52.217-8 Option to Extend Services (NOV 1999)

The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates, provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor within 10 days.

FAR 52.222-55 -- Minimum Wages Under Executive Order 13658 (Dec 2015)

(a) Definitions. As used in this clause--

“United States'' means the 50 states and the District of Columbia.

“Worker''—

(1) Means any person engaged in performing work on, or in connection with, a contract covered by Executive Order 13658, and—

(i) Whose wages under such contract are governed by the Fair Labor Standards Act

(29 U.S.C. chapter 8), the Service Contract Labor Standards statute (41 U.S.C. chapter

67), or the Wage Rate Requirements (Construction) statute (40 U.S.C. chapter 31, subchapter IV);

(ii) Other than individuals employed in a bona fide executive, administrative, or professional capacity, as those terms are defined in 29 CFR part 541; and

(iii) Regardless of the contractual relationship alleged to exist between the individual and the employer.

(2) Includes workers performing on, or in connection with, the contract whose wages are calculated pursuant to special certificates issued under 29 U.S.C. 214(c).

(3) Also includes any person working on, or in connection with, the contract and individually registered in a bona fide apprenticeship or training program registered with the Department of

Labor's Employment and Training Administration, Office of Apprenticeship, or with a State

Apprenticeship Agency recognized by the Office of Apprenticeship.

(b) Executive Order Minimum Wage rate.

(1) The Contractor shall pay to workers, while performing in the United States, and performing on, or in connection with, this contract, a minimum hourly wage rate of $10.10 per hour beginning January 1, 2015.

(2) The Contractor shall adjust the minimum wage paid, if necessary, beginning January 1, 2016, and annually thereafter, to meet the applicable annual E.O. minimum wage. The

Administrator of the Department of Labor's Wage and Hour Division (the Administrator) will publish annual determinations in the Federal Register no later than 90 days before the effective date of the new E.O. minimum wage rate. The Administrator will also publish the applicable E.O. minimum wage on www.wdol.gov (or any successor Web site) and a general notice on all wage determinations issued under the Service Contract Labor Standards statute or the Wage Rate Requirements (Construction) statute, that will provide information on the

E.O. minimum wage and how to obtain annual updates. The applicable published E.O.

minimum wage is incorporated by reference into this contract.

(3)

(i) The Contractor may request a price adjustment only after the effective date of the new annual E.O. minimum wage determination. Prices will be adjusted only for increased labor costs (including subcontractor labor costs) as a result of an increase in the annual E.O. minimum wage, and for associated labor costs (including those for subcontractors). Associated labor costs shall include increases or decreases that result from changes in social security and unemployment taxes and workers' compensation insurance, but will not otherwise include any amount for general and administrative costs, overhead, or profit.

(ii) Subcontractors may be entitled to adjustments due to the new minimum wage, pursuant to paragraph (b)(2). Contractors shall consider any subcontractor requests for such price adjustment.

(iii) The Contracting Officer will not adjust the contract price under this clause for any costs other than those identified in paragraph (b)(3)(i) of this clause, and will not provide duplicate price adjustments with any price adjustment under clauses implementing the Service Contract Labor Standards statute or the Wage Rate

Requirements (Construction) statute.

(4) The Contractor warrants that the prices in this contract do not include allowance for any contingency to cover increased costs for which adjustment is provided under this clause.

(5) A pay period under this clause may not be longer than semi-monthly, but may be shorter to comply with any applicable law or other requirement under this contract establishing a shorter pay period. Workers shall be paid no later than one pay period following the end of the regular pay period in which such wages were earned or accrued.

http://www.wdol.gov/

(6) The Contractor shall pay, unconditionally to each worker, all wages due free and clear without subsequent rebate or kickback. The Contractor may make deductions that reduce a worker's wages below the E.O. minimum wage rate only if done in accordance with 29 CFR

10.23, Deductions.

(7) The Contractor shall not discharge any part of its minimum wage obligation under this clause by furnishing fringe benefits or, with respect to workers whose wages are governed by the Service Contract Labor Standards statute, the cash equivalent thereof.

(8) Nothing in this clause shall excuse the Contractor from compliance with any applicable

Federal or State prevailing wage law or any applicable law or municipal ordinance establishing a minimum wage higher than the E.O. minimum wage. However, wage increases under such other laws or municipal ordinances are not subject to price adjustment under this subpart.

