AE Design SOW - EHRM Infrastructure Upgrades 11-14-2023.pdf

VA Portland Health Care System 3710 Southwest US Veterans Hospital Road 11/14/2023 Portland, OR 97239‐2964

ARCHITECT‐ENGINEER DESIGN STATEMENT OF WORK

EHRM INFRASTRUCTURE UPGRADES

PROJECT NO: 648‐24‐701 EHRM Infrastructure Upgrades – Phase 2 ‐ Portland HCS

PROJECT NAME: EHRM Infrastructure Upgrades – Phase 2 ‐ Portland HCS

VAAR Magnitude of Construction is between: $5M and $10M.

**The Certification and Accreditation (C&A) does not apply, a Security Accreditation Package is not required**

1. GENERAL INTENT:

The Contractor (herein referred to as “A‐E”) shall provide Architect‐Engineer (A‐E) services to design a construction project at the Portland VA Medical Center (VAMC) in accordance with this design statement of work.

Upgrades will occur at the Portland VA Medical Center and the Vancouver Campus.

2. SCOPE OF WORK:

A‐E Part One Services (also known as Design Phase Services) for this design project include site visits, field investigation, studies, and user interviews to prepare drawings, specifications, and cost estimates for all facets of work and disciplines/trades to facilitate a construction project to upgrade the facility infrastructure to support the new Electronic Health Record Modernization (EHRM) system in accordance with VA OEHRM Site Infrastructure

Requirements (provided by VHA). The Vancouver Washington facility project shall include, but is not limited to, provide a redundant fiber run from the Main Computer Room (MCR) to each (TR) in buildings

1,2,3,4,11,12,13,14,15,17,18,20,21,24,25,27, and Trailer 3. Add primary fiber home run in buildings 1 (TR’s), 2 (1

TE), 17 (3 TR’s), and 18 (1 TR). Add approximately 25 additional data drops in building 2 sterile processing, upgrade facility power distribution as required, upgrade facility HVAC distribution as required, physical security assessment and upgrades, and hazardous material abatement.

The Portland Oregon facility project shall include, but is not limited to, add primary fiber home run in buildings

100 (2 TR’s), 103 (4 TR’s) and 104(1 TR), provide two new (TR’s) in building 100 and relocate existing TR equipment, upgrade facility power distribution as required, upgrade facility HVAC distribution as required, add redundant fiber home run in buildings 100 (2 TR’s), 103 (4 TR’s), and 104 (1 TR).

A‐E Part Two Services (also known as Construction Period Services) for this design project include responding to construction contractor Requests For Information (RFIs) during the solicitation (solicitation support) and construction phases of the construction project; attendance at pre‐bid, post‐award, and commissioning kick off construction project conferences; review of construction material submittals and shop drawings; 1 site visit per month during construction (both scheduled and emergent) to ensure compliance with the design drawings and specifications; preparation of site visit reports; coordination with project commissioning requirements (see Third‐

Party Commissioning under section 14); review of any construction project modifications for cost and technical acceptability; attendance and participation during the final acceptance inspection; preparation of the punch list;

and preparation of record drawings of the completed construction project based on the construction contractor’s

3710 Southwest US Veterans Hospital Road 11/14/2023 Portland, OR 97239‐2964 as‐built drawings. The A‐E shall prepare a submittal log to be utilized by the VA during construction period services, maintain RFI log, and provide meeting minutes for weekly construction meetings throughout the duration of construction. All Part Two Services are optional line items and will not be exercised at the time of award.

The above paragraphs constitute a basic outline of the work to be accomplished, and in no way comprise all the details for design of this project. The A‐E shall initiate detailed inspection of the project site to determine the needs and conditions for the design of this project. Copies of VAMC record drawings and the EHRM infrastructure readiness assessment documents will be made available to the highest rated A‐E firm. The A‐E will verify the validity of the record drawings prior to the start of design work and conduct site investigations as necessary throughout the design. Portland VA Healthcare system and Vancouver Campus Maps (SOW Attachment 09) will give the A‐E firm a basic understanding of both campuses.

The A‐E shall be solely responsible for the management, including alc l associated labor, equipment, materials, mailing costs, and inspection, to meet the requirements of the design project. The A‐E shall further provide meeting minutes for all meetings held under this design project.

3. DESIGN WITHIN FUNDING LIMITATIONS:

The design shall be prepared by the A‐E to permit the award of a construction contract, using Federal Acquisition Regulation procedures for the construction of the facilities, at a cost that does not exceed the project’s estimated construction contract price, which will be provided to the firm selected to provide a price proposal. The design project must comply with VAAR 836.606‐71, Application of 6 percent architect‐engineer fee limitation. The VAAR Magnitude of Construction is between: $5M and $10M.

4. DESIGN INDEPENDENCE, FURNITURE, AND EQUIPMENT:

Designs for construction must produce a “complete and usable” facility or improvement when constructed. VA policy (VHA Office of Capital Assets Management, Engineering and Support memo Updated Construction Guidance and Expectations dated Sep 12, 2016) requires the A‐E to certify that their design (including all bid alternates/bid deducts) is independent of any future construction project. In addition, the A‐E must certify that it has produced a design that does not include furniture and equipment that will be procured separately. Equipment that can be part of the design includes those items to meet code requirements for building occupancy; items covered in the

VA’s Master Construction Specifications (PG‐18‐1) Divisions 1 through 10, 13 through 26, or 28 through 48; non‐

IT equipment items covered by Division 27; and items covered by Division Numbers 12 31 00, 12 32 00, 12 34 00, and 12 36 00.

The A‐E shall submit as part of the Final Bid Documents submittal a signed letter on company letterhead stating the design’s independence.

5. DESIGN CRITERIA:

The VA Technical Information Library (TIL) available at http://www.cfm.va.gov/til/index.asp is managed by the VA

Office of Construction & Facilities Management and is the master repository for all VA Numbered Standards for

Construction to include design and construction specifications, procedures, standard details, BIM/CAD standards, equipment guides, space planning, and design guides. The documents of the TIL shall be the minimum design criteria for all VA projects performed in the construction of new facilities and the modernization, alteration, 3710 Southwest US Veterans Hospital Road 11/14/2023 Portland, OR 97239‐2964 addition, or improvement of its real property. All design documents shall be developed in accordance with the VA

TIL, including (but not limited to) the following listed Department of Veterans Affairs References:

PG‐18‐1 Master Construction Specifications SOW Attachment 01 VHA Required Division 01 Specification Sections List

PG‐18‐3

Design and Construction Procedures [Including but not limited to: Codes, Standards, and Executive Orders]

PG‐18‐4 Standard Details and CAD Standards PG‐18‐5 Equipment Guide List H‐18‐8 Seismic Design Requirements PG‐18‐9 Space Planning Criteria

PG‐18‐10

Design Manuals (by discipline) [Including but not limited to: Guiding Principles checklists as indicated for Minor Projects in Sustainable Design Manual, Life Cycle Cost Analysis]

PG‐18‐12 Design Guides (graphical, by function) PG‐18‐13 Barrier‐Free Design Standard PG‐18‐14 Room Finishes, Door, and Hardware Schedule PG‐18‐15 A‐E Submission Requirements, Volume C PG‐18‐17 NEPA Interim Guidance for Projects H‐7545 VA Cultural Resource Management Procedures See SOW Section 17 OIT Infrastructure Standard for Telecommunications Spaces v3.1 (1 July 2021)

The following references should also be used to complete the design documents:

VA Standards Alert 017 – Infrastructure Standard for Telecommunications Spaces and all standards, guides, and manuals incorporated by reference (https://www.cfm.va.gov/til/sAlert/sAlert017.pdf)

00 VA OEHRM Site Infrastructure Requirements v2.0 (SOW Attachment 02)

HEFP SEP Design Alerts (SOW Attachment 03)

CONSTRUCTION CONTRACTOR RESTRICTIONS (SOW Attachment 12)

Where conflicts exist between VA adopted codes and standards and the documents on the TIL, the A‐E shall bring this to the attention of the VA. The resolution of the conflict shall be made by the authority having jurisdiction for VA to ensure consistency department‐wide.

6. DESIGN COLLABORATION:

The A‐E during this design project shall collaborate with the VHA Office of Healthcare Environment and Facilities

Programs Special Engineering Program (HEFP/SEP) staff, VISN 20, and the Independent Life Safety Review Agent

(LS Agent) for the project. Design submittal comments from these contractors, if concurred with by VA, shall be incorporated into the design. HEFP/SEP and/or VISN deliverables shall be coordinated with the A‐E’s design submittals to ensure compliance with all requirements is met. The A‐E is required to ensure all elements of the design adhere to the Life Safety Code, including recommendations for temporary construction barriers, prior to the Independent Life Safety review.

3710 Southwest US Veterans Hospital Road 11/14/2023 Portland, OR 97239‐2964

7. INDEPENDENT LIFE SAFETY REVIEW:

The A‐E shall incorporate any comments from the VA 3rd party life safety review.

8. ENVIRONMENTAL PROTECTION:

The A‐E shall assist the VA with completion of a National Environmental Policy Act (NEPA) assessment. If the NEPA assessment results in potential environmental impacts, the A‐E shall be responsible for completing any auxiliary documentation required per PG‐18‐17, NEPA Interim Guidance for Projects located on the TIL

(http://www.cfm.va.gov/til/etc/NEPAGuidance.pdf). Additional requirements may include, but are not limited to, Environmental Assessment, Environmental Impact Statement, and Record of Decision. The NEPA analysis and concluding documentation must be completed by the Final Bid Documents submittal.

9. PHYSICAL SECURITY:

The A‐E must include a certified physical security specialist. The specialists must be involved with the design, beginning with the concept phase, and the qualifications must be submitted to the COR for review and approval prior to the concept/basis of design phase. The specialists shall meet the specific requirements listed in the VA

Physical Security and Resiliency Design Manual (PSRDM) revised April 1, 2021, located on the TIL

(https://www.cfm.va.gov/til/PhysicalSecurity/dmPhySec.pdf). The A‐E shall ensure that all applicable aspects of the VA PSRDM are incorporated into the design and shall prepare a written report acknowledging compliance as required by the VAMC. The A‐E must inform the COR of any physical security items that will be difficult to achieve during the concept/basis of design phase and assist the VA with waiver requests as necessary.

10. TELECOMMUNICATIONS DESIGN:

In accordance with Telecommunications and Special Telecommunications Systems Design Manual, February 2016, (https://www.cfm.va.gov/til/dManual/dmTelecomm.pdf), paragraph 1.2 (d), “Telecommunications design must be performed and stamped by a BICSI® Registered Communications Distribution Designer (RCDD®) for all projects.”

11. SUBMITTAL REQUIREMENTS:

Design submittals shall follow the requirements of Program Guide, PG‐18‐15, Volume C, A‐E Submission

Instructions for Minor and NRM Construction Program dated November 2008. This document is included as SOW

Attachment 06. Submittal documents shall be prominently marked “For Official Use Only (FOUO)” if they contain qualifying data as defined in VHA Memorandum 2019‐11‐13 Sensitive Infrastructure Data Classification ‐ For

Official Use Only (FOUO). This memo is included as SOW Attachment 04, as it is hosted on a non‐public VHA site.

The A‐E shall deliver design submittal documents that follow the iterative phase breakdown for design work in

PG‐18‐15 and as additionally specified below. Specific requirements for each discipline/work product listed under each phase can be found in PG‐18‐15. It is expected for the phase of design that each of the checked items in the

SD/DD/CD columns will be completed for the submittal. The A‐E shall attend a review meeting following each design submittal as indicated under the Project Schedule section of this Statement of Work. Each new submittal will incorporate all VA comments from the previous submittal.

3710 Southwest US Veterans Hospital Road 11/14/2023 Portland, OR 97239‐2964

The following submittals will be required for this project:

Quality Assurance/Quality Control (QA/QC) Plan

Basis of Design (BD) ‐ 10% ‐ In addition to the requirements in PG‐18‐15, a Basis of Design is required.

Basis of Design is a narrative presentation of facts, sufficiently complete, to demonstrate that the project concept is fully understood, and that subsequent design details and their ultimate presentation in the final drawings and specifications will be based on sound architectural and engineering decisions.

Conceptual drawings of the planned design and the initial cost estimate will additionally be included.

Schematic Design (SD) ‐ 35%

Design Development (DD) ‐ 65%

Construction Documents (CD) ‐ 95%

Final Bid Documents (Bid) ‐ 100%

12. DRAWING FORMAT:

All drawings shall adhere to VA project software requirements for available at http://www.cfm.va.gov/til/projReq.asp.

13. SUBMITTAL FORMATS:

Submittals shall be provided in electronic and hard copy formats as listed below. Portable Document Format (.pdf), Microsoft Office Suite formats (.doc, .xls, and .ppt), Microsoft Project (.mpp), and Autodesk Revit Project (.rvt) files are acceptable. The A‐E must establish a submittal exchange service or SharePoint site to provide all electronic copies of required submittals. The A‐E must ensure the submittal exchange service is accessible by VA personnel and provide station personnel and PCAC with the information necessary to access the service. Submittals shall additionally be compliant with Section 508 of the Rehabilitation Act (29 U.S.C. '794 d); information on the requirements for accessible media can be found at https://section508.gov/. The A‐E shall be responsible for providing:

Meeting/Conference Agendas and Minutes

Agendas and other required documents for all status update meetings will be provided to the Post‐Award CO/CS and COR a minimum of 24 hours in advance of the meeting. At the initial status update meeting, the frequency of subsequent status update meetings will be established and mutually agreed to by the contractor, VA station personnel, and the Post‐Award CO/CS.

Meeting minutes for all formal meetings and conferences held with the VA, including weekly construction meetings, shall be submitted within seven calendar days of the meeting or conference. All documents in any of the electronic formats listed above.

IF APPLICABLE

Minimum meeting minutes requirements

3710 Southwest US Veterans Hospital Road 11/14/2023 Portland, OR 97239‐2964

Project name, project number, meeting host, meeting name

Date, time, meeting ID, call‐in number, duration, and consecutive number of total related meetings

Participant list (name, title, phone number (office and mobile), email, attended meeting (yes/no))

Agenda items (decisions, action items, and fixes or next steps)

Next meeting date and time

Detailed attachment list

Construction Cost Estimates

Construction cost estimates shall comply with the VA Manual for Preparation of Cost Estimates & Related

Documents for VA Facilities dated February 1, 2019, located on the TIL (http://www.cfm.va.gov/cost/index.asp).

All estimates in any of the electronic formats listed above.

Quality Assurance/Quality Control (QA/QC) Plan

All documents in any of the electronic formats listed above.

Basis of Design (BD)

All documents in any of the electronic formats listed above.

Two half‐size paper bond sets of drawings to VA

Schematic Design (SD)

All documents in any of the electronic formats listed above.

Two paper bond sets of specifications to VA

Two paper bond sets of investigation reports, design calculations, space planning data, and cost estimate to VA

Design Development (DD), and Construction Documents (CD)

All documents in any of the electronic formats listed above.

Memo annotating what was not upgraded and corresponding justifications.

One full‐size paper bond set of drawings to VA

Two half‐size paper bond sets of drawings to VA

Two paper bond sets of specifications to VA

Two paper bond sets of investigation reports, design calculations, space planning data, construction schedule, construction statement of work (SOW), and cost estimate to VA

Final Bid Documents (Bid)

3710 Southwest US Veterans Hospital Road 11/14/2023 Portland, OR 97239‐2964

PDF files of drawings, specifications, and any miscellaneous design analysis documents, such as submittal log and physical security compliance report

Certified memo annotating what areas/times were not upgraded and the corresponding justifications

Certified memo that the A‐E design is independent of future projects and includes all equipment required for the project to be activated/fully functional

Word files of specifications

Revit and AutoCAD files of drawings

One full‐size paper bond set of drawings to VA

Two half‐size paper bond sets of drawings to VA

Two paper bond sets of specifications to VA

One paper bond set of investigation reports, design calculations, space planning data, construction schedule, construction SOW, and cost estimate to VA

14. OPTION ITEM REQUIREMENTS:

Solicitation Support Services

Pre‐bid site visit to include meeting and project walk around. This is the meeting where contractors are invited to the job site to visually inspect the construction site to accurately develop a construction bid package.

Answer any technical questions/requests for information (RFIs) received from contractors over the duration of the solicitation, including questions asked during the site visit. Questions from contractors may come at multiple times and cover several questions over the course of the solicitation period.

Technical question responses will be provided to the Contracting Officer who will distribute the information via amendment to the solicitation.

Answers to RFIs will be required from the A‐E within five calendar days of the date the questions are sent to the A‐E from either the project COR or CO. An alternate response period may be submitted for review, however, unless approved by the CO and COR, the A‐E is required to comply with the five‐calendar‐day requirement.

Throughout the solicitation period, the A‐E shall provide addenda as necessary if required to revise specs and drawings.

In response to any technical questions and/or addenda issued during the solicitation period, the A‐E shall provide any final revisions to the 100% FC CD as part of the construction contract. These documents shall be labeled Final Construction.

Construction Period Services (CPS)

Requests for Information (RFI)

3710 Southwest US Veterans Hospital Road 11/14/2023 Portland, OR 97239‐2964

Requests for Information shall be submitted within three calendar days of submittal to the A‐E.

Submittal Reviews

Submittal reviews shall be submitted within seven calendar days of submittal to the A‐E.

Site Visit Reports

Site visit reports shall be submitted within seven calendar days of the visit. All documents in any of the electronic formats listed above.

Modification/Change Order Requests

Modification requests shall be submitted within seven calendar days (check all against Dan’s email) of submittal to the A‐E. This includes the review of the contractor’s change order/modification proposal for construction change orders, as well as the formulation of an IGCE for the modification, as requested. The

A‐E's reply regarding their review of cost proposals and their recommendations shall include an independent breakdown of costs in detail, quantities, and unit prices and shall cover both additions and deductions of labor, materials, and equipment. The A‐E shall also supply cost estimates as requested by the COR for Requests for Proposals for anticipated changes. All documents in any of the electronic formats listed above. Note: If major modification, VA will provide additional time and document format guidance.

Punch List

Punch list shall be submitted within seven calendar days of the final acceptance inspection. All documents in any of the electronic formats listed above.

Record Drawings

Record drawings shall be delivered to the VA within 30 calendar days after VA acceptance of the construction project. Autodesk Revit Project (.rvt) format and AutoCAD (.dwg) format.

Third‐Party Commissioning

The A‐E shall provide Commissioning and Commissioning Agent services and deliverables in accordance with the reference document, OCFM Whole Building Commissioning Process Manual located on the TIL (https://www.cfm.va.gov/til/Cx‐RCx/CxManual.PDF). See “Commissioning Agent Tasks” in each section of the reference document. The Commissioning Agent shall be involved in all phases of the project, including both design and construction. It is anticipated that the Commissioning Agent will participate in the following: design reviews, owner’s requirements updates, design phase commissioning planning

(facilitate), commissioning specification reviews (facilitate), construction project meetings, construction observation visits, equipment startup and testing, Testing Adjusting and Balancing (TAB) verification, and project commissioning (facilitate in coordination with General Contractor). The commissioning process shall be adapted to the size and complexity of the project. Deliverables shall be as described in the reference document. Additionally, the A‐E shall develop the commissioning plan, pre‐functional checklists, systems functional performance test checklists, integrated system test checklists, and edited master specification templates to serve as a starting point for the commissioning process on all EHRM projects based on the following Systems to be Commissioned.

3710 Southwest US Veterans Hospital Road 11/14/2023 Portland, OR 97239‐2964

HVAC (VA Master Specification Section 23 08 00): Direct Digital Control System, Chilled Water System, Condenser Water System, Steam/Heating Hot Water System, HVAC Air Handling System, HVAC

Ventilation/Exhaust Systems, HVAC Terminal Unit Systems, Decentralized Unitary HVAC Systems, Humidity Control Systems, Hydronic Distribution Systems

Electrical (VA Master Specification Section 26 08 00): Grounding and Bonding Systems, Electric Power

Monitoring Systems, Low‐Voltage Distribution System, Emergency Power Generation Systems

Communications (VA Master Specification Section 27 08 00): Grounding and Bonding Systems, Structured

Cabling System

Electronic Safety and Security (VA Master Specification Section 28 08 00): Grounding and Bonding, Physical Access Control Systems, Access Control Systems, Security Access Detection Systems, Video

Surveillance System

15. PROJECT SCHEDULE/PERIOD OF PERFORMANCE:

The A‐E shall perform Part One Services/Design Phase work according to the schedule shown below. The A‐E is also responsible for following Specification Section 01 32 16.01, Architectural and Engineering CPM Schedules, located in SOW Attachment 05. If a due date on the timeline below falls on a Holiday or Weekend, the submittal shall be due the following business day. The remaining timeline will not be shifted to accommodate Holidays or

Weekends.

QA/QC Submittal & 10% BD Submittal

60 calendar days after receipt of Notice of Award

QA/QC & 10% BD Review Meeting

20 calendar days after VA receipt of QA/QC & 10% BD

Submittals

35% SD Submittal 45 calendar days after VA acceptance of QA/QC & 10% BD

Submittals

35% SD Review Meeting 30 calendar days after VA receipt of 35% SD Submittal

65% DD Submittal 45 calendar days after VA acceptance of 35% SD Submittal

65% DD Review Meeting 30 calendar days after VA receipt of 65% DD Submittal

95% CD Submittal 45 calendar days after VA acceptance of 65% DD Submittal

95% CD Review Meeting 30 calendar days after VA receipt of 95% CD Submittal

Final Bid Documents Submittal 30 calendar days after VA acceptance of 95% CD Submittal

Final Bid Documents Acceptance Meeting

30 calendar days after VA receipt of Final Bid Documents

Submittal

3710 Southwest US Veterans Hospital Road 11/14/2023 Portland, OR 97239‐2964

Total Part One Services/Design Phase Schedule

365 calendar days

The (365) calendar days listed for Total Part One Services in the project schedule may fluctuate based on when

95% CD Submittal meets all VA guidelines and acceptance is issued. If 95% CD Submittal is not accepted due to insufficient design requirements throughout the design period and additional time is deemed necessary, it is the responsibility of the A‐E firm to cover all costs associated with such delays.

Solicitation Support Services (Option Line Item) shall be performed for the length of time between the time the option is exercised and award of the construction project. Construction Period Services (Option Line Items) and

Third‐Party Commissioning (Option Line Item) shall be performed for the length of time between the time the option(s) are exercised and acceptance of Construction Completion. The VA has 365 calendar days from final acceptance of the design to exercise the option(s) for Solicitation Support Services, Construction Period Services, and Third‐Party Commissioning.

16. CONTRACT OVERSIGHT:

All contracts for this project shall be awarded by the Program Contracting Activity Central (PCAC); only a warranted

VA Contracting Officer shall have authority to change the terms and conditions of a contract. These changes may involve the contract award amount, contract period of performance, issuance of stop work orders, and changes to the statement of work.

PCAC shall designate a Contracting Officer’s Representative (COR) to monitor and manage the A‐E’s performance under the design project contract. The COR shall be a representative of the VAMC Engineering team and have the technical knowledge required to monitor and oversee the project.

A COR from the VAMC Engineering team shall also be designated for the construction project contract to monitor and manage the construction contractor’s performance under the construction project contract. This designation under the construction contract shall be considered equivalent to the industry standard of “Owner’s

Representative” and does not supersede or eliminate the A‐E’s responsibility for Part Two Services/Construction

Period Services. The A‐E ultimately shall be responsible for any errors and omissions with the design discovered during and after the construction phase.

17. OI&T INFRASTRUCTURE STANDARD FOR TELECOMMUNICATIONS SPACES:

The current version for this standard is located on the TIL (https://www.cfm.va.gov/til/dguide/OIT‐

InfrastrucStdTelecomSpaces.pdf). The design for this project must meet the Campus Support Center (CSC) requirements of the Infrastructure Standard for Telecommunications Spaces (The Standard).

The Standard serves as the master reference document of criteria for Department of Veterans Affairs (VA) facility

Information Technology (IT) support infrastructure. It defines the technical requirements necessary to maintain optimum reliability and efficiency within VA facilities and computing centers. IT Support Infrastructure is defined as all passive telecommunications and information technology equipment and supporting physical space and equipment.

3710 Southwest US Veterans Hospital Road 11/14/2023 Portland, OR 97239‐2964

This Standard is maintained by the Enterprise Data Center Infrastructure Collaboration Team (EDICT). Questions or concerns should be directed to Enterprise Data Center and Infrastructure Engineering (DCIE) at

VAITESEDatacenterEngineering2@va.gov.

Users must ensure their use of this technology/standard is consistent with VA policies and standards, including, but not limited to, VA Handbooks 6102 and 6500; VA Directives 6004, 6513, and 6517; and National Institute of

Standards and Technology (NIST) standards, including Federal Information Processing Standards (FIPS). Users must ensure sensitive data is properly protected in compliance with all VA regulations. Prior to use of this technology, users should check with their supervisor, Information Security Officer (ISO), Facility Chief Information

Officer (CIO), or local Office of Information and Technology (OI&T) representative to ensure that all actions are consistent with current VA policies and procedures prior to implementation.

18. EXEMPTIONS TO VA OEHRM SITE INFRASTRUCTURE REQUIREMENTS:

Any variances or exemptions to SOW Attachment 02, most recent version, must be referenced, documented, and discussed with the CO, the COR, and HEFP SEP. Following approval of variance or exemption, the A‐E shall submit documentation describing variance or exemption, indicate reference in VA documentation, describe any mitigating measures, and include an attachment with documentation of discussion with the CO, the COR, and

HEFP SEP.

19. SOW ATTACHMENTS:

The following documents are attached to this SOW for A‐E use and incorporation into the project documents:

VHA Required Division 01 Specification Sections (SOW Attachment 01)

00 VA OEHRM Site Infrastructure Requirements v2.0 (SOW Attachment 02)

HEFP SEP Design Alerts (SOW Attachment 03)

Sensitive Infrastructure Data Classification Memo ‐ FOUO (SOW Attachment 04)

01 32 16.01 EHRM Architectural and Engineering CPM Schedules (SOW Attachment 05)

Program Guide, PG‐18‐15 Volume C ‐ A‐E Submission Instructions for Minor and NRM Construction Program dated November 2008 (SOW Attachment 06)

Seasonal Influenza with Vaccines (SOW Attachment 07)

VHA Directive 1061 Prevention of Healthcare Associated Legionella Disease (SOW Attachment 08)

Portland VA Healthcare system and Vancouver Campus Maps (SOW Attachment 09)

Site Self‐Assessment X‐Matrix (SOW Attachment 10)

Underground Utilities Drawing (SOW Attachment 11)

CONSTRUCTION CONTRACTOR RESTRICTIONS (SOW Attachment 12)

Post Award CD Review Checklist (SOW Attachment 13)

End of SOW