(9) The Contractor shall pay the E.O. minimum wage rate whenever it is higher than any applicable collective bargaining agreement(s) wage rate.

(10) The Contractor shall follow the policies and procedures in 29 CFR 10.24(b) and 10.28 for treatment of workers engaged in an occupation in which they customarily and regularly receive more than $30 a month in tips.

(c)

(1) This clause applies to workers as defined in paragraph (a). As provided in that definition--

(i) Workers are covered regardless of the contractual relationship alleged to exist between the contractor or subcontractor and the worker;

(ii) Workers with disabilities whose wages are calculated pursuant to special certificates issued under 29 U.S.C. 214(c) are covered; and

(iii) Workers who are registered in a bona fide apprenticeship program or training program registered with the Department of Labor's Employment and Training

Administration, Office of Apprenticeship, or with a State Apprenticeship Agency recognized by the Office of Apprenticeship, are covered.

(2) This clause does not apply to--

(i) Fair Labor Standards Act (FLSA)-covered individuals performing in connection with contracts covered by the E.O., i.e. those individuals who perform duties necessary to the performance of the contract, but who are not directly engaged in performing the specific work called for by the contract, and who spend less than 20 percent of their hours worked in a particular workweek performing in connection with such contracts;

(ii) Individuals exempted from the minimum wage requirements of the FLSA under 29

U.S.C. 213(a) and 214(a) and (b), unless otherwise covered by the Service Contract

Labor Standards statute, or the Wage Rate Requirements (Construction) statute. These individuals include but are not limited to--

(A) Learners, apprentices, or messengers whose wages are calculated pursuant to special certificates issued under 29 U.S.C. 214(a).

(B) Students whose wages are calculated pursuant to special certificates issued under 29 U.S.C. 214(b).

(C) Those employed in a bona fide executive, administrative, or professional capacity (29 U.S.C. 213(a)(1) and 29 CFR part 541).

(d) Notice. The Contractor shall notify all workers performing work on, or in connection with, this contract of the applicable E.O. minimum wage rate under this clause. With respect to workers covered by the Service Contract Labor Standards statute or the Wage Rate Requirements

(Construction) statute, the Contractor may meet this requirement by posting, in a prominent and accessible place at the worksite, the applicable wage determination under those statutes. With respect to workers whose wages are governed by the FLSA, the Contractor shall post notice, utilizing the poster provided by the Administrator, which can be obtained at www.dol.gov/whd/govcontracts, in a prominent and accessible place at the worksite. Contractors that customarily post notices to workers electronically may post the notice electronically provided the electronic posting is displayed prominently on any Web site that is maintained by the contractor, whether external or internal, and customarily used for notices to workers about terms and conditions of employment.

(e) Payroll Records.

(1) The Contractor shall make and maintain records, for three years after completion of the work, containing the following information for each worker:

(i) Name, address, and social security number;

(ii) The worker's occupation(s) or classification(s);

(iii) The rate or rates of wages paid;

(iv) The number of daily and weekly hours worked by each worker;

http://www.dol.gov/whd/govcontracts

(v) Any deductions made; and

(vi) Total wages paid.

(2) The Contractor shall make records pursuant to paragraph (e)(1) of this clause available for inspection and transcription by authorized representatives of the Administrator. The

Contractor shall also make such records available upon request of the Contracting Officer.

(3) The Contractor shall make a copy of the contract available, as applicable, for inspection or transcription by authorized representatives of the Administrator.

(4) Failure to comply with this paragraph (e) shall be a violation of 29 CFR 10.26 and this contract. Upon direction of the Administrator or upon the Contracting Officer's own action, payment shall be withheld until such time as the noncompliance is corrected.

(5) Nothing in this clause limits or otherwise modifies the Contractor's payroll and recordkeeping obligations, if any, under the Service Contract Labor Standards statute, the

Wage Rate Requirements (Construction) statute, the Fair Labor Standards Act, or any other applicable law.

(f) Access. The Contractor shall permit authorized representatives of the Administrator to conduct investigations, including interviewing workers at the worksite during normal working hours.

(g) Withholding. The Contracting Officer, upon his or her own action or upon written request of the

Administrator, will withhold funds or cause funds to be withheld, from the Contractor under this or any other Federal contract with the same Contractor, sufficient to pay workers the full amount of wages required by this clause.

(h) Disputes. Department of Labor has set forth in 29 CFR 10.51,Disputes concerning contractor compliance, the procedures for resolving disputes concerning a contractor's compliance with

Department of Labor regulations at 29 CFR part 10. Such disputes shall be resolved in accordance with those procedures and not the Disputes clause of this contract. These disputes include disputes between the Contractor (or any of its subcontractors) and the contracting agency, the Department of

Labor, or the workers or their representatives.

(i) Antiretaliation. The Contractor shall not discharge or in any other manner discriminate against any worker because such worker has filed any complaint or instituted or caused to be instituted any proceeding under or related to compliance with the E.O. or this clause, or has testified or is about to testify in any such proceeding.

(j) Subcontractor compliance. The Contractor is responsible for subcontractor compliance with the requirements of this clause and may be held liable for unpaid wages due subcontractor workers.

(k) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph

(k) in all subcontracts, regardless of dollar value, that are subject to the Service Contract Labor

Standards statute or the Wage Rate Requirements (Construction) statute, and are to be performed in whole or in part in the United States.

FAR 52.223-2 Affirmative Procurement of Biobased Products Under Service and

Construction Contracts (SEPT 2013)

(a) In the performance of this contract, the contractor shall make maximum use of biobased products that are United States Department of Agriculture (USDA)-designated items unless—

(1) The product cannot be acquired—

(i) Competitively within a time frame providing for compliance with the contract performance schedule;

(ii) Meeting contract performance requirements; or

(iii) At a reasonable price.

(2) The product is to be used in an application covered by a USDA categorical exemption (see

7 CFR 3201.3(e)). For example, all USDA-designated items are exempt from the preferred procurement requirement for the following:

(i) Spacecraft system and launch support equipment.

(ii) Military equipment, i.e., a product or system designed or procured for combat or combat-related missions.

(b) Information about this requirement and these products is available at http://www.biopreferred.gov.

(c) In the performance of this contract, the Contractor shall—

(1) Report to http://www.sam.gov, with a copy to the Contracting Officer, on the product types and dollar value of any USDA-designated biobased products purchased by the Contractor during the previous Government fiscal year, between October 1 and September 30; and

(2) Submit this report no later than—

(i) October 31 of each year during contract performance; and

(ii) At the end of contract performance.

FAR 52.232-40 Providing Accelerated Payments to Small Business Subcontractors (DEC 2013)

(a) Upon receipt of accelerated payments from the Government, the Contractor shall make accelerated payments to its small business subcontractors under this contract, to the maximum extent practicable and prior to when such payment is otherwise required under the applicable contract or subcontract, after receipt of a proper invoice and all other required documentation from the small business subcontractor.

http://www.biopreferred.gov/ http://www.sam.gov/

(b) The acceleration of payments under this clause does not provide any new rights under the Prompt

Payment Act.

(c) Include the substance of this clause, including this paragraph (c), in all subcontracts with small business concerns, including subcontracts with small business concerns for the acquisition of commercial items.

Contract Time

AGAR 452.211-75 Effective Period of the Contract (FEB 1988) The effective period of this contract is from Date of Award through June 30, 2017.

Invoice Processing Platform (IPP)

The Forest Service is utilizing the Invoice Processing Platform (IPP) for the electronic submission and tracking of contracts/purchase orders, invoices, and payment information. IPP is a secure

Government-wide, Web-based invoice processing service. Visit http://www.ipp.gov to learn more.

Upon award of a contract, Contractors must enroll at https://www.ipp.gov/vendors/enrollment-vendors.htm. Contractors shall submit all invoices electronically via IPP. Paper copies of invoices will no longer be accepted.

FAR 52.252-2 Clauses Incorporated by Reference (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available.

Also, the full text of a clause may be accessed electronically at this/these address(es): Federal

Acquisition Regulations - http://www.acquisition.gov/far and the Agriculture Acquisition Regulations

– http://www.usda.gov/procurement/policy/agar.html.

FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES

52.232-39 Unenforceability of Unauthorized Obligations (JUN 2013)

52.245-9 Use and Charges (APR 2012)

FAR 52.212-5 Contract Terms and Conditions Required to Implement Statutes or Executive

Orders - Commercial Items (FEB 2016)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015)

(2) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(3) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-

77, 108-78 (19 U.S.C. 3805 note)).

http://www.ipp.gov/ https://www.ipp.gov/vendors/enrollment-vendors.htm https://www.ipp.gov/vendors/enrollment-vendors.htm http://www.acquisition.gov/far http://www.usda.gov/procurement/policy/agar.html

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.]

___ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with

Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C.

3509).

___ (3) 52.203-15, Whistleblower Protections under the American Recovery and

Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009).

___ (4) 52.204-10, Reporting Executive compensation and First-Tier Subcontract Awards

(Oct 2015) (Pub. L. 109-282) (31 U.S.C. 6101 note).

___ (5) [Reserved]

___ (6) 52.204-14, Service Contract Reporting Requirements (Jan 2014) (Pub. L. 111-117, section 743 of Div. C).

___ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery

Contracts (Jan 2014) (Pub. L. 111-117, section 743 of Div. C).

___ (8) 52.209-6, Protecting the Government’s Interest When Subcontracting with

Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015) (31 U.S.C. 6101 note).

___ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility

Matters (Jul 2013) (41 U.S.C. 2313).

___ (10) [Reserved]

___ (11) (i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15

U.S.C. 657a).

___ (ii) Alternate I (Nov 2011) of 52.219-3.

___ (12) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business

Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a).

___ (ii) Alternate I (Jan 2011) of 52.219-4.

___ (13) [Reserved]

_X__ (14) (i) 52.219-6, Notice of Total Small Business Aside (Nov 2011) (15 U.S.C. 644).

___ (ii) Alternate I (Nov 2011).

___ (iii) Alternate II (Nov 2011).

___ (15) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C.

644).

___ (ii) Alternate I (Oct 1995) of 52.219-7.

___ (iii) Alternate II (Mar 2004) of 52.219-7.

___ (16) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)).

___ (17) (i) 52.219-9, Small Business Subcontracting Plan (Oct 2015) (15 U.S.C. 637 (d)(4)).

___ (ii) Alternate I (Oct 2001) of 52.219-9.

___ (iii) Alternate II (Oct 2001) of 52.219-9.

___ (iv) Alternate III (Oct 2015) of 52.219-9.

_X__ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)).

___ (19) 52.219-14, Limitations on Subcontracting (Nov 2011) (15 U.S.C. 637(a)(14)).

___ (20) 52.219-16, Liquidated Damages—Subcontracting Plan (Jan 1999) (15 U.S.C.

637(d)(4)(F)(i)).

___ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside

(Nov 2011) (15 U.S.C. 657f).

_X__ (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15

U.S.C. 632(a)(2)).

The Contractor represents that it __ is, ___ is not a small business concern under

NAICS Code __________ assigned to contract number _________________.

___ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically

Disadvantaged Women-Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)).

___ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small

Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015)

(15 U.S.C. 637(m)).

_X__ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

_X__ (26) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (Feb 2016)

(E.O. 13126).

_X__ (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

_X__ (28) 52.222-26, Equal Opportunity (Apr 2015) (E.O. 11246).

___ (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

_X__ (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C.

793).

___ (31) 52.222-37, Employment Reports on Veterans (Oct 2015) (38 U.S.C. 4212).

_X__ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations

Act (Dec 2010) (E.O. 13496).

_X__ (33) (i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627).

___ (ii) Alternate I (Mar 2015) of 52.222-50, (22 U.S.C. chapter 78 and E.O. 13627).

___ (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

___ (35) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-

Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

___ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

___ (36) (i) 52.223-13, Acquisition of EPEAT® -Registered Imaging Equipment (Jun 2014)

(E.O.s 13423 and 13514

___ (ii) Alternate I (Oct 2015) of 52.223-13.

___ (37) (i) 52.223-14, Acquisition of EPEAT® -Registered Television (Jun 2014) (E.O.s

13423 and 13514).

___ (ii) Alternate I (Jun 2014) of 52.223-14.

___ (38) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C.

8259b).

___ (39) (i) 52.223-16, Acquisition of EPEAT® -Registered Personal Computer Products

(Oct 2015) (E.O.s 13423 and 13514).

___ (ii) Alternate I (Jun 2014) of 52.223-16.

_X__ (40) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving

(Aug 2011) (E.O. 13513).

_X__ (41) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83).

___ (42) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014)

(41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19

U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-

283, 110-138, 112-41, 112-42, and 112-43).

___ (ii) Alternate I (May 2014) of 52.225-3.

___ (iii) Alternate II (May 2014) of 52.225-3.

___ (iv) Alternate III (May 2014) of 52.225-3.

___ (43) 52.225-5, Trade Agreements (Feb 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

_X__ (44)